DOL121RB20559 New Dormitory and Welcome Center Construction and Demolition of Buildings 12 14 and 15 _Confo.pdf

94-1291-2825 3169

Project Title: CONSTRUCTION OF A NEW DORMITORY AND WELCOME CENTER, AND THE DEMOLITION OF BUILDINGS 12, 14 AN D15 AT THE DETROI T JOB CORPS CENTER IN DETROIT, MI

The work involves construction services of a 296 bed Dormitory Building (approximately 72,000 square feet total), which consists of two wings connected by the Common Areas, and a Welcome Center (480 square feet); as well as the demolition of three (3) storage buildings and the foundation of a fourth building located in the footprint of the new dormitory building. The SOW also includes site improvements such as landscaping and fencing around perimeter of the Center. The extent of work will be described in the Specifications attachments included in the Solicitation.

Detroit Job Corps Center 11801 Woodrow Wilson Street

Detroit, MI 48206 Tel: (313) 852-0300

Scheduled Pre-Bid Conference: Friday, September 7, 2012 at 10:00 AM EDT

Ronette C. McBean, Contract Specialist (202) 693-3702 Kandawaswika Kahari, Detroit Job Corps Center Facilities Manager (313) 852-0336

- This requirement has been set-aside for 100% Service Disabled Veteran Owned Small Businesses

- NAICS code of 236220 for Commercial and Institutional Building Construction

- Building Construction and Small Business Size Standard of $33.5 Million

- Estimated Construction Cost is between $8,000,000 and $14,000,000

- Please Reference Section C for the project’s Specifications and Drawings.

The last day to submit questions to Ronette C. McBean, is Friday, September 14, 2012 at 4:00 PM EDT. Questions will only be accepted via e-mail at the following address: mcbean.ronette@dol.gov

X

1. SOLICITATION NO. 2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12B.) Fourteen (14) Days

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 4-85) STANDARD FORM 1442

Prescribed by GSA YFAR (48 CFR) 52.236-1(d) NSN 7540-01-155-3212

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION, OFFER

AND AWARD x

(Construction, Alteration, or Repair)

SOLICITATION SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

E-MAIL: RONETTE C. MCBEAN mcbean.ronette@dol.gov

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____10______ calendar days and complete it within ____486_____ calendar days after receiving award, notice to proceed. This performance period is X mandatory, negotiable. (See _____________________________.)

YES NO

A. Sealed offers in original and __One (1)__copies to perform the work required are due at the place specified in Item 8 by _2:00 PM EDT__

(hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference

D. Offers providing less than ___90 Days______ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NOTICE: SET-ASIDE for Total SERVICE DISABLED VETERAN OWNED SMALL BUSINESSES

DOL121RB20559

09-01-2012 1 of 88

U.S. Department of Labor ETA/OCM SEE SECTION L Employment and Training Administration Office of Contracts Management 200 Constitution Ave, NW Room N-4643 Washington DC 20210

52.211-10

X

September 27, 2012

X

See Block 7

14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO.

16. REMITTANCE ADDRESS

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS 0001 – Construction of a New Dormitory and Welcome Center and Demolition… $__________________

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20B. SIGNATURE 20C. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY CODE 1630 27. PAYMENT WILL BE MADE BY

28. NEGOTIATED AGREEMENT 29. AWARD Your Contractor agrees offer on this solicitation, is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work, requisitions identified award consummates the contract. which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER

TO SIGN

30B. SIGNATURE 30C. DATE 31B. UNITED STATES OF AMERICA

BY

OFFER

AWARD

STANDARD FORM 1442(REV. 4-85)BACK

(Include ZIP Code) (Include area code)

(Include only if different than Item 14)

(Insert any number equal to or greater than the minimum requirement stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

(Type or print)

(4 copies unless otherwise specified)

(Type or print) Maria J. Pizarro, CPCM CFCM Branch Chief, Contracting Officer

Division of Job Corps Procurement/Job Corps A&E Construction Branch

(Type or print)

(Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror)

(To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

ETA

ETA Payment Office U.S. Department of Labor 200 Constitution Avenue, NW (Suite N-4702)

WASHINGTON DC 20210

Table of Contents

PART I - THE SCHEDULE .......................................................................................................................... A-1

SECTION A - SOLICITATION/CONTRACT FORM ............ .................................................................... A-1

SF 1442 SOLICITATION, OFFER, AND AWARDNOTICE: Total Service Disabled Veteran Owned Small Business SET-ASIDE (Construction, Alteration, or Repair) .......................................................... A-1

SECTION B - SUPPLIES OR SERVICES AND PRICE/COSTS ............................................................... B-1

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK ....................................... C-1

SECTION D - PACKAGING AND MARKING ................. .......................................................................... D-1

SECTION E - INSPECTION AND ACCEPTANCE .................................................................................... E-1

E.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE .................................E-1 E.2 INSPECTION AND ACCEPTANCE ........................................................................................................E-1

SECTION F - DELIVERIES OR PERFORMANCE ....................................................................................F-1

F.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE ................................. F-1

F.2 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

ALTERNATE I (APR 1984) .................................................................................................................. F-1 F.3 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEPT 2000) ............................................... F-1 F.4 TIME EXTENSION (SEPT 2000) ............................................................................................................ F-2 F.5 PERIOD OF PERFORMANCE ................................................................................................................ F-2 F.6 PLACE OF PERFORMANCE ................................................................................................................... F-2 F.7 DELIVERABLE – RELEASABLE COPIES – FREEDOM OF INFORMATION ACT ............................. F-2

SECTION G - CONTRACT ADMINISTRATION DATA .......... ................................................................ G-1

G.1 PRE-CONSTRUCTION CONFERENCE ................................................................................................. G-1 G.2 PERIODIC PROJECT MEETINGS.......................................................................................................... G-1 G.3 SUBCONTRACTS .................................................................................................................................. G-1 G.4 SHOP DRAWINGS ................................................................................................................................. G-1 G.5 OPERATIONS, STORAGE AREAS AND SECURITY ........................................................................... G-2 G.6 PROJECT SAFETY ................................................................................................................................. G-3 G.7 DISPOSAL OF REFUSE ......................................................................................................................... G-3 G.8 CONTRACTOR DAILY PROGRESS LOGS/REPORTS ......................................................................... G-3 G.9 SCHEDULE OF PROGRESS .................................................................................................................. G-3 G.10 INVOICE PREPARATION AND SUBMISION .................................................................................... G-4 G.11 PAYMENT TERMS .............................................................................................................................. G-4 G.12 PAYMENT TO CONTRACTOR ........................................................................................................... G-5 G.13 METHOD OF PAYMENT ..................................................................................................................... G-6 G.14 FURNISHING INFORMATION AND RECORDS ................................................................................ G-6 G.15 WORKERS’ COMPENSATION LAWS ................................................................................................ G-6 G.16 REQUIRED INSURANCE .................................................................................................................... G-7 G.17 EQUITABLE ADJUSTMENTS ............................................................................................................. G-8 G.18 WEATHER DELAYS (EXCUSABLE DELAY) .................................................................................... G-9 G.18.1 ADVERSE AND UNUSUALLY SEVERE WEATHER DELAYS...................................................... G-9

G.19 TEST RESULTS .................................................................................................................................. G-10 G.20 AS-BUILT RECORD OF MATERIALS AND INSTALLATION ........................................................ G-10 G.21 SUBSTANTIAL COMPLETION ......................................................................................................... G-11 G.22 CONTRACT CLOSEOUT ................................................................................................................... G-12

SECTION H - SPECIAL CONTRACT REQUIREMENTS ......... ............................................................... H-1

H.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE ................................ H-1 H.2 COMENCEMENT OF WORK................................................................................................................. H-1 H.3 PROPOSAL PREPARATION COSTS ..................................................................................................... H-1 H.4 DAVIS BACON WAGE DETERMINATION.......................................................................................... H-1 H.5 SUBCONTRACTING RESPONSIBILITIES ........................................................................................... H-2 H.6 NOTICE OF CONSTRUCTIVE CHANGES ............................................................................................ H-2 H.7 ENVIRONMENTAL COMPLIANCE ...................................................................................................... H-2 H.8 INSTALLATION RULES AND REGULATIONS ................................................................................... H-2 H.9 SPECIAL UTILITY PROVISION ............................................................................................................ H-2 H.10 DESIGNATION OF GOVERNMENT INSPECTOR ............................................................................. H-2 H.11 ACCOUNTING AND AUDITING SERVICES ..................................................................................... H-2 H.12 CONTRACT NUMBER IDENTIFICATION ......................................................................................... H-3 H.13 SUBMISSION OF CORRESPONDENCE ............................................................................................. H-3 H.14 OTHER CONTRACTORS ..................................................................................................................... H-3 H.15 LAWS APPLICABLE ............................................................................................................................ H-3 H.16 DISPOSITION OF MATERIAL ............................................................................................................ H-3 H.17 HAZARDOUS OCCUPATION ORDERS ............................................................................................. H-3 H.18 RIGHTS AND OBLIGATIONS ............................................................................................................. H-4 H.19 RESTRICTION ON USE OF DOL FUNDS FOR LOBBYING .............................................................. H-4 H.20 INITIATION OF LIQUIDATED DAMAGES ........................................................................................ H-4 H.21 COMPLIANCE WITH NONDISCRIMINATION AND EQUAL OPPORTUNITY LAWS ................... H-4 H.22 MODIFICATIONS AND CHANGE ORDERS ...................................................................................... H-4

PART II - CONTRACT CLAUSES .............................................................................................................. I-1

SECTION I - CONTRACT CLAUSES ........................................................................................................ I-1

I.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE ................................... I-1 I.2 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (FEB 2012) ............................. I-3

I.3 52.219-27 NOTICE OF SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS SET-

ASIDE (NOV 2011) ................................................................................................................................. I-4 I.4 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2012) .......... I-5

I.5 52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (DEC 2010) ..................................................................................................................................... I-7 I.6 52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (JUL 2012) ................................................... I-8

I.7 52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (JUL 2012) ....................................................................................... I-10 I.8 52.223-3 HAZARDOUS MATERIAL IDENTIFICAITON AND MATEIAL SAFETY DATA (JUL 1995)I-11

I.9 52.225-11 BUY AMERICAN ACT—CONSTRUCTION MATERIALS UNDER TRADE

AGREEMENTS (MAY 2012) ......................................................................................................................... I-12

I.10 52.225-12 NOTICE OF BUY AMERICAN ACT REQUIREMENT—CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (FEB 2009) ......................................................................... I-16

I.11 52.228-1 BID GUARANTEE (SEP 1996) ................................................................................................ I-17 I.12 52.228-15 PERFORMANCE AND PAYMENT BONDS--CONSTRUCTION (OCT 2010) ................... I-18 I.13 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (OCT 2008) ......................... I-19 I.14 52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) ALT I ............ I-25 I.15 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994) .............................................................. I-26 I.16 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) ................................................ I-27

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER AT TACHMENTS .................................. J-1

SECTION J - LIST OF ATTACHMENTS .................................................................................................... J-1

J.1 LIST OF ATTACHMENTS ....................................................................................................................... J-1 J.2 WAGE DETERMINATION ....................................................................................................................... J-3

PART IV - REPRESENTATIONS AND INSTRUCTIONS .......................... K-Error! Bookmark not defined.

SECTION K - REPRESENTATIONS, CERTIFICATIONS AND OT HER STATEMENTS OF

OFFERORS .......................................................................................................................................... K-2

K.1 NOTICE LISTING SOLICITATION PROVISIONS INCORPORATED BY REFERENCE .................... K-2 K.2 52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985) ....................... K-2 K.3 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (APR 2010) ....................... K-3 K.4 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (APR 2011) ..................................... K-5 K.5 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999) ............................. K-8

SECTION L - INSTRUCTIONS, CONDITIONS, AND NOTICES T O OFFERORS ................................ L-1

L.1 NOTICE LISTING SOLICITATION PROVISIONS INCORPORATED BY REFERENCE ......................L-1 L.2 52.216-1 TYPE OF CONTRACT (APR 1984) .........................................................................................L-1

L.3 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999) ................................................L-1 L.4 52.233-2 SERVICE OF PROTEST (SEP 2006) .......................................................................................L-2 L.5 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995) ...........................L-3 L.6 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) .................L-3 L.7 52.252-3 ALTERATIONS IN SOLICITATION (APR 1984) ....................................................................L-3 L.8 52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984) ..................................................L-3 L.9 GENERAL BID PREPARATION INSTRUCTIONS .................................................................................L-3 L.9.1 PRE-PROPOSAL CONFERENCE .........................................................................................................L-4 L.9.2 NOTICE TO OFFERORS .......................................................................................................................L-4 L.9.3 JOINT VENTURE OFFERORS .............................................................................................................L-4 L.9.4 TEAMING/PARTNERING OFFERORS ................................................................................................L-4 L.9.5 INCURRED EXPENSES ........................................................................................................................L-4 L.9.6 CONTRACT FORMS .............................................................................................................................L-5 L.10 BIDS SUBMISSION REQUIREMENTS .................................................................................................L-5 L.11 BID OPENING ADDRESS .....................................................................................................................L-6

SECTION M – AWARD FACTORS ........................................................................................................... M-1

M.1 AWARD FACTORS .............................................................................................................................. M-2

PART I - THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICE/COSTS

PRICE/COST SCHEDULE

ITEM NO SUPPLIES/

SERVICES

QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lump Sum Firm Fixed Price

The Contractor shall provide all supervision, personnel, equipment, transportation, material, and other items and services necessary to perform the construction of the New Dormitory and Welcome Center, and the Demolition of Buildings 12, 14 and 15 at the Detroit Job Corps Center. All work shall be performed in accordance with the specifications and drawings as furnished by the U.S. Department of Labor. No other services other than construction shall be permitted under this contract.

NET AMOUNT

DOL121RB20559 Section C Description/Specifications

C-1

SECTION C - DESCRIPTION/SPECIFICATIONS/DRAWINGS/STA TEMENT OF WORK

CONSTRUCTION SCOPE OF WORK

FOR

THE CONSTRUCTION OF A NEW DORMITORY AND WELCOME CEN TER, AND THE

DEMOLITION OF BUILDINGS 12, 14 AND 15

AT THE

DETROIT JOB CORPS CENTER

DETROIT, MICHIGAN

U.S. DEPARTMENT OF LABOR

SECTION C – DESCRIPTION/SPECIFICATIONS

Any conflicts between the contents of the specification and the terms and conditions of the contract, refer to FAR 52.215- 8 “Order of Precedence – Uniform Contract Format” as incorporated by reference. The drawings and specifications are available for download at the following hyperlink as it appears also within the Federal Business Opportunities website:

http://www.solicitationattachments.com/detroit/

SECTION 00 0110 – TABLE OF CONTENTS

Division ....... Section Title ............................................................................. ...........................................Pages in Specs

PROCUREMENT AND CONTRACTING DOCUMENTS GROUP

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREME NTS

00 0105 ........ Certifications 00 0107 ........ Seals 00 0110 ........ Table of Contents .................... List of Drawings 00 1000 ........ Solicitation Documents

SPECIFICATIONS GROUP

General Requirements Subgroup

DIVISION 01 - GENERAL REQUIREMENTS

01 1000 ........ Summary 01 2900 ........ Payment Procedures 01 3100 ........ Project Management and Coordination 01 3200 ........ Construction Progress Documentation 01 3233 ........ Photographic Documentation 01 3300 ........ Submittal Procedures 01 4000 ........ Quality Control, Testing and Inspection Services 01 4200 ........ References 01 5000 ........ Temporary Facilities and Controls .................... Temporary Project and Directional Signage Sketches 01 6000 ........ Product Requirements 01 7300 ........ Execution 01 7419 ........ Construction Waste Management and Disposal .................... CWM-1 Construction Waste Identification Form .................... CWM-3 Construction Waste Reduction Work Plan Form .................... CWM-5 Cost/Revenue Analysis of Construction Waste Reduction Work Plan Form .................... CWM-7 Construction Waste Reduction Progress Report Form 01 7700 ........ Closeout Procedures 01 7823 ........ Operation and Maintenance Data 01 7839 ........ Project Record Documents 01 7900 ........ Demonstration and Training 01 9113 ........ Commissioning Requirements

Facility Construction Subgroup

DIVISION 02 - EXISTING CONDITIONS

02 3200 ........ Geotechnical Investigations .................... Report of Geotechnical Investigation 02 4116 ........ Structure Demolition 02 4119 ........ Selective Demolition

DIVISION 03 - CONCRETE

03 1516 ........ Post-Installed Anchors 03 3003 ........ Cast-in-Place Concrete 03 4100 ........ Precast Structural Concrete 03 4103 ........ Precast Concrete Wall Panels

DIVISION 04 - MASONRY

04 2000 ........ Unit Masonry 04 4313.13 ... Anchored Stone Masonry Veneer

DIVISION 05 - METALS

05 1200 ........ Structural Steel Framing 05 2100 ........ Steel Joist Framing 05 3000 ........ Steel Decking 05 4000 ........ Cold-Formed Metal Framing 05 5000 ........ Metal Fabrications 05 5100 ........ Metal Stairs 05 5213 ........ Pipe and Tube Railings 05 5300 ........ Metal Gratings 05 7500 ........ Decorative Formed Metal

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 1000 ........ Rough Carpentry 06 1600 ........ Sheathing 06 4023 ........ Interior Architectural Casework

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 1326 ........ Self-adhering Sheet Waterproofing 07 1900 ........ Water Repellents 07 2100 ........ Thermal Insulation 07 2500 ........ Weather Barriers 07 2713 ........ Modified Bituminous Sheet Air Barriers 07 4213.53 ... Metal Soffit Panels 07 5423 ........ Thermoplastic Polyolefin (TPO) Roofing 07 6200 ........ Sheet Metal Flashing and Trim 07 7129 ........ Manufactured Roof Expansion Joints 07 7200 ........ Roof Accessories 07 8413 ........ Penetration Firestopping 07 8446 ........ Fire-resistive Joint Systems 07 9200 ........ Joint Sealants 07 9500 ........ Expansion Control

DIVISION 08 - OPENINGS

08 1113 ........ Hollow Metal Doors and Frames 08 3113 ........ Access Doors and Frames

08 4113 ........ Aluminum-framed Entrances and Storefronts 08 4413 ........ Glazed Aluminum Curtain Walls 08 7100 ........ Door Hardware 08 7400 ........ Access Control System and Hardware 08 8000 ........ Glazing 08 8853 ........ Security Glazing 08 9119 ........ Fixed Louvers

DIVISION 09 - FINISHES

09 2216 ........ Non-structural Metal Framing 09 2900 ........ Gypsum Board 09 3000 ........ Tiling 09 5113 ........ Acoustical Panel Ceilings 09 6513 ........ Resilient Base and Accessories 09 6516 ........ Resilient Sheet Flooring 09 6519 ........ Resilient Tile Flooring 09 6813 ........ Tile Carpeting 09 9113 ........ Exterior Painting 09 9123 ........ Interior Painting 09 9600 ........ High-performance Coatings

DIVISION 10 - SPECIALTIES

10 1100 ........ Visual Display Surfaces 10 1419 ........ Dimensional Letter Signage 10 1423 ........ Panel Signage .................... Interior Panel Sign Schedule 10 2213 ........ Wire Mesh Partitions 10 2600 ........ Wall Protection 10 2800 ........ Toilet, Bath, and Laundry Accessories 10 4413 ........ Fire Extinguisher Cabinets 10 4416 ........ Fire Extinguishers

DIVISION 11 - EQUIPMENT

11 1200 ........ Parking Control Equipment 11 5200 ........ Audio-visual Equipment

DIVISION 12 - FURNISHINGS

NOT APPLICABLE

DIVISION 13 - SPECIAL CONSTRUCTION

NOT APPLICABLE

DIVISION 14 - CONVEYING EQUIPMENT

14 2100 ........ Electric Traction Elevators

Facility Services Subgroup

DIVISION 21 - FIRE SUPPRESSION

211300 ......... Fire Suppression Systems

DIVISION 22 - PLUMBING

22 0000 ........ General Plumbing 22 0500 ........ Common Plumbing Materials and Requirements 22 0700 ........ Plumbing Insulation 22 1116 ........ Plumbing Piping 22 1119 ........ Plumbing Specialties 22 1123 ........ Plumbing Pumps 22 1600 ........ Natural Gas Piping and Specialties 22 3300 ........ Domestic Water Heaters 22 4000 ........ Plumbing Fixtures

DIVISION 23 - HEATING VENTILATING AND AIR CONDITION ING

23 0000 ........ General Mechanical 23 0500 ........ Common HVAC Materials and Requirements 23 0593 ........ HVAC Testing, Adjusting and Balancing 23 0700 ........ HVAC Insulation 23 0800 ........ Commissioning of HVAC Systems 23 0900 ........ Building Management and HVAC Control System 23 0993 ........ Sequence of Operation 23 0997 ........ Variable Frequency Controllers 23 2000 ........ Hydronic Pumps 23 2113 ........ Hydronic Piping and Specialties 23 2500 ........ Hydronic Systems Cleaning and Treatment 23 3113 ........ Metal Ducts 23 3300 ........ Duct Accessories 23 3400 ........ Fans and Ventilators 23 3713 ........ Diffusers, Registers, and Grilles 23 5216 ........ Condensing Boilers and Accessories 23 6500 ........ Fluid Coolers 23 7200 ........ Air-to-Air Energy Recovery Equipment 23 8126 ........ Ductless Split System Heat Pumps 23 8146 ........ Water-Source Heat Pumps 23 8239 ........ Unit Heaters 23 8316 ........ Radiant-Heating Hydronic Piping

DIVISION 26 - ELECTRICAL

26 0500 ........ Common Work Results for Electrical 26 0519 ........ Conductors and Cables 26 0526 ........ Grounding and Bonding 26 0529 ........ Hangers and Supports for Electrical Systems 26 0533 ........ Raceways and Boxes 26 0534 ........ Telecommunications Conduit System 26 0553 ........ Electrical Identification 26 0923 ........ Lighting Control Devices 26 2416 ........ Panelboards 26 2726 ........ Wiring Devices 26 2813 ........ Fuses 26 2816 ........ Enclosed Switches 26 2913 ........ Enclosed Controllers 26 3213 ........ Engine Generator System 26 5100 ........ Interior Lighting 26 5600 ........ Exterior Lighting

DIVISION 27 - COMMUNICATIONS

NOT APPLICABLE

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 0500 ........ Common Work Results for Electronic Safety and Security 28 3111 ........ Digital, Addressable Fire Alarm System

Site and Infrastructure Subgroup

DIVISION 31 - EARTHWORK

31 1000 ........ Site Clearing 31 2000 ........ Earth Moving

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 1216 ........ Asphalt Paving 32 1313 ........ Concrete Paving 32 1373 ........ Concrete Paving Joint Sealants 32 1723 ........ Pavement Markings 32 3113 ........ Chain Link Fences and Gates 32 3119 ........ Decorative Metal Fences and Gates 32 9200 ........ Turf And Grasses

DIVISION 33 - UTILITIES

33 0513 ........ Manholes and Structures 33 1116 ........ Site Water Distribution 33 4000 ........ Storm Drainage 33 4600 ........ Subdrainage

END OF SECTION 00 0110

LIST OF DRAWINGS – VOLUME 1

LS.1 FIRST FLOOR LIFE SAFETY PLAN - DORMITORY

LS.2 SECOND FLOOR LIFE SAFETY PLAN - DORMITORY

C0.1 SITE SURVEY

C0.2 SITE SURVEY

C0.3 SOIL BORING PLAN

C0.4 CONSTRUCTION STAGING PLAN

C0.5 EXISTING CONDITIONS / SITE REMOVALS / DEMOLITION

C0.6 SITE PLAN AND LAYOUT - DORMITORY

C0.7 GRADING PLAN

C0.8 WELCOME CENTER - SITE REMOVALS / SITE PLAN

C0.9 WELCOME CENTER - SITE LAYOUT / GRADING

C0.10 SOIL EROSION PLAN

C0.11 CONSTRUCTION DETAILS

C0.12 CONSTRUCTION DETAILS

C0.13 CONSTRUCTION DETAILS

C1.1 SEWER PLAN - STORM AND SANITARY SEWERS

C1.2 SEWER PLAN - STORM AND SANITARY SEWER PROFILES

C1.3 SEWER AND WATER MAIN REMOVAL

C1.4 WATER MAIN LAYOUT

C1.5 DWSD STANDARDS

C1.6 DWSD STANDARDS

WC-A1.1 WELCOME CENTER - PLANS & SCHEDULES, BUILDING 1D - PLAN AND SECTION

WC-A1.2 WELCOME CENTER - EXTERIOR AND INTERIOR ELEVATIONS

WC-A1.3 WELCOME CENTER - SECTIONS & DETAILS

WC-A1.4 WELCOME CENTER - INTERIOR DETAILS

A1.0 DORMITORY - BASEMENT FLOOR PLAN

A1.1 DORMITORY - FIRST FLOOR PLAN

A1.1A DORMITORY - AREA A - FIRST FLOOR PLAN

A1.1B DORMITORY - AREA B - FIRST FLOOR PLAN

A1.1C DORMITORY - AREA C - FIRST FLOOR PLAN

A1.2 DORMITORY - SECOND FLOOR PLAN

A1.2A DORMITORY - AREA A - SECOND FLOOR PLAN

A1.2B DORMITORY - AREA B - SECOND FLOOR PLAN

A1.2C DORMITORY - AREA C - SECOND FLOOR PLAN

A1.3 TYPICAL UNIT PLANS

A1.4 HONORS DORM PLAN

A1.5 AREA A - FIRST FLOOR CENTRAL AREA PLAN

A1.6 AREA A - SECOND FLOOR CENTRAL AREA PLAN

A1.7 AREA B - FIRST FLOOR CENTRAL AREA PLAN

A1.8 AREA B - SECOND FLOOR CENTRAL AREA PLAN

A2.1 ROOF PLAN

A2.2 ROOF DETAILS

A3.1 DOOR SCHEDULE AREA A

A3.2 DOOR SCHEDULE AREA B AND C

A3.3 WINDOW/CURTAIN WALL ELEVATIONS AND DOOR DETAILS

A3.4 WINDOW AND CURTAIN WALL DETAILS

A4.1 DORMITORY - EXTERIOR ELEVATIONS

A4.2 DORMITORY - EXTERIOR ELEVATIONS

A5.1 BUILDING SECTIONS

A5.2 BUILDING SECTIONS

A5.3 DETAIL SECTIONS

A5.4 STAIR PLANS

A5.5 STAIR SECTIONS

A5.6 STAIR PLANS, SECTIONS AND DETAILS

A6.1 ARCHITECTURAL DETAILS

A6.2 ARCHITECTURAL DETAILS

A6.3 ARCHITECTURAL DETAILS

A6.4 ARCHITECTURAL DETAILS

A7.1 ROOM FINISH SCHEDULE

A7.2 INTERIOR ELEVATIONS

A7.3 INTERIOR ELEVATIONS

A8.1 FIRST FLOOR REFLECTED CEILING PLAN

A8.1A AREA A - FIRST FLOOR REFLECTED CEILING PLAN

A8.1B AREA B - FIRST FLOOR REFLECTED CEILING PLAN

A8.1C AREA C - FIRST FLOOR REFLECTED CEILING PLAN

A8.2 SECOND FLOOR REFLECTED CEILING PLAN

A8.2A AREA A - SECOND FLOOR REFLECTED CEILING PLAN

A8.2B AREA B - SECOND FLOOR REFLECTED CEILING PLAN

A8.2C AREA C - SECOND FLOOR REFLECTED CEILING PLAN

A9.1 FIRST FLOOR - FLOOR FINISH PLAN

A9.1A AREA A - FIRST FLOOR - FLOOR FINISH PLAN

A9.1B AREA B - FIRST FLOOR - FLOOR FINISH PLAN

A9.1C AREA C - FIRST FLOOR - FLOOR FINISH PLAN

A9.2 SECOND FLOOR - FLOOR FINISH PLAN

A9.2A AREA A - SECOND FLOOR - FLOOR FINISH PLAN

A9.2B AREA B - SECOND FLOOR - FLOOR FINISH PLAN

A9.2C AREA C - SECOND FLOOR - FLOOR FINISH PLAN

WC-S1.0 WELCOME CENTER FOUNDATION PLAN, FRAMING PLAN, DETAILS

S0.1 STRUCTURAL NOTES

S1.0A DORMITORY - FOUNDATION PLAN - AREA A

S1.0B DORMITORY - FOUNDATION PLAN - AREA B

S1.0C DORMITORY - FOUNDATION PLAN - AREA C

S1.1 DORMITORY - FIRST FLOOR FRAMING PLANS

S1.2A DORMITORY - SECOND FLOOR FRAMING PLAN - AREA A

S1.2B DORMITORY - SECOND FLOOR FRAMING PLAN - AREA B

S1.2C DORMITORY - SECOND FLOOR FRAMING PLAN - AREA C

S1.3A DORMITORY - ROOF FRAMING PLAN - AREA A

S1.3B DORMITORY - ROOF FRAMING PLAN - AREA B

S1.3C DORMITORY - ROOF FRAMING PLAN - AREA C

S2.1 DORMITORY - FOUNDATION DETAILS

S2.2 DORMITORY - FOUNDATION DETAILS

S2.3 DORMITORY - MASONRY DETAILS

S2.4 DORMITORY - FRAMING DETAILS

S2.5 DORMITORY - FRAMING DETAILS

LIST OF DRAWINGS – VOLUME 2

M0.0 MECHANICAL SYMBOLS, LEGEND AND GENERAL NOTES

MP1.0 WELCOME CENTER AND BUILDINGS 1D/1E - MECHANICAL PLANS

FP1.0 DORMITORY - BASEMENT FLOOR PLAN - FIRE PROTECTION

FP1.1 DORMITORY - FIRST FLOOR PLAN - FIRE PROTECTION

FP1.2 DORMITORY - SECOND FLOOR PLAN - FIRE PROTECTION

P1.0A DORMITORY - AREA A - BELOW FLOOR - PLUMBING

P1.0B DORMITORY - AREA B - BELOW FLOOR - PLUMBING

P1.0C DORMITORY - AREA C - BELOW FLOOR - PLUMBING

P1.1A DORMITORY - AREA A - BASEMENT & FIRST FLOOR - PLUMBING

P1.1B DORMITORY - AREA B - BASEMENT & FIRST FLOOR - PLUMBING

P1.1C DORMITORY - AREA C - FIRST FLOOR - PLUMBING

P1.2A DORMITORY - AREA A - SECOND FLOOR - PLUMBING

P1.2B DORMITORY - AREA B - SECOND FLOOR - PLUMBING

P1.2C DORMITORY - AREA C - SECOND FLOOR - PLUMBING

P2.0 PLUMBING - ENLARGED PLANS

P3.0 PLUMBING - WASTE AND VENT RISERS

P3.1 PLUMBING - WATER AND GAS RISERS

P4.0 PLUMBING - DETAILS

P5.0 PLUMBING - FIXTURE SCHEDULE

M1.1A DORMITORY - AREA A - BASEMENT & FIRST FLOOR PLAN - HVAC

M1.1B DORMITORY - AREA B - BASEMENT & FIRST FLOOR PLAN - HVAC

M1.1C DORMITORY - AREA C - FIRST FLOOR PLAN - HVAC

M1.2A DORMITORY - AREA A - SECOND FLOOR PLAN - HVAC

M1.2B DORMITORY - AREA B - SECOND FLOOR PLAN - HVAC

M1.2C DORMITORY - AREA C - SECOND FLOOR PLAN - HVAC

M2.1A DORMITORY - AREA A - FIRST FLOOR PLANS - HVAC PIPING

M2.1B DORMITORY - AREA B - FIRST FLOOR PLANS - HVAC PIPING

M2.1C DORMITORY - AREA C - FIRST FLOOR PLANS - HVAC PIPING

M2.2A DORMITORY - AREA A - SECOND FLOOR PLAN - HVAC PIPING

M2.2B DORMITORY - AREA B - SECOND FLOOR PLAN - HVAC PIPING

M2.2C DORMITORY - AREA C - SECOND FLOOR PLAN - HVAC PIPING

M3.0 MECHANICAL - SECTIONS

M3.1 MECHANICAL - SECTIONS

M4.0 MECHANICAL - SCHEMATICS

M4.1 MECHANICAL - SCHEMATICS

M4.2 MECHANICAL - DETAILS

M4.3 MECHANICAL - DETAILS

M5.0 MECHANICAL - SCHEDULES

M5.1 MECHANICAL - SCHEDULES

E0.0 ELECTRICAL COORDINATION

ES1.1 ELECTRICAL SITE DEMOLITION PLAN

ES1.2 ELECTRICAL SITE PLANS

E1.0 WELCOME CENTER - ELECTRICAL PLANS

E1.1A DORMITORY - AREA A - BASEMENT & FIRST FLOOR PLAN - LIGHTING

E1.1B DORMITORY - AREA B - BASEMENT & FIRST FLOOR PLAN - LIGHTING

E1.1C DORMITORY - AREA C - FIRST FLOOR PLAN - LIGHTING

E1.2A DORMITORY - AREA A - SECOND FLOOR PLAN - LIGHTING

E1.2B DORMITORY - AREA B - SECOND FLOOR PLAN - LIGHTING

E1.2C DORMITORY - AREA C - SECOND FLOOR PLAN - LIGHTING

E2.1A DORMITORY - AREA A - BASEMENT & FIRST FLOOR PLAN - POWER & SPL. SYS.

E2.1B DORMITORY - AREA B - BASEMENT & FIRST FLOOR PLAN - POWER & SPL. SYS.

E2.1C DORMITORY - AREA C - FIRST FLOOR PLAN - POWER & SPL. SYS.

E2.2A DORMITORY - AREA A - SECOND FLOOR PLAN - POWER & SPL. SYS.

E2.2B DORMITORY - AREA B - SECOND FLOOR PLAN - POWER & SPL. SYS.

E2.2C DORMITORY - AREA C - SECOND FLOOR PLAN - POWER & SPL. SYS.

E3.1 ONE-LINE POWER RISER DIAGRAM

E3.2 ELECTRICAL SERVICE DETAILS

E3.3 FIRE ALARM SYSTEM ONE-LINE DIAGRAM

E4.1 ELECTRICAL SCHEDULES & DETAILS

E4.2 BUILDINGS 1D/1E POWER PLANS

E4.3 ELECTRICAL SCHEDULES & DETAILS

E4.4 ELECTRICAL SCHEDULES & DETAILS

E4.5 ELECTRICAL SCHEDULES & DETAILS

DOL121Rb20559 Section D Packaging and Marking

D-1

SECTION D - PACKAGING AND MARKING

[For this Solicitation, there are NO clauses in this Section]

DOL111RB20559 Section E Inspection and Acceptance

E-1

SECTION E - INSPECTION AND ACCEPTANCE

E.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are hereby incorporated by reference (by Citation Number, Title, and Date) in accordance with the clause at FAR "52.252-2 CLAUSES INCORPORATED BY REFERENCE" in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to the full text of a clause.

NUMBER TITLE DATE

52.246-12 INSPECTION OF CONSTRUCTION AUG 1996

E.2 INSPECTION AND ACCEPTANCE

(a) The Contracting Officer or the Contracting Officer's duly authorized representative will inspect and accept the supplies and/or services to be provided under this contract.

(b) Inspection and acceptance will be performed at:

Detroit Job Corps Center 11801 Woodrow Wilson Street Detroit, Michigan 48206

U.S. Department of Labor National Office of Job Corps Office of Job Corps Attn: William “Bill” Dakshaw 200 Constitution Avenue, NW Room N-4464 Washington, DC 20210

The Government will perform inspections and tests, as may be applicable, in a manner that does not unduly delay the work. All progress inspections shall be documented by the Government to included, but not limited to, a description of the work completed and a determination as to whether or not the work is acceptable. A copy of the inspection report shall be included within the contract file. Based on the progress report, the Contracting Officer shall initiate any needed follow-up actions to ensure that the terms of the contract are being fulfilled.

DOL111RB20559 Section F Deliveries or Performance

F-1

SECTION F - DELIVERIES OR PERFORMANCE

F.1 NOTICE LISTING CONTRACT CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are hereby incorporated by reference (by Citation Number, Title, and Date) in accordance with the clause at FAR "52.252-2 CLAUSES INCORPORATED BY REFERENCE" in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to the full text of a clause.

NUMBER TITLE DATE

52.242-14 SUSPENSION OF WORK APR 1984

52.247-34 F.O.B. DESTINATION NOV 1991

F.2 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

ALTERNATE I (APR 1984)

The Contractor shall be required to

(a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 486 calendar days.* The time stated for completion shall include final cleanup of the premises.

(End of Clause)

F.3 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of (See Below) for each calendar day of delay until the work is completed or accepted.

LIQUIDATED DAMAGES

PART OR STAGE OF THE WORK FOR EACH DAY OF DELAY

$838.61

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

DOL111RB20559 Section F Deliveries or Performance

F-2

F.4 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

F.5 PERIOD OF PERFORMANCE

Substantial completion beneficial occupancy shall be achieved within 426 calendar days following receipt of a notice to proceed. The work under this contract shall be fully complete within 486 calendar days following notice to proceed.

F.6 PLACE OF PERFORMANCE

Detroit Job Corps Center 11801 Woodrow Wilson Street Detroit, Michigan 48206

F.7 DELIVERABLE - RELEASABLE COPIES - FREEDOM OF I NFORMATION ACT

The Freedom of Information Act (FOIA) permits withholding information under several exemptions, including Exemption 4 which protects "trade secrets and commercial or financial information obtained from a person [that is] privileged or confidential," 5 U.S.C. 552(b)(4). Within 5 business days of contract award, the contractor shall provide a statement that the contract is available for full disclosure under the FOIA or provide a scanned PDF of the redacted copy of the contract identifying the specific potions the contractor believes are covered by the particular exemption requested. Any redactions must be fully supported under the FOIA. In the event the Government notifies the contractor that it does not agree with a proposed redaction, the contractor shall have 5 business days to submit additional information to support the requested redaction. For subcontracts, within 5 business days of the contractor's award of any subcontract over $500,000 the contractor shall provide the Government a scanned PDF copy of the subcontract with a statement that the copy is either available for full disclosure, or identifying the specific portions believed to be covered by the particular exemption requested.

Redactions should be limited to those protections provided under the FOIA. Following the procedures above, the Government has the right to notify the contractor of any disagreement with proposed redaction or exemption requests.

DOL121RB20559 Section G Contract Administration Data

G-1

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 PRE-CONSTRUCTION CONFERENCE

A pre-construction conference and an informal partnering (a non-written agreement) session will be held two weeks after approval of performance and payment bonds and insurance in which both meetings will begin at 10:00 a.m. at the Detroit Job Corps Center in Detroit, Michigan. The Notice to Proceed (NTP) will be issued at the pre-construction conference.

The Contractor is required to attend both meetings. Major subcontractors may attend, but may not participate therein other than through the Contractor. As prescribed by FAR 36.212 entitled Preconstruction Orientation, the Contracting Officer will inform the contractor of all significant matters of interest at the pre-construction conference including contractual, administrative, and construction responsibilities and authorities. The conference will also inform the Contractor of procedures and enable them to become familiar with various contract documents and a site visit will follow.

The Contracting Officer and the Contract Specialist will attend the pre-construction conference as Lead Facilitators.

G.2 PERIODIC PROJECT MEETINGS

All progress meetings will be held at a place, method, and time established at the discretion of the Contracting Officer, for the purpose of coordination with the Contractor and status updates of the project. Periodic progress meetings will be scheduled weekly for the duration of construction through substantial completion to discuss work progress, payments, any problems or deficiencies noted during inspection visits, overdue reports, any requests for information (RFIs) or changes (RFCs), and the construction schedule. These meetings shall include the Contracting Officer, Contract Specialist, COR, the A-E and the Engineer Support Contractor (ESC) either in person or telephonically. Meeting minutes resulting from the progress meetings will be prepared and issued by the Project Manager (PM) and furnished immediately to the Contracting Officer and COR after preparation. The minutes will identify at a minimum: (a) topics discussed, (b) critical submittals and status, (c) actions required, responsible parties, and time frames to resolve, (d) progress achieved since last meeting, (e) Quality Control deficiencies and issues, and (f) clear photographs taken by a simple point-and-shoot camera of construction progress. Photographs of progress and/or problems will be furnished via e-mail to the Contracting Officer, Contract Specialist, and COR prior to each meeting or upon their random requests. A copy of the minutes shall be placed in the contract file. In addition, two additional progress meetings may be held as designated by the Contracting Officer;

one during the later part of the project completion and the other during the early part of the close-out phase of the project.

G.3 SUBCONTRACTS

Nothing contained in the contract shall be construed as creating any contractual relationship between any subcontractor and the Government. The divisions or sections of the specifications are not intended to control the Contractor in dividing the work among subcontractors, or to limit the work performed by any trade.

The Contractor shall insert a clause in each subcontract issued under this contract which incorporates all FAR Clauses (beginning with “52”, and all general and special provisions of this contract into the subcontract by reference except that all references to the government or Job Corps shall mean the General Contractor.

The Contractor shall be responsible to the Government for acts and omissions of its own employees and of subcontractors and their employees. The Contractor shall also be responsible for the coordination of the work of the trades, subcontractors, and suppliers.

The Government will not undertake to settle any differences between or among the Contractor, subcontractors or suppliers.

G.4 SHOP DRAWINGS

The contractor shall maintain and submit to the Government as a part of the Close-out documents, a complete set of Shop Drawings as approved by the A/E.

G-2

The Contracting Officer’s representative for the review of shop drawings will be the Design/Architect/Engineer or other representatives determined at the preconstruction conference. If there appears to be a change of scope as the result of a shop drawing review, the Contracting Officer will resolve the matter pursuant to Clause 52.243-7 of the General Provisions.

As prescribed by FAR 52.236-21 entitled Specifications and Drawings for Construction, the Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government’s reasons therefore. Any work done before such approval shall be at the Contractor’s risk.

G.5 OPERATIONS, STORAGE AREAS AND SECURITY

All operations of the Contractor (including storage of materials) upon Government premises shall be confined to areas authorized or approved by the Contracting Officer. The Contractor shall erect whatever barriers or enclosures are necessary to define the site and protect the materials, equipment and work. The Contractor shall hold and save the Government, its officers and agents, and the Center Operating Contractor free and harmless from liability of any nature occasioned by its operations.

The Contractor shall comply with regulations governing the operations on the premises, which are occupied and shall perform the contract in a manner that will not interfere with the conduct of normal business.

All persons employed under this contract shall, while on the premises, observe the regulations in effect at the site, and are cautioned that entrance to any existing building outside the scope of the contract is forbidden, except by official permission.

The Contractor will be doing work on federally-owned or federally-controlled property. All persons employed under this contract, and sub-contracts issued herein under, are to observe security regulations in effect at the site. The Contractor and all persons employed under the contract are required to comply with established security, sign-in, and random search procedures.

All work that will affect or alter the normal operations of the Center is to be coordinated with the operating Contractor of the Center through the Contractor at least one week in advance. If the work requires partial or total interruption of utilities, five days written notice must be given.

The Contractor shall furnish…