Draft_PWS_-_NWS_Main-Supp_Rotary_Wing_as_of_(5_Aug_14).docx

NORTH WARNING SYSTEM AIRLIFT

Rotary-Wing Airlift Services

PERFORMANCE WORK STATEMENT

The PWS applies to rotary airlift services to the North Warning System in Canada. PWS has three distinct requirements, (main rotary-wing airlift, supplemental rotary-wing airlift support and bulk fuel rotary-wing airlift services). Appendix 1 contains specific main rotary wing airlift requirements, Appendix 2 contains specific supplemental rotary airlift support requirements, Appendix 3 contains specific bulk fuel rotary-wing airlift requirements and Appendix 4 lists approximate site locations. Inuvik, Hall Beach (FOX-M), Cambridge Bay (CAM-M), Iqaluit and Goose Bay will be considered as the base of operations for all work accomplished under this PWS.

1.0 DESCRIPTION OF SERVICES

1.1. The Contractor shall provide all personnel, services, equipment, tools, oil, facilities, supervision and direct materials necessary for the performance of the air transportation services hereunder, including sufficient number of ground personnel for adequate maintenance and ground operation, except as otherwise noted in this contract. The Contractor’s price includes all costs of performance (including spares, aircraft basing, lodging, crew rotation costs, and aircraft heaters sufficient to support operations in the Arctic environment) and costs for fuel handlers, except for items covered under reimbursable expenses. The Contractor must comply with the provisions of the Canada Transportation Act, S.C. 1996, c. 10, the Aeronautics Act, R.S.C. 1985, c. A-2, the Canadian Aviation Regulations, SOR/96-433 and with all regulations, directions, orders and rules made pursuant to those Acts which are applicable to the services to be performed under the Contract. In particular, the Contractor must hold a valid Air Operator Certificate issued by Transport Canada and a valid license issued by the Canadian Transportation Agency.

1.2. Prior to contract start the Contractor shall furnish the Contracting Officer/Contracting Officer’s Representative (CO/COR) with the name, address, and telephone number of an agent who will serve as a liaison between the Contractor and the CO/COR. The agent must have authority to schedule contract services. The agent shall be available by telephone at all times.

1.3. During the last week of each month, the O&M Contractor will provide the Contractor with a tentative flight schedule for the following month. At least 24 hours prior to the scheduled departure time, the O&M Contractor and the Contractor shall mutually agree to the actual flight departure time.

1.4. Contractor uncontrollable delays/diversions. In the event a flight is delayed/diverted because of weather or other uncontrollable factors, a minimum waiting period of four (4) hours is required before a flight can be canceled. The final decision for flight cancellation due to weather rests with the aircraft commander. Canceled flights shall be rescheduled and operated within 24 hours or as mutually agreed between the Contractor and the Operations and Maintenance (O&M) Contractor on the direction of the Government. If the crew must remain overnight (RON) through no fault of the Contractor or at the specific request of the CO/COR or HQ ACC AMIC Det 1 Representative, the Contractor will be reimbursed per diem rates consistent with Treasury Board of Canada, www.tbs-sct.gc.ca. Food and lodging arrangements are the Contractor’s responsibility at the Base of Operations (except for Cambridge Bay and Fox-Main). The Government will reimburse the Contractor in accordance with the contract schedule.

1.5. Flight delays/diversions caused by such events as maintenance and crew problems are considered Contractor controllable delays and shall be at the Contractor’s expense.

1.5.1. The contractor shall maintain a 95% reliability rate computed monthly by subtracting the total number of contractor-controllable delayed departures at the originating and en route stations from the contractor’s total number of scheduled departures and stating this as a percentage of total departures.

1.5.2. A delay shall be deemed to have occurred at the originating or en route station if the contractor’s aircraft departs the blocks more than 20 minutes (120 minutes when the flight was added to the monthly schedule with less than 48 hour notice) after the scheduled departure time, except in those instances when the aircraft arrives at the next scheduled destination on time. Delays at originating and en route stations caused by factors beyond the control and without fault or negligence of the contractor shall be considered as contractor-uncontrollable; a delay for any other reason shall be considered contractor-controllable. Immediately following a delay an Aircraft Unavailability Record (Attachment 2) will be completed. The contractor-uncontrollable delay time experienced at the origination and en route stations on a mission shall be added to the scheduled departure time at the next en route station for purposes of determining the scheduled departure time at that station on that mission. When an aircraft is unavailable for a period of more than 48 hours with no substitution pursuant to FAR 52.212-4, the government’s financial obligation under the appropriate “Basing Fee” CLIN will be reduced by the pro-rated cost directly equal to the number of days that the aircraft was not available.

1.5.3. Failure to maintain a 95% schedule reliability rate will be reason for terminating the contract pursuant to FAR 52.212-4; however, nothing in this paragraph shall limit the right of the Government to terminate this contract for cause for other reasons or to limit any other rights and remedies provided the Government by law or under this contract.

1.5.4. The contractor may refuse any mission for safety reasons. However, missions must be rescheduled and flown as agreed to by NWS O&M Contractor.

1.6. The Contractor will obtain a flight number from the O&M Contractor prior to leaving the base of operations. This flight number will remain unchanged until the aircraft reaches it’s final destination. Note that each trip must be assigned a new flight number (the next number in sequence).

1.7. The type of aircraft will depend on weather, urgency of requirements, estimated time to perform the work, distances to and between sites and absolute limitations of civil twilight. Aircraft performing the “main rotary” and “supplemental” missions must have precision sling capability to the designated point. Aircraft performing the “main rotary” mission will be IFR capable and be crewed by two pilots during the period of 1 Oct - 31 Mar. List of Aircraft (Attachment 3) will be submitted the ACC AMIC/PKB for approval prior to Aircraft being used for mission purposes as well as if there are any updates to aircraft fleet.

1.8. The Contractor shall be required to carry a survival kit and two fire extinguishers on the aircraft.

1.9. The Contractor shall be responsible for the removal from all North Warning System (NWS) sites all hazardous, unused and waste materials owned or generated in the operations of the Contractor owned aircraft. Examples of such materials include, but are not limited to; unserviceable aircraft component and parts, used engine fluids, and any used or unusable petroleum, oil, and lubricants (POL) products.

1.10. The Contractor shall provide a daily flight log (Attachment 5) within 24 hours upon completion of each mission to the NWS O&M Contractor through the Logistic Support Site (LSS) Manager, if possible. Flight Log will include any required per diem, lodging and landing fees. In addition, the contractor shall perform a visual fuel sampling, a clear and bright test, each time NWS fuel is taken and the flight log will be annotated to reflect fuel sampling has been accomplished. If commercial fuel is acquired, then the contractor shall annotate the cost and location of where the fuel was purchased.

1.10.1. On days when there is no mission scheduled and when the scheduled mission cannot be performed due to weather at the distant site, the pilot will, on a weekly basis, report the weather conditions at all the sites within that zone. This applies to the “main rotary” and “supplemental” missions. The contractor will consolidate inputs from the zones and forward a Consolidated Mission Report (Attachment 6) to ACC AMIC Det-1 (NWSO) along with the twice-monthly invoice package.

1.11 PROHIBITED ACTIVITIES

1.11.1. All air carrier employees are prohibited from possessing alcoholic beverages on any North Warning System site.

1.11.2. Weapons are normally prohibited on North Warning Sites. The Contractor must ensure that weapons are secured at all times in a designated area as determined by the O&M Contractor.

1.11.3. Smoking is allowed in designated areas only.

1.12 LIABILITY FOR PERSONAL CARGO

1.12.1. Contractor shall be responsible for the loss and/or damage to the passenger baggage and personal equipment while such items are in his custody or on board his aircraft. Liability for these items is limited to the actual value thereof, not to exceed $2,800.00 US per passenger. In the event it should become necessary to off load passengers at any location or station, other than at the direction of the Contracting Officer, the Contractor shall be responsible for such off loading, passenger care, and safeguarding personal baggage from loss, theft, and/or weather damage, reloading, and all costs incident to such services until such time as the Contractor moves or causes to be moved such passengers to their intended destination or to such other location as directed by the Contracting Officer. The Contracting Officer shall be notified immediately of any off-loading.

1.13 RESPONSIBILITY FOR GOVERNMENT CARGO

1.13.1. To the extent insurance required by this contract is not required for payment of third party claims, the balance of said insurance shall apply to Government cargo loss, damage or destruction thereto. In the event of an accident, the Contractor shall be responsible for providing continuous protection of all cargo aboard the aircraft and for delivery of the cargo to the point designated by the COR or HQ ACC AMIC Detachment 1 personnel.

1.14 FLIGHT SCHEDULE

1.14.1. The North Warning System Operations and Maintenance contractor (NWS O&M) will provide the Contractor with a tentative flight schedule for the following month. The Contractor will coordinate downtime for scheduled maintenance (not to exceed 48 continuous hours without CO/COR, AMIC Det 1 personnel approval) with the LSS manager for inclusion on the monthly schedule. At least 24 hours prior to the scheduled departure time, the O&M Contractor and the airlift contractor shall mutually agree to the actual flight departure time to include flexibility in preparing airlift to other sites in case of inclement weather conditions for the primary scheduled destination. The Contractor shall not initiate any action to perform any work under this contract, which would exceed the contracted amount. The nature of NWS will occasionally require flights to be added to the monthly schedule after publication. The contractor shall have the aircraft positioned and ready to take on passengers or cargo in accordance with this PWS and shall meet all scheduled take-off times. ACC AMIC Det-1 personnel retain the authority to amend any direction given to the contractor by the O&M contractor. CO/COR/AMIC Det-1 representatives reserves’ the right to schedule a flight if deemed it serves the best interests of the USAF/CF for the NWS; this request may supersede any requests made by the NWS O&M contractor and will be coordinated with the NWS O&M contractor and DND within 72 hours prior to the newly scheduled flight departure time.

1.14.2. If a new flight is added to the schedule at anytime, the LSS manager/Contractor must provide 48 hours notification to the airlift contractor and AMIC Det 1.

1.15 MINISTRY OF TRANSPORTATION (Transport Canada)

1.15.1. Following the completion of any Civil Aviation Agency inspection, copies of the inspection report shall be forwarded to the Contracting Officer, HQ ACC AMIC/PKB, 11817 Canon Blvd. Ste. 306, Newport News, VA USA 23606.

2. DELIVERABLES/SERVICE DELIVERY SUMMARY

2.1 DELIVERABLES MANAGEMENT. The Contractor shall provide deliverables as specified in the in Table 1. If a deliverable due date falls on a weekend or holiday, the Contractor shall submit the deliverable on the last work day prior to the due date.

TABLE 1 – DELIVERABLES

2.2 SERVICES SUMMARY (SS): This SS implements AFI 63-138, Acquisition of Services, and identifies critical success factors for the contract. The SS items are listed in the table 2.

2.2.1 PURPOSE. The SS lists performance objectives for the required services the Government will survey. The absence of any contract requirement from the SS shall not detract from its enforceability nor limit the rights or remedies of the Government under any other provision of the contract including the clauses entitled “Inspection of Services” or “Inspection” or “Default” in Section E and Section I of the contract.

2.2.2 Components. The SS states the performance objective (required service), and threshold (performance standard, accept and reject points (if applicable)) in either a qualitative or quantitative fashion for each critical success factor.

2.2.3 Quality Assurance Surveillance Plan. The SS shall be used as the baseline to develop the Government Quality Assurance Surveillance Plan. The Plan shall identify the audit methods and procedures the Government will use to evaluate the Contractor's performance.

2.2.4 RIGHT TO SURVEIL. The Government reserves the right to survey all services and requirements called for in this PWS IAW FAR Part 52.246 to determine whether the Contractor is meeting performance objectives and goals.

TABLE 2 – SERVICES SUMMARY

a) 100% of deliverable requirements are met and received on time

AND

b) critical information is accurate

3 GOVERNMENT FURNISHED PROPERTY AND SERVICES

3.1. The Canadian Government, through the NWS O&M Contractor, shall provide:

3.1.1. 115V electricity and electrical hook-up, at all NWS sites.

3.1.2. Coordination of all hazardous material shipments with the Contractor.

3.1.3. Aviation fuel will be provided at no cost to the airlift Contractor.

3.1.4. Government or O&M contractor personnel will provide the contractor a list of personnel authorized for flight prior to boarding. The contractor shall not permit any unauthorized personnel to board the aircraft.

3.2 FUEL

3.2.1. When fuel is obtained at NWS sites, the Contractor is required to take a fuel sample test and supply results to O&M Contractor. Samples will be taken downstream from aircraft refueling system filter separator unit on a weekly basis or prior to the next refueling operation at any unattended airstrip, including SRR sites designated as refueling locations, depending on frequency of refueling requirement. Results shall include testing for water, particle and fiber. In addition, provide matched weight monitors using a mini-monitor type kit to provide correlation sample for laboratory analysis. Note that laboratory analysis is the responsibility of the NWS O&M Contractor. Contractor shall carry a field test kit or mini-monitor kit to perform the above on-site aviation fuel test per the American Society for Test Material (ASTM). Note: Except for Zone 5 and when operationally preferable, fuel shall be taken from NWS sites whenever available. Missions shall be coordinated between the O&M contractor and the airlift contractor to minimize the use of commercial fuel. ACC AMIC Det-1 personnel may relax or restrict this requirement further based on available cost reimbursable funding at any time.

3.2.2. To obtain fuel from the NWS sites, the Contractor must have a portable refueling pump with dry-break female adapters to accommodate 2 ½ inch, 2 inch, 1 ½ inch and 1 inch Kamvalok or Emco Wheaton pipe fittings provided at helipads and/or other locations, i.e. beach tankage.

3.2.3. The Contractor shall obtain written authorization from National Defence Headquarters, Attn: Director Aerospace and Engineering Project Management (DAEPM), Radar & Communications System (R&CS), MGen George R. Pearkes Building, Ottawa, Ontario K1A 0K2 prior to establishing a fuel “cache” at any NWS sites. The request shall reference applicable contract number.

3.2.4. The aviation fuel currently in use at NWS sites is JET A-1 (A-3) fuel with three additives consisting of a fuel system icing inhibitor (FSII), static dissipater and a corrosion inhibitor. This fuel has a pour point of -52C degrees and has been designated as JET A-1 (A-3). This specification is subject to change, but will be coordinated with the contractor in advance to ensure compatibility.

3.3. Hangar space for maintenance repairs and overnight storage of aircraft is available at Cambridge Bay and Hall Beach LSS sites.

3.4. Food and lodging is provided at Cambridge Bay and Hall Beach for Contractor personnel involved in the performance of this contract. The Contractor is responsible for their toiletries and towels. (Washer and dryers are available.) When operating from Iqaluit, Inuvik, or Goose Bay, food and lodging will be at the Contractor’s expense on a NON-cost reimbursable basis. Food and lodging at all other locations will be at the Contractor’s expense on a cost reimbursable basis by the government when government accommodations are not available.

3.5. Landing Fees (Cost Reimbursable Expense). In the event the Contractor is directed by the CO/COR or HQ ACC AMIC Detachment 1 personnel to stop at a commercial airport, or other points, and is assessed a landing fee, the government will reimburse the Contractor for such landing fees and all en route navigational service charges, provided all receipts are provided.

4 GENERAL INFORMATION

4.1 NOTICE OF ACCIDENTS

4.1.1. DOD Missions. When a Contractor’s aircraft is involved in an accident or incident in support of a DOD mission as defined in 49 CFR, Part 830, the Contractor will transmit the following information by the most expeditious means available, to the Transportation Branch (757-225-2377) at HQ ACC AMIC/PLGT, 11817 Canon Blvd. Ste. 502, Newport News, VA USA 23606. On the next business day, notify the CO at HQ ACC AMIC/PKB (757-225-3913), the COR at HQ ACC AMIC/PLG (757-764-9490) and the HQ ACC AMIC Detachment 1 (819-939-4500/613-296-2149).

4.1.1.1. Carrier and trip number

4.1.1.2. Aircraft type and number

4.1.1.3. Date and time of the accident

4.1.1.4. Last point of departure and point of intended landing of the aircraft.

4.1.1.5. Nature of the accident and the extent of known damage to the aircraft.

4.1.1.6. Total number of crewmembers and passengers on board.

4.1.1.7. Number of injured and fatalities aboard the aircraft.

4.1.1.8. Condition of baggage or government-owned material, if any, on board.

4.1.2. Notice of Accidents - Non - DOD Missions. When a contractor's aircraft is involved in an accident or incident in support of a non-DOD mission, as defined in 49 CFR, Part 830, the contractor will transmit the information in paragraph 4.2.1 above, by the most expeditious means available on the next business day to HQ ACC AMIC/PLGT (757-225-2377), the CO at HQ ACC AMIC/PKB (757-225-3913), the COR at HQ ACC AMIC/PLG (757-764-9490), and the HQ ACC AMIC Detachment 1 (819-939-4924/819-939-4922).

4.1.3. Aircraft Medical Incidents. Report all aircraft medical incidents in flight, or while DOD passengers are under control of the aircraft captain, to HQ ACC AMIC Detachment 1 (819-939-4924/819-939-4922), the CO at HQ ACC AMIC/PKB (757-225-3913), and the COR at HQ ACC AMIC/PLG (757-764-9490) within 48 hours.

4.1.4. DOD Casualties. In cases where a death occurs on a Contractor’s aircraft, the following information shall be furnished via telephone to the numbers listed below: Name, Social Security Number (SSN) and component of service identified as Army-USA, Air Force USAF, Navy-USN, Marine Corps-USMC, or Coast Guard-USCG. The following is a list of phone numbers for service casualty offices:

US Army: (800) 626-3317 US Navy: (800) 368-3202 US Marines: (800) 847-1597 US Air Force: (800) 433-0048 Coast Guard (USCG):

Atlantic Area Op’s Center: (757) 398-6390 (accidents east of Mississippi River) Pacific Area Op’s Center: (510) 437-3701 (accidents west of Mississippi River) A scanned informational copy shall be provided via email to the Transportation Branch (757-225-2377) at HQ ACC AMIC/PLGT at accamic.lg@langley.af.mil.

4.2 INSURANCE

4.2.1. The contractor shall procure and maintain a level of insurance coverage commensurate with the commercial standard and in accordance with the Government of Canada’s statutory limits during the entire period of performance under this contract.

4.3 NOTICE OF POST-AWARD/ PRE-PERFORMANCE CONFERENCE

4.3.1. The Contractor shall attend a Post-Award conference conducted by the CCC with the HQ ACC AMIC Contracting Officer, Contracting Officers Representative and HQ ACC AMIC Detachment 1 personnel in attendance. The Contractor shall be notified of the exact time and location of the conference at least 2 weeks prior to the scheduled conference date. The contractor shall bear all costs associated with attendance of the conference, including travel and per diem.

4.4 PERFORMANCE OF SERVICE DURING CRISIS DECLARED BY THE PRESIDENT OR SECRETARY OF DEFENSE OR OVERSEAS COMBATANT COMMANDER

4.4.1. In the event of a declared crisis, the Contractor is not relieved from the requirements of this contract. The contractor providing services designated as essential by the North Warning System Office (NWSO) or Air Combat Command (ACC) is expected to use all means at its disposal to continue to provide services, in accordance with the terms and conditions of the contract during periods of crisis, or until appropriately released by the contracting officer.

4.4.2. In the event the contractor is contacted by a third party for search and rescue or medical evacuation (SAR/MEDEVAC), the contractor is authorized to provide support, at their discretion, only after clearing the SAR with the appropriate SAR authority in Canada and the O&M contractor (to deconflict with NWS mission requirements). Flying hours and cost reimbursable will be billed to the requesting agency. Basing fee, if applicable, will not be affected while supporting SAR/MEDEVAC. The contractor will notify the CO/COR, or HQ ACC AMIC Det 1 personnel as soon as practical to include details including nature of the event, requesting agency, pickup/drop-off locations.

4.5 INVOICING

4.5.1. Cost Summary Report - The Contractor shall submit a bi-monthly flying/cost summary report containing the following information: (Attachment 2)

4.5.2. Total hours billed on current invoice and copy of flight logs for that period.

4.5.3. Total passengers and a listing of the cargo carried.

4.5.4. Total of reimbursable expenses on current invoices and all applicable receipts.

4.5.5 Contract year to date total of hours/miles and reimbursable expenses expended per CLIN and SUBCLIN and remaining balances per contract.

4.5.6. The contractor shall provide a notice, by CLIN, when 75 % of the estimated quantity or total funded amount has been used. This notice shall be sent via fax or e-mail simultaneously to the HQ ACC AMIC/PKB, CCC, and HQ ACC AMIC/PLGT and HQ ACC AMIC Detachment 1.

4.5.7. Allowable Cost Reimbursable items will be limited to; aviation fuel purchased for the performance of this contract IAW paragraph 3.2. When flights are delayed/diverted to points other than NWS stations, and the crew must remain overnight (RON), the contractor shall be reimbursed for per diem IAW paragraph 1.4. The contractor shall be reimbursed for landing fees or en route navigational service charges IAW paragraph 3.5.

4.6 WEIGHT AND BALANCE OF ALL CARGO LOADS

4.6.1 The airlift contractor shall supervise loading the aircraft and be responsible for proper weight and balance of all cargo loaded on the aircraft. Actual weight shall be used for each mission when transporting passengers and or cargo. Actual weight is defined as interrogated or scaled weight when transporting passengers. Scaled weight shall be used when loading and transporting cargo. An additive weight of 20 lbs. per person may be used for hand carried baggage.

APPENDIX 1

Main Rotary -Wing Airlift

1.0 SPECIFICATIONS FOR HELICOPTER AIRLIFT - INUVIK & CAMBRIDGE BAY

1.1. Cargo and Personnel Movement. The period of performance of this contract is from 1 October to 30 September annually. The Contractor shall provide a rotary wing aircraft equipped with removable and/or foldable passenger seating which provides seating with seat belts for a minimum of eight passengers. The helicopter must also have the capacity of transporting on each flight any combination of passenger(s) and/or cargo totaling a payload minimum of 1,450 pounds; i.e. four passengers weighing 800 pounds and tools and equipment weighing 650 pounds (note, the O&M contractor does not have the authority to demand additional capacity above these minimums). This payload does not include helicopter crewmembers and Contractor equipment required for the performance of this contract. The aircraft shall be capable of transporting the total payload a range of 150 nautical miles nonstop under IFR conditions. The aircraft and crew shall be capable of IFR flight between the periods of 01 October to 15 March, inclusive. The aircraft shall be in compliance with established Canadian Safety requirements and be equipped with tie-down devices to restrain the movement of cargo.

1.2. All flights shall normally originate at either Inuvik or Cambridge Bay; alternatively, flights may originate from BAR-2, PIN-M, PIN-3, CAM-3 to support work projects. Inuvik flights fly to and from, Komokuk Beach (Bar-1), Stokes Point (Bar-B), Shingle Point (Bar-2), Tuktoyuktuk (Bar-3), Storm Hills (Bar-BA3), Liverpool Bay (Bar-DA1), Nicholson Peninsula (Bar-4), Horton River (Bar-E), Cape Parry (Pin-M), Keats Point (Pin-1BD), and Croker River (Pin-1BG) by any combination of routes.

1.3. Cambridge Bay missions fly to Harding River (Pin-2A), Bernard Harbour (Pin-CB), Lady Franklin PT (Pin-3), Edinburgh Island (Pin-DA), Cape Peel West (Pin-EB), Sturt PT North (Cam-A3A), Jenny Lind Island (Cam-1A), Hat Island (Cam-B), Gladman Point (Cam-2), the communities of GJOA Haven (Cam-CB), Shepherd Bay (Cam-3) and Simpson Lake (Cam-D) and Coppermine and return to Cambridge Bay by any combination of routes.

2.0 SPECIFICATIONS FOR HELICOPTER AIRLIFT - IQALUIT, GOOSE BAY, AND HALL BEACH

2.1. Cargo and personnel movement. The Contractor shall provide a rotary wing aircraft equipped with removable and/or foldable passenger seating which provides seating with seat belts for up to eight passengers. The helicopter must also have the capacity of transporting on each flight any combination of passenger(s) and/or cargo totaling a payload of 1,450 pounds; i.e. four passengers weighing 800 pounds and tools and equipment weighing 650 pounds. This payload does not include helicopter crewmembers and Contractor equipment required for the performance of this contract.

2.2. The aircraft shall be capable of transporting the total payload a range of 150 nautical miles, except for Iqaluit which requires 350 nautical miles, nonstop under IFR conditions. The aircraft and crew shall be capable of IFR flight between the periods, 01 October to 15 March, inclusive. The aircraft shall be in compliance with established Canadian Safety requirements and be equipped with tie-down devices to restrain the movement of cargo.

2.3. All flights normally originate at Iqaluit, Goose Bay, or Hall Beach; alternatively, flights may originate from FOX-3, DYE-M, BAF-3, LAB-2, LAB-6 to support work projects. At Iqaluit passengers and cargo move from, to and between Cape Hooper (Fox-4), Broughton Island (Fox-5), Cape Dyer (Dye M), Cape Mercy (Baf-2), Brevoort Island (Baf-3), Loks Land (Baf-4A), Resolution Island (Baf-5), the communities of Pangnirtung and Broughton Island and return to Iqaluit by any combination of routes.

2.4. At Goose Bay passengers and cargo move from, to and between Cape Kakaviak (Lab-1), Saglek (Lab-2), Cape Kiglapait (Lab-3), Big Bay (Lab-4), Tukialik Bay (Lab-5), Cartwright (Lab-6), the communities of Nain, Hopedale and Makovik and return to Goose Bay NFLD by any combination of routes.

2.5. At Hall Beach, passengers and cargo move from, to and between Nadluardjuk Lake (Fox-B), Dewar Lakes (Fox-3), Kangok Fiord (Fox-CA), Pelly Bay (Cam-4), Cape McLoughlin (Cam-5A), Lailor River (Cam-FA), Rowley Island (Fox-1), Bray Island (Fox-A), Longstaff Bluff (Fox-2), including Spence Bay and Pelly Mission and return to Hall Beach by any combination of routes.

APPENDIX 2

ROTARY SUPPLEMENTAL AIRLIFT SERVICES

1.0. AIRCRAFT REQUIREMENTS

1.1. This requirement is for the utilization of two (2) rotary-wing aircraft to be used within all of the North Warning System sites. The Contractor shall provide rotary wing aircraft equipped with removable and/or foldable passenger seating which provides seating with seat belts for up to eight passengers. The helicopters must also have the capacity of transporting on each flight any combination of passenger(s) and/or cargo totaling a payload of 1,450 pounds; i.e. four passengers weighing 800 pounds and tools and equipment weighing 650 pounds. The helicopters shall meet all of the requirements of the Main Rotary except for the IFR and 350 non-stop nautical miles, (the 150 non-stop nautical miles requirement shall apply).

2.0. SITE LOCATIONS

INUVIK (ZONE#1), CAMBRIDGE BAY (ZONE # 2), Hall Beach (ZONE #3), IQALUIT AREA (ZONE #4), and GOOSE BAY (ZONE #5)

2.1. Inuvik and Goose Bay shall be considered as the original point of origin for the start and finish of supplemental rotary operations for this PWS. Inuvik, Hall Beach, Cambridge Bay, Iqaluit and Goose Bay will be considered as the base of operations. Specific basing will be per direction of HQ ACC AMIC Det 1 program manager at NWSO in consultation with DND and the O&M contractor and is subject to change during the period of performance.

2.2. Inuvik missions fly to and from, Komokuk Beach (Bar-1), Stokes Point (Bar-B), Shingle Point (Bar-2), Tuktoyuktuk (Bar-3), Storm Hills (Bar-BA3), Liverpool Bay (Bar-DA1), Nicholson Peninsula (Bar-4), Horton River (Bar-E), Cape Parry (Pin-M), Keats Point (Pin-1BD), and Croker River (Pin-1BG) by any combination of routes. Bar-2, Pin-M upon occasion the community of Paulatuk will be used as staging locations.

2.3. Cambridge Bay missions fly to Harding River (Pin-2A), Bernard Harbour (Pin-CB), Lady Franklin PT (Pin-3), Edinburgh Island (Pin-DA), Cape Peel West (Pin-EB), Sturt PT North (Cam-A3A), Jenny Lind Island (Cam-1A), Cambridge Bay (Cam-M), Hat Island (Cam-B), Gladman Point (Cam-2), Shepherd Bay (Cam-3), Simpson Lake (Cam-D), and the communities of GJOA Haven (Cam-CB), and Coppermine and return to Inuvik by any combination of routes.

2.4. Hall Beach, passengers and cargo move from, to and between Nadluardjuk Lake (Fox-B), Dewar Lakes (Fox-3), Kangok Fiord (Fox-CA), Pelly Bay (Cam-4), Cape McLoughlin (Cam-5A), Lailor River (Cam-FA), Rowley Island (Fox-1), Bray Island (Fox-A), Longstaff Bluff (Fox-2), including Spence Bay and Pelly Mission and return to Hall Beach by any combination of routes.

2.5. Goose Bay passengers and cargo move from, to and between Cape Kakaviak (Lab-1), Saglek (Lab-2), Cape Kiglapait (Lab-3), Big Bay (Lab-4), Tukialik Bay (Lab-5), Cartwright (Lab-6), the communities of Nain, Hopedale and Makkovik and return to Goose Bay by any combination of routes.

2.6. Iqaluit passengers and cargo move from, to and between Cape Hooper (Fox-4), Broughton Island (Fox-5), Cape Dyer (Dye-M), Cape Mercy (Baf-2), Brevoort Island (Baf-3), Loks Land (Baf-4A), Resolution Island (Baf-5) including the community of Pangnirtung, Iqaluit (LSS-Q) and Resolute Bay (Baf-5) and return to Iqaluit by any combination of routes.

3.0. PRIMARY PERIOD OF PERFORMANCE

3.1. The primary period of operation is from 1 June to 30 September annually. The actual performance dates depend on the scheduling, weather and other uncontrollable events. For the primary period of operations, the Contractor must be available to provide service on a 24-hour (12 hour duty day) 7-day per week basis.

APPENDIX 3

Rotary Wing Bulk Fuel Airlift

1.0 SPECIFICATIONS FOR ANNUAL BULK FUEL TRANSFER

1.1. The Contractor shall provide annual Bulk Fuel resupply airlift support to NWS SRR sites using contractor-furnished rotary wing aircraft capable of transporting internal container/bladder, with a minimum of 1,500 liters of fuel per trip. The helicopters shall be equipped with a minimum of two (2) seats with seat belts for the Bulk Fuel technician and laborer who will accompany the crew during resupply operations. The helicopters shall be capable of flying a distance of 150 nautical miles nonstop. The helicopters shall be in compliance with established Canadian safety requirements and be equipped with tie down devices to restrain the movement of cargo. The Contractor shall have sufficient helicopters to perform simultaneous operations at two locations.

1.2. The Bulk Fuel airlift service shall be performed on a continuous basis covering all North Warning System (NWS) SRR sites until resupply of all sites has been completed. The resupply shall normally begin with one aircraft in Zone 1, Inuvik, NWT, and one aircraft in Zone 5, Goose Bay, Labrador. The aircraft work their respective ways toward Zone 3, Hall Beach, NU. Refueling will continue at each SRR site until the transfer quantity is reached. Refueling will then begin at the next SRR site tank listed and continue until the transfer quantity is reached. In case of adverse weather conditions, the aircraft captain and O&M Contractor representative shall mutually select the next site. Extenuating circumstances may require the aircraft to move fuel to LRR sites as directed by the CO/COR or HQ ACC AMIC Det 1 personnel.

1.3. The Contractor shall airlift bulk fuel from designated tanks to the SRR site tanks. Helicopter pads are available at all designated helicopter refueling sites.

1.4. The primary period of operation for this service is 1 April through 30 September of each year. The actual performance dates depend on the scheduling, weather and other uncontrollable events. For the primary period of operations, the Contractor must be available to provide service on a 24-hour (12 hour duty day) 7-day per week basis.

1.5. The Contractor shall provide the following:

1.5.1. The Contractor shall provide a minimum of three (3) each fuel transfer pumps, with a minimum capacity of 190 liters per minute, explosive proof diesel engine with suction and discharge hose and dry-break couplings. One (1) is required at the beach storage tank to pump the fuel into the helicopter fuel transfer tank and the other is required at the summit storage tank to pump fuel from the helicopter fuel transfer tank. One (1) additional pump is required as backup to reduce work stoppage should a pump mechanical failure occur. All dry-break adapters for pump and hoses are required. In-line filtering system is also required. The Contractor shall have a minimum of 50 feet (2 X 25 ft.) of hose to support the beach pumping operation.

1.5.2. The Contractor shall have immediately available sufficient spill response materials and equipment which would allow the initial spill response (containment and initial cleanup) of one full load of fuel being transferred (1,500 liters). Contractor shall submit an Environmental Response Plan to North Warning System Office and the O&M Contractor when performance starts.

1.5.3. The Contractor shall provide a sufficient number of fuel handlers for the refueling operation.

Fuel Tank Locations and Capacities:

Estimated Hours 190

Zone 1 Staging Locations - Tuktoyuktuk and Pin-M. In emergencies only Paulutuk will operate in place of Pin-M

Estimated Hours 370

Zone 2 Staging Locations - Coppermine, Cam-M (LSS-C) and Gjoa Haven. If Pin-3 and Cam-3 is functioning it will operate in place of Gjoa Haven.

Estimated Hours 540

Zone 3 Staging Locations - Gjoa Haven, Pelly Bay (Mission) and Fox-M (LSS-F). If Cam-3 is functioning it will be used in place of Gjoa Haven.

Zone

Type

Site Code

Site Name

Fuel Storage Location

Est. Transfer Qty (Litres)

Est. Distance From Storage to SRR Tank (Miles)

Estimated Hours 180

Zone 4 Staging Locations – If Fox-M (LSS-F), or Fox-3 is functioning, Fox-2 will be used instead of Broughton Island, Pangnirtung and Iqaluit. If Fox-3/Dye-M are functioning, they will be used in place of Broughton Island and Pangnirtung.

Estimated Hours 125

Zone 5 Staging Locations - Nain, Hopedale and Makkovic. If Lab-2 is functioning it will used in place of Nain. If Lab-6 is functioning it can be used for staging.

Note: Using any LRR as a staging location is dependent on the O&M Contractor’s other operations and maintenance activities and will be scheduled accordingly.

APPENDIX 4

APPROXIMATE SITE LOCATIONS