HMMF 01 11 Summary of Work (003).pdf

RSNF TUWAIQ SHIPS INITIAL OPERATIONAL NAVAL MISSILE MAINTENANCE FACILITY,

CAPABILITY (IOC) DESIGN AL KHARJ, KINGDOM OF SAUDI ARABIA

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

Under the Foreign Military Sales (FMS) case, SR-P-SBV the Kingdom of Saudi Arabia (KSA) has a requirement for a design bid build RFP to construct (1) Harpoon Block II Missile Maintenance Facility (HMMF), Earth Covered Magazine (ECM) with Intrusion Detection System (IDS), Paint and Flammable Storage Facility, and associated site work and utilities at the Naval Missile Maintenance Facility (NMMF) in AL Kharj to support the introduction of 4 Multi-Mission Surface Combatant Ships (MMSCs) to the Royal Saudi Naval Forces (RSNF). This work shall be done according to the design documents including plans and specifications provided herein. In addition, all construction and other associated efforts shall be done in accordance with local building codes and internationally recognized standards with respect to safety and general construction, and as described in these documents. Moreover, the construction contractor will be responsible for reviewing and confirming the site conditions in the topographic and geotechnical surveys and reports provided. The Contractor shall also perform a pre-construction site investigation with the USACE field staff and RSNF to evaluate and finalize travel routes, site conditions, and any other incidental work to make requirements fully functional in order to provide the Government with a complete construction and warranty for this project.

The Contractor is to construct new facilities at NMMF Al Kharj as identified below:

Construct One (1) Harpoon Missile Maintenance Facility (HMMF) and required pavements and infrastructure including connections to existing pavements and utilities.

Construct One (1) Earth Covered Magazine (ECM) and required pavements and infrastructure including connections to existing pavements and utilities.

Construct One (1) Paint and Flammable Storage Facility and required pavements and infrastructure including connections to existing pavements and utilities.

Construct One (1) Fire Pump House and required pavements and infrastructure including connections to existing pavements and utilities.

1.1.2 1.2.2 Location

Naval Missile Maintenance Facility: Is located in Al Kharj approximately 78 KM east of Riyadh and 375 KM south-west of King Abdulaziz Naval Base (KANB).

The naval munitions facilities at Al Kharj are operated by the RSNF in support of both the RSNF Eastern and Western Fleet. The effort includes the construction of (1) HMMF, ECM with IDS, and Paint and Flammable Storage Facility. It also includes limited demolition and site preparations

SECTION 01 11 00 Page 1

READY TO ADVERTISE CLIN 0001 14 MAY 2021

RSNF TUWAIQ SHIPS INITIAL OPERATIONAL NAVAL MISSILE MAINTENANCE FACILITY,

CAPABILITY (IOC) DESIGN AL KHARJ, KINGDOM OF SAUDI ARABIA

necessary for phasing of the work. The construction and associated work shall be done and provided to the customer with high quality, complete and useable operational condition.

1.2 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

In addition to work being executed in accordance with the Technical Requirements described in this package, all work shall be coordinated and approved with the CONTRACTING OFFICER prior to further coordination with representatives of the RSNF and other Command elements, either identified or not, that may be impacted during this project. The Contractor shall be responsible for coordinating and completing all work under this contract within the performance period under this contract. Base Life Support Area is not available, the Contractor is responsible for the sustainment of their work force, and the Contractor shall plan for daily commutes to access work sites. Base access is the sole responsibility of the Contractor. The Contractor shall follow all regulation and process put forth by the RSNF necessary to obtain and maintain base access for the duration of the project. USACE has no obligation to act as an intermediary. The U.S. Government will not be responsible for any lack of coordination and communication by the Contractor which results in delays.

The Contractor is responsible for all delays with base access for personnel, vehicles, and deliveries.

-- End of Section --

SECTION 01 11 00 Page 2

READY TO ADVERTISE CLIN 0001 14 MAY 2021