S-100.doc

NZAS 90-6065-4A/B

Attachment 1

FA4626-09-R-0014

SECTION S-100

MEASUREMENT AND PAYMENT

1.

GENERAL

1.1 The following description of work, measurement of pay quantities, and method of payment shall govern payment made to the Contractor under these Special Provisions. The wording “for furnishing all materials, plan, equipment, and labor to complete each item to an acceptable condition, including testing”, is implied to be contained in each item of work described below. The cost of any incidental work or materials required to complete the item, even though not specifically mentioned herein, shall be merged with and become a part of the applicable pay items.

2.

DESCRIPTION OF SCHEDULE ITEMS

0001. Mobilization. Mobilization shall consist of preparatory work incurred before beginning the actual construction on the project sites. There will be only one mobilization paid per LF site.

0002. Security Delays. Security Delays shall be measured per crew-hour; should the Contracting Officer determine that the Contractor incurred a work stoppage or could not begin work as scheduled, and that the stoppage or delay was caused by the Government. The Contractor will be paid per Crew Hour for delays which result in verifiable lost progress at the hourly rate which shall include crew labor and equipment time lost during normal work hours (0745 to 1615) and shall not include evenings, Saturdays, Sundays or Federal Holidays.

0003. Trenching. Includes all work necessary to complete trench excavation for new conduit and service conductors at Launch Facilities based on a maximum trench width of 12 inches. Also includes dewatering, backfill/compaction of trench, hauling in clean sand bedding and wasting excess material by grading it onto site. Trench Excavation will be paid by the Cubic Yard (CY).

0004. Exterior Conduit System. Includes all work necessary to furnish and install 3 inch rigid steel conduit, in trench from Support Building to Meter on service pole at Launch Facilities. Includes waterproof coating, all fittings, offsets, connectors, couplers and elbows. Exterior Conduit System will be paid by the Linear Foot (LF) of conduit installed.

0005. Service Conductors. Includes all work necessary to furnish service conductors and install in conduit system from Main Circuit Breaker in Support Building to Meter on service pole at Launch Facilities. Line item includes 4 #300kcmil conductors per linear foot. Includes terminations, connections, pulling lubricant and testing. Service Conductors will be paid by the Linear Foot (LF).

0006. Interior Conduit System. Includes all work necessary to furnish rigid steel conduit system inside of Support Building from the Main Circuit Breaker, through the exterior wall and into trench for connection to the exterior conduit system. Includes supporting systems, core-drilling, exterior water proof seal, fittings, conduit bodies, connectors, couplers, pull boxes, offsets and elbows. Interior Conduit System will be paid by Lump Sum (LS) per site.

0007. Demolition. Includes all work necessary to demolish existing conduit riser at service pole meter, cut-off, removal, capping, sealing and grouting of existing feeders and conduits at floor and at grade level for permanent abandonment. Demolition will be paid by Lump Sum (LS) per site.

END OF SECTION S-100

MEASUREMENT AND PAYMENT

SECTION S-100-

MALMSTROM AIR FORCE BASE

ATTACHMENT 1

S-100-1