LDS.pdf
PDF 82 KB Posted
- Solicitation number
- FA813726R0008
About this file
This is a Liquidated Damages assessment document for federal contract/delivery order WWYK150083, which pertains to the repair of Transformer Vault 6 at facility B9001. The document establishes the financial penalties assessed for each calendar day of delay in completing the contracted work, in accordance with FAR 36.206 and DFARS 236.206. The total liquidated damages amount is $227.75 per day for Phase 1, calculated based on the combination of engineering and government personnel costs required to manage and oversee the project.
The daily cost breakdown includes engineering staff totaling $122.36, comprising an Engineering Manager (0.5 hours at $57.69/hour), Project Manager (1 hour at $36.06/hour), Engineering Tech/Inspector (1 hour at $28.52/hour), Project Engineers (0.5 hours at $38.46/hour), and Clerical support (0.5 hours at $19.41/hour). Government personnel costs total $105.39 daily, including FAS staff (GS-12/5, 0.5 hours at $39.19/hour), Legal representation (GS-13/5, 1 hour at $46.60/hour), and Contracting staff (GS-12/5, 1 hour at $39.19/hour). The assessment is based on the contractor's complete control over work pace and the reasonableness of the rate relative to project requirements.
View the file
Other files
Show all 17
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PROJECT NUMBER & TITLE: WWYK150083--REPAIR TRANSFORMER VAULT 6, B9001
FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$
ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$
SUBTOTAL 122.36$
GOVERNMENT TITLE Hrs RATE TOTAL
FAS (GS-12/5) 0.5 39.19$ 19.60$
Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$
SUBTOTAL 105.39$
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$
Contracting Officer (Signature)
Contracting Officer (Print)
Date:
LIQUIDATED DAMAGES
In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work.
b. The contract provides for LDs for delay of work for each calendar day of the contract.
c. Considering the requirement, the rate of assessment is reasonable.
Sheet1
File details come from the government source that posted it. Updated .