HSFLGL-13-B-00004_SF-30_Amendment_000001.pdf

(x)

HSFLGL-13-B-00004

x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

GLYNCO GA 31524

ATTN: Sonya D. Armstrong

FLETC GL

PRO BLDG 93

1131 CHAPEL CROSSING RD

FEDERAL LAW ENFORCEMENT TRNG CTR

DEPARTMENT OF HOMELAND SECURITY

GLYNCO GA 31524

FLETC GL

BLDG: 93 ATTN: Sonya D. Armstrong

1131 CHAPEL CROSSING RD

FEDERAL LAW ENFORCEMENT TRNG CTR

DEPARTMENT OF HOMELAND SECURITY

000001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

08/02/2013

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

1. This Amendment 000001 changes the subject solicitation as follows:

A. The SF-1442 is replaced with the attached revised SF1442. Item 13. Addtional

Solicitation Requirements: d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

B. Section F. Deliveries or Performance: FAR Clause 52.211-12 Liquidated

Damages-Construction (SEP 2000) is revised and attached with this Amendment. Replacement

Page 13 is provided.

C. The attached site visit attendance sheet is hereby provided to prospective bidders.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Sonya D. Armstrong

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

sdarmstrong Typewritten Text 08/16/2013 sdarmstrong Typewritten Text

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 7

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

HSFLGL-13-B-00004/000001

The site visit was held on 15 August 2013 at FLETC, Glynco, GA.

D. Bidders are reminded that all technical inquiries must be submitted in writing to the Contracting Officer no later than 23 August 2015.

Inquiries shall be sent via email to sonya.armstrong@dhs.gov .

E. Bid Date remains 3 September 2013, 3:00 P.M.

Eastern Time at FLETC, Glynco, GA. If attending the formal bid opening, the bidder is required to notify the Contracting Officer via email no later than 30 August 2013, 1:00 P.M. Eastern Time to obtain a visitor pass. Request must include Company Name, Full Name of Attendee, State whether the attendee is a U.S. Citizen. Delay in providing this information may result in no access to the bid opening. It is the bidder's responsibility to ensure arrival to obtain the pass in sufficient time to attend the bid opening.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

13G0064C01

DEPARTMENT OF HOMELAND SECURITY

FEDERAL LAW ENFORCEMENT TRNG CTR

1131 CHAPEL CROSSING RD

BLDG: 93 ATTN: Sonya D. Armstrong

FLETC GL

GLYNCO GA 31524

Sonya Armstrong 912-267-2542 x

08/02/2013

HSFLGL-13-B-00004

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

PROJECT TITLE: RENOVATE BUILDING 64, FEDERAL LAW ENFORCEMENT TRAINING CENTER,

GLYNCO, GA

NAICS: 236220

SIZE STANDARD: $33.5 MILLION

1. This procurement is a 100% HubZone Set-Aside (Small Business HubZone).

2. The estimated cost of construction is between $5M - $10M.

3. Bids are due on Tuesday, September 3, 2013 at 3:00 PM (Eastern Time). The Bids will be publicly opened in Building 93, Room 111, at the Federal Law Enforcement

Training Center in Glynco, Georgia.

4. A Pre-Bid Conference/Site visit shall be held on Thursday, August 15, 2013 at

10:00 AM (Eastern Time). Bidders are Strongly Encouraged to Attend. See Section L for further details.

5. Facsimile Offers and/or Modifications to Offers are NOT authorized.

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

15 365 calendar days and complete it within ________________ ________________ calendar days after receiving

09/03/2013

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected. _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d) sdarmstrong Typewritten Text sdarmstrong

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

DEPARTMENT OF HOMELAND SECURITY

FEDERAL LAW ENFORCEMENT TRNG CTR

1131 CHAPEL CROSSING RD

PRO BLDG 93

FLETC GL

ATTN: Sonya D. Armstrong

GLYNCO GA 31524

Sonya D. Armstrong

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 69

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

HSFLGL-13-B-00004

6. Telegraphic Offers are NOT authorized;

however, Timely telegraphic modifications to offers are authorized.

7. Technical inquiries must be submitted in writing within ten (10) calendar days prior to the receipt of Bids. Inquiries shall be submitted via email to sonya.armstrong@dhs.gov .

Late Submissions will NOT be addressed.

8. Offerors shall provide a statement of compliance with FAR 52.222-50, Combating Trafficking in Persons, requirements and confirm subcontractors will accomplish a statement of compliance upon award.

9. Acceptance of an Award certifies that the firm will comply with FAR 52.222-50, Combating Trafficking in Persons, by notifying all employees and subcontractors at all levels.

Delivery: 365 Calendar Days after Award.

FOB: Destination

0001 Provide all necessary management, quality control, labor, materials, and equipment to Renovate Building 64 at the Federal Law Enforcement Training Center, Glynco, GA as described in the attached project specifications and drawings.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

HSFLGL-13-B-00004

Section D – Packaging and Marking

D.1 PAYMENT OF POSTAGE AND FEES

The Contractor shall pay all postage and fees related to submitting information (including forms, reports, etc.) to the Contracting Officer.

D.2 MARKING

All information submitted to the Contracting Officer shall clearly indicate the contract number and name of the Contractor for which the information is being submitted.

END OF SECTION D

Section E - Inspection and Acceptance

52.246-1 Contractor Inspection Requirements. (APR 1984)

52.246-12 Inspection of Construction. (APR 1996)

52.246-21 Warranty of Construction. (MAR 1994)

END OF SECTION E

Section F - Deliveries or Performance

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 calendar days after Award. The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 Liquidated Damages - Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $456.46 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

sdarmstrong