Old_Courthouse_Renovation_2nd_Phase.pdf

Gadsden County

Board of County Commissioners

Invitation to Bid (Construction) OLD COURTHOUSE

RENOVATION 2ND PHASE

ITB: ITB: 26-16

RELEASE DATE: July 16, 2026

DEADLINE FOR QUESTIONS: August 6, 2026

RESPONSE DEADLINE: August 20, 2026, 10:00 am

RESPONSES MUST BE SUBMITTED ELECTRONICALLY TO:

https://procurement.opengov.com/porta!/gadsdencountyfl https://www.gadsdencountyfl.gov/home

• Gadsden County does not discriminate on the basis of race, color, national origin, sex, religion, age, marital status and disability/handicapped status in employment or provision of service.

• Gadsden County is an Equal Opportunity Employer

• MBE/WBE businesses are encouraged to participate

• Gadsden County strictly enforces open and fair competition

ADA - Special Accommodations: Any person requiring accommodation by the County due to a disability should call the Purchasing Office at 850-875-7243 or 850-627-4053 at least five (5) business days prior to any pre-response conference, response opening, or meeting. If you are hearing or speech impaired, please contact the County Purchasing Office by the Florida Relay Service, which can be reached at 1-800-955-8771 (TDD).

https://procurement.opengov.com/porta!/%7bproject.government.code%7d https://www.gadsdencountyfl.gov/home

TABLE OF CONTENTS

1. INTENT AND GENERAL INFORMATION

2. SCHEDULE OF EVENTS AND QUESTIONS

3. CONE OF SILENCE

4. SCOPE OF WORK

5. PROPOSAL RESPONSE REQUIREMENTS

6. PROPOSAL RECEIPT AND OPENING

7. EVALUATION OF PROPOSALS AND SELECTION PROCESS

8. EVALUATION CRITERIA

9. INTENT TO AWARD AND CONTRACT EXECUTION

10. STANDARD TERMS AND CONDITIONS

11. INSURANCE REQUIREMENTS

12. INSTRUCTIONS TO PROPOSERS

13. PRICE PROPOSAL

14. VENDOR QUESTIONNAIRE

Attachments:

A - ITB 25-16 Courthouse Renovations Draft Contract rev. 6.30.26

B - ITB 26-16 Courthouse Renovations - LEGAL ADVERTISEMENT

Invitation To Bid ITB: 26-16 Old Courthouse Renovation 2nd Phase

SECTION 1 INTENT AND GENERAL INFORMATION

Gadsden County Board of County Commissioners (i.e., “Board” or “County” or “BOCC”) is seeking Bids from General Contractors licensed in the State of Florida (i.e., “Bidder”

“Respondent”, or “Proposer”) for the renovation of the Gadsden County Courthouse in

Quincy, Fl, located at 10 E. Jefferson Street, Quincy, FL. The project will require renovations to be approved by the Historical Restoration Society.

The project is funded by a grant through the Department of State, Division of Historical

Resources, grant number 25. h.sc.100.009 pursuant to Line Item 3234, contained in the

2025 General Appropriations Act, HB 5001, Laws of Florida. The funder has authority to issue the grant in accordance with Section 267.0617, Florida Statutes.

Interested firms and individuals who are currently under contract with Gadsden County under previously issued solicitations, and who are interested in this Project, must submit a Bid at this time.

A Respondent interested in preparing a response for this Solicitation must complete the requirements set forth in this Solicitation, its attached documents and documents incorporated by reference, and any addendum issued by the County, (collectively referred to as the “Solicitation”). Under the Bid process of Gadsden County, the conditions set forth herein are binding on the Respondent as confirmed by the signature of a person with legal authority to bind the Bidder on the cover letter transmitting

(Proposal Transmittal Form located in the VENDOR QUESTIONNAIRE) to the County in response to this Solicitation.

While every effort is made to ensure the accuracy and completeness of information in this Solicitation, it is recognized that the information may not be complete in every detail and that all work may not be expressly mentioned in the Solicitation. It is the responsibility of the Respondent to include in their Proposal all pertinent information in accordance with this Solicitation.

The project is funded by a grant through the Department of State, Division of Historical

Resources, grant number 25. h.sc.100.009 pursuant to Line Item 3234, contained in the

2025 General Appropriations Act, HB 5001, Laws of Florida. The funder has authority to issue the grant in accordance with Section 267.0617, Florida Statutes.

Gadsden County BOCC reserves the right to reject any or all proposals, may waive informalities, and/or may make awards in the best interest of the BOCC.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=2522178

SECTION 2 SCHEDULE OF EVENTS AND QUESTIONS

Failure to comply with this or any other paragraph of this Solicitation shall be sufficient reason for rejection of the Proposal.

All times listed in the Schedule of Events for this Solicitation are Eastern

Standard Time (EST).

Dates are approximate and are subject to change.

Advertisement Date: July 16, 2026

Release Date: July 16, 2026

Mandatory Pre-Bid Conference

(Mandatory):

August 5, 2026, 10:00am

9-B East Jefferson Street - 2nd Floor

Admin Conference Room

Questions Due from Prospective

Bidders:

August 6, 2026, 10:00am

Responses to Questions Due: August 10, 2026, 3:00pm

BIDS DUE: August 20, 2026, 10:00am

BID OPENING: August 20, 2026, 10:15am

Board Approval of Intended Award: TBD

Posting of Intended Award: TBD

Board Approval of Award: TBD

Posting of Award: TBD

A. In accordance with the STANDARD TERMS AND CONDITIONS section of this

Solicitation, all inquiries concerning this Solicitation must be submitted in writing by 10:00 am on Thursday, August 6, 2026 through the County's OpenGov

Portal, located at https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754.

B. All answers to inquiries will be posted on the County's OpenGov Portal.

Proposers may also click “Follow” on this Solicitation to receive an email https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=undefined https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754 notification when answers are posted. It is the Respondent's responsibility to check the website for answers to inquiries. The failure of the Proposer to address the posting may be a basis to determine that the Proposer is non-responsive to this Solicitation.

C. If necessary, an Addendum or Addenda will be posted in accordance with the

STANDARD TERMS AND CONDITIONS section of this Solicitation.

D. Proposers will be notified of the County’s desire to enter additional discussions and/or schedule oral presentations. The Schedule of Events will be amended as appropriate to reflect such.

SECTION 3 CONE OF SILENCE

A. A Cone of Silence will be in effect for this Solicitation beginning with the advertisement date indicated in the SCHEDULE OF EVENTS AND QUESTIONS section, and will terminate upon issuance of a Notice of Award. A violation of the

“Cone of Silence” renders any award voidable at the sole discretion of the County

Administrator with approval from the Board of County Commissioners and may subject the potential Proposer/Contractor or representative to debarment.

B. The prospective Proposer shall not have any communication with any County

Commissioners, employees, or the Design Professional related to this

Solicitation.

C. No interpretation of the meaning of the plans, specifications or this Solicitation shall be made to a Proposer orally. Any such oral or other interpretations or clarifications shall be without legal effect. All requests for interpretations or clarifications shall be in writing and posted on the County’s OpenGov portal.

D. The Cone of Silence shall not apply to:

1. Communications at the pre-Proposal meeting, if applicable.

2. Communications during contract negotiations between designated County employees and the intended Proposer.

3. Communication with a Proposer by a Procurement Department employee following the Competitive Procurement opening to clarify the Proposer's

Response.

4. Communication following the filing of a challenge to a Competitive

Procurement between the protesting Proposer or the selected Proposer and the Procurement Department, County Administrator's Office, and County

Attorney's Office concerning the challenge.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=2522183

SECTION 4 SCOPE OF WORK

4.1 Old Courthouse Renovations Phase 2

The project is for the restoration and renovation of the historic Gadsden County

Courthouse in Quincy, Florida at 10 E. Jefferson St. Work items include paint exterior and repair wood rot; remove non-historic paint on exterior steps and landing using the gentlest means possible in accordance with SOI Standards, and seal exterior steps and landing; restore eight (8) cupola windows: clean and seal Terrazzo flooring;

repair/replace metal roof; and repair/replace eight (8) exterior doors.

All window and/or door replacements shall be submitted to the Bureau of Historic

Preservation for review and approval before any window and/or door replacement work commences.

Water repellant coating specifications will be submitted to the Division of Historical

Resources for review and approval prior to application on the building.

All tasks associated with the Project shall meet the requirements set forth in this agreement and the EOR’s submittals. All work must be documented photographically of the restoration activity.

4.2 Engineering Drawings and Specifications

The engineering drawings and specifications can be found online at https://app.box.com/s/kiiggxeaf8j9nfawl0seg0r1f9ec35cr/folder/391565547932 and may also be obtained by contacting:

Tom Riley, Architect, LEED AP, BD + C

Clemons, Rutherford & Associates

2027 Thomasville Rd.

Tallahassee, FL 32308

PHONE: 850.385.6153

E-mail triley@craarchitects.com

OR

Pheshe Bennett

Gadsden County Procurement Office

5-B East Jefferson Street – Room 204

Quincy, FL 32351

PHONE: 850.627.4053

pbennett@gadsdencountyfl.gov

With copy of any email to: Procurement@gadsdencountyfl.gov https://app.box.com/s/kiiggxeaf8j9nfawl0seg0r1f9ec35cr/folder/391565547932 mailto:triley@craarchitects.com mailto:pbennett@gadsdencountyfl.gov mailto:Procurement@gadsdencountyfl.gov

4.3 Project Funding and Budget

This project is funded through the Department of State, Division of Historical Resources pursuant to Line Item 3234, contained in the 2025 General Appropriations Act, HB

5001, Laws of Florida. The grant agreement is available under the Attachment Section of this Solicitation. The grant retrofit budget for the project is $460,000 from the grant and matching funds will be used to purchase the ATS Generator.

There may be times when the County must consult and seek approval of change orders from the funding agency.

Proposer must be registered in System of Award Management (SAM.gov) and be familiar with federal and state regulations as they pertain to construction projects, specifically local government.

The Successful Proposer must comply with all grant agreement requirements, hereby incorporated by reference and will be provided upon request per this Solicitation, and to assist the County with any needed amendments or clarifications to the agreements.

The Successful Proposer may be requested to present the concept and/or final plans at a public meeting (i.e., Board meeting, workshop, special meeting, etc.).

4.4 Project Team

A. Project Owner: The County is the project owner and the contracting agency. The

County team will include, but is not limited to, the County Administrator or their designee, Building Official, Facilities Manager, Construction Manager, Procurement Coordinator, and the Grant Manager.

B. Engineer of Record (EOR): The EOR is responsible for performing all engineering, design, drawings, specifications, civil permits, project management, and CEI services for the Project. The EOR is Clemons Rutherford

& Associates (CRA) selected through a previous solicitation, and the key contact for CRA on this project is Tom Riley, Project Manager/Professional Architect.

C. Construction Contractor (i.e., successful Respondent or Contractor): The

Construction Contractor will be a General Contractor (GC) licensed in the State of Florida with a minimum of five (5) continuous years as a GC. The main objective is to collaborate with the EOR during the delivery of the work for the successful and timely completion of the project and within budget. Provides input to the EOR and County regarding constructability, sequence of construction, and any other ideas that bring value to the project.

4.5 Project Milestones and Target Dates

Contract Execution TBD

Pre-Construction Meeting TBD

Issuance of Notice to Proceed TBD

Submit CPM construction schedule 30 calendar days from issuance of Notice to Proceed

(NTP)

Pre-construction Activities TBD

Substantial Completion 30 calendar days from deadline (current deadline

12.31.2026)

Final Completion/Acceptance of work 30 calendar days from Substantial Completion

The milestones and/or target dates are subject to change based on the actual date of the contract execution, the issuance of the Notice to Proceed (NTP), or other unknown factors.

4.6 Project Goals

The County will be addressing the following Project Goals:

A. Contractor Involvement: Harness construction knowledge to inform key decisions regarding construction approach, sequencing, early work packages, etc.

B. Operations & Maintenance (O & M) Coordination: Efficiently and safely renovate/restore the Courthouse

C. Collaboration: Establish and maintain a collaborative environment among the

County, the Courthouse staff, EOR, and the Contractor for a successful project completion.

D. Constructability/Value: Incorporate integrated constructability and value engineering into the Project.

E. Quality: Deliver the Project in a manner consistent with the Project design and specifications.

F. Cost: Minimize initial capital and life-cycle cost.

G. Schedule: Achieve completion of the project in accordance with the project milestones and target dates shown above.

H. Risk: Achieve an optimal balance of risk allocation between the County and the

Contractor.

I. Safety: Implement a comprehensive safety program that incorporates industry’s best practices.

4.7 Scope of Services

The selected Contractor shall provide all labor, materials, equipment, construction services, supervision, and incidentals necessary to complete the project including, but not limited to:

General Repair/Renovation

• Renovations/repairs as defined by the construction documents which include drawings and specifications.

• Permitting

• Structural upgrades and repairs

4.8 Phase I: Pre-Construction

A. The Selected Contractor will participate in a pre-construction meeting after the

Board approves the Contract and before the issuance of the Notice to Proceed, which is also contingent upon the Construction Contractor providing all required insurance certifications and bonds.

B. At the pre-construction meeting, the Selected Contractor will provide, at a minimum, for discussion and approval by the County and EOR:

1. Tentative work schedule.

2. Phasing and sequencing with any alternative methods and materials.

3. Identified risks and potential mitigation efforts if applicable.

4. Tentative Schedule of draws, aligned with the grant requirement schedule.

5. Proposed mobilization date, construction start date, substantial completion date, and completion date.

C. Grant and contract requirements will be addressed, i.e., weekly reports with pictures, change orders, budget overrun, etc.

D. Permits: The Construction Contractor will be responsible for all local permits. The

EOR will apply for any state (civil) permits needed.

4.9 Phase 2: Construction

A. General:

1. The construction phase will include, but is not limited to, mobilization, phasing, and scheduling of the work, obtaining bids and quotes for work, materials and/or supplies, and the execution of subcontracts or procurements beginning with mobilization through completion of the project.

2. During the construction, the Construction Contractor will interface and coordinate with the EOR as conditions and construction activities dictate, to discuss scheduling foreseeable problems, equipment and material delivery days, sub-contractor/vendor performance, safety, and any other issues pertinent to potential delays, budget overrun that could impact the successful and timely completion of the project.

3. The Construction Contractor shall review all invoices from subcontractors/vendors; ensure all work, materials and supplies were to specifications; and resolve any discrepancies before they are submitted to the

Cunty for review and approval.

B. All window and/or door replacements shall be submitted to the Bureau of Historic

Preservation for review and approval before any window and/or door replacement work commences.

C. Water repellant coating specifications will be submitted to the Division of

Historical Resources for review and approval prior to application to the building.

D. Change Orders: The County, without invalidating the Construction contract, may order or approve requested changes in the work within the general scope of the project, consisting of additions, deletions, or other revisions to the engineering drawings and specifications, project schedule, costs, etc. Such changes will be approved only through an executed change order with changes justified in writing and additional costs documented with quotes.

E. Quality Control: The Construction Contractor is responsible for the work, materials, equipment and supplies for this project, and shall review the work, materials, equipment and supplies of all subcontractors and/or vendors used on the project to ensure it meets all design specifications as it is being performed and/or delivered. The Construction Contractor will review any disputes that cannot be resolved or may result in a change order with the EOR for resolution, and to the satisfaction of the County, if applicable.

F. Inspections: Assist the EOR and the County in performing periodic and final inspections. All inspections preceding the final inspection, the Construction

Contractor shall furnish a detailed report of observed discrepancies and omissions in the work performed by subcontractors or vendors and/or materials and supplies provided by such.

G. Monitoring the Schedule and Weekly Reports:

H. The Construction Contractor shall monitor the construction schedule and budget and shall provide the Engineer of Record (EOR) and the County with any concerns or problems within a specified amount of time that will be determined at the pre- construction meeting and incorporated into the Notice to Proceed.

I. The Construction Contractor shall provide the EOR and County with written weekly summary reports and pictures documenting before, during, and after work progress. All rain days, challenges or concerns, completed work, pending or approved change orders, total billed to date with balance forward, etc. shall be documented in the weekly report.

J. Safety: The Construction Contractor shall monitor that safety and accident prevention measures are established and maintained at the project site. Any observed hazardous conditions, violations, or potentially hazardous conditions shall be reported immediately to subcontractors/vendors supervisory personnel onsite. A written report of such incident and follow-up report of the remediations shall be provided to the subcontractor/vendor, EOR, and the County.

K. Project Records: The Construction Contractor shall:

1. Maintain records at the job site, including a current set of contract documents, a project log, and progressive photographs of the project, record of construction progress, problems and concerns, work logs, payroll records, and any related interviews, etc.

2. All records shall be open for inspection by the EOR and the County.

3. All records shall be delivered to the County in an organized format to the

County at completion of the Project.

SECTION 5 PROPOSAL RESPONSE REQUIREMENTS

A. The County has established certain mandatory requirements that must be included as part of any response that are described in the Solicitation

INSTRUCTIONS TO PROPOSERS section are hereby incorporated by reference. The use of the terms “shall,” “must,” or “will” (except to indicate simple futurity) in this Solicitation indicates a mandatory requirement or condition. The words “should” or “may” in this Solicitation indicate desirable attributes or conditions but are permissive in nature. Deviation from, or omission of, such a desirable feature will not by itself cause rejection of a Proposal.

B. Proposals not meeting all material requirements of this request, or which fail to provide all required information, documents, or materials such as request forms, bonds, etc., may be rejected as non-responsive. Material requirements of the bid are those set forth as mandatory, or without which an adequate analysis and comparison of replies is impossible, or those which affect the competitiveness of replies or the cost to the County. A Respondent whose replies, past performance or current status that do not reflect the capability, integrity, or reliability to perform fully and in good faith the requirements of the Solicitation may be rejected as non-responsible.

C. The County reserves the right to determine which Proposals meet the material requirements of the Solicitation and which Proposals are responsible and/or responsive. Further, the Board of County Commissioners may reject any and all

Bids and seek new Bids when it is in the best interest of the County to do so.

D. A Proposal by a corporation shall be executed in the corporate name by the president or a vice-president or other corporate officer accompanied by evidence of authority to sign. The corporate seal shall be affixed and attested by the secretary or an assistant secretary. The corporate address and state of incorporation shall be provided on the Solicitation Proposal Transmittal Form

(located in the VENDOR QUESTIONNAIRE section of this Solicitation), for a

Proposal by a/an:

1. Partnership shall be executed in the partnership name and signed by a partner (whose title must appear under the signature), accompanied by evidence of authority to sign. The official address of the partnership shall be provided on the Proposal Form.

2. Limited liability company shall be executed in the name of the firm by a member and accompanied by evidence of authority to sign. The state of formation of the firm and the official address of the firm shall be shown.

3. Individual shall show the Respondent's name and business address.

4. Proposal by a joint venture shall be executed by each joint venture member in the manner indicated on the Proposal form. The official address of the joint venture must be provided on the Proposal Form.

5. All names shall be printed in ink or typed below the signatures.

E. Acknowledgement of receipt of all Addenda shall be made with the County's

OpenGov portal located at https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754.

Failure to acknowledge receipt of all Addenda may result in the Proposal being rejected.

F. The postal, email addresses, and telephone number for communication regarding the Proposal shall be listed in the Proposer's OpenGov Vendor Profile.

G. A Respondent seeking to do business with the County shall, at the time of submitting a Proposal, be appropriately registered with the Department of State in accordance with the provisions of Chapters 605, 607, 617, or 620 Florida

Statutes, as applicable. For further information on required filing and forms, please go to the following sites: http://sunbiz.org/index.html or https://www.dos.myflorida.com/.

The Proposal shall contain evidence of Respondent's authority and qualification to do business in the state or locality where the Project is located, or Respondent shall covenant in writing to obtain such qualification prior to award of the Contract and attach such covenant to the Proposal. Proposer’s state contractor license number, if any, shall also be shown on the Proposal Transmittal Form located in the VENDOR QUESTIONNAIRE section of this Solicitation.

H. The Respondent shall be appropriately registered with the System for Awards

Management (SAM.gov) at the time of submitting a proposal. Please visit

SAM.gov for additional information regarding registration. If a Proposer has already registered with SAM.gov, a Unique Entity Identifier (UEI) number must be provided on the Proposal Transmittal Form located in the VENDOR

QUESTIONNAIRE section of this Solicitation.

I. The Proposal should address the requirements in a clear and concise manner in the order stated herein.

J. Proposals must include the information/documents specified and requested in the Solicitation. Proposals that do not adhere to the format or include the https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754 http://sunbiz.org/index.html https://www.dos.myflorida.com/ requested information/documents may be considered incomplete and therefore unresponsive by the County.

K. Respondents shall submit a preliminary schedule narrative and milestone timeline reflecting its approach to meeting the County’s target milestones. The schedule must include, but is not limited to preconstruction activities, bidding/early bid packages, permitting, mobilization, phased construction (if applicable), substantial completion, and final completion. The schedule is for evaluation purposes only and is not a guaranteed contract schedule until incorporated into the negotiated Contract and Notice to Proceed.

L. The County reserves the right to seek additional/supplemental representation on specific issues as needed.

M. Proposals should be typed or clearly written. No changes in or corrections to

Proposals will be allowed after the Proposals are opened.

N. The signer of the Proposal must declare that the Proposal is, in all respects, fair and in good faith without collusion or fraud and that the signer of the Proposal has the authority to bind the principal Proposer.

O. The County shall not be liable for any costs incurred by Respondent prior to entering into a contract. Therefore, all Proposers are encouraged to provide a simple, straightforward, and concise description of their ability to meet the

Solicitation requirements.

P. Refer to the INSTRUCTIONS TO PROPOSERS section of this Solicitation for additional information and instructions.

SECTION 6 PROPOSAL RECEIPT AND OPENING

A. All Proposals shall be submitted electronically by 10:00 am on Thursday, August 20, 2026 via the County's OpenGov Portal located at https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754.

B. The County OpenGov Portal Clock is the official clock for the determination of all deadline dates and times. The responsibility for submitting the Proposal to the

County Procurement Office no later than the specified time and date is solely that of the Bidder. The County will not be responsible for delays caused by technical difficulties, such as poor internet connectivity. The County strongly recommends completing your response well ahead of the deadline.

C. Submission of Proposals by mail, fax or other electronic means will not be accepted.

D. Proposal will not be accepted after the submission deadline.

E. A Proposal may be withdrawn or modified prior to the time fixed for the opening ofProposals, by clicking "Un-submit Response". Negligence on the part of the

Respondent in preparing the Proposal confers no right for withdrawal of the

Proposal after it has been opened.

F. All Proposals will be opened on the date and time indicated in the SCHEDULE

OF EVENTS AND QUESTIONS (i.e., date Proposals are due) section of this

Solicitation, or as modified by addendum.

G. Pricing shall be valid for a period of ninety (90) days from opening of Proposal or until award is made, whichever occurs later.

H. Time is of the essence. The Construction Contractor shall achieve Substantial

Completion by the date set forth in the Contract. For each calendar day of delay attributable to the Construction Contractor, the County may assess liquidated damages as set forth herein. In addition, the Construction Contractor shall not be entitled to construction phase fee or general conditions for the period of delay. The Construction Contractor shall not be entitled to any extension of

Contract Time unless it demonstrates that the delay impacted the critical path and was not caused by the Construction Contractor or its subcontractors.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754

SECTION 7 EVALUATION OF PROPOSALS AND SELECTION

PROCESS

A. Respondents who satisfy the required qualifications and are deemed responsible and responsive and who submit a timely proposal shall be ranked by a Selection

Committee appointed by the County Administrator.

B. In ranking proposals, the Selection Committee shall evaluate the proposals based on this Solicitation, the information provided by the Proposer, and rank each proposal for compliance with the qualifications of each Proposer and compliance with the mandatory requirements of the Solicitation.

C. A Respondent whose Proposal, past performance, or current status that does not reflect the capability, integrity, or reliability to perform fully and in good faith the requirements of the Solicitation and contract may be rejected as non-responsible.

D. Responses to this Solicitation, not meeting the requirements specified herein may be considered non-responsive or not responsible, as applicable.

E. The County may consider the following factors in addition to price when determining whether a Response is responsive and responsible:

1. Ability, capacity, and skill of the Respondent to perform the contract.

2. Whether the Respondent can perform the contract within the time specified, without delay, interference, or conflict with current workload.

3. Character, integrity, reputation, judgment, experience, and efficiency of the

Bidder.

4. Quality of performance of previous contracts.

5. Previous and existing compliance by the Respondent with laws and regulations relating to the contract.

6. Sufficiency of the financial resources and ability of the vendor to perform the contract or provide the Work.

7. Quality, availability and adaptability of the supplies or contractual services to the particular use required.

8. Ability of the Respondent to provide further maintenance and service for the use of the subject of the contract, if applicable.

9. Number and scope of conditions attached to the bid or quote.

10. Qualifications of personnel, licensing, and corporate qualifications.

11. Evidence of improper litigation.

12. Use of one or more subcontractors with a record of inferior performance.

F. For the purposes of this Solicitation, the County may consider evidence within the ten-year period preceding this Solicitation.

G. Clarification from Proposers: The County may seek clarification from any or all

Respondents and consider such supplementary information in the evaluation of the Proposal.

H. In the best interest of the County, the BOCC reserves the right to reject any and all responses or waive any minor irregularity or technicality in responses received. Proposers are cautioned to make no assumptions unless their response has been deemed responsive.

I. The Selection Committee will evaluate the Proposals that are responsible and responsive to the requirements of this Solicitation using the weighted criteria listed in order of importance found in the EVALUATION CRITERIA section of this

Solicitation.

J. Proposers may be selected for interviews or oral presentations (shortlisted) as may be necessary. The County makes no commitment to any Respondent to this Solicitation beyond consideration of the written response to this

Solicitation. All Proposers will be notified of the shortlisted Proposers as well as the date, time, and location of interviews and/or oral presentations. The County may consider any supplementary information from interviews or presentations in the evaluation of the Response.

K. In the event the lowest, responsive, responsible bid for construction project exceeds the grant or EOR probable cost estimates, the County Administrator or their designee is authorized, when time or economic considerations preclude rebidding of work of a reduced scope, to negotiate an adjustment of the scope of work with the lowest, responsive, responsible bidder, to bring the bid within the available funding.

L. The County reserves the right to reject any and all Proposals, including without limitation, nonconforming, non-responsive, unbalanced, or conditional

Responses. The County reserves the right to reject the Proposal of any

Respondents whom it finds, after reasonable inquiry and evaluation, to be non-responsible. The County also reserves the right to waive all informalities not involving price, time, or changes in the Work and to negotiate contract terms with the successful Respondent.

M. More than one Proposal for the same work from an individual or entity under the same or different names will not be considered. Reasonable grounds for believing that any Respondent has an interest in more than one Proposal for the

Work may be cause for disqualification of that Respondent and the rejection of all

Proposals in which that Respondent has an interest.

N. Individual Committee members will be removed from the Committee if unable to participate in all reviews, and scoring will be based on the scores of the remaining Committee members.

O. Reference Checks: The County may conduct reference checks relevant to the

Proposal with any or all of the references cited in the Proposal to verify any and all information and rely on or consider any relevant information from the cited references in the evaluation of the Proposal.

P. In evaluating Proposals, the County will consider whether or not the Proposals comply with the prescribed requirements, and such alternates, unit prices and other data, as may be requested in the Proposal Form or prior to issuance of the

Notice to Proceed.

Q. In evaluating Proposals, the County will consider the qualifications of

Respondents and may consider the qualifications and experience of subcontractors, suppliers, and other individuals or entities proposed for those portions of the Work for which the identity of subcontractors, suppliers and other individuals or entities may be required to be submitted as provided herein. Refer to the INSTRUCTIONS TO PROPOSERS section of this Solicitation.

R. The County may conduct such investigations as it deems necessary to establish the responsibility, qualifications, and financial ability of Respondents, proposed subcontractors, suppliers, individuals, or entities to perform the work. Any bidder or sub-contractor having access to County facilities or property may be required to be screened to a level that may include but not limited to fingerprinting and a statewide criminal background check with any all fees for such the responsibility of the Respondent or subcontractor.

S. Responses to this Solicitation not meeting the requirements specified herein will be considered non-responsive or not responsible, as applicable.

T. Right of Rejection: The County reserves the right to reject a bid or all proposals per Section 8.9, if in the best interest of the County. All Respondents are cautioned to make no assumptions unless their Proposal (response) has been deemed responsive.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=2522172

U. The Proposals deemed best by the Selection Committee shall be presented by the County Administrator in the form of an Agenda Request to the Gadsden

County Board of Commissioners, who shall either accept or deny the recommendation of the selection committee as presented by the County

Administrator.

SECTION 8 EVALUATION CRITERIA

The selection committee will evaluate the Proposals that are responsible and responsive to the requirements of this RFP using the following weighted criteria listed in order of importance:

No. Evaluation Criteria Scoring

Method

Weight

(Points)

1. Experience with Similar Projects & Firm

Qualifications

Respondents must be:

• Licensed in State of Florida as a General

Contractor

• Have experience with related facilities, and

• Have experience with public sector projects

Points Based 25

(25% of Total)

2. Project Approach & Project

Timeline/Schedule/Milestone Plan

Time is of the essence. The Construction

Contractor shall achieve Substantial Completion by the date set forth in the Contract. For each calendar day of delay attributable to the

Construction Contractor, the County may assess liquidated damages as set forth herein. In addition, the Construction Contractor shall not be entitled to construction phase fee or general conditions for the period of delay. The

Construction Contractor shall not be entitled to any extension of Contract Time unless it demonstrates that the delay impacted the critical path and was not caused by the Construction Contractor or its subcontractors.

A. Contract Execution TBD

B. Pre-Construction Meeting 10 days from Contract Execution

C. Issuance of Notice to Proceed Issued upon completion of Building Permitting

D. Pre-construction Activities 10 days from Issuance of Building Permitting

E. Substantial Completion 30 days from deadline of 12.31.26

F. Final Completion and Acceptance 30 days from Substantial Completion*

*Consecutive calendar days.

**The milestones and/or target dates are subject to change based on the actual date of the contract execution, the issuance of the Notice to Proceed

(NTP), or other unknown factors.

Points Based 35

(35% of Total)

3. Cost Proposal Points Based 20

(20% of Total)

4. References on Recent Projects/Past

Performance

Points Based 10

(10% of Total)

5. Community Engagement/Local Preference Points Based 5

(5% of Total)

6. Minority Based Enterprise/Disabled Veteran

Preferences (required in grant)

Points Based 5

(5% of Total)

SECTION 9 INTENT TO AWARD AND CONTRACT EXECUTION

A. The County reserves the right to incorporate the successful Response into the

Contract. Failure of a firm to accept this obligation may result in the cancellation of the award to said Respondent and the County shall then negotiate with the next ranked Respondent.

B. The construction, interpretation, and performance of this Solicitation, and all transactions under it, shall be governed by the laws of the State of Florida and

Gadsden County. The Agreement shall include all terms and conditions of this

Solicitation, any addenda, response, and the County’s contract issued as a result of this Solicitation.

C. The County reserves the right to make award(s) to more than one Respondent and/or by individual items, group of items, all or none, or a combination, thereof.

D. The selected Respondent will be required to assume responsibility for all Work offered in the Response. The County will consider the selected firm to be the sole point of contact regarding contractual matters, including payment on any or all charges.

E. All notices for the intent to award, award, or other events will be posted to the

County’s OpenGov portal/website in accordance with the SCHEDULE OF

EVENTS AND QUESTIONS section of this Solicitation.

F. The Response(s) deemed best by the selection committee shall be presented by the County Administrator in the form of an Agenda Request to the Gadsden

County Board of Commissioners, who shall either accept or deny the recommendation of the selection committee as presented by the County

Administrator.

G. After successful posting of the intent to award for 72 hours per the SCHEDULE

OF EVENTS AND QUESTIONS section of this Solicitation, and Board approval of an award, the County will negotiate a contract with the successful

Respondent(s) in accordance with County policy, Florida Law, this Solicitation, and the successful Respondents' proposal.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=undefined https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754/document?section=undefined

SECTION 10 STANDARD TERMS AND CONDITIONS

Conformity and adherence to the terms and conditions of this Solicitation shall be considered by the County as part of its evaluation and award determination process.

Respondents shall review the Draft Contract included with this Solicitation, as well as all required forms, certifications, and questionnaire items contained within the Vendor

Questionnaire and Attachments sections of the Solicitation. Submission of a Response constitutes acknowledgment and acceptance of the terms, conditions, and requirements set forth therein, unless specific exceptions are clearly identified in the Response.

10.1 Definitions

General terms used throughout this Solicitation are provided below. Additional definitions may be provided as applicable to a specific section or subject matter.

A. Addendum means a written modification to this Solicitation issued by the

County.

B. Award means the determination of a successful Respondent(s) in response to this Solicitation, resulting in an offer of a Contract.

C. Board means the Gadsden County Board of County Commissioners (BOCC).

D. Contract or Agreement means the legally enforceable document agreed to and signed by the County and the successful Respondent(s).

E. County means the Gadsden County Board of County Commissioners and its employees.

F. Evaluation Committee means the committee appointed by the County to review and evaluate Responses when applicable.

G. Invitation to Bid (ITB) means a competitive sealed bid solicitation used when price is the primary basis for award and award is made to the lowest responsive and responsible bidder.

H. Request for Proposals (RFP) means a competitive sealed proposal solicitation used when factors other than price are considered in determining award.

I. Request for Qualifications (RFQ) means a qualifications-based competitive solicitation used to evaluate and rank firms based on demonstrated competence and qualifications.

J. Invitation to Negotiate (ITN) means a competitive sealed solicitation used when negotiations are contemplated to determine the best value to the County.

K. Invitation to Quote (ITQ) means a written solicitation for written pricing or quotes, typically used for informal or written quotation procurements as permitted by County policy and Florida Law.

L. Response means any Bid, Proposal, Qualification Statement, Reply, or other submittal provided in response to this Solicitation.

M. Respondent means any firm, individual, or organization, Bidder, Proposer, Offeror, Contractor, Consultant, or other entity submitting a Response in reply to this Solicitation.

N. Scope of Work (SOW) means the services, work, or commodities to be provided as described in this Solicitation.

O. Solicitation means this competitive procurement document, including all addenda, attachments, questionnaire items, and documents incorporated by reference, whether issued as an ITB, RFP, RFQ, ITN, ITQ, or other method authorized by Florida Law.

P. Successful Respondent means a Respondent awarded a Contract as a result of this Solicitation.

10.2 Issuance of Addenda

If this Solicitation is amended, the County Procurement Office will issue a written

Addendum. If an Addendum is issued, all terms and conditions not specifically modified shall remain unchanged.

An Addendum will be issued if any events, dates, and/or times referenced in Section 1.0 change. Respondents are required to register for an account via the County's OpenGov

Portal. Once the Respondent has completed registration, they will receive addenda notifications to their email by clicking “Follow” on this project. Ultimately, it is the sole responsibility of each Respondent to periodically check the site at https://procurement.opengov.com/portal/gadsdencountyfl for any addenda.

10.3 Florida Public Records Law and Confidentiality

A. By submitting a Response in response to this Solicitation, a Respondent acknowledges that the County is a governmental entity subject to the Florida

Public Records Law (Chapter 119, Florida Statutes). The Respondent further acknowledges that any materials or documents provided to the County may be

“public records” and, as such, may be subject to disclosure to, and copying by, the public unless otherwise specifically exempt by Law.

B. Should the Respondent provide the County with any materials which it believes, in good faith, contain information that would be exempt from disclosure or https://procurement.opengov.com/portal/gadsdencountyfl copying under Florida Law; the Respondent shall indicate that belief by typing or printing, in bold letters, the phrase:

1. “PROPRIETARY INFORMATION” on the face of each affected page of such materials. The Respondent shall submit to the County both a complete copy of such material and a redacted copy in which the exempt information on each affected page, and only such exempt information, has been rendered unreadable. In the event a Respondent fails to submit both copies of such material, the copy submitted will be deemed a public record subject to disclosure and copying regardless of any annotations to the contrary on the face of such document or any page(s) thereof.

2. NOTE: The County will not accept Response submittals when the entire submittal is labeled as exempt from public disclosure. References and cost or price information will be deemed a public record, and if a claim of confidentiality/proprietary information is made, the County may deem the Response submittal as “non-responsive.”

C. Should any person request to examine or copy any material so designated and provided the affected Respondent has otherwise fully complied with this provision, the County, in reliance on the representations of the Respondent, will produce for that person only the redacted version of the affected materials. If the person requests to examine or copy the complete version of the affected material, the County shall notify the Respondent of that request, and the

Respondent shall reply to such notification, in writing that must be received by the County no later than 4:00 p.m., EST, of the second County business day following Respondent’s receipt of such notification, either permitting or refusing to permit such disclosure or copying.

D. Failure to provide a timely written reply shall be deemed consent to disclosure and copying of the complete copy of such material. If the Respondent refuses to permit disclosure or copying, the Respondent agrees to, and shall, hold harmless and indemnify the County for all expenses, costs, damages, and penalties of any kind whatsoever which may be incurred by the County, or assessed or awarded against the County, in regard to the County’s refusal to permit disclosure or copying of such material. If litigation is filed in relation to such request and the

Respondent is not initially named as a party, the Respondent shall promptly seek to intervene as a defendant in such litigation to defend its claim regarding the confidentiality of such material. This provision shall take precedence over any provisions or conditions of any Response submitted by a Respondent in response to this Solicitation and shall constitute the County’s sole obligation with regard to maintaining confidentiality of any document, material, or information submitted to the County.

10.4 Right to Protest

Any person who is adversely affected by the decision or intended decision of the County shall file with the Purchasing Division a notice of intent to protest in writing within 72 hours after the posting of the bid tabulation. Thereafter, a formal protest shall be filed, in writing, within ten (10) calendar days after the date of the filing of the notice of intent to protest.

Any Respondent who desires to formally protest shall follow the procedures outlined in the Gadsden County Procurement Policy, incorporated by reference, and can be obtained by contacting the County Purchasing Director at (850) 627-8433 or email:

Procurement@gadsdencounty.gov.

The failure to file a notice of intent to protest or failure to file a formal written protest shall constitute a waiver of proceedings.

A written protest is filed with the County upon delivery to and receipt by the Purchasing

Division.

10.5 Requests for Clarification and Assistance

All inquiries concerning this Solicitation must be submitted in writing by 10:00 am on

Thursday, August 6, 2026 through the County's eProcurement Portal, located at https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754.

All answers to inquiries will be posted on the County's OpenGov Portal. Bidders may also click “Follow” on this Solicitation to receive an email notification when answers are posted. It is the Respondent's responsibility to check the website for answers to inquiries.

10.6 ADA – Special Accommodations

Any person requiring special accommodation by the County due to a disability should call the County Purchasing Office at least five (5) working days prior to any pre-response conference, response opening, or meeting. If you are hearing or speech impaired, please contact the Board’s Purchasing Office by using the Florida Relay

Service, which can be reached at 1-800-955-8771 (TDD). The Purchasing Office telephone number is: 850-627-8433.

10.7 Respondent’s Responsibility

It is understood and the Respondent hereby agrees to be solely responsible for obtaining all materials and determining the best methods that will be utilized to meet the intent of the specifications of this Solicitation.

mailto:Procurement@gadsdencounty.gov.

https://procurement.opengov.com/portal/gadsdencountyfl/projects/262754

Failure by the Respondent to acquaint themselves with the available information will not relieve them from responsibility for estimating properly the difficulty or cost of successfully performing the Work.

Respondents are expected to examine the specifications and all instructions pertaining to the required work/commodities/services. Failure to do so will be at Respondent’s risk.

10.8 Indemnification and Hold Harmless

Respondents must complete and sign the County’s Indemnification and Hold Harmless certification as provided within the VENDOR QUESTIONNAIRE section or as otherwise required in the Solicitation. Reference the Draft Contract for additional information.

10.9 Right of Rejection

The County reserves the right to reject any Response found to be…