Construction_-_Certificate_as_to_Corporate_Principal.pdf

This is a Certificate as to Corporate Principal form issued by the Greater Orlando Aviation Authority (GOAA) for use in connection with the Airsides 1 & 3 Pond Dredging project (IFB 26-995-IFB, BP-00516) at Orlando International Airport in Florida. The form requires the Secretary of a bidding corporation to certify the authenticity of the company's bid bond, verify the signatory's authority and title, and confirm that the bond was duly executed on behalf of the corporation. Bids are due October 23, 2026 at 2:00 p.m., with a mandatory site visit scheduled for September 24, 2026 at 9:00 a.m. The project scope encompasses sediment removal from four stormwater management ponds in the base bid (approximately 41,500 cubic yards) and three additional ponds in additive alternate 1 (approximately 26,000 cubic yards), along with embankment restoration, effluent piping, pumping setup, and erosion control. Contract duration extends 210 calendar days to substantial completion from Notice to Proceed, plus an additional 60 calendar days for final completion. Committee review is tentatively scheduled for November 17, 2026, with Aviation Authority Board approval anticipated for December 16, 2026.

Bidders must provide proof of bondability and maintain performance and payment bonds equal to the total contract price, along with comprehensive insurance coverage including professional liability ($1 million), commercial general liability ($5 million), automobile liability ($5 million), and pollution liability ($1 million). A combined Local Developing Business (LDB) and Veteran Business Enterprise (VBE) participation goal of 2 percent applies to both the base bid and additive alternate 1. Respondents must demonstrate experience with at least two pond dredging projects of similar size and scope completed within the past five years in the United States. Liquidated damages are assessed at $5,600 per calendar day for delays beyond substantial completion and $2,800 per calendar day for delays beyond final completion. Contractors must comply with FAA Advisory Circular 150/5370-2 and 49 CFR Part 1542 Airport Security standards, develop a Safety Plan Compliance Document, and obtain GOAA identification badges and appropriate security training. Questions regarding the solicitation are due October 12, 2026 at 5:00 p.m. Award is contingent upon receipt of grant funding from the Airport Improvement Program or Passenger Facility Charge Program.