FA461026Q0040_Conformed Through Amend 0001.pdf

This is a Solicitation, Offer, and Award document (Standard Form 1442) for a fixed-price construction contract issued by FA4610 (United States Air Force Installation Contracting Center) for the Department of the Air Force.

The solicitation seeks a contractor to engineer, furnish, install, and test a new 2-inch, 4-inch PVC duct bank installation including one 7-way futureepath innerduct and 48-strand minextend micro fiber cable placed in one of the microducts, with single-mode fiber optical cable along the proposed service route to the encroachment of California Highway 1 (CA-1) including installation under the highway in accordance with the Performance Work Statement (PWS) included in Section J. The work is identified as XUMU 20260001A 15501 FOC Comm Install, with a North American Industry Classification System (NAICS) code of 237130 and a size standard of USD 45,000,000 in annual receipts. This is a 100 percent small business set-aside contract with Product Service Code Z2NZ under a firm fixed-price arrangement. The project is located at Vandenberg Space Force Base, California. Sealed offers are due by 20 August 2026 at 1:30 PM Pacific Standard Time, with a pre-proposal site visit scheduled for 04 August 2026 at 09:30 AM Pacific Time. All requests for information must be submitted by 07 August 2026 at 1:30 PM PST. The contractor must begin performance within 10 calendar days and complete within 180 calendar days after receiving the award or notice to proceed, with a performance period designated as mandatory and negotiable. Performance and payment bonds are required at 10 calendar days. Liquidated damages are assessed at $930.65 per calendar day of delay. The contracting officer is Jeffrey Grelck, and the contract specialist is Shelby Cordts, both at Spaceforce.mil. The inspection and acceptance location is at both the destination (Vandenberg SFB) and the DoDAAC F4D1F3 address in California.