A001_Rainier.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A001 04/16/09 N/A WA NPS ERFO 2009(1)-42(2)

Mount Rainier Emergency Repairs

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

DTFH70-09-R-00019

9B. DATED (SEE ITEM 11)

April 10, 2009

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers (_X _ ) is extended, ( ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

N/A

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

N/A

D OTHER (Specify type of modification and authority) N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

WA FS ERFO 2009(1)-42(2), Mount Rainier Emergency Repairs

See page 2 for revisions

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A001, dated 4/16/09 WA NPS ERFO 2009(1)-42(2) Solicitation No. DTFH70-09-R-00019 Mount Rainier Emergency Repairs

REVISIONS ARE AS FOLLOWS:

SF 1442, SOLICITATION, OFFER, AND AWARD (Pen & Ink change)

Page A-3, Block 13A. Revises proposal due date from 05/12/2009 to 05/20/2009.

SPECIAL NOTICE (Pen & Ink change)

Correct Catworks, LLC phone number by adding the number 3 - (360) 666-1113

NOTICE TO OFFEROR

Page A-1, revises the date to submit questions and revises the dates for the project visits

CONTRACT CLAUSES

Page C-11. Revises, FAR Clause 52.211-10 Commencement, Prosecution, and Completion of Work, Alternate I.

Page C-11. Deletes, FAR Clause 52.211-13 Time Extension.

SPECIAL CONTRACT REQUIREMENTS

Page E-18, Subsection 108.04, subsection title Failure to Complete Work on Time. Deletes the interim liquidated damages.

ENCLOSURES

Pages:

A-1 C-11 E-18

New proposal due date: 05-20-2009

A-1

Notice to Offeror Project: WA NPS ERFO 2009(1)-42(2), Mount Rainier Emergency Repairs

03USC02/25/09

NOTICE TO OFFEROR

I. Project Location.

The project work is located inside of the Mount Rainier National Park. The two project locations are located (1) on the Nisqually-Paradise Road at MP 12.3 (Glacier Hill) and (2) on the Stevens Canyon Road at MP 14.1.

Signs have not been erected to identify the project limits.

Arrangements may be made with Government personnel to review the project site. Contact Eric Walkinshaw at phone number (360) 569-2166 prior to the trip. Meet park staff at the Stevens Canyon Entrance Station at 1:00 PM on 05/5/09 and 05/7/09.

II. Pre-bid Information.

Requests for technical information (Plan and Division 100 –700 Specification questions only) about this project will only be accepted in writing (see Block 9 on page A-5)

REPS & CERTS. Submit or update Representations and Certifications online at http://orca.bpn.gov prior to bid submittal. For more details go to FAR Provision 52.204-8 Annual Representations and Certifications (see page B-2). If you have previously registered on-line and the NAICS code for this solicitation is different than the code listed in your online file, please note the amended changes on the lines provided in FAR 52.204-8.

Joint Venture Agreements are allowable on competitive 8(a) set-asides. However, the joint venture agreement must be received by SBA before the proposal due date and approved before contract award. If you are contemplating a joint venture on this project, you must advise your assigned Business Opportunity Specialist (BOS) as soon as practicable to ensure compliance with established regulations. Any corrections and/or changes needed can be made only when your BOS has adequate time for a thorough review before the proposal due date. NO

CORRECTIONS OR CHANGES ARE ALLOWED AFTER TIME OF SUBMISSION OF

PROPOSAL OR BIDS.

Revised by Amendment A001

TECHNICAL QUESTIONS REGARDING PROPOSED WORK FOR THIS

PROJECT WILL NOT BE ACCEPTED AFTER THE CLOSE-OF-BUSINESS ON

May 15, 2009.

Questions can be submitted and answers viewed by going to project information at http://www.wfl.fha.dot.gov/edi/current.htm

C-11

Contract Clauses WA NPS ERFO 2009(1)-42(2), Mount Rainier Emergency Repairs subcontract, the subcontractor, or its principals, is or is not debarred, suspended, or proposed for debarment by the Federal Government.

(c) A corporate officer or a designee of the Contractor shall notify the Contracting Officer, in writing, before entering into a subcontract with a party that is debarred, suspended, or proposed for debarment (see FAR 9.404 for information on the Excluded Parties List System). The notice must include the following:

(1) The name of the subcontractor.

(2) The Contractor’s knowledge of the reasons for the subcontractor being in the

Excluded Parties List System.

(3) The compelling reason(s) for doing business with the subcontractor notwithstanding its inclusion in the Excluded Parties List System.

(4) The systems and procedures the Contractor has established to ensure that it is fully protecting the Government’s interests when dealing with such subcontractor in view of the specific basis for the party’s debarment, suspension, or proposed debarment.

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984) Alternate I (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than July 31, 2009, subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by June 16, 2009. The completion date will be extended by the number of calendar days after the above date that the contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.211-12 Liquidated Damages—Construction (Sep 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of: See Special Contract Requirements, Subsection 108.04.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Revised by A001

E-18

Special Contract Requirements Project: WA NPS ERFO 2009(1)-42(2), Mount Rainier Emergency Repairs

Liquidated damages in the amount specified in Table 108-1 will be assessed for each calendar day beyond the time specified in FAR Clause 52.211-10 until substantial completion of the work.

Liquidated damages will not be assessed for the following:

(a) The day of the final inspection.

(b) Days required to perform work added to the contract after substantial completion including items identified during the final inspection that were not required before that time.

(c) Delays by the Government after all work is complete and before a formal acceptance is executed.

(d) Periods of time when all work is complete but acceptance is delayed pending the plant establishment period or similar warranty period.

(e) During winter shutdown periods ordered by the CO.

Revised by Amendment A001