FA2823-13-R-0002.pdf

This acquisition w ill be conducted using competitive 8(a) procedures IAW FAR 19.805 1(a)

For this procurement, it has been determined that competition w ill be limited to 8(a) certif ied f irms serviced by or have an approved bona fide off ice w ithin the geographical boundaries of SBA's Region IV (Alabama, Florida, Georgia, Kentucky, Mississippi, North Carolina, South

Carolina, and Tennessee).

Specif ications - see specif ications dated 1 Dec 12, Attachment #1

SEE SCHEDULE, offeror is required to complete and return SF 1442, Section B through Section K

Faxed or emailed proposals w ill NOT be accepted.

A site visit w ill be held for the f irst task order project (FTFA 12-1030 Demolish Building 1219) and w ill be conducted at 1300 on 08 October

2013, see Section L. Site visits w ill be conducted on individual task orders after aw ard. Questions regarding the f irst task order project are due 1400 on 16 October 2013.

Funds are currently not available for this project. Funding w ill be cited on each individual task order as stated in Section G.

The Magnitude of Construction is betw een $10,000,000 and $25,000,000

The Magnitude of Construction of individual task orders issued hereunder are betw een $2,000 and $2,500,000

KRISTINA B. BRANNON 850-882-3407

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

23-Sep-2013

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______ calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________2 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________23 Oct 2013 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

AFTC/PZIO EGLIN - FA2823

308 WEST D AVENUE, SUITE 130 (BLDG 260)

EGLIN AFB FL 32542-5418

FA2823

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

FA2823-13-R-0002 57

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA2823-13-R-0002

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 12 Months

BASIC YEAR, BUILDING DEMOLITION

FFP

Furnish all plant, labor, materials, and equipment, and perform all operations in connection with Building Demolition (Indefinite Delivery Indefinite Quantity

Contract), Eglin AFB FL in accordance with Specifications dated 1 Dec 12. The applicable wage determination will be cited at the individual task order level.

Liquidated Damages, if assessed, will be assessed at the rate of $186.58 per day

IAW FAR 52.211-12.

SEE SECTION B BID SCHEDULE (CLINS 1001 THROUGH 1033)

The Period of Performance is 21 November 2013 to 20 November 2014.

FOB: Destination

PROJECT: FTFA 13-1010

SIGNAL CODE: A

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

1001 12 Months

OPTION OPTION YEAR 1, BUILDING DEMOLITION

FFP

Furnish all plant, labor, materials, and equipment, and perform all operations in connection with Building Demolition (Indefinite Delivery Indefinite Quantity

Contract), Eglin AFB FL in accordance with Specifications dated 1 Dec 12. The applicable wage determination will be cited at the individual task order level.

Liquidated Damages, if assessed, will be assessed at the rate of $186.58 per day

SEE SECTION B BID SCHEDULE (CLINS 2001 THROUGH 2033)

The Period of Performance is 21 November 2014 to 20 November 2015.

UNIT UNIT PRICE MAX AMOUNT

2001 12 Months

OPTION OPTION YEAR 2, BUILDING DEMOLITION

FFP

Furnish all plant, labor, materials, and equipment, and perform all operations in connection with Building Demolition (Indefinite Delivery Indefinite Quantity

Contract), Eglin AFB FL in accordance with Specifications dated 1 Dec 12. The applicable wage determination will be cited at the individual task order level.

SEE SECTION B BID SCHEDULE (CLINS 3001 THROUGH 3033)

The Period of Performance is 21 November 2015 to 20 November 2016.

UNIT UNIT PRICE MAX AMOUNT

3001 12 Months

OPTION OPTION YEAR 3, BUILDING DEMOLITION

FFP

Furnish all plant, labor, materials, and equipment, and perform all operations in connection with Building Demolition (Indefinite Delivery Indefinite Quantity

Contract), Eglin AFB FL in accordance with Specifications dated 1 Dec 12. The applicable wage determination will be cited at the individual task order level.

SEE SECTION B BID SCHEDULE (CLINS 4001 THROUGH 4033)

The Period of Performance is 21 November 2016 to 20 November 2017.

UNIT UNIT PRICE MAX AMOUNT

4001 12 Months

OPTION OPTION YEAR 4, BUILDING DEMOLITION

FFP

Furnish all plant, labor, materials, and equipment, and perform all operations in connection with Building Demolition (Indefinite Delivery Indefinite Quantity

Contract), Eglin AFB FL in accordance with Specifications dated 1 Dec 12. The applicable wage determination will be cited at the individual task order level.

SEE SECTION B BID SCHEDULE (CLINS 5001 THROUGH 5033)

The Period of Performance is 21 November 2017 to 20 November 2018.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

1001 Destination Government Destination Government

2001 Destination Government Destination Government

3001 Destination Government Destination Government

4001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 365 dys. ADC 12 96 CEG/CEP - F1T2BR

JAMIE WOODY

501 DE LEON ST BLDG 634 STE 100

EGLIN AFB FL 32542

850-883-0256

F1T2BR

1001 730 dys. ADC 12 (SAME AS PREVIOUS LOCATION)

2001 1095 dys. ADC 12 (SAME AS PREVIOUS LOCATION)

3001 1460 dys. ADC 12 (SAME AS PREVIOUS LOCATION)

4001 1825 dys. ADC 12 (SAME AS PREVIOUS LOCATION)

52.211-13 Time Extensions SEP 2000

52.211-18 Variation in Estimated Quantity APR 1984

52.242-14 Suspension of Work APR 1984

52.242-17 Government Delay Of Work APR 1984

52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use within the timeframe specified in the individual task orders. The time stated for completion shall include final cleanup of the premises. The Contracting Officer shall specify either a number of days or a calendar date for completion after the date the contractor receives the notice to proceed.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $186.58 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

Section H - Special Contract Requirements

H-025 INCORPORATION OF SECTION K OCT 1998

Section K of the solicitation is hereby incorporated by reference.

H-800 IMPLEMENTATION OF WARRANTY–CONSTRUCTION JAN 2000

(a) Any manufacturer’s warranties which extend beyond or in addition to the normal one year warranty required by

FAR 52.246-21 shall be furnished to the government in their entirety, including the names of vendors responsible for servicing these warranties.

(b) Prior to final acceptance of the work covered by this contract, the contractor shall furnish in writing to the

Contracting Officer a list of all items of equipment furnished. This list will be accompanied by the applicable warranty documentation. This list shall include;

(i) Nomenclature of the item, type and serial number where applicable, and name and address of the manufacturer.

(ii) Cost

(iii) Period of warranty

(iv) Name, address and telephone number of the subcontractor or supplier

(v) Name, address and telephone number of the servicing agency that will be responsible for the warranty service.

H-801 MEDICAL INFORMATION JAN 2000

The name of the Contractor’s physician(s) and preferred hospital (for use in the event of industrial injury of employees) shall be posted by the Contractor at the site of the work in a prominent place where it can easily be seen by the workers. This information shall also be furnished to the Director of Base Medical Services, 96 MDG/SG, Eglin AFB FL 32542-5300.

H-803 INSPECTION AND SURVEILLANCE JAN 2000

The Director, Civil Engineering, Eglin Air Force Base, Florida, is designated as the representative of the Contracting

Officer for the purpose of surveillance and inspection of performance of work under this contract. This designation does not include authority to direct or authorize the Contractor to make changes in the scope or terms of the contract without the written authority of the Contracting Officer. Contractor shall notify Construction Management Branch, 96 CEG/CEOM, telephone 882-2864, at least 24 hours in advance of the date work will commence under this contract; contractor shall also notify that office at earliest possible time of anticipated absence(s) from the job site.

H-807 ON-BASE PERFORMANCE JAN 2000

(a) Work on this project shall be accomplished during normal hours, which are 7:00 AM to 3:30 PM, Monday through Friday, except Federal holidays. Any work desired to be accomplished during other than the normal hours will require prior approval of the Contracting Officer. The Contractor must submit a written request to the

Contracting Officer.

(b) The Contractor’s performance may be interrupted from time to time because of high priority mission schedules.

For each calendar day and/or portion of a calendar day that the contractor is removed from the job site, the contract schedule will be adjusted by one (1) calendar day.

(c) If building remains occupied throughout construction, special provisions apply as follows: No special provisions identified.

H-810 HURRICANE SEASON JAN 2000

Hurricane season for the state of Florida is normally the period from 01 June through 30 November. During an actual hurricane, tropical storm or tropical depression condition, you may be contacted by the contracting office and requested to secure equipment, clean up your work area and properly protect stored materials. In accordance with the contract clause FAR 52.236-9, ―Protection of Existing Vegetation, Structures, Equipment, Utilities and

Improvements‖ and FAR 52.236-12 ―Cleaning Up,‖ you should keep this in mind and maintain your work area free from debris and in a safe and secure condition at the completion of each work day. A duty is imposed on the

Contractor to monitor local weather conditions, weather bulletins and base closure information in the local media.

The Contractor must contact the Contract Administrator with a report of conditions adversely affecting the construction site.

H-811 CONSTRUCTION PERMITS APR 2009

In accordance with (IAW) FAR 52.236-7, the Contractor shall obtain a construction permit for any construction work on Eglin Air Force Base. An AF Form 103 ―Base Civil Engineering Work Clearance Request‖ must be submitted with all required signatures, to the Contract Inspector prior to beginning of performance on the job site.

No work shall begin until approval of the AF Form 103 has been granted.

H-813 ENVIRONMENTAL INSURANCE REQUIREMENTS JAN 2000

The Contractor shall, at its own expense, provide and maintain insurance during the entire performance period of this contract which specifically provides coverage for environmental damages with a minimum amount of $1,000,000.00 per occurrence.

H-817 UTILITIES JAN 2000

All reasonable required amounts of water and electric power will be made available to the Contractor by the

Government without cost to the Contractor.

H-818 UTILITY OUTAGES JAN 2000

Contractor shall notify the Contracting Officer’s Representative (COR) in writing two weeks prior to any utility outage anticipated during the performance of this contract.

H-819 NO UTILITIES JAN 2000

Power and water are not available at the job site, nor will they be made available by the Government. Contractor is responsible for providing temporary lighting for working at night, portable generators, and portable water.

H-820 SALVAGE MATERIALS JAN 2000

(a) All items of Government property indicated on the drawings or in the specifications to be removed and disposed of by the contractor shall become the property of the contractor and shall be removed promptly from the Eglin AFB

Reservation and legally disposed of EXCEPT items identified on individual task orders issued hereunder.

(b) Contractors are encouraged to recycle salvage materials when possible. Contact the Eglin Recycling Center, 850-882-7744, for assistance.

H-825 ASBESTOS REMOVAL REQUIREMENTS OCT 1992

The contractor shall comply with the applicable requirements of 29 CFR 1910.1001 and 40 CFR 61, Subparts A and

M and with laws, ordinances, rules and regulations of federal, state, and local authorities regarding handling, transporting, and disposing of asbestos waste materials. Where the requirements of this specification and referenced documents vary, the most stringent requirements shall apply.

H-829 HAZARDOUS WASTE REMOVAL JAN 2000

The Contractor shall dispose of all hazardous waste in accordance with all applicable local, federal and state environmental laws and regulations, including but not limited to 40 CFR 260-268, Hazardous Waste Management, and Rule 17-30 Florida Administrative Code. The Contractor shall assume the responsibility of determining what constitutes ―hazardous waste‖ and complying with all environmental laws and regulations governing its removal.

H-837 DAILY REPORT TO INSPECTOR JAN 2000

(a) The Contractor shall submit a Daily Report to 96 CEG/CEOM inspector on AF 4003. The report shall include weather conditions, work accomplished, test accomplished, test reports, delays and discrepancies.

(b) The report to the inspector shall be the original signed by the contractor or his superintendent and turned into 96

CEG/CEOM inspector by 12:00 noon the following work day.

H-841 SUPERINTENDENT (DEC 2012)

Upon notification of award, the Prime Contractor shall identify a superintendent and alternate for this contract and job site. The full name, home address, SSN#, date of birth, state driver’s license #, days/hours of access required, and consent to a background check for security purposes of each such employee shall be required. The Prime Contractor’s superintendent and/or alternate shall be accountable for all individuals allowed onto the installation. The likelihood of a potential employee meeting all security requirements and being granted authorization to access the base should be considered in all hiring and subcontracting decisions. The U.S. Air Force will not be responsible or liable for any costs or delays that a contractor incurs due to a contractor’s employee being denied access to Eglin AFB. The Superintendent and/or alternate shall be responsible for collecting badges/PVC cards from all employees upon completion of the project/contract or termination of service. Prior to final payment approval, the Superintendent shall provide a company letter stating that all Eglin AFB access badges issued in the performance of this contract have been properly turned into the 96 Security Forces Squadron (SFS). This letter must have some type of validation from the 96 SFS badging office employee either by stamp or signature.

H-842 WEATHER DELAYS MAY 2003

The Anticipated Normal Weather Delay Schedule shown below is developed by month for this geographic location using National Oceanic and Atmospheric Administration (NOAA) and similar Weather Averaging System data for the project’s general location. The Government has included additional time in the allowed performance period using this data. (The basic performance period allows seven calendar days for every five-day working days assuming based on working Monday through Friday. The contractor’s progress schedule must take these anticipated adverse weather delays into account in all weather-dependent activities to ensure timely completion of the job.

MONTHLY ANITCIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON A 5-DAY WORKWEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

5 5 5 3 3 5 8 6 5 3 4 5

Upon acknowledgement of Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on his Daily Report (AAC Form 3), the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for fifty percent or more of the Contractor’s scheduled workday and must cause a delay in the work activities critical to contract completion.

In order to obtain relief from contract schedule requirements, the Contractor will have to demonstrate not only that the anticipated amount of weather delay was exceeded by actual weather interruption, but also that reasonable efforts were made to compensate for such excess interruptions through changes in work hours, changes in the planned sequence of work, increased concurrent activities, or other available measures. Contemporaneous documentation of such efforts and prompt coordination thereof with government inspectors is encouraged (see below).

In the event that all reasonable effort to complete the required performance on schedule fail and it is determined that excessive inclement weather was the cause of that failure, the Contractor may request extension of the project performance period for any weather delays suffered because of adverse weather beyond the number day indicated on the chart. The number of workdays of delay added to the schedule shall be converted to calendar days by adding the appropriate number of weekend days associated with that number of workdays.

(1) Adverse weather days will not be granted for other than normal workdays that the Contractor requested to work solely for the Contractor’s convenience to meet the contract performance period.

(2) Any extensions to the contract because of change orders will have the normal adverse weather days figured into the extension period.

(3) If the contract dictates an alternate performance period other than a normal Monday through Friday five-day workweek, an extension will be considered based on the contract requirement for a workday.

Upon the request of the Contractor made within one workweek after the relevant events, the government inspector will review the Contractor’s documentation of weather delays and circumstances relevant to the availability of work-arounds and promptly confirm or dispute the Contractor’s conclusions in writing to the Contractor and the

Contracting Officer. If the Contractor requests an adjustment to the contract schedule based on the government inspector’s review, the contractor shall notify the Contracting Officer in writing and provide relevant information and recommendations regarding the request. The Contracting Officer shall determine whether the request should be promptly granted, deferred pending determination of cumulative weather effects during the contract performance period, denied, or some combination thereof. The reason for any deferral or denial will be simultaneously communicated to the Contractor in writing.

The findings of the Contracting Officer shall be final and conclusive subject to appeal under the Disputes clause.

Upon any extension, the Contractor shall immediately submit to the Contracting Officer a revised progress schedule to meet the revised performance period.

H-846 INSURANCE CLAUSE IMPLEMENTATION MAR 2004

The Contractor shall obtain and maintain the minimum kinds and amounts of insurance during performance of this contract as specified in FAR Sub Part 28.3.

WIDE AREA WORK FLOW DODAAC AND EMAIL DISTRIBUTION TABLE

SF 1449

THE FOLLOWING CODES WILL BE REQUIRED TO ROUTE YOUR INVOICES AND ADDITIONAL

EMAILS CORRECTLY THROUGH WAWF.

Invoice Type: CONSTRUCTION INVOICE

*Contract Number: See Block #1 of the task order award

*Task Order: See Block #2 of the task order award

*Issue Date: See Block #3 of the task order award

*Issue DODAAC: See Block #6 of the task order award

*Admin DODAAC: See Block #7 of the task order award

Inspected By DODAAC/Ext: See Block #14 of the task order award

*Ship To Code/Ext: See Block #14 of the task order award

Ship From Code:

*Pay DODAAC: See Block #15 of the task order award

ADDITIONAL EMAIL NOTIFICATIONS:

1. kristina.brannon@eglin.af.mil

2. kristine.wright@eglin.af.mil

Payments may be expedited electronically via the Internet through the Wide Area Work Flow (WAWF) system.

WAWF may be accessed at https://wawf.eb.mil.

WAWF Training may be accessed online at http://www.wawftraining.com.

Payment information may be accessed using the DFAS website at https://www.dfas.mil. Your purchase order/contract number or invoice will be required to inquire status of your payment.

Section I - Contract Clauses

52.202-1 Definitions JAN 2012

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management JUL 2013

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

DEC 2010

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011

52.215-12 Subcontractor Certified Cost or Pricing Data OCT 2010

52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997

52.215-21 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data--

Modifications

OCT 2010

52.219-8 Utilization of Small Business Concerns JAN 2011

52.219-14 Limitations On Subcontracting NOV 2011

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-5 Davis-Bacon Act--Secondary Site of the Work JUL 2005

52.222-6 Davis Bacon Act JUL 2005

52.222-7 Withholding of Funds FEB 1988

52.222-8 Payrolls and Basic Records JUN 2010

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility FEB 1988

52.222-21 Prohibition Of Segregated Facilities FEB 1999

52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-30 Davis-Bacon Act--Price Adjustment (None or Separately

Specified Method)

DEC 2001

52.222-35 Equal Opportunity for Veterans SEP 2010

52.222-36 Affirmative Action For Workers With Disabilities OCT 2010

52.222-37 Employment Reports on Veterans SEP 2010

52.222-50 Combating Trafficking in Persons FEB 2009

52.222-54 Employment Eligibility Verification JUL 2012

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

DEC 2012

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995

52.228-13 Alternative Payment Protections JUL 2000

52.228-14 Irrevocable Letter of Credit DEC 1999

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes APR 2003

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-17 Interest OCT 2010

52.232-18 Availability Of Funds APR 1984

52.232-23 Assignment Of Claims JAN 1986

52.232-27 Prompt Payment for Construction Contracts OCT 2008

52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.233-1 Disputes JUL 2002

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.243-4 Changes JUN 2007

52.244-5 Competition In Subcontracting DEC 1996

52.244-6 Subcontracts for Commercial Items DEC 2010

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2010

52.249-3 Termination for Convenience of the Government

(Dismantling, Demolition, or Removal of Improvements)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A Central Contractor Registration Alternate A FEB 2013

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.225-7012 Preference For Certain Domestic Commodities DEC 2012

252.227-7033 Rights in Shop Drawings APR 1966

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7005 Airfield Safety Precautions DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items and Commercial

Components (DoD Contracts)

JUN 2012

252.247-7023 Transportation of Supplies by Sea MAY 2002

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.216-18 ORDERING. (OCT 1995)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the Schedule. Such orders may be issued from contract award date through the last day of the last option year exercised by the Contracting Officer.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c) If mailed, a delivery order or task order is considered "issued" when the Government deposits the order in the mail. Orders may be issued orally, by facsimile, or by electronic commerce methods only if authorized in the

Schedule.

52.216-19 ORDER LIMITATIONS. (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $2,000.00, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor:

(1) Any order for a single item in excess of $2,500,000.00;

(2) Any order for a combination of items in excess of $5,000,000.00; or

(3) A series of orders from the same ordering office within 10 days that together call for quantities exceeding the limitation in subparagraph (1) or (2) above.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal

Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the

Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) above.

(d) Notwithstanding paragraphs (b) and (c) above, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 5 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons.

Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and

Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after the performance period specified in each task order issued hereunder.

52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 calendar days before contract expiration.

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30 calendar days before contract expiration; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 calendar days before the contract expires. The preliminary notice does not commit the

Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 5 years and 6 months.

52.219-18 NOTIFICATION OF COMPETITION LIMITED TO ELIGIBLE 8(A) CONCERNS (JUN 2003)--

ALTERNATE I (APR 2005)

(a) Offers are solicited only from small business concerns expressly certified by the Small Business Administration

(SBA) for participation in the SBA's 8(a) Program and which meet the following criteria at the time of submission of offer--

(1) The Offeror is in conformance with the 8(a) support limitation set forth in its approved business plan; and

(2) The Offeror is in conformance with the Business Activity Targets set forth in its approved business plan or any remedial action directed by the SBA.

(3) The offeror's approved business plan is on the file and serviced by .

(b) By submission of its offer, the Offeror certifies that it meets all of the criteria set forth in paragraph (a) of this clause.

(c) Any award resulting from this solicitation will be made to the Small Business Administration, which will subcontract performance to the successful 8(a) offeror selected through the evaluation criteria set forth in this solicitation.

(d)(1) Agreement. A small business concern submitting an offer in its own name shall furnish, in performing the contract, only end items manufactured or produced by small business concerns in the United States or its outlying areas. If this procurement is processed under simplified acquisition procedures and the total amount of this contract does not exceed $25,000, a small business concern may furnish the product of any domestic firm. This paragraph does not apply to construction or service contracts.

(2) The TBD-Name of Contractor will notify the AFTC/PZI (OL-EGLIN) Contracting Officer in writing immediately upon entering an agreement (either oral or written) to transfer all or part of its stock or other ownership interest to any other party.

52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB

2009)

(a) Definitions. ―Commercially available off-the-shelf (COTS) item,‖ ―construction material,‖ ―domestic construction material,‖ and ―foreign construction material,‖ as used in this provision, are defined in the clause of this solicitation entitled ―Buy American Act--Construction Materials‖ (Federal Acquisition Regulation (FAR) clause

52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American Act should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American Act before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the

Buy American Act, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR

52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.225-11 BUY AMERICAN ACT--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (NOV

2012)

(a) Definitions. As used in this clause--

Caribbean Basin country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Netherlands, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan or United Kingdom);

(2) A Free Trade Agreement country (Australia, Bahrain, Canada, Chile, Colombia, Costa Rica, Dominican

Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, East Timor, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Maldives, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra

Leone, Solomon Islands, Somalia, Tanzania, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

(4) A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin

Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St.

Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

Designated country construction material means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean

Basin country construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

Least developed country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

―Free Trade Agreement country construction material‖ means a construction material that—

(1) Is wholly the growth, product, or manufacture of a Free Trade Agreement (FTA) country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a FTA country into a new and different construction material distinct from the materials from which it was transformed.

―Least developed country construction material‖ means a construction material that—

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the

United States means the 50 States, the District of Columbia, and outlying areas.

WTO GPA country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a WTO GPA country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a WTO GPA country into a new and different construction material distinct from the

(b) Construction materials.

(1) This clause implements the Buy American Act (41 U.S.C. chapter 83) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). In addition, the Contracting Officer has determined that the WTO GPA and Free Trade Agreements (FTAs) apply to this acquisition. Therefore, the Buy

American Act restrictions are waived for designated county construction materials.

(2) The Contractor shall use only domestic or designated country construction material in performing this contract, except as provided in paragraphs (b)(3) and (b)(4) of this clause.

(3) The requirement in paragraph (b)(2) of this clause does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

[Contracting Officer to list applicable excepted materials or indicate ``none'']

(4) The Contracting Officer may add other foreign construction material to the list in…