COMBINED SYNOPSIS-SOLN.pdf

RFQ 1305M224Q0313

Page - 1

REQUEST FOR QUOTES (RFQ) 1305M224Q0313, FY 2025 DRYDOCKING AND REPAIRS

TO NOAA SHIP GORDON GUNTER

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format at FAR Subpart 12.6, as supplemented with additional information included in this notice, and is being conducted pursuant to FAR Part 12 and Subpart 13.5. The synopsis/solicitation constitutes an RFQ and incorporates provisions and clauses in effect through Federal Acquisition Circular No. 2024-05 dated 05/22/2024. Should the Government issue an order resulting from this RFQ, it will be a firm fixed-price supply type purchase order in the form of a written offer to the supplier and shall require the supplier’s acceptance by notification to the Government, in writing, as defined at FAR 2.101. THIS ANNOUNCEMENT CONSTITUTES THE ONLY

SOLICITATION; QUOTES ARE BEING REQUESTED AND AN ADDITIONAL

SOLICITATION WILL NOT BE ISSUED.

This requirement is 100% set-aside for small business concerns. The associated North American Industry Classification System (NAICS) code is 336611, Ship Building and Repairing, which has a corresponding size standard of 1,300 employees.

The National Oceanic and Atmospheric Administration (NOAA), Eastern Acquisition Division, 200 Granby Street, Norfolk, Virginia 23510, on behalf of Office of Marine and Aviation Operations (OMAO) is soliciting quotes for FY2025 Intermediate Drydocking and Repairs to NOAA Ship GORDON GUNTER. The contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), and related items and costs necessary to perform all work in accordance with the Statement of Work/Specifications referenced as Attachment I.

The Government anticipates award of all Base Items. Option Items may be exercised by the Contracting Officer at the time of award or at any time during the contract performance period.

The NOAA Ship GORDON GUNTER’s home port is located in Pascagoula, MS. The PLACE OF PERFORMANCE for the work specified herein shall be the CONTRACTOR’s FACILITY.

The ship is not available for a bidder’s ship inspection at this time. However, should the ship’s schedule change, an inspection may be scheduled. Should that occur, the location, time and date will be established and communicated via an amendment to this RFQ. Vendors submitting quotes on this requirement shall prepare their quote based on this RFQ, attachments hereto and reference documents cited. Questions regarding the RFQ documents, attachments and references may be submitted via email in accordance with the information contained in

FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (SEP 2023) ADDENDUM.

Provide the following contract line item numbers (CLINs) in accordance with Attachment

(1) hereto titled "NOAA SHIP GORDON GUNTER FY 25 DRYDOCK REPAIR SPECIFICATIONS (rev. C): CLINs 1000 through 5000. The price proposal shall be completed using the Price Schedule provided at Attachment IV, in accordance with the instructions

Page - 2 provided in FAR Clause 52.212-1 INSTRUCTIONS TO OFFERORS-COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES of this solicitation.

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR: www.acquisition.gov CAR: http://www.ecfr.gov/cgi-bin/text-idx?tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl NAM: http://www.ago.noaa.gov/acquisition/AcqManual/09_part1330-52.html

(End of Clause)

FAR CLAUSE 52.212-4, CONTRACT TERMS AND CONDITIONS—COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES (NOV 2023) applies to this acquisition with the following addenda:

(a) CAR 1352.246-70 PLACE OF ACCEPTANCE (APR 2010)

The Contracting Officer or the duly authorized representative will accept supplies and/or services to be provided under this contract.

The place of acceptance will be on board NOAA Ship GORDON GUNTER at the Contractor’s Facility (TBD)

CAR 1352.271-70 INSPECTION AND MANNER OF DOING WORK (APR 2010)

CAR 1352.201-70 CONTRACTING OFFICER’S AUTHORITY (APR 2010)

CAR 1352.201-72 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (APR 2010)

(a) Mr. Jerrod F. Orians is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Department of Commerce/NOAA 151 Watts Avenue Pascagoula, MS 39567 Phone Number: (240) 472-8512 Email: Jerrod.F.Orians@noaa.gov

(b) The responsibilities and limitations of the COR are as follows:

http://www.acquisition.gov/ http://www.ecfr.gov/cgi-bin/text-idx?tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl http://www.ago.noaa.gov/acquisition/AcqManual/09_part1330-52.html

Page - 3

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

(c) CAR 1352.271-87 CHANGES – SHIP REPAIR (APR 2010)

CAR 1352.271-72 ADDITIONAL ITEM REQUIREMENTS (AIR) - GROWTH WORK

(APR 2010)

(a) This clause applies to Additional Item Requirements (AIR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes - Ship Repair clause or mutually agreed upon by the parties. The contractor shall perform AIR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The AIR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling. The estimated quantity of labor hours and handling fees represent the Government's best estimate for growth that may be required throughout the contract performance period. All growth work shall be paid at the prices stated in the Schedule.

(b) The contractor shall take into account the potential for ordering all estimated AIR quantities in developing the Production Schedule. The ordering of any portion of the AIR quantities does not in itself warrant an extension to the original contract completion date; however, for planning purposes, the Government anticipates ordering AIR in accordance with the following schedule:

(1) No more than 75% of the hours during the first half of the contract period of performance.

(2) No more than 50% of the hours during the third quarter of the contract period of performance.

(3) No more than 30% of the hours during the fourth quarter of the contract period of performance.

(c) The AIR labor rate shall be a flat, hourly rate to cover the entire effort and shall be burdened to include:

Page - 4

(1) Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production: Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging.

(2) Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include: Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire Watch, General Labor (including general support of journeyman tasks), Cleaning (including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making).

(d) Additional Item Requirements do not include replacement work performed pursuant to the Inspection and Manner of Doing Work or Guarantees clauses.

(e) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(f) The contractor shall submit to the Contracting Officer the following information in all AIR proposals:

(1) Number of labor hours estimated; broken down by specific direct production labor category.

(2) Material estimates, individually broken out and priced. When requested by the Contracting Officer, material quotes shall be provided.

Page - 5

(3) Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer.

(4) Material/subcontractor handling fee and the basis for the fee.

(g) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

(End of clause)

CAR 52.271-85 DOCUMENTATION OF REQUESTS FOR EQUITABLE

ADJUSTMENTS (APR 2010)

(f) FAR 52.242-15 STOP-WORK ORDER (AUG 1989)

FAR 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

(g) and (i) NAM 1330-52.232.71 ELECTRONIC SUBMISSION OF PAYMENT

REQUESTS (FEB 2023)

The Contractor must submit payment requests electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP). The Contractor must use the IPP website to register, access, and submit payment requests. The IPP website address is https://www.ipp.gov.

"Payment request" means any request for contract financing payment or invoice payment to the Contractor. To be considered proper, invoices must be prepared in accordance with, and contain all elements specified in, the contract payment clause (e.g., FAR 52.212-4(g), FAR 52.232- 25(a)(3), FAR 52.232-26(a)(2), FAR 52.232-27(a)(2)).

The Contractor must include the following documents as attachments to payment requests submitted through the IPP: None

If the Contractor is unable to comply with the requirement to submit payment requests through the IPP due to a threat to national security; a matter of unusual or compelling urgency; or because the political, financial, or communications infrastructure of a foreign country does not support access to the IPP, the Contractor must request an exception in writing. Contact the Contracting Officer for more information about requesting an exception.

For informational purposes: When submitting an invoice to the IPP portal, the contractor shall simultaneously submit an electronic copy of invoices to the Technical Point of Contact (TPOC) Port Engineer Mr. Steve Spindler, Email stephen.spindler@noaa.gov and to Contract Specialist Michelle Blake, Email michelle.blake@noaa.gov. However, for Prompt Payment https://www.ipp.gov/ mailto:stephen.spindler@noaa.gov mailto:michelle.blake@noaa.gov

Page - 6

ACT purposes, the original invoice is considered to be the invoice that is submitted by the contractor to the IPP portal.

(End of solicitation and contract language)

(j) FAR 52.247-34 F.O.B. DESTINATION (JAN 1991)

CAR 1352.271-79 LIABILITY AND INSURANCE (APR 2010)

CAR 1352.271-90 INSURANCE REQUIREMENTS (APR 2010)

(a) The contractor shall procure and thereafter maintain the following insurance:

(1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271-79. This insurance shall be for $1,000,000.00.

(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.

(3) Full coverage in accordance with the State Worker's Compensation law; and

(4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act.

(b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number (to be provided at the time of award) for repair/alteration of NOAA SHIP GORDON GUNTER in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (date) and that each such policy contains the following clause:

"It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer."

(End of clause)

(m) FAR 52.211-11 LIQUIDATED DAMAGES – SUPPLIES, SERVICES OR

RESEARCH AND DEVELOPMENT (SEP 2000)

Page - 7

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $16,358.66 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(o) CAR 1352.271-88 GUARANTEES (APR 2010)

(a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 90 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 90-day period until its expiration.

(c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item.

(d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs.

(1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense.

(2) Where corrections and repairs are to be made by other than the contractor due to nonreturn of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract.

(e) The contractor's liability shall only extend for an additional 90-day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and Insurance clause.

(f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable

Page - 8 deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

(g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause.

(End of clause)

(q) CAR 1352.209-73 COMPLIANCE WITH THE LAWS (APR 2010)

(r) CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

(w) FAR 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (MAR 2023)

(x) FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

(y) NOTICE OF POST-GOVERNMENT EMPLOYMENT RESTRICTIONS (OCT 2015)

By submission of an offer in response to a NOAA solicitation or acceptance of a contract, the contractor acknowledges the restriction on current NOAA employees regarding contact with offerors regarding prospective employment and the corresponding obligations for contractors who engage them. The contractor further acknowledges that it has provided notice to former NOAA employees who will provide service to NOAA under the contract of post-Government employment restrictions that apply to them. Such restrictions include, but are not limited to, those set forth in:

(a) 41 U.S.C. § 2103 regarding contacts between a federal employee working on a procurement and an offeror about prospective employment;

(b) 18 U.S.C. § 207 regarding the restrictions on former federal employees having contact with a federal agency on behalf of another person or entity concerning a specific party matter with which the former employee was involved as a federal employee or for which the former federal employee had official responsibility;

(c) 18 U.S.C. § 207 regarding the restrictions on former senior employees and senior political employees from having contact with his former federal agency on behalf of another person or entity concerning any official matter; and

(d) 41 U.S.C. § 2104 regarding the restrictions on a former federal employee involved in an acquisition over $10,000,000 from accepting compensation from a contractor.

Page - 9

(End of Clause)

(z) NOAA/AGO SCHEDULE OF DELIVERABLES:

ITEM DESCRIPTION QTY DUE DATE

DELIVER

TO REFERENCE

1 Insurance Certificate

1 Within 2 days of contract award

See Block #7 of SF33

CAR 1352.271-79 and

CAR 1352.271-90

Specification

Deliverables (List Not Inclusive)

Various See Specification COR Specification

(End of clause)

(aa) CAR 1352.270-70 PERIOD OF PERFORMANCE (APR 2010)

(a) The period of performance for work to be conducted on board NOAA ship GORDON GUNTER will be seventy-nine (79) calendar days, beginning on or about December 9, 2024 with a planned completion date of February 26, 2025, not including the ship’s transit time from its homeport in Pascagoula, MS to and from the contractor’s facility. No work to be accomplished on board the GORDON GUNTER may be performed on the following dates unless requested in advance and specifically approved in writing by the COR: December 24, 25, and 31 of 2024 and January 1, 2025. Once the contract has been awarded, and the Insurance Certificate has been received in accordance with NAM 1330-52.215-70 SCHEDULE OF DELIVERABLES, the Contracting Officer may issue a notice to proceed (NTP) prior to the period of performance start date for work on board the ship. The NTP authorizes the contractor to start ordering materials, aligning resources, etc., to prepare for the anticipated start date for work on board the vessel.

(b) The NTP may be issued orally, by e-mail, or in writing by the Contracting Officer after receipt of the Contractor's insurance certificate. In no event will a delay in providing insurance certificate constitute a waiver of the completion date. Oral notification will be confirmed in writing by the Contracting Officer.

(ab) CAR 1352.271-73 SCHEDULE OF WORK (APR 2010)

(a) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within one (1) working day of the vessel's arrival at the contractor's facility:

(1) Production Schedule

(2) Work Package Network

(3) Total Manpower Loading Curve

(4) Trade Manning Curves

(5) Subcontracting List

Page - 10

(b) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(c) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than five (5) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR.

(d) Any unauthorized deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance, including, but not limited to, liquidated damages.

(ac) CAR 1352.271-75 DELIVERY AND SHIFTING OF THE VESSEL (APR 2010)

(a) The Government shall deliver the vessel to the contractor, at the location specified in the contract.

(b) Whether the specified location of performance is the contractor's own facility or any other authorized facility, it shall be understood to mean the fairway of the facility. The contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock, and, upon completion of all work, from the pier or dock to the fairway of the facility.

(c) While the vessel is in the possession of the contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the contractor without additional charge to the Government.

(ad) CAR 1352.271-76 PERFORMANCE (APR 2010)

(a) The contractor shall not commence work until a notice to proceed has been issued by the Contracting Officer.

(b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract.

(c) Without additional charge to the Government, and without specific requirement in the contract, the contractor shall:

• Make available, at the facility, to personnel of the vessel while in drydock or on a marine railway, sanitary facilities adequate for the number of personnel using them and acceptable to the Contracting Officer;

Page - 11

• Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to the vessel;

• Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and

• Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for personnel designated by the Government.

(d) Except as otherwise provided in the contract, the contractor shall furnish all necessary material, labor, supervision, services, equipment, tools, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work.

(e) The contractor shall conduct dock and sea trials of the vessel as required by the contract.

Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the contractor and the Government on board to determine whether the work provided by the contractor has been satisfactorily performed. Dock and sea trials not specified which the contractor requires for its own benefit shall not be undertaken by the contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the contractor. The contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials.

(End of clause)

(ae) FAR 52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED

LINE ITEM (MAR 1989)

The Government requires the delivery of the numbered line items, identified in the Schedule as an option item in the quantity and at the price stated in the Schedule. The option quantities shown in Section B are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract period of performance. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of the essence initial notification will be provided verbally followed within 24 hours by a facsimile or e-mail of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at time of award, during the contract period of performance or within six months after the date of award. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, no later than 24 hours thereafter, unless proper sequencing of

Page - 12 the work requires a delay in beginning performance of the option. In that case, the option CLIN shall be commenced as soon as proper sequencing permits. The exercise of any option item during the contract period of performance will not normally extend the contract performance period. The government shall give the contractor 30 days notice prior to exercising an option after the contract period of performance and within the six months after the date of award.

(End of Clause)

(af) CAR 1352.245-70 GOVERNMENT FURNISHED PROPERTY (APR 2010)

The Government will provide the following item(s) of Government property to the Contractor.

The contractor shall be accountable for, and have stewardship of, the property in the performance of this contract. This property shall be used and maintained by the contractor in accordance with provisions of the "Government Property" clause included in this contract.

Work Item Description Qty Unit Value

3.4.2 Sponson 1 EA $45,000/$45,000

3.7.2 ABT/UPS Components 1 LO $4,450/$4,450

3.8.2 Turning equipment 1 LO $65,000/$65,000

3.34.2.1 Main Propulsion Motor Brush Sets 2 EA $1,250/$2,500

3.34.2.2 Turning Motor, Jackshaft, Driven Pulley, 1 LO $43,000/$43,000 Belt, Misc. Drive Gear

3.46.2 Carrier Transicold 90RMC050-D-6 AC 3 EA $250,000/$750,000 Chilled Water Unit with regulator Valves

3.47.2 Bulwark Sections 2 EA $125,000/$250,000

3.48.2 Var. Items per 3.48.2.1, 3.48.2.2 1 LO $45,000/$45,000 and 3.48.3.3

(End of Clause)

(ag) FAR 52.203-3 GRATUITIES (APR 1984)

(ah) CAR 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010)

(ai) NAM 1330-52.270-304 NOAA ACQUISITION AND GRANTS OFFICE

OMBUDSMAN (OCT 2016)

(a) The NOAA Acquisition and Grants Office (AGO) Ombudsman is available to organizations to promote responsible and meaningful exchanges of information.

Generally, the purpose of these exchanges will be to:

1. Allow contractors to better prepare for and propose on business opportunities.

2. Advise as to technologies and solutions within the marketplace that the

Page - 13

Government may not be aware of, or is not fully benefiting

3. Identify constraints in transparency

(b) The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her.

Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA.

(aj) FAR 52.232-18 AVAILABILITY OF FUNDS (APR 1984)

(ak) NAM 1330-52.203-71 NOTICE OF POST-GOVERNMENT EMPLOYMENT

RESTRICTIONS (OCT 2015)

By submission of an offer in response to a NOAA solicitation or acceptance of a contract, the contractor acknowledges the restriction on current NOAA employees regarding contact with offerors regarding prospective employment and the corresponding obligations for contractors who engage them. The contractor further acknowledges that it has provided notice to former NOAA employees who will provide service to NOAA under the contract of post-Government employment restrictions that apply to them. Such restrictions include, but are not limited to, those set forth in:

(a) 41 U.S.C. § 2103 regarding contacts between a Federal employee working on a procurement and an offeror about prospective employment;

(b) 18 U.S.C. § 207 regarding the restrictions on former Federal employees having contact with a Federal agency on behalf of another person or entity concerning a specific party matter with which the former employee was involved as a Federal employee or for which the former Federal employee had official responsibility;

(c) 18 U.S.C. § 207 regarding the restrictions on former senior employees and senior political employees from having contact with his former Federal agency on behalf of another person or entity concerning any official matter; and

(d) 41 U.S.C. § 2104 regarding the restrictions on a former Federal employee involved in an acquisition over $10,000,000 from accepting compensation from a contractor.

(End of solicitation and contract language)

***End addendum to FAR CLAUSE, 52.212-4, CONTRACT TERMS AND

CONDITIONS – COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (NOV

2023)***

Page - 14

FAR CLAUSE 52.212-5, CONTRACT TERMS AND CONDITIONS REQUIRED TO

IMPLEMENT STATUTES OR EXECUTIVE ORDERS -- COMMERCIAL PRODUCTS

AND COMMERCIAL SERVICES (MAY 2024)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L.

115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) ( 31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 4655).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) ( 41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

https://www.acquisition.gov/far/part-52#FAR_52_203_19 https://www.acquisition.gov/far/part-52#FAR_52_204_23 https://www.acquisition.gov/far/part-52#FAR_52_204_25 https://www.acquisition.gov/far/part-52#FAR_52_209_10 https://www.acquisition.gov/far/part-52#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/part-52#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_233_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/4655 https://www.acquisition.gov/far/part-52#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_15

Page - 15

__ (4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C.

4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

X (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (6) [Reserved].

__ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (9) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

__ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) ( Pub. L. 115–390, title II).

__ (11)

(i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders— Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

__ (ii) Alternate I (Dec 2023) of 52.204-30.

X (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Nov 2021) ( 31 U.S.C. 6101 note).

X (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) ( 41 U.S.C. 2313).

__ (14) [Reserved].

__ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) ( 15 U.S.C. 657a).

__ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

__ (17) [Reserved] https://www.acquisition.gov/far/part-52#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/part-3#FAR_3_900 https://www.acquisition.gov/far/part-52#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_204_14 https://www.acquisition.gov/far/part-52#FAR_52_204_15 https://www.acquisition.gov/far/part-52#FAR_52_204_27 https://www.acquisition.gov/far/part-52#FAR_52_204_28 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_204_30 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/part-52#FAR_52_204_30 https://www.acquisition.gov/far/part-52#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_4

Page - 16

X (18)

(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-6.

__ (19)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

__ (20) 52.219-8, Utilization of Small Business Concerns (Feb 2024) ( 15 U.S.C. 637(d)(2) and (3)).

__ (21)

(i) 52.219-9, Small Business Subcontracting Plan (Sep 2023) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Jun 2020) of 52.219-9.

__ (v) Alternate IV (Sep 2023) of 52.219-9.

__ (22)

(i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) ( 15 U.S.C. 644(r)).

__ (ii) Alternate I (Mar 2020) of 52.219-13.

X (23) 52.219-14, Limitations on Subcontracting (Oct 2022) ( 15 U.S.C. 637s).

__ (24) 52.219-16, Liquidated Damages—Subcontracting Plan (Sep 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__ (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (Feb 2024) ( 15 U.S.C. 657f).

X (26)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (Feb 2024) ( 15 U.S.C. 632(a)(2)).

https://www.acquisition.gov/far/part-52#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_6 https://www.acquisition.gov/far/part-52#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_7 https://www.acquisition.gov/far/part-52#FAR_52_219_8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_13 https://www.acquisition.gov/far/part-52#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_16 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_28

Page - 17

__ (ii) Alternate I (Mar 2020) of 52.219-28.

__ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) ( 15 U.S.C. 637(m)).

__ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) ( 15 U.S.C. 637(m)).

__ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) ( 15 U.S.C. 644(r)).

__ (30) 52.219-33, Nonmanufacturer Rule (Sep 2021) ( 15U.S.C. 637(a)(17)).

X (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

X (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Feb 2024).

X (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (34)

(i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

X (35)

(i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

X (36)

(i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (Jul 2014) of 52.222-36.

X (37) 52.222-37, Employment Reports on Veterans (Jun 2020) ( 38 U.S.C. 4212).

X (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

X (39) https://www.acquisition.gov/far/part-52#FAR_52_219_28 https://www.acquisition.gov/far/part-52#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/part-52#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/part-52#FAR_52_222_3 https://www.acquisition.gov/far/part-52#FAR_52_222_19 https://www.acquisition.gov/far/part-52#FAR_52_222_21 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_26 https://www.acquisition.gov/far/part-52#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_35 https://www.acquisition.gov/far/part-52#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_36 https://www.acquisition.gov/far/part-52#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_40

Page - 18

(i) 52.222-50, Combating Trafficking in Persons (Nov 2021) ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (40) 52.222-54, Employment Eligibility Verification (May 2022) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in

FAR 22.1803.)

__ (41)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA– Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

X (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (44) 52.223-20, Aerosols (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (45) 52.223-21, Foams (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (46) 52.223-23, Sustainable Products and Services (May 2024) ( E.O. 14057, 7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

__ (47)

(i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

X (48)

(i) 52.225-1, Buy American-Supplies (Oct 2022) ( 41 U.S.C. chapter 83).

__ (ii) Alternate I (Oct 2022) of 52.225-1.

__ (49) https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.acquisition.gov/far/part-22#FAR_22_1803 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_11 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_20 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_21 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/part-52#FAR_52_223_23 https://www.federalregister.gov/executive-order/14057 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/42/6962 https://www.govinfo.gov/link/uscode/42/8259b https://www.govinfo.gov/link/uscode/42/7671l https://www.acquisition.gov/far/part-52#FAR_52_224_3 https://www.acquisition.gov/far/part-52#FAR_52_224_3 https://www.acquisition.gov/far/part-52#FAR_52_225_1 https://www.acquisition.gov/far/part-52#FAR_52_225_1

Page - 19

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108- 302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (Dec 2022) of 52.225-3.

__ (iv) Alternate III (Feb 2024) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (NOV 2023) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ( 42 U.S.C. 5150).

__ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) ( 42 U.S.C. 5150).

X (55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) ( E.O. 13513).

__ (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

__ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

__ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) ( 41 U.S.C. 4505, 10 U.S.C. 3805).

X (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) ( 31 U.S.C. 3332).

__ (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) ( 31 U.S.C. 3332).

https://www.acquisition.