B08_Final_Solicitation_Package-08-24-26.pdf

SECTION

15A. NAME AND

ADDRESS

OF OFFEROR

SOLICITATION, OFFER, AND AWARD 1. This Contract is a Rated Order under the Defense Priorities and Allocations System (DPAS) - Code of Federal Regulations - at 15 CFR 700.

RATING PAGE

2. CONTRACT NUMBER 3. SOLICITATION NUMBER 4. TYPE OF SOLICITATION 5. DATE ISSUED 6. REQUISITION/PURCHASE NUMBER

CODE7. ISSUED BY 8. ADDRESS OFFER TO (If other than item 7)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

9. Sealed offers in original and copies for furnishings the supplies or services in the Schedule will be received at the place specified in item 8, or if hand carried, in the depository located in until local time

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision Number 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR

INFORMATION

CALL:

A. NAME B. TELEPHONE (NO COLLECT CALLS)

AREA CODE NUMBER EXTENSION

C. EMAIL ADDRESS

11. TABLE OF CONTENTS

(X) DESCRIPTION PAGE(S) (X) SECTION PAGE(S)DESCRIPTION

A B

C D E F G H

I

J

K

L

M EVALUATION FACTORS FOR AWARD

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND OTHER

STATEMENTS OF OFFERORS

PART IV - REPRESENTATIONS AND INSTRUCTIONS

LIST OF ATTACHMENTS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

CONTRACT CLAUSESSOLICITATION/CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/COSTS

DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

PACKAGING AND MARKING

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

CONTRACT ADMINISTRATION DATA

SPECIAL CONTRACT REQUIREMENTS

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

OFFER (Must be fully completed by offeror)

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause Number 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

10 CALENDAR DAYS (%) 20 CALENDAR DAYS (%) 30 CALENDAR DAYS (%) CALENDAR DAYS (%)

DATEAMENDMENT NUMBERAMENDMENT NUMBER DATE

CODE FACILITY 16. NAME AND THE TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

AREA CODE NUMBER EXTENSION

15C. CHECK IF REMITTANCE ADDRESS IS

DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL OPEN COMPETITION UNDER THE

UNITED STATES CODE AT:

10 U.S.C. 3204(a) ( )41 U.S.C. 3304(a) (

24. ADMINISTERED BY (If other than Item 7)

26. NAME OF CONTRACTING OFFICER (Type or print)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is unusable

23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

25. PAYMENT WILL BE MADE BY

27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

CODE

ITEM

STANDARD FORM 33 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214 (c)

SEALED BID (IFB) INVITATION FOR BID

NEGOTIATED (RFP) REQUEST FOR

PROPOSAL

(Hour) (Date)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

15B. TELEPHONE NUMBER

CODE

OF PAGES

0044054243140P2026B0004 brian_baugh@contractor.nps.go v

Vicki Freese-supler

NPS, DSC Contracting Services Div 1 Denver Federal Center, Building 50 P.O. Box 25287 Denver CO 80225-0287

PDS

1400 MD

Brian Baugh

2 1

09/30/2026

000 000-0000

08/24/2026

1 74

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

140P2026B0004

BRCA 318695 - Rehabilitate Main Water System at

East Creek and Yovimpa, Bryce Canyon National

Park

a) This acquisition is being conducted as a Total Small Business Set-Aside. The North American Industrial Classification System

(NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation.

b) Estimated Price Range: More Than $10,000,000 (note the estimated price range per the allowable ranges in FAR 36.204.)

c) Refer to section "L" for information regarding a pre-bid site visit.

d) Information and requirements stated in sections "B" through "J" & attachments noted in section "J" apply to this solicitation and subsequent contract.

e) Refer to section "L" for bid submittal requirements.

f) Bidders shall submit bids and questions, and acknowledge solicitation amendments as stated in section "L" of this solicitation.

g) All Federal state & local taxes must be included in your proposal; project is not tax exempt.

00010

BASE

Product/Service Code: Z1NE

Product/Service Description: MAINTENANCE

OF WATER

SUPPLY FACILITIES

Date 08/24/2026

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKAGING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING PLATFORM

SYSTEM (FEB 2021)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

SPECIAL REQUIREMENT 2: INVOICE PROCESSING

SPECIAL REQUIREMENT 3: PERFORMANCE OF WORK BY THE CONTRACTOR

(End of Local Clause)

SPECIAL REQUIREMENT 4: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S - INTERMOUNTAIN

REGION (JUN 2009)

SPECIAL REQUIREMENT 5: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE

ITEMS

SPECIAL REQUIREMENT 6: KEY PERSONNEL

CONSTRUCTION CONTRACT ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B)

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.219-14 LIMITATIONS ON SUBCONTRACTING (OCT 2022)

52.222-55 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER 14026.

DEVIATION (DEVATION MAY 2026)

52.222-90 ADDRESSING DEI DISCRIMINATIONBY FEDERAL CONTRACTORS (DEVIATION MAY

2026)

52.223-2 REPORTING OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2024) (DEVIATION FEB 2025)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (DEVIATION

MAY 2026)

52.225-11 BUY AMERICAN – CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (NOV

2023)

52.228-11 INDIVIDUAL SURETY - PLEDGE OF ASSETS (FEB 2021) (DEVIATION MAY 2023)

The Contractor shall obtain from each person acting as an individual surety on a performance bond or a payment bond—

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020) (DEVIATION MAY

2023)

52.236-2 DIFFERING SITE CONDITIONS (DEVIATION JAN 2026)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (DEVIATION JAN 2026) 38

52.236-5 MATERIAL AND WORKMANSHIP (DEVIATION JAN 2026)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (DEVIATION JAN 2026)

52.236-7 PERMITS AND RESPONSIBILITIES (DEVIATION JAN 2026)

52.236-8 OTHER CONTRACTS (DEVIATION JAN 2026)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (DEVIATION JAN 2026)

52.236-10 OPERATIONS AND STORAGE AREAS (DEVIATION JAN 2026)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (DEVIATION JAN 2026)

52.236-12 CLEANING UP (DEVIATION JAN 2026)

52.236-13 ACCIDENT PREVENTION (DEVIATION JAN 2026)

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (DEVIATION JAN 2026)

52.236-17 LAYOUT OF WORK. (DEVIATION JAN 2026)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (DEVIATION JAN 2026)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984) .. 44

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2025)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION

DEVIATION MAY 2026)

52.214-5 FALSE STATEMENTS IN BIDS (APR 1984)

52.214-5 SUBMISSION OF BIDS (DEC 2016)

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

52.214-7 – LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

52.214-31, Facsimile Bids

52.214-12 PREPARATION OF BIDS (APR 1984)

52.214-18 PREPARTION OF BIDS CONSTRUCTION

52.214-19 CONTRACT AWARD-SEALED BIDDING CONSTRUCTION

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (FEB 2024)

52.223-1 BIOBASED PRODUCT CERTIFICATION (DEVIATION MAY2026)(FEB 2025)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

52.216-1 TYPE OF CONTRACT (APR 1984)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

52.228-1 BID GUARANTEE (SEP 1996)

52.228-17 INDIVIDUAL SURETY – PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.232-38 SUBMISSION OF ELECTRONIC FUNDS TRANSFER INFORMATION WITH OFFER (JUL

2013)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996) (DEVIATION)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

SPECIAL INSTRUCTION: BRAND NAME OR EQUAL

SECTION L – INSTRUCTION FOR THE SUBMISSION OF BIDS

SECTION M – BASIS FOR AWARD

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF33) - pages 1- 3 of this package

End of Section A

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION B – BID SCHEDULE

CONTRACT BID SCHEDULE

SOLICITATION NUMBER: 140P2026B0004

PARK - PMIS: BRCA 318695

PROJECT TITLE: Rehabilitate Main Water System at East Creek and Yovimpa

Refer to Section H of the solicitation for additional information regarding contract options.

Contract Price Schedule Template National Park Service (NPS) - Denver Service Center (DSC) | 3-13-18

Notice: Offerors are required to submit, a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars.

Contract Line Item Number

(CLIN)

Contract Line Item (CLI) Title Quantity Unit of Measure Unit Price Total Price

1 CLIN 1 - Raw Water Main from Well House to Water Storage Tanks 1 Lump Sum

2 CLIN 2 - Potable Water Supply to Visitor’s Center (Main Road)

1 Lump Sum

3 CLIN 3 - Potable Water Supply to Lodge Area 1 Lump Sum

4 CLIN 4 - Archeological Monitoring 1 Lump Sum

TOTAL BASE PRICE (Contract Line Item Number 1 through 4) ----------------------------------------------------------------------------

5 OPTION A - Residential Area 1 Lump Sum

6 OPTION B - North Campground 1 Lump Sum

7 OPTION C - Maintenance Yard 1 Lump Sum

8 OPTION D - Site Sanitary 1 Lump Sum

9 OPTION E - Water Storage Tanks 1 Lump Sum

10 OPTION F - Yovimpa Water Demo 1 Lump Sum

11 OPTION G - Mixing Circle Stand Pipe 1 Lump Sum

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item Number 5 through 11) -------------------------------------------------------

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Number 1 through 11) -------------------------

All measurement and payment information is included in Division 01 Specifications Section 01 27 00 Definition of Contract Line Items.

End of Section B

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION C – SPECIFICATIONS / DRAWINGS

The work of this contract is for the construction of: BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa.

This project is located at Bryce Canyon Recreational Area, Utah. The surrounding area is rural with limited staging locations available; the nearest suppliers and lodging facilities are located in St. George or Salt Lake City, UT and will require unique material delivery requirements. The Park will remain open during construction thus contract activities and logistics must be structured and scheduled to minimize visitor impact. The site requires protective measures to ensure the surrounding area remains undisturbed. The anticipated 550 calendar day period of performance includes potential weather shutdown and winter construction may be required.

This project is intended to address deferred maintenance of critical system components of the Bryce Canyon National Park Main Water System. Water line improvements may require rehabilitating or replacing existing lines through either trenchless or open trench methods. This project may also require upgrading water mains, laterals, and service connections in visitor, employee, and administrative areas to ensure adequate water volume is available for future installation of fire suppression systems. Primary project objective will be to rehabilitate and/or replace the raw water line which transmits water from the Park owned and operated wells west of BRCA, to the Park raw water storage tanks. Note that the wells and a portion of the raw water line (approx. 500 linear feet) are on Dixie National Forest land managed by the US Forest Service (USFS). Design and Construction will require coordination with USFS and any access to the wells will need to be coordinated through USFS. The current line has multiple known, and potentially unknown leaks, which need to be repaired. This project will also include installing all new valves along the raw waterline. The current intent is to place the new waterline along the same utility corridor as the existing line.

This project will also include work as follows:

1. Enlarge one of the Park’s raw water storage tanks

2. Address repair of laterals from the potable water supply line to water meters for various buildings

3. Address damaged service connections

4. Rehabilitate and/or replace the Lodge Loop Fire Protection Supply. (This may require increasing the finished water line from 6” to 8” to meets appropriate fire protection flows, to be determined by the A/E).

5. Replace Mission 66 sewer connections

6. Decommission and demolish obsolete assets including the Yovimpa Point Water System

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

End of Section C

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION D – PACKAGING AND MARKING

Section Does Not Apply

End of Section D

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its Subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

End of Section E

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION F – DELIVERIES OR PERFORMANCE

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,420.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

(a)

(1) Within five days after the work commences on the contract or another period of time determined by the

Contracting Officer, the Contractor shall prepare and submit to the Contracting Officer for approval a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the

Contractor contemplates starting and completing the work (including acquiring materials, plant, and equipment).

(2) The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period.

(3) If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall continually update the actual progress in the schedule and shall submit it to the Contracting

Officer by the means prescribed in the contract for transmittals or as directed by the Contracting Officer.

(c)

(1) If the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to recover lost time and execute in accordance with the approved schedule, without additional cost to the Government.

(2) Such steps may include increasing the number of shifts, overtime operations, days of work, and/or the amount of construction plant.

(3) The Contractor shall submit, for approval, supplementary schedule(s) that demonstrate how the lost time will be recovered.

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

(d) If the Contractor does not recover the lost time, the Contracting Officer may determine that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20-days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

End of Section F

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the Contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3-days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30-days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in CPARS for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30-days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60-days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60-calendar days after receipt of the CPAR. On day 15, the evaluation will become available in CPARS marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60-days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the Contractor on (date). The Contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven (7)-days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice) https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.cpars.gov/ https://www.cpars.csd.disa.mil/ https://www.cpars.gov/

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING

PLATFORM SYSTEM (FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP);

2. Completed copy of the Pay Estimate Form (including signed certification of Subcontractor payments);

3. Completed copy of the Limitations on Subcontracting Report

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts;

5. A copy of the current construction schedule (refer to project specification section 013216); and

6. A copy of the current Schedule of Values. (refer to project specification section 013216).

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email Invoice Processing Platform - Contact Us (treasury.gov) or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause)

End of Section G https://www.ipp.gov/ https://www.ipp.gov/ https://www.fiscal.treasury.gov/ipp/contact.html https://www.fiscal.treasury.gov/ipp/contact.html

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 550 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of Local Clause)

SPECIAL REQUIREMENT 2: INVOICE PROCESSING

To ensure the timely and efficient processing of contractor invoices, the contractor is required to submit a draft invoice package, which must include all necessary documentation as specified in the Section G clause titled "Electronic Invoicing and Payment Requirements – Invoice Processing Platform System (FEB 2021)." This draft invoice package should be submitted to the National Park Service Contracting Officer’s Representative (COR) and, if applicable, the Construction Management Representative (CMR) assigned to the contract, at least seven (7) calendar days prior to the intended submission to the Invoice Processing Platform (IPP) system.

Upon receipt of the draft invoice package, the COR will provide a signed cover letter, which the contractor must upload into the IPP system along with their final invoice package.

If the contractor does not receive the signed cover letter from the COR within the specified seven (7) calendar days, the contractor is authorized to proceed with uploading the invoice package, along with the draft invoice review email sent to the COR, into the IPP system for approval, in accordance with the timelines established by the Prompt Payment Act.

(End of Local Clause)

SPECIAL REQUIREMENT 3: PERFORMANCE OF WORK BY THE CONTRACTOR

The Contractor shall perform on the site, and with its own organization, work equivalent to at least thirty (30%) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction, and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of Local Clause)

SPECIAL REQUIREMENT 4: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S -

INTERMOUNTAIN REGION (JUN 2009)

The Contractor is prohibited from utilizing All-Terrain Vehicles (ATV)s on National Park Service lands. ATV is defined as: A motorized off-highway vehicle (OHV) traveling on four or more low-pressure tires, having a seat to be straddled by the operator and a handlebar for steering control.

Use of Utility Terrain Vehicles (UTVs) are permitted. UTV (also called a side-by-side) is defined as: A motorized OHV having four or more low pressure tires, designed with side-by-side seats, seatbelts, steering wheel, and optional cab, brush cage, or ROPS.

(End of Local Clause)

SPECIAL REQUIREMENT 5: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED

LINE ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

Contractor within 90-days after contract award. Performance of added line-item tasks shall be at the price negotiated in the contract Schedule.

(End of clause)

SPECIAL REQUIREMENT 6: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager: ___________________________

Job Site Superintendent: ___________________________

Job Site Quality Control Manager: ______________________

Job Site Safety Manager: ___________________________

(b) During the first 120 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15-calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 120-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15-days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer.

Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15-calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

(End of clause)

CONSTRUCTION CONTRACT ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B).

Federal Acquisition Regulation (FAR) 36.211(b) requires agencies provide description of policies and procedures that apply to definitization of equitable adjustments for change orders under construction contracts and data on the time required to definitize equitable adjustments for change orders under construction contracts. This information can be found at: https://www.doi.gov/pam/acquisition/policy/constructioncontract.

End of Section H https://www.doi.gov/pam/acquisition/policy/constructioncontract

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

Federal Acquisition Regulation: https://www.acquisition.gov/far/ Department of the Interior Acquisition Regulation (CFR, Title 48, Chapter 14): http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (NOV 2021)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (DEVIATION

APRIL 2026)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (DEVIATION APRIL 2026)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (DEVIATION APRIL 2026)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH CONTRACTOR’S

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (DEVIATION MAY 2026)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS

(DEVIATION MAY 2026)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (DEVIATION MAY

2026)

52.210-1 MARKET RESEARCH (DEVIATION JULY 2025)

52.214-26 AUDIT AND RECORDS SEALED BIDDING (JUN 2020)

52.214-27 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA MODIFICATIONS-SEALED

BIDDING (JUN 2020)

52.214-28 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA – MODIFICATIONS-SEALED BIDDING (JUN

2020)

52.214.29 ORDER OF PRECEDENCE (JAN 1986)

52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST AND PRICING DATA (AUG 2011)

52.215-12 SUBCONTRACTOR CERTIFIED COST AND PRICING DATA (JUN 2020)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (DEVIATION JAN 2026)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (DEVIATION JAN 2026)

https://www.acquisition.gov/far/ http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400 http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and Yovimpa, Bryce Canyon National Park

Page

52.219-16 LIQUIDATED DAMAGES—SUBCONTRACTING PLAN (DEVIATION JAN 2026)

52.222-3 CONVICT LABOR (DEVIATION MAY 2026)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION (DEVIATION MAY

2026)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (DEVIATION MAY 2026)

52.222-7 WITHHOLDING OF FUNDS (DEVIATION MAY 2026)

52.222-8 PAYROLLS AND BASIC RECORDS (DEVIATION MAY 2026)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (DEVIATION MAY 2026)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (DEVIATION MAY 2026)

52.222-12 CONTRACT TERMINATION - DEBARMENT (DEVIATION MAY 2026)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIRMENTS AND RELATED REGULATIONS

(MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (DEVIATION MAY 2026)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES (DEVIATION MAY 2026) 52.222-20 CONTRACTS FOR MATERIALS, SUPPLIES, ARTICLES AND EQUIPMENT EXCEEDING $15,000

(DEVIATION MAY 2026)

52.222-32 CONSTRUCTION WAGE RATE REQUIREMENTS – PRICE ADJUSTMENT (ACTUAL METHOD)

(DEVIATION MAY 2026)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (DEVIATION MAY 2026)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (DEVIATION MAY 2026)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (DEVIATION MAY 2026)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEVIATION

MAY 2026)

52.222-50 COMBATING TRAFFICKING IN PERSONS (DEVIATION MAY 2026)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (DEVIATION MAY 2026)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (DEVIATION MAY 2026)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2024)

52.223-7 NOTICE OF RADIOACTIVE MATERIALS (DEVIATION MAY 2026)

52.223-12 MAINTENANCE, SERVICE, REPAIR, OR DISPOSAL OF REFRIGERATION EQUIPMENT AND AIR

CONDITIONERS (DEVIATION MAY 2026)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.226-7 DRUG-FREE WORKPLACE (MAY 2024)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (MAY 2024)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (DEVIATION SEP 2025)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS CONTRACTORS (MAR 2023)

52.233-1 DISPUTES (MAY 2014) – ALTERNATE 1 (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

Solicitation No.

140P2026B0004

National Park Service (NPS) – Denver Service Center (DSC) BRCA 318695 – Rehabilitate Main Water System at East Creek and…