AMND 02.pdf

AMENDMENT OF SOLICITATION/ MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

AMD 02 08/19/2025

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

FEDERAL PRISON INDUSTRIES, UNICOR

400 FIRST STREET, N.W.

WASHINGTON, DC 20534

ATTN: Deatrice Luck, Contract Specialist

SEE BLOCK 6.

8. NAME AND ADDRESS OF CONTRACTOR (No., street, country, State and Zip Code) (x) 9A. AMENDMENT OF SOLICITATION NO.

PRC0002-25 ⊠

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENT OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and the date specified for receipt of Offers _ is XX, __ is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate Letter or telegram which includes a reference to the solicitation and amendment number. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the Solicitation and this amendment and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(X) A. THIS CHANGE ORDER ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, Appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103 (b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF :

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor __ is not, ⊠ is required to sign this document and return 1 copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The solicitation identified in block 10 A is as followed:

Solicitation PRC0002-25 amends:

REMOVE: SUBMISSIONS:

1.) Information Gathering and Reporting Phase and Evaluation and Recommendations Report - 30 Calendar days after Purchase Order Execution.

2.) Submission of 100% Complete Scope of Work - 30 Calendar days after Purchase Order Execution.

3.) Final Corrected Bid Set of SOW - 20 Calendar days after Receipt of Government Comments ***The Government will review and provide comments back on submissions within 20 calendar days. ***

ADD: SUBMISSIONS:

1.) Information Gathering and Reporting Phase and Evaluation and Recommendations Report - 30 Calendar days after Purchase Order Execution.

2.) Government Review and Comments - 15 Calendar days after receipt of Evaluation and Recommendations Report.

3.) Submission of 100% Complete Scope of Work - 20 Calendar days after receipt of government's comments of Evaluation and Recommendations Report.

4.) Government Review and Comments - 15 Calendar days after receipt of 100% Complete Scope of Work.

5.) Final Corrected Bid Set of SOW - 20 Calendar days after Receipt of Government Comments ***The Government will review and provide comments back on submissions within 20 calendar days. ***

REMOVE: ELEVATOR DESIGN MUST BE COMPLETED SEVENTY (70) DAYS AFTER AWARD.

REPLACE: ELEVATOR DESIGN MUST BE COMPLETED NINETY (90) DAYS AFTER AWARD.

REMOVE: The total performance period, including Government review times and corrections by the Architect, will not exceed 70 calendar days for elevator design work unless time is extended by the Contracting Office in writing for justifiable delays.

REPLACE: The total performance period, including Government review times and corrections by the Architect, will not exceed 90 calendar days for elevator design work unless time is extended by the Contracting Office in writing for justifiable delays.

As provided, all other terms and conditions remain unchanged.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Deatrice Luck, Contract Specialist

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

___________________________________________ BY _________________________________________ 08/19/2025 (Signature of the person authorized to sign) (Signature of contracting officer)

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR(48 CFR) 53.243

AMENDMENT OF SOLICITATION/ MODIFICATION OF CONTRACT