2_ATT_1_VAMA_161264_FINAL_CD_Specifications.pdf

VANDERBILT MANSION

NATIONAL HISTORIC SITE

HYDE PARK, NEW YORK

REHAB VANDERBILT MANSION FOUNDATION AND

SUPPORT WALLS

VAMA

PMIS NO. 161264

PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

DENVER SERVICE CENTER

August 1, 2016

FINAL CONSTRUCTION DOCUMENT SUBMISSION

VAMA - 161264 1

080116 TABLE OF CONTENTS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

011100 Summary of Work 012601 Contract Modification Procedures 012700 Definition of Contract Line Items 013100 Project Management and Coordination 013216 Construction Schedule 013233 Photographic Documentation for Historic Preservation Projects 013323 Submittal Procedures Material Submittal List

013513.22 Archeological Protection

013523 Safety Requirements 013591 Historic Preservation Treatment Procedures 014000 Quality Requirements 014200 References 015000 Temporary Facilities and Controls

015719.11 Indoor Air Quality Management

015719.12 Noise & Acoustics Management

015723 Under an Acre Pollution Prevention 016700 Product Requirements 017329 Cutting and Patching 017340 Execution 017419 Construction Waste Management and Disposal 017419A Appendix A: Project Waste Management Plan Worksheet 017419B Appendix B: Standard Solid Waste Conversions 017700 Closeout Procedures 017823 Operation and Maintenance Data 017900 Demonstration and Training 018113 Sustainable Design Requirements for Non-LEED™ Projects Closeout and Operation & Maintenance Requirements Form

DIVISION 02 – EXISTING CONDITIONS

020550 Temporary Protection 024119 Selective Removals

DIVISION 03 – CONCRETE

Not Used

DIVISION 04 – MASONRY

040120 Brick Masonry Restoration 040140 Stone Masonry Restoration

VAMA - 161264 2

DIVISION 05 – METALS

050175 Historic Treatment of Cast and Wrought Iron 051200 Structural Steel Framing 057300 Decorative Metal Railings

DIVISION 06 – WOODS, PLASTICS, AND COMPOSITES

061053 Miscellaneous Rough Carpentry 062013 Exterior Finish Carpentry 062023 Interior Finish Carpentry

DIVISION 07 – THERMAL AND MOISTURE PROTECTION

071326 Foundation Waterproofing 079200 Joint Sealants

DIVISION 08 – OPENINGS

080150 Wood Window and Door Restoration 085169 Metal Storm Windows 087000 Hardware

DIVISION 09 – FINISHES

090320 Historic Treatment of Plaster 092100 Exterior Stucco 096400 Wood Flooring Restoration 099113 Painting 099300 Staining and Transparent Finishing

DIVISION 10 – SPECIALTIES

108113 Bird Netting

DIVISION 11 – EQUIPMENT

Not Used

DIVISION 12 – FURNISHINGS

Not Used

DIVISION 13 – SPECIAL CONSTRUCTION

Not Used

DIVISION 14 – CONVEYING EQUIPMENT

144216 Vertical Wheelchair Lift

DIVISION 21 – FIRE SUPPRESSION

VAMA - 161264 3

Not Used

DIVISION 22 – PLUMBING

Not Used

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING

Not Used

DIVISION 25 – INTEGRATED AUTOMATION

Not Used

DIVISION 26 – ELECTRICAL

260519 Low-Voltage Electrical Power Conductors, Cables and Conduits 262726 Wiring Devices 265000 Custom Fabricated Light Fixtures

DIVISION 27 – COMMUNICATIONS

Not Used

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

Not Used

DIVISION 31 – EARTHWORK

310000 Earthwork 311100 Clearing and Grubbing 311319 Temporary Tree and Plant Protection 312513 Erosion and Sedimentation Controls

DIVISION 32 – EXTERIOR IMPROVEMENTS

321214 Asphalt Paving 329200 Turf and Grasses

DIVISION 33 – UTILITIES

334100 Storm Drainage Piping 334600 Foundation Drainage System 334900 Storm Drainage Structures

END OF TABLE OF CONTENTS

VAMA - 161264 01 11 00- 1

080116 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Work phases.

3. Work under other contracts.

4. Government Furnished Materials.

5. Contractor use of premises.

6. Public use of site.

7. Occupancy requirements for buildings.

8. Work Restrictions.

9. Special Construction Requirements.

10. Additional Reports.

11. Conflicting Documents.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Vanderbilt Mansion National Historic Site; 119 Vanderbilt Park Road, Hyde Park, New York 12538.

B. The Work consists of the following:

1. The Work includes the exterior rehabilitation of Vanderbilt Mansion, including stone repair and rehabilitation, brick masonry rehabilitation, stone paving, ornamental metal work rehabilitation, window and door restoration, and replacement of wheelchair lift.

C. Project will be constructed under a single prime contract.

1.3 WORK UNDER OTHER CONTRACTS

A. General: Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the Work of this Contract with work performed under separate contracts.

1.4 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine construction operations to areas indicated.

VAMA - 161264 01 11 00- 2

2. Limit site disturbance, including earthwork and clearing of vegetation, to 40 feet beyond building perimeter; 10 feet beyond surface walkways, patios, surface parking, and utilities less than 12 inches in diameter; 15 feet beyond primary roadway curbs and main utility branch trenches; and 25 feet beyond constructed areas with permeable surfaces (such as pervious paving areas, storm water detention facilities, and fields) that require additional staging areas in order to limit compaction in the constructed area.

B. Storage of Materials: Confine storage of materials to the Project Site.

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Preservation of Historic Features:

1. Prevent damage to building components and historic contents. Inform Contracting Officer immediately of any inadvertent damage that occurs to the interior contents or exterior of the structure.

2. Due to the fragility of the building interior contents, all contractor and sub-contractor access to the building interior will be coordinated with the Contracting Officer and monitored by an NPS Museum Monitor.

3. All work on window sash and doors removed for restoration will take place outside the building; only removal and reinstallation will be performed inside.

E. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

F. Construction Camp: Establishment of a camp within the park will not be permitted.

G. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

VAMA - 161264 01 11 00- 3

1.5 PUBLIC USE OF SITE

A. The public will be allowed access to surrounding grounds excluding the designated construction area. Public tours will take place under NPS oversight during selected periods in which delays to the project will not occur.

B. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public.

Road closures will be permitted, when required, upon specific approval of Contracting Officer but must maintain public and emergency access at all times.

1.6 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings that will be under construction during the entire contract period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government's day-to-day operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from the CO.

b. Maintain existing building in a weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building and its occupants during construction period.

c. Maintain a minimum of two exits at all times. The main door or the basement door must always be accessible. Handicap access is not needed during construction.

1.7 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 48 hours in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.8 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: By written permission from the Contracting Officer.

2. Early Morning Hours: By written permission from the Contracting Officer.

VAMA - 161264 01 11 00- 4

3. Hours for Core Drilling: By written permission.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.9 SPECIAL CONSTRUCTION REQUIREMENTS

A. Project Website: A project website administered by the NPS will be used for purposes of managing communication and documents during the construction stage.

1. See Division 01 Section “Project Management and Coordination” for requirements on using the Project Website.

B. Park will be closed on Thanksgiving, Christmas Day and New Year’s Day. No work shall be performed.

1.10 ADDITIONAL REPORTS

A. A Hazardous Materials Assessment report has been prepared by Western Analytical Laboratory, Inc. on January 9, 2014. A copy of this report is available to all plan holders with this package.

B. A Cleaning Test report has been prepared. A copy of this report is available to all plan holders with this package.

C. If conflicts occur between the report and drawings or specifications, the drawings and specifications govern.

1.11 CONFLICTING DOCUMENTS

A. If a conflict, discrepancy, contradiction, or inconsistency occurs within or between the Specifications and the Drawings, resolution shall be controlled by the following:

VAMA - 161264 01 11 00- 5

1. Figures, dimensions, or numbers given on drawings and any scaled measurements:

Figures, dimensions, or numbers shall govern.

2. Large scale drawings and small scale drawings: Larger scale drawings shall govern.

3. Technical Specifications and Drawings: Technical Specifications shall govern.

4. Shop Drawings and Submittals: Shop Drawings and other submittals from the Contractor, subcontractor, or supplies do not constitute a part of the Contract Documents.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

VAMA - 161264 01 26 01 - 1

080116 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

VAMA - 161264 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

VAMA - 161264 01 26 01 - 3

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm#ct

VAMA - 161264 01 26 01 - 4

Form, or their own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS.

All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region) http://www.nps.gov/dscw/publicforms.htm#ct

VAMA - 161264 01 26 01 - 5

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………Up to 10% Profit………………………..…8%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

VAMA - 161264 01 26 01 - 6

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 01 26 01

VAMA - 161264 01 27 00 - 1

080116 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 1: PMIS 161264: Complete the Exterior Rehabilitation of the Vanderbilt Mansion.

1. This item consists of the work to the exterior of Vanderbilt Mansion. Exterior work includes foundation waterproofing, stone repair and restoration, replacement of handicapped lift, brick masonry restoration, stone paving, ornamental metal work restoration, t-cap replacement and window restoration.

2. Payment will be made at the contract lump sum price.

3.2 SCHEDULE OF OPTIONS

A. Contract Line Item No. 2, Option A: Provide complete existing wood window sash and door restoration. Restore and refinish all existing wood window and door sash, panels, frames and hardware at first, second, and third floors.

1. The price shall incorporate removing and restoring existing wood storm windows and doors. Seal all openings to ensure protection from insect infiltration.

2. Payment will be made at the contract lump sum price.

B. Contract Line Item No. 3, Option B: Provide new storm windows – all openings. In addition to Option A Work, provide aluminum storms and operable screens at first and second floor openings as indicated.

C. Contract Line Item No. 4, Option C: Restore and reinstall existing wood shutters. Shutters to be fixed open, inoperable.

VAMA - 161264 01 27 00 - 2

080116 DEFINITION OF CONTRACT LINE ITEMS

D. Contract Line Item No. 5, Option D: Restoration of Wine Cellar. Interior work includes wood flooring restoration, interior finish carpentry, lighting, painting and interior plaster repair.

3.3 SCHEDULE OF UNIT PRICES

A. Contract Line Item No. 6: Additional Stone Repointing.

1. Unit of Measurement: Per Linear Foot.

B. Contract Line Item No. 7: Additional Stone Dutchman Repair.

1. Unit of Measurement: Per Cubic Foot, ½ Cubic Foot, minimum.

END OF SECTION 01 27 00

VAMA - 161264 01 31 00 - 1

080116 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Coordination Drawings.

5. Requests for Information (RFIs).

6. NPS/DSC SharePoint Project Website.

7. Project meetings.

8. Environmental Coordination.

9. Permits

B. Related Requirements:

1. Division 01 Section “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Division 01 Section “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Division 01 Section “Closeout Procedures” for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Authority Having Jurisdiction (AHJ): An AHJ is an agency that has been granted legal authority over a location, action or resource. This authority includes the ability to issue a permit or other legal permission document.

B. Construction Permits: Are those permits obtained by the contractor based on means and methods used to execute the work. Construction Permits are issued to the Contractor and not to the National Park Service (NPS).

C. Government Furnished Permits: Are those permits that are obtained by NPS during the design process and provided to the Contractor for compliance with the provisions through construction.

These permits may address impacts to natural resources, construction stormwater, etc.

VAMA - 161264 01 31 00 - 2

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Project closeout activities.

9. Commissioning activities.

1.4 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

VAMA - 161264 01 31 00 - 3

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Temporary Storm Water Pollution Prevention Plan (SWPP or UPPP).

11. Indoor Air Quality (IAQ) Management Plan.

12. Contractors Commissioning Plan.

13. Historic Preservation Treatment Plan.

14. Anticipated organization and pace for window removal and reinstallation.

15. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The AHJ issuing the permit.

c. Information required from the Government to complete the permit application.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to Proceed will not be issued, and the Contracting Officer will consider other contractual remedies.

Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the form created on the NPS/DSC SharePoint Project website.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

VAMA - 161264 01 31 00 - 4

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete the RFI Form on the NPS/DSC SharePoint website as follows:

1. Enter the general information at the top of the form.

2. Under the “Action” section at the bottom of the form, select “Question” then select

“CMR” in the drop-down of the “Send to” box.

3. Enter the details of the question and attach related documents.

4. Select “Submit Form” at the bottom of the page.

D. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT WEB SITE

A. Use the NPS/DSC SharePoint Project website for communication throughout the contract period. The NPS/DSC SharePoint Project website will be used for the following functions:

1. Project directory.

2. Project correspondence.

3. Meeting agendas and minutes.

4. Contract modifications forms and logs.

5. RFI form and processing.

6. Task and issue management.

7. Photo documentation.

8. Baseline schedule, schedule updates and calendar management.

9. Submittal form and processing.

10. Payment coordination documentation.

VAMA - 161264 01 31 00 - 5

11. Drawing and specification document hosting, viewing, and updating.

12. Online document collaboration.

13. Reminder and tracking functions.

14. Archiving functions.

15. Notification of submittal and RFI statuses and current responsible party.

16. Permits and addendums

B. Some documents however are not suitable to be shared using the NPS/DSC SharePoint Project website. Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared using the NPS/DSC SharePoint Project website and shall be coordinated with the SharePoint Project team as appropriate.

C. Submit to the CO a list of all employees who will need access to the website. The users will receive an invitation to register from the Department of Interior (DOI). Once the user is registered on the DOI website, they will be given access to the NPS/DSC SharePoint Project website. For login procedures and other SharePoint information, refer to the Workflows website at http://www.nps.gov/dscw/precon_spproj.htm.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later

1.7 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. NPS/DSC SharePoint Project website.

17. Acceptance/rejection of work.

18. Progress meetings.

19. Submittal procedures.

20. NPS Final Accessibility Inspection.

21. Environmental requirements.

22. Permit requirements.

http://www.nps.gov/dscw/precon_spproj.htm

VAMA - 161264 01 31 00 - 6

23. As-constructed drawings/operation and maintenance (O&M) manuals.

24. Saturday, Sunday, holiday and night work.

25. Reference materials.

26. Value engineering.

27. Schedule of values.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

VAMA - 161264 01 31 00 - 7

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of authorities having jurisdiction.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

z. Interim Accessibility Inspections; DSC-CQC Accessibility Inspection Report

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

1.8 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan(WMP).

c. Implementation of the Indoor Air Quality (IAQ) Management Plan.

d. Implementation of the Storm Water Pollution Prevention Plan(SWPPP).

e. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

f. Training for Contractor personnel in accordance with their position requirements.

g. Monitoring and documentation of environmental procedures.

VAMA - 161264 01 31 00 - 8

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements.

2. Regulatory Requirements.

3. Indoor Air Quality (IAQ) Management.

4. Noise & Acoustics Management.

5. Temporary Storm Water Pollution Prevention Environmental Management.

6. Construction Waste Management.

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the building industry.

2. Overview of environmental issues related to the Project.

3. Review of site specific procedures and management plans:

a. Construction Waste Management.

b. Indoor Air Quality (IAQ) Management.

c. Noise & Acoustics Management.

d. Temporary Storm Water Pollution Prevention.

4. Pollution Prevention (P2) practices: Submit evidence of P2 training.

5. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution Prevention Plan.

1.9 PERMITS

A. General:

1. Permits and Responsibilities: The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor’s fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the work.

2. For the purpose of this contract the Contractor will not be considered an agent of the Government. Therefore the Contractor will comply with the appropriate federal, state and local laws.

VAMA - 161264 01 31 00 - 9

B. Potential Permits: The permits listed below were identified during the design process as likely to be required based on typical means and methods of construction. The list is provided to assist the contractor in determining which permits will be required for the contract’s chosen means and methods. The list shall not be considered complete, as it is the responsibility of the contractor to determine means and methods, and obtain the required permits. It is the responsibility of the Contractor to obtain all permits required to legally conduct the work.

1. Stormwater Pollution Prevention Permit – NPS/NYS Department of Environmental

Conservation

2. Dewatering Permit – NPS/NYS Department of Environmental Conservation

C. Coordination with AHJ Issuing Permits

1. Coordination: Contact the AHJs as needed and sufficiently in advance to avoid delaying the work: Coordinate meetings, reporting requirements, inspections, or any other requirements.

D. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with AHJs, Construction Manager, and Park to avoid conflicts and to ensure orderly execution of the Work.

2. Supply all needed information to AHJs issuing permits, pay any fees required and provide all material needed to comply with the permit’s conditions and provisions.

3. Upload permits to the NPS/DSC SharePoint project website when the permits are obtained.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

VAMA - 161264 01 32 16 - 1

080116 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

VAMA - 161264 01 32 16 - 2

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be posted on the NPS DSC SharePoint project website, provided in the native electronic file…