Solicitation_Amendment_FA810625RB0010001_SF_30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

Created On:

10 Jan 2025, 17:07 PM Central Standard Time

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form

The following changes have been made:

INFORMATION FROM TO

Response Due Date 23 Dec 2024 24 Jan 2025

Contract Clauses

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

52.243-1 Changes-Fixed-Price. Aug 1987

FAR Clauses Incorporated by Full Text

52.243-7 Notification of Changes. (Tailored) (Jan 2017)

As prescribed in , insert the following clause:43.107

Notification of Changes (Jan 2017)

"Contracting Officer," as used in this clause, does not include any representative of the Contracting Officer.(a) Definitions.

"Specifically Authorized Representative (SAR)," as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this paragraph and shall be issued to the designated representative before the SAR exercises such authority.

The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this (b) Notice.

contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within (to be negotiated) calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and 10 written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state-

The date, nature, and circumstances of the conduct regarded as a change;(1)

The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;(2)

The identification of any documents and the substance of any oral communication involved in such conduct;(3)

In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;(4)

The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including-(5)

What line items have been or may be affected by the alleged change;(i)

What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;(ii)

To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be (iii) caused by the alleged change;

What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and(iv)

The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.(6)

Following submission of the notice required by paragraph (b) of this clause, the Contractor shall diligently continue performance of this (c) Continued performance.

contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, FA810625RB0010001 however, that if the Contractor regards the direction or communication as a change as described in paragraph (b) of this clause, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing promptly and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall promptly countermand any action which exceeds the authority of the SAR.

The Contracting Officer shall promptly, within (to be negotiated) calendar days after receipt of notice, respond to the notice in writing. (d) Government response. 10 In responding, the Contracting Officer shall either-

Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;(1)

Countermand any communication regarded as a change;(2)

Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or(3)

In the event the Contractor's notice information is inadequate to make a decision under paragraphs (d)(1), (2), or (3) of this clause, advise the Contractor what (4) additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

Equitable adjustments.(e)

If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in (1) the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-

In the contract price or delivery schedule or both; and(i)

In such other provisions of the contract as may be affected.(ii)

The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is (2) responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in paragraphs (b) and (c) of this clause.

Note: The phrases "contract price" and "cost" wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

(End of clause)

The following clauses were deleted:

DFARS Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

252.204-7021 Contractor Compliance with the Cybersecurity Maturity Model Certification Level Requirement. Jan 2023

List of Attachments

Miscellaneous text in this section has been modified to:

Section J

1. Performance Work Statement

2. Planned Government Furnished Property

3. Data Item Description (DIDs) A001-A026

4. Wage Determinations

5. Contract Data Requirements List (CDRL) A001-A0026

6. Divestment Tracker

FA810625RB0010001

CP 405 739 2216, STAFF DR BLDG 30001 STE 1AG1104A

TINKER AFB, OK 73145-3303

UNITED STATES

Starla Young, Email: starla.young@us.af.mil Telephone: 312-884-7753 AdminBy:

SCD: PAS:

- Revise- Attachment 1, Performance Work Statement dated 13 December 2024

- Add Attachment 6, Divestment Tracker

- Add Clauses: FAR 5.243-1 & 52.243-7

- Remove clause FAR 252-204-7021