S02. Solicitation 36C25020B0060_1.pdf

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014) STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within ____________ calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES NO

a. Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________

(hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

1 71

36C25020B0060

X

08/02/2021

541-21-1-4002-0001

541-376

701 /AL

Department of Veterans Affairs

Network Contracting Office (NCO) 10

VA Healthcare System

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

Department of Veterans Affairs

ATTN: 36C25020B0060, Stanley R. Burdine

Network Contracting Office (NCO) 10

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

Stanley Burdine stanley.burdine@va.gov

Expand Primary Care for Patient Aligned Care Team (PACT) Realignment, Project No. 541-376

Project provides an additional 12,000 square feet on three floors by an expansion on VA-owned land on the east side of ambulatory care addition at the Louis Stokes Cleveland VA Medical Center, 10701 East Boulevard, Building 1

Cleveland, OH 44106.

Contractor shall provide all labor, equipment, supplies and supervision necessary to Expand Primary Care for PACT

Realignment at the Louis Stokes Cleveland VA Medical Center (VAMC), 10701 East Boulevard, Cleveland, OH 44106.

The project magnitude for the project is between $10,000,000 and $15,000,000.

The NAICS code for this project is 236220. The business size standard is $39.5 million.

All work shall be conducted in complete accordance with the specifications, drawings, and terms of the contract.

All work shall be coordinated with the Veteran Affairs (VA) Contracting Officer and the Contracting Officer's

Representative (COR).

All Bidder's/Offeror's shall insert bid(s) in the appropriate block(s) on the attached sheet titled "SF 1442

Block 17 Continuation on page 6." Bid(s) will be evaluated on price.

Site Visit and place of performance is at Louis Stokes Cleveland VA Medical Center (VAMC), 10701 East Boulevard, VA

Administration Building Lobby, Cleveland, OH 44106.

An organized site visit will be conducted in accordance with FAR 52.236-27 and Social distancing guidelines - see solicitation section titled "SITE VISIT INFORMATION" on page 42.

Cut-off date and time to submit Requests for Information (RFI) is 08-12-2021 at 3:30 PM EST. RFIs shall be emailed to

Stanley Burdine at stanley.burdine@va.gov.

This project is a 100% set-aside for a Service-Disabled Veteran Owned Small Business (SDVOSB). All bidders must be verified in VETBIZ and registered in SAM at the time of the offer due date and the time of award to be eligible for award. For eligibility under the NAICS, see VAAR 852.219.10 paragraph for performance requirements.

Public Law 105-339, Section 1534 provides "no agency may obligate or expend funds appropriated for the agency for a fiscal year to enter a contract described in Section 4212(a) of Title 38 with a contractor from which a report was required under Section 4212(d) of that title with respect to the preceding fiscal year, if such contractor did not submit such report."

10 885

X X FAR 52.211-10

X

2 12:00PM EDT

09-02-2021

X

14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

PHONE: FAX:

28. NEGOTIATED AGREEMENT 29. AWARD Your

Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code)

(Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

(Type or print)

(4 copies unless otherwise specified)

(Type or print) (Type or print)

(Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror)

(To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

See "SF 1442 Block 17 continuation" on page 6.

Department of Veterans Affairs

Network Contracting Office (NCO) 10

VA Healthcare System

2780 Airport Drive, Suite 340

Columbus OH 43219-2292

36C250 Department of Veterans Affairs

Financial Services Center

Invoices to be Submitted Electronically www.ob10.com/us/en/veterans-affairs// e-Invoice Setup Info Phone 877-489-6135

Ronald T. Heidemann

Contracting Officer

Table of Contents

PART I - THE SCHEDULE

SECTION A - SOLICITATION/CONTRACT FORM

A.1 SF 1442 SOLICITATION, OFFER, AND AWARD (Construction, Alteration, or

Repair)

A.2 SF 1442 SOLICITATION, OFFER, AND AWARD (CONSTRUCTION,

ALTERATION, OR REPAIR)– BACK

SF 1442 BLOCK 17 (CONTINUATION)

A.3 FAR 52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

A.4 FAR 52.203-14 DISPLAY OF HOTLINE POSTER(S) (JUN 2020)

A.5 FAR 52.204-1 APPROVAL OF CONTRACT (DEC 1989)

A.6 FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(JUL 2020) (DEVIATION)

A.7 FAR 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS

AND CERTIFICATIONS (DEC 2014)

A.8 FAR 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE,

SOFTWARE, AND SERVICES DEVELOPED OR PROVIDED BY KASPERSKY LAB

AND OTHER COVERED ENTITIES (JUL 2018)

A.9 FAR 52.204-24 REPRESENTATION REGARDING CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT

(OCT 2020)

A.10 FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT

2018)

A.11 FAR 52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION

REGARDING RESPONSIBILITY MATTERS (OCT 2018)

A.12 FAR 52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR

AGREEMENTS—CERTIFICATION (FEB 2021)

A.13 FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984) ALTERNATE I (APR 1984)

A.14 FAR 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

A.15 FAR 52.216-1 TYPE OF CONTRACT (APR 1984)

A.16 FAR 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM

REREPRESENTATION (NOV 2020)

A.17 FAR 52.222-26 EQUAL OPPORTUNITY (SEP 2016)

A.18 FAR 52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

A.19 FAR 52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES

(JUN 2020)

A.20 FAR 52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE

NATIONAL LABOR RELATIONS ACT (DEC 2010)

A.21 FAR 52.225-11 BUY AMERICAN—CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (JAN 2021)

A.22 FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT—

CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

A.23 FAR 52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC

2007) ALTERNATE I (DEC 2007)

A.24 FAR 52.228-1 BID GUARANTEE (SEP 1996)

A.25 FAR 52.228-17 INDIVIDUAL SURETY—PLEDGE OF ASSETS (BID

GUARANTEE) (FEB 2021)

A.26 FAR 52.233-2 SERVICE OF PROTEST (SEP 2006)

A.27 FAR 52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB

1997) ALTERNATE II (APR 1984)

A.28 FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB

1995)

A.29 FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE

(FEB 1998)

A.30 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

A.31 VAAR 852.203-70 COMMERCIAL ADVERTISING (MAY 2018)

A.32 VAAR 852.204-70 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR

PERSONNEL (MAY 2020)

A.33 VAAR 852.211-72 TECHNICAL INDUSTRY STANDARDS (NOV 2018)

A.34 VAAR 852.219-10 VA NOTICE OF TOTAL SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS SET-ASIDE (NOV 2020) (DEVIATION)

A.35 VAAR 852.219-74 LIMITATIONS ON SUBCONTRACTING—MONITORING AND

COMPLIANCE (JUL 2018)

A.36 VAAR 852.228-70 BOND PREMIUM ADJUSTMENT (JAN 2008)

A.37 VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND

VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009)

A.38 VAAR 852.232-70 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION

CONTRACTS (WITHOUT NAS– CPM) (NOV 2018)

A.39 VAAR 852.232-72 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (NOV

2018)

A.40 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION

(OCT 2018)

A.41 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (OCT 2018)

A.42 VAAR 852.236-71 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION

(APR 2019)

A.43 VAAR 852.236-79 CONTRACTOR PRODUCTION REPORT (APR 2019)

A.44 VAAR 852.236-80 SUBCONTRACTS AND WORK COORDINATION (APR 2019)

ALTERNATE I (APR 2019)

A.45 VAAR 852.236-90 RESTRICTION ON SUBMISSION AND USE OF EQUAL

PRODUCTS (APR 2019)

A.46 VAAR 852.236-92 NOTICE TO BIDDERS—ADDITIVE OR DEDUCTIVE BID LINE

ITEMS (APR 2019)

A.47 VAAR 852.242-70 GOVERNMENT CONSTRUCTION CONTRACT

ADMINISTRATION (APR 2019)

A.48 VAAR 852.242-71 ADMINISTRATIVE CONTRACTING OFFICER (OCT 2020)

A.49 VAAR 852.243-70 CONSTRUCTION CONTRACT CHANGES—SUPPLEMENT

(SEP 2019)

A.50 VAAR 852.246-71 REJECTED GOODS (OCT 2018)

A.51 VAAR 852.252-70 SOLICITATION PROVISIONS OR CLAUSES INCORPORATED

BY REFERENCE (JAN 2008)

A.52 VAAR 852.270-1 REPRESENTATIVES OF CONTRACTING OFFICERS (JAN

2008)

A.53 SUPPLEMENTAL INSURANCE REQUIREMENTS

A.54 MANDATORY WRITTEN DISCLOSURES

A.55 IT CONTRACT SECURITY

A.56 LIST OF ATTACHMENTS……………………………………………………………….70

SF 1442 BLOCK 17 (CONTINUATION)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within 120 calendar days after the date offers are due (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.).

Contractor’s Name: _______________________________

CAGE Code: _______________________________

DUNS: _______________________________

The following bids are submitted in lieu of completing block 17 on the attached SF 1442:

Bid Item 1 (Base Bid): ___________________________________________

Bid Item 2 (Alternate NO. 1): ___________________________________________

Bid Item 3 (Alternate NO. 2): ___________________________________________

Bid Item 4 (Alternate NO. 3): ___________________________________________

**NOTE: A SINGLE AWARD MAY BE MADE ON BID ITEM 1 (BASE BID), BUT IN THE EVENT THE OFFER EXCEEDS THE FUNDS AVAILABLE, A SINGLE AWARD MAY BE MADE ON BID ITEM 2, BID ITEM 3, OR BID ITEM 4, IN THAT ORDER, BASED ON AVAILABLE FUNDING. OFFERORS SHOULD QUOTE A PRICE ON EACH ITEM LISTED AND WILL NEED TO SUBMIT A TOTAL COST FOR EACH BID ITEM. “FOR ALTERNATE BID ITEMS, BIDDERS SHOULD ENSURE THAT THE ALL-INCLUSIVE PRICE AFTER THE DEDUCTIONS ARE

SUBTRACTED HAS BEEN ENTERD.”

BID ITEM 1 (BASE BID): Work includes all labor, material, equipment and supervision to perform the required General

Trades, Sitework/Civil, Landscaping, Structural, Mechanical, Plumbing, Electrical, and Fire Protection work on this Project as described/depicted in the Construction Documents, and all related General Conditions required for the Work. All phases of work shall be complete within 885 calendar days after the receipt of Notice to Proceed.

BID ITEM 2 (Alternate 1): All Work identified in Bid Item 1 above, except 2nd Floor Improvements extending approximately from column line L to the south wall of the Addition shall not be constructed and shall instead be left as a Shell Space. Refer to

Sheets AS-2.1B and ASC-2.1B and MEP drawings. All phases of work shall be complete within 885 calendar days after the receipt of Notice to Proceed.

BID ITEM 3, (Alternate 2): All Work identified in Bid Item 1 above, except 2nd Floor Improvements extending approximately from column line M to the south wall of the Addition shall not be constructed and shall instead be left as a Shell Space. Refer to

Sheets AS-2.1B and ASC-2.1B and MEP drawings. All phases of work shall be complete within 885 calendar days after the

BID ITEM 4, (Alternate 3): All Work identified in Bid Item 1 above, except the entire 2nd Floor Addition footprint shall be left as a Shell space. Additionally, all improvements identified within the interior of the 2nd Floor shall not be constructed. Refer to Sheets AS-2.1B and AS-C-2.1B and MEP drawings. All phases of work shall be complete within 885 calendar days after the

**The first 45 calendar days after contractor receipt of the Notice to Proceed are designated for the contractor to get employees badged, get VA schedule approval, submittal of the schedule of values, project drawings, safety plan, mobilization plan, Waste

Disposal plan, Storm Water Pollution Prevention (SWPP) plan and all other submittals. The contractor will not be permitted to mobilize before 45 calendar days, without the Contracting Officer's approval.

A.3 52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the

Contractor may request, in writing, an extension of time, to be received by the Contracting

Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting

Officer, is justified.

(End of Clause)

A.4 52.203-14 DISPLAY OF HOTLINE POSTER(S) (JUN 2020)

(a) Definition.

"United States," as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)—

(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites—

(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

(3) Any required posters may be obtained as follows:

Poster(s) Obtain From

Department of Veterans Affairs Hotline VA Office of Inspector General (53E), P.O. Box

34647, Washington, DC 20043-4647

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the threshold specified in Federal Acquisition

Regulation 3.1004(b)(1) on the date of subcontract award, except when the subcontract—

(1) Is for the acquisition of a commercial item; or

(2) Is performed entirely outside the United States.

(End of Clause)

A.5 52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of Contracting Officer and shall not be binding until so approved.

(End of Clause)

A.6 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR

2020) (JUL 2020) (DEVIATION)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is

236220.

(2) The small business size standard is $39.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management

(SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal

Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services—Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—

Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a

Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the

Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal

Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at

52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction

Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--

Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate.

(Basic, Alternates II and III.) This provision applies to solicitations containing the clause at

52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(C) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—

Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or

Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution

Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at

52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the

Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to

Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to

Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for

EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in

SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

A.7 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS

AND CERTIFICATIONS (DEC 2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

A.8 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE,

SOFTWARE, AND SERVICES DEVELOPED OR PROVIDED BY KASPERSKY

LAB AND OTHER COVERED ENTITIES (JUL 2018)

(a) Definitions. As used in this clause—Covered article means any hardware, software, or service that—

(1) Is developed or provided by a covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a covered entity.

Covered entity means—

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab;

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky

Lab; or https://www.sam.gov/

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal

Year 2018 (Pub. L. 115–91) prohibits Government use of any covered article. The Contractor is prohibited from—

(1) Providing any covered article that the Government will use on or after October 1, 2018;

and

(2) Using any covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement. (1) In the event the Contractor identifies a covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the

Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the

Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 1 business day from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; brand; model number (Original

Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number);

item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: Any further available information about mitigation actions undertaken or recommended.

In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a covered article, any reasons that led to the use or submission of the covered article, and any additional efforts that will be incorporated to prevent future use or submission of covered articles.

(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts, including subcontracts for the acquisition of commercial items.

(End of Clause)

A.9 52.204-24 REPRESENTATION REGARDING CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR

EQUIPMENT (OCT 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the

Offeror has represented that it ‘‘does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of https://dibnet.dod.mil/ https://dibnet.dod.mil/ any contract, subcontract, or other contractual instrument’’ in paragraph (c)(1) in the provision at

52.204–26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212–3, Offeror Representations and Certifications–

Commercial Items. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it ‘‘does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services’’ in paragraph (c)(2) of the provision at 52.204–26, or in paragraph (v)(2)(ii) of the provision at 52.212–3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204–25, Prohibition on Contracting for

Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization

Act for Fiscal Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after

August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal

Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award

Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services.”

(d) Representations. The Offeror represents that—

(1) It [ ] will, [ ] will not provide covered telecommunications equipment or services to the

Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds “will’’ in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It [ ] does, [ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services.

The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds “does’’ in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the

Offeror has responded “will’’ in the representation in paragraph (d)(1) of this provision, the

Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded “does’’ in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph

(b)(2) of this provision.

(End of Provision)

A.10 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS

(OCT 2018)

(a) Definitions. As used in this provision—

"Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission

Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed

Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in

(c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for

Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of Provision)

A.11 52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION

REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) The Contractor shall update the information in the Federal Awardee Performance and

Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management via https://www.sam.gov.

(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-

212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consists of two segments—

(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by—

(i) Government personnel and authorized users performing business on behalf of the

Government; or

(ii) The Contractor, when viewing data on itself; and

(2) The publicly-available segment, to which all data in the non-public segment of FAPIS is automatically transferred after a waiting period of 14 calendar days, except for—

(i) Past performance reviews required by subpart 42.15;

(ii) Information that was entered prior to April 15, 2011; or

(iii) Information that is withdrawn during the 14-calendar-day waiting period by the

Government official who posted it in accordance with paragraph (c)(1) of this clause.

(c) The Contractor will receive notification when the Government posts new information to the

Contractor's record.

(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the nonpublic segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information. The contractor must cite 52.209-9 and request removal within 7 calendar days of the posting to FAPIIS.

(2) The Contractor will also have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.

(3) As required by section 3010 of Pub. L. 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.

(d) Public requests for system information posted prior to April 15, 2011, will be handled under

Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

(End of Clause)

A.12 52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR

AGREEMENTS—CERTIFICATION (FEB 2021)

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial items as defined at FAR 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

_____ (1) The Offeror certifies that—

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C.

2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act

(22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

(2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there.

Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/ nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of noncompliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that…