B08_Atch_1_HAFO_314578_Specifications_-_Final_UPDATED.pdf

HAFO 314578 TOC-1

REHABILITATE OPERATIONAL BUILDINGS AT IDAHO PARKS

HAGERMAN FOSSIL BEDS NATIONAL MONUMENT

IDAHO

PMIS NO. 314578

PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

FINAL CONSTRUCTION DOCUMENTS

APRIL 4, 2024

HAFO 314578 Final Specifications

April 4, 2024

SEALS PAGE

Civil Engineer Structural

Architect

Divisions 7-9

Mechanical and Plumbing Engineer

Fire Protection Engineer Fire Alarm Engineer

Exp. 5/31/2024

04/04/2024

04/04/202404/04/2024

HAFO 314578 Final Specifications

April 4, 2024

Electrical Engineer

03/28/2024

HAFO 314578 TOC-2

TABLE OF CONTENTS

DIVISION 00

DIVISION 01

01 11 00 SUMMARY OF WORK

01 26 01 CONTRACT MODIFICATION PROCEDURES

01 27 00 DEFINITION OF CONTRACT LINE ITEMS

01 31 00 PROJECT MANAGEMENT & COORDINATION

01 32 16 CONSTRUCTION SCHEDULE

01 32 33 PHOTOGRAPHIC DOCUMENTATION

01 33 23 SUBMITTAL PROCEDURES

• SUBMITTAL LIST

01 35 13.22 ARCHEOLOGICAL PROTECTION

01 35 23 SAFETY REQUIREMENTS

01 40 00 QUALITY REQUIREMENTS

01 42 00 REFERENCE STANDARDS

01 50 00 TEMPORARY FACILITIES AND CONTROLS

01 57 19.11 INDOOR AIR QUALITY MANAGEMENT

01 57 19.12 NOISE & ACOUSTICS MANAGEMENT

01 57 23 UNDER AN ACRE STORM WATER POLLUTION PREVENTION

01 67 00 PRODUCT REQUIREMENTS

01 73 29 CUTTING AND PATCHING

01 73 40 EXECUTION

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 77 00 CLOSEOUT PROCEDURES

01 78 23 OPERATION AND MAINTENANCE DATA

• O&M SPREADSHEET

01 79 00 DEMONSTRATION AND TRAINING

01 81 13 SUSTAINABLE DESIGN REQUIREMENTS FOR NON-LEED PROJECTS

01 91 14 TOTAL BUILDING COMMISSIONING

HAFO 314578 TOC-3

DIVISION 2

02 41 13 SITE SELECTIVE DEMOLITION

DIVISION 3

03 20 00 CONCRETE REINFORCING

03 30 00 CAST-IN-PLACE CONCRETE

DIVISIONS 4 AND 5: NOT USED

DIVISION 6

06 10 00 ROUGH CARPENTRY

06 16 00 SHEATHING

DIVISION 7

07 11 13 BITUMINOUS DAMPPROOFING

07 21 00 THERMAL INSULATION

07 25 00 WEATHER BARRIERS

07 26 00 VAPOR RETARDERS

07 41 13.16 STANDING SEAM METAL ROOF PANELS

07 46 46 FIBER-CEMENT SIDING

07 62 00 SHEET METAL FLASHING AND TRIM

07 72 53 SNOW GUARDS

07 92 00 JOINT SEALANTS

DIVISION 8

08 11 13 HOLLOW METAL DOORS AND FRAMES

08 31 13 ACCESS DOOR AND FRAMES

08 71 00 DOOR HARDWARE

DIVISION 9

09 29 00 GYPSUM BOARD

09 65 13 RESILIENT BASE AND ACCESSORIES

09 91 13 EXTERIOR PAINTING

09 91 24 INTERIOR PAINTING

DIVISION 10-20: NOT USED

HAFO 314578 TOC-4

DIVISION 21

21 00 00 FIRE SUPPRESSION BASIC REQUIREMENTS

21 05 00 COMMON WORK RESULTS FOR FIRE SUPPRESSION SYSTEMS

21 08 00 COMMISSIONING OF FIRE SUPPRESSION SYSTEMS

21 13 00 FIRE SUPPRESSION SPRINKLER SYSTEMS

21 30 01 DIESEL FIRE PUMPS

DIVISION 22

22 05 00 COMMON WORK RESULTS FOR PLUMBING PIPING

22 05 17 SLEEVES AND SLEEVE SEALS FOR PLUMBING PIPING

22 05 18 ESCUTCHEONS FOR PLUMBING PIPING

22 05 29 HANGERS AND SUPPORTS FOR PLUMBING PIPING AND EQUIPMENT

22 05 48 VIBRATION AND SEISMIC CONTROLS FOR PLUMBING PIPING

22 05 53 IDENTIFICATION FOR PLUMBING EQUIPMENT

22 13 16 SANITARY WASTE AND VENT PIPING

22 13 19 SANITARY WASTE PIPING SPECIALTIES

DIVISION 23

23 05 00 COMMON WORK RESULTS FOR HVAC

23 05 29 HANGERS AND SUPPORTS FOR HVAC EQUIPMENT

23 05 48 VIBRATION AND SEISMIC CONTROLS FOR HVAC

23 05 53 IDENTIFICATION FOR HVAC EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 09 23.12 CONTROL DAMPERS

23 31 13 METAL DUCTS

23 33 00 AIR DUCT ACCESSORIES

23 34 16 CENTRIFUGAL HVAC FANS

23 82 39.16 PROPELLER UNIT HEATERS

DIVISION 24 AND 25: NOT USED

DIVISION 26

26 05 00 COMMON WORK RESULTS FOR ELECTRICAL

26 05 19 LOW-VOLTAGE ELECTRICAL POWER CONDUCTORS AND CABLES

HAFO 314578 TOC-5

26 05 26 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

26 05 29 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS

26 05 33 RACEWAY AND BOXES FOR ELECTRICAL SYSTEMS

26 05 48 VIBRATION CONTROLS FOR ELECTRICAL SYSTEMS

26 05 53 IDENTIFICATION FOR ELECTRICAL SYSTEMS

26 09 23 LIGHTING CONTROL DEVICES

26 24 16 PANELBOARDS

26 27 13 ELECTRICITY METERING

26 27 26 WIRING DEVICES

26 28 16 ENCLOSED SWITCHES AND CIRCUIT BREAKERS

26 43 13 SURGE PROTECTION FOR LOW VOLTAGE ELECTRICAL POWER CIRCUITS

26 51 00 LIGHTING FIXTURES

26 56 00 EXTERIOR LIGHTING

DIVISION 27: NOT USED

DIVISION 28

28 00 01 ELECTRONIC SAFETY BASIC REQUIREMENTS

28 08 00 COMMISSIONING OF FIRE ALARM

28 16 11 INTRUSION DETECTION

28 31 00 FIRE DETECTION AND ALARM

DIVISION 29-30: NOT USED

DIVISION 31

31 10 00 SITE CLEARING

31 20 00 EARTH MOVING

31 25 00 EROSION AND SEDIMENT CONTROL

DIVISION 32

32 13 20 SITE CONCRETE

32 15 00 AGGREGATE SURFACING

DIVISION 33

33 14 16 SITE WATER UTILITY DISTRIBUTION

33 16 00 WATER UTILITY STORAGE TANKS

HAFO 314578 TOC-6

33 30 00 SITE SANITARY SEWERAGE

33 51 33 DRY WELLS

APPENDIX:

1. WATER SYSTEM DESIGN REPORT, DATED 11/01/2006 PROVIDED BY PARK.

2. TOPOGRAPHIC SURVEY, HOLLADAY ENGINEERING, NOT DATED, PROVIDED BY

PARK.

HAFO 314578 01 11 00 - 1

051121 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes the following:

1. Work Covered by Contract Documents

2. Contractor Use of Site

3. Public Use of Site

4. Occupancy Requirements for Buildings

5. Conduct of Operations

6. Work Restrictions

7. Special Construction Requirements

8. Soils Investigation Report

9. Additional Reports

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Hagerman Fossil Beds National Monument, Hagerman, ID. The work area is adjacent to the Administration and Museum Collections Storage Buildings.

B. The Work consists of:

1. Work consists of installation of a new dry-pipe fire suppression system serving the existing Maintenance and Paleontology Lab Building. To serve the existing (+/-5,320 SF) building, a new +/-323 SF pump house and 70,000 gallon water tank will be constructed. Finishes on the existing building will be repaired to the extent needed to facilitate new fire suppression.

2. New pump house design is in keeping with the style and materiality of the existing building

– slab on grade with wood frame walls, interior gypsum board finish with ceiling open to structure. Exterior wall finish to be horizontal lap fiber cement siding and roof finish to be standing seam metal. Relocation of existing electrical line required. Work on existing septic tank anticipated. New electrical meter, fire pump, and associated mechanical systems required.

3. All interior work at existing Paleontology Lab Building to be conducted with Park staff present. All cabinets are to be covered with a 10 mil polyethylene tarp by Contractor.

Existing shelving with open tops are to be covered with minimum 3/4 inch thick hard material spanning entire open top and 10 mil polyethylene tarp by Contractor. Park Curator will work with Contractor and be present during work. All construction dust and debris generated from work in the Paleo Collections Lab shall be cleaned up at the end of every day. Protect/cover any electrical outlets and vents to prevent dust intrusion in work areas.

C. Project will be constructed under a single prime contract.

HAFO 314578 01 11 00 - 2

1.3 WORK PHASES

A. The Work shall be conducted in one phase.

1.4 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of site for construction operations. Limit use of premises to areas within the Construction limits indicated on drawings. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine constructions operations to area within project limits around northeastern portion of site, adjacent to existing pump house as indicated on staging plan and coordinated with CO.

B. Storage of Materials: Confine storage of materials to staging area shown on plans.

C. Parking: Confine parking to staging area.

D. Stockpiling: Confine stockpiling to staging on area shown on plans.

E. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer (CO) and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

F. Preservation of Site Elements:

1. Prevent damage to adjacent Administration and Museum Collections Storage Buildings, existing pump house, and historic stone root cellar

2. Prevent damage to existing electrical hook-ups and hose bibs.

3. Existing adjacent conex boxes to remain in place and be accessible to Government.

4. Protect dirt two track path to remain adjacent to Project Work Limits.

G. Driveways and Entrances: Keep driveways and building entrances serving premises clear and available to Government employees and emergency vehicles at all times. Do not use for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

H. Construction Camp: Establishment of a camp within park will not be permitted.

HAFO 314578 01 11 00 - 3

I. Hauling Restrictions: Comply with legal load restrictions in hauling of materials. Load restrictions on park roads are identical to state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

J. Bridge Restrictions: Identify jurisdictions, load restrictions, permit requirements, time and calendar restrictions as outlined.

1.5 PUBLIC USE OF SITE

A. Contractor shall conduct their operations to ensure the least inconvenience to public.

1.6 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings under construction during the entire contract period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform Work so as not to interfere with Government's day-to-day operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from Contracting Officer.

b. Maintain Government access to existing Conex boxes on site.

c. Maintain existing building in weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building and occupants during construction period.

d. Contractor to submit schedule where areas of the building may be closed off during interior work, to be approved by Contracting Officer with at least 7-day notice.

e. Park staff must be present whenever contractor is working inside the Paleontology Lab Building in order to monitor and protect collections.

1.7 CONDUCT OF OPERATIONS

A. Contractor shall conduct his operations in conformance with rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed unless stated in the Work Restrictions below or without prior consent from the Contracting Officer. Submit requests 3 business days in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

HAFO 314578 01 11 00 - 4

1.8 WORK RESTRICTIONS

A. On-Site Work Hours: Interior work at existing building shall be performed during normal business working hours of 7 a.m. to 4:30 p.m., Monday through Friday, so that Park staff may be present whenever contractor is working inside building. Exterior work may occur at any time.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two business days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours and length of Utility Shutdowns: Water shutdown is assumed, no longer than 2 weeks maximum.

D. Nonsmoking Building/Tobacco Use/Vaping: Smoking is not permitted within building or within 25 feet of entrances, operable windows, or outdoor air intakes. Tobacco use and vaping is restricted to areas outside of 25 feet of all buildings’ doors, windows, and outdoor air intakes.

Contractor shall provide butt collection devices and designate a location within the staging area for smoking that is at least 25 feet from any building entrance, window, or air intake.

1.9 SPECIAL CONSTRUCTION REQUIREMENTS

A. Project Website: A Project Teams website shall be provided for purposes of managing communication and documents during construction stage.

1. See Section 01 31 00 "Project Management and Coordination" for requirements on using Project Website.

B. The building has potential for elevated radon levels. Radon levels are mitigated through continuous ventilation and monitoring devices are present to ensure levels do not exceed OSHA limit of 4.0 piC/L. Radon levels should be checked regularly if ventilation is non-functional or disabled and safety protocols should be implemented if radon levels exceed OSHA limits. Work in building may be delayed until levels return to below safe limits. Contractor shall confirm with Park staff each day before performing any work in the building that the ventilation system has been running and functioning properly.

HAFO 314578 01 11 00 - 5

1.10 ADDITIONAL REPORTS

A. The “Water System Design Report” dated 11/1/2006 is available in an appendix with this package.

B. The undated “Maintenance Complex Topographic Survey” by Holladay Engineering is available with this package.

C. In case of conflict between report and drawings or specifications, specifications govern.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

HAFO 314578 01 26 01 - 1

012721 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with preparation of modifications will not be allowed. Costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager (PM), Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

HAFO 314578 01 26 01 - 2

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: Costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate.

The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on project site. Modification costs for salaried workers are only allowed within the structure of a 40-hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: The hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens; includes insurance and taxes the business must pay on behalf of the worker to government entities and educational forums, such as:

1) Social Security

2) Medicare

3) Workers Compensation – Policy and company calculation to be made available.

4) Federal Unemployment Tax Act (FUTA) - Cap Rate and percentage to be proportionally allocated over one year.

5) State Unemployment Tax Act (SUTA) - Cap Rate and percentage to be proportionally allocated over one year.

HAFO 314578 01 26 01 - 3

6) Union agreement costs - Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects Contractor from claims resulting from bodily injury or property damage to a third party. Include as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees the Contractor will pay the labor and material costs incurred. Banks and Insurance companies charge a premium for individual project based on a sliding scale related to the size of the project.

Include as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: Covers the contractor’s loss due to fire, high winds, or other natural forces. Not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Proposal be received in the format and within the time frame specified in the Request for Proposal (RFP) letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. Proposal shall be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Government’s form.

http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm

HAFO 314578 01 26 01 - 4

3. Requests for extensions of contract time as a result of change must be justified with a Time Impact Analysis (TIA). Refer to Section 01 32 16 "Construction Schedule", for time impact analysis requirements. TIA and associated costs shall be received with the proposal by the date shown within the Request for Proposal letter. Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer (CO) upon request.

5. Contractor shall review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing hours required for each craft directly engaged in modification work. Any work proposed requiring overtime work or premium pay shall be itemized separately. Rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, Federal Insurance Contributions Act (FICA), FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. Labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. Estimated cost for materials shall include quotes from multiple sources. Material prices shall include applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for work being performed.

2. Do not include costs for "miscellaneous tools and equipment", in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 shall be broken out separately.

3. Regardless of ownership, rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. United States (U.S.) Army Corps of Engineers, Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

HAFO 314578 01 26 01 - 5

4. Estimated equipment rates shall include operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires and tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per Federal Acquisition Regulation (FAR) 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate full rate for equipment only for duration that equipment will be utilized to accomplish work of the modification.

6. Standby unit rates used in accordance with paragraph 1.3, D, 2, above. If the U.S. Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then 1/2 of equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, established standby rate shall apply from the first day of the delay.

8. Equipment not used and on job site for up to five consecutive days may be classified at standby rates, provided the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work.

Equipment still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10% Profit…………………6.00%

2. Total aggregate limit of markup (OH&P) for Contractor and Subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If Contractors form a partnership, partnership may only receive home office overhead and profit in same amount as an individual Contractor (refer to paragraph 1.3,E,1 above). It is the responsibility of the partners to decide on division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, overhead and profit mark-ups are required on net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

HAFO 314578 01 26 01 - 6

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

HAFO 314578 01 27 00 - 1

012721 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. Section explains in general, what is and is not included in a contract line item, and limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of work, include costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item Number 01, Maintenance Building and Paleontology Lab

1. This item consists of installation of dry pipe sprinkler system in existing building.

1. Measurement for payment will be by percentage of work completed in the previous month.

2. Payment will be made at the contract lump sum price.

B. Contract Line Item Number 02, Pump House

1. This item consists of construction of new pump house and water tank to supply new sprinkler system in Maintenance Building and Paleontology Lab, including installation of new associated underground utilities.

2. Measurement for payment will be by percentage of work completed in the previous month.

3. Payment will be made at the contract lump sum price.

C. Contract Line Item Number 03, Option 01 – Archeology Monitoring

1. This item consists of all work associated engaging an Archeological Monitor to review all site related activities per specifications.

2. Measurement for payment will be by percentage of work completed in the previous month.

3. Payment will be made at the contract lump sum.

END OF SECTION 01 27 00

HAFO 314578 01 31 00 - 1

042123 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination

3. Submittals

4. Coordination Drawings

5. Requests for Information (RFIs)

6. NPS/DSC Project Website

7. Project Meetings

8. Environmental Coordination

9. Emergency Procedures

10. Permits

B. Related Requirements:

1. Section 01 32 16 "Construction Schedule" for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 "Execution" for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 "Closeout Procedures" for coordinating closeout of the Contract.

4. Section 01 91 14 "Total Building Commissioning" for coordinating the work with Owner’s

Commissioning Authority.

1.2 DEFINITIONS

A. Agency with Jurisdiction B. Construction Permits – Contractor Provided C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

http://www.nps.gov/dscw/definitionsdc_a.htm http://www.nps.gov/dscw/definitionsdc_c.htm http://www.nps.gov/dscw/definitionsdc_g.htm

HAFO 314578 01 31 00 - 2

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to:

1. Preparation of Contractor's Construction Schedule

2. Preparation of the Schedule of Values

3. Installation and removal of temporary facilities and controls

4. Delivery and processing of submittals

5. Progress meetings

6. Permit requirements

7. Pre-installation conferences

8. Project closeout activities

9. Commissioning activities

1.4 SUBMITTALS

A. Coordination Drawings: Prepare Coordination Drawings if limited space availability necessitates maximum utilization of space for efficient installation of different components or if coordination is required for installation of products and materials fabricated by separate entities.

1. Content: Project-specific information, drawn accurately to scale. Do not base Coordination Drawings on reproductions of Contract Documents or standard printed data. Include following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on Contract Drawings and make specific note of dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to Contracting Officer (CO) for resolution of such conflicts.

c. Indicate space requirements for routine maintenance and anticipated replacement of components during the life of the installation.

d. Show location and size of access doors required for access to concealed dampers, valves, and controls.

e. Indicate required installation sequences.

HAFO 314578 01 31 00 - 3

2. Refer to individual Sections for Coordination Drawing requirements for Work in those Sections.

3. Follow NPS DSC Electronic Drawing Standards. See CAD/BIM (Computer Aided Design/Building Information Modeling) & Drafting Standards page > DSC Requirements section.

B. Coordination Drawing Organization: Organize coordination drawings as follows:

1. Floor Plans and Reflected Ceiling Plans: Show architectural, structural, mechanical, plumbing, fire-protection, fire-alarm, and electrical elements. Show locations of visible ceiling-mounted devices relative to acoustical ceiling grid. Supplement plan drawings with section drawings where required to adequately represent the Work.

2. Plenum Space: Indicate sub-framing for support of ceiling and wall systems, mechanical and electrical equipment, and related Work. Locate components within ceiling plenum to accommodate layout of light fixtures indicated on Drawings. Indicate areas of conflict between light fixtures and other components.

3. Mechanical Rooms: Provide coordination drawings for mechanical rooms showing plans and elevations of mechanical, plumbing, fire-protection, fire-alarm, and electrical equipment.

4. Structural Penetrations: Indicate penetrations and openings required for all disciplines.

5. Slab Edge and Embedded Items: Indicate slab edge locations and sizes and locations of embedded items for metal fabrications, sleeves, anchor bolts, bearing plates, angles, door floor closers, slab depressions for floor finishes, curbs and housekeeping pads, and similar items.

6. Mechanical and Plumbing Work:

a. Sizes and bottom elevations of ductwork, piping, and conduit runs, including insulation, bracing, flanges, and support systems.

b. Dimensions of major components, such as dampers, valves, diffusers, access doors, cleanouts and electrical distribution equipment.

c. Fire-rated enclosures around ductwork.

7. Electrical Work:

a. Runs of vertical and horizontal conduit 1-1/4 inches in diameter and larger.

b. Light fixture, exit light, emergency battery pack, smoke detector, and other fire-alarm locations.

c. Panel board, switch board, switchgear, transformer, busway, generator, and motor control center locations.

d. Location of pull boxes and junction boxes, dimensioned from column center lines.

8. Fire-Protection System:

a. Locations of standpipes, mains piping, branch lines, pipe drops, and sprinkler heads.

9. Review: Contracting Officer will review coordination drawings to confirm Work is being coordinated; details of coordination are Contractor's responsibility. If Contracting Officer determines coordination drawings are not prepared in scope or detail, or are otherwise deficient, Contracting Officer will inform Contractor, who shall make changes and resubmit.

https://www.nps.gov/dscw/ds-cad-bim-drafting.htm https://www.nps.gov/dscw/ds-cad-bim-drafting.htm

HAFO 314578 01 31 00 - 4

10. Coordination Drawing Prints: Prepare coordination drawing prints according to requirements in Section 01 33 23 "Submittal Procedures."

C. Coordination Digital Data Files: Prepare coordination digital data files according to:

1. File Preparation Format: Same digital data software program, version, and operating system as original Drawings.

2. File Submittal Format: Submit or post coordination drawing files using Portable Document Format (PDF) file format.

3. Contracting Officer will furnish Contractor one set of digital data files (AutoCad.dwg) of Drawings for use in preparing coordination digital data files.

a. Contracting Officer makes no representations as to accuracy or completeness of digital data files as they relate to Drawings.

b. Digital Data Software Program: Drawings are available in AutoCad.dwg.

D. Division 1 documents:

1. Letter designating Project Superintendent

2. Construction Schedule

3. A Comprehensive Schedule of Values

4. Accident Prevention Plan

5. A List of Subcontractors for this project

6. Written statements from Subcontractors certifying compliance with applicable labor standard clauses.

7. Certificates of Insurance and Standard Form SF1413 for Contactor and all Subcontractors

8. Waste Management Plan

9. Quality Control Plan

10. Under an Acre Pollution Prevention Plan (UPPP)

11. Indoor Air Quality (IAQ) Management Plan

12. Contractors Commissioning Plan

13. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit

b. Agency(ies) with Jurisdiction issuing the permit

c. Information required from Government to complete permit application

E. Provide items listed to Contracting Officer at least one week prior to Pre-Construction Conference, or as directed by Contracting Officer.

1. Failure to submit items may result in:

a. Construction conference may be cancelled, Notice to Proceed may not be issued, and Contracting Officer will consider other contractual remedies.

b. Work shall not commence until written Notice to Proceed has been issued and Certificates of Insurance and SF1413 documents are received for Contractor and all Subcontractors.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of Contract Documents, Contractor shall prepare and submit an RFI utilizing form created on NPS/DSC management software website.

HAFO 314578 01 31 00 - 5

1. Contracting Officer will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of RFI: Include detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially

2. Date

3. RFI subject

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution: If Contractor's suggested resolution impacts Contract

Time or Contract Sum, Contractor shall state impact in RFI.

8. Contractor's signature

9. Requested date for response

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete RFI Form on NPS/DSC Project Website as follows:

1. Enter general information at the top of the form.

2. Under the "Action" section at the bottom of the form, select "Question" then select "CMR" in drop-down of "Send to" box.

3. Enter details of question and attach related documents.

4. Select "Submit Form" at bottom of page.

D. Contracting Officer’s Action: Contracting Officer will review each RFI, determine action required, and respond. Contracting Officer will determine critical nature of each RFI and issue response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in Contract Documents.

e. Requests for adjustments in Contract Time or Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. Contracting Officer's action may include a request for additional information; time for response will date from time of receipt of additional information.

3. Contracting Officer's action on RFIs may result in need for a change to Contract Time or Contract Sum. All contract changes will be processed following terms and conditions of contract.

HAFO 314578 01 31 00 - 6

1.6 PROJECT WEB SITE

A. Use NPS/DSC management software website for communication throughout contract period on:

1. Project directory

2. Project correspondence

3. Meeting agendas and minutes

4. Contract modifications forms and logs

5. RFI form and processing

6. Task and issue management

7. Photo documentation

8. Baseline schedule, schedule updates and calendar management

9. Submittal form and processing

10. Payment coordination documentation

11. Drawing and specification document hosting, viewing, and updating

12. Online document collaboration

13. Reminder and tracking functions

14. Archiving functions

15. Notification of submittal and RFI statuses and current responsible party

16. Permits and addendums

B. Some documents are not suitable to be shared using the NPS/DSC management software website.

Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared using NPS/DSC management software website and shall be coordinated with Project team as appropriate.

C. Submit to Contracting Officer a list of employees who will need access to the website. Users will receive an invitation to register from Department of Interior (DOI). Once registered on DOI website, user will be given access to NPS/DSC management software website.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later.

1.7 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. Meeting agenda will include the following as a minimum:

1. Roles & Responsibilities / Lines of Authority

2. Park rules and regulations

3. Jobsite Safety

4. Resolution of comments on required Division 1 documents

5. Coordination of Subcontractors

6. Labor law application

7. Modifications

8. Payments to Contractor

9. Payroll reports

10. Contract time

HAFO 314578 01 31 00 - 7

11. Liquidated damages

12. Contractor Performance Evaluation

13. Display of Hotline posters

14. Notice to proceed

15. Correspondence procedures

16. NPS/DSC Project website

17. Acceptance/rejection of work

18. Progress meetings

19. Submittal procedures

20. Environmental requirements

21. Permit requirements

22. As-constructed drawings/operation and maintenance (O&M) manuals.

23. Saturday, Sunday, holiday and night work.

24. Reference materials

25. Value engineering

26. Schedule of Values

B. Progress Meetings: Contracting Officer will schedule weekly meetings with Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented. Participants at meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Meeting agenda will include:

a. Approval of minutes of previous meetings

b. Submittal status

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, etc.)

g. Inspections of work in progress and projected (Special inspections, etc.)

h. Construction Schedule update (provide updated Critical Path Method (CPM)).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements

C. Preinstallation Conferences: Conduct at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend meeting. Advise Contracting Officer of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for particular activity under consideration, including requirements for:

a. Contract Documents

HAFO 314578 01 31 00 - 8

b. Options

c. Related RFIs

d. Related Change Orders

e. Purchases

f. Deliveries

g. Submittals

h. Review of mockups

i. Possible conflicts

j. Compatibility requirements

k. Time schedules

l. Weather limitations

m. Manufacturer's written instructions

n. Warranty requirements

o. Compatibility of materials

p. Acceptability of substrates

q. Temporary facilities and controls

r. Space and access limitations

s. Regulations of agency(ies) with jurisdiction

t. Testing and inspecting requirements

u. Installation procedures

v. Coordination with other work

w. Required performance results

x. Protection of adjacent work

y. Protection of construction and personnel

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if conference cannot be successfully concluded. Initiate whatever actions are necessary to resolve impediments to performance of Work and reconvene conference at earliest feasible date.

1.8 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate on-site party responsible for overseeing Contractor’s conformance to environmental goals for project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to this project; familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of Waste Management Plan (WMP).

c. Implementation of Indoor Air Quality (IAQ) Management Plan.

d. Implementation of Storm Water Pollution Prevention Plan (SWPPP).

HAFO 314578 01 31 00 - 9

e. Present overview of environmental issues and summarize site specific procedures relating to management plans at Preconstruction conference.

f. Training for Contractor personnel in accordance with position requirements.

g. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements

2. Regulatory Requirements

3. Indoor Air Quality (IAQ) Management

4. Noise and Acoustics Management

5. Under an Acre Pollution Prevention Environmental Management

6. Construction Waste Management

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on project site. Training shall include:

1. Overview of environmental issues related to building industry.

2. Overview of environmental issues related to Project.

3. Review of site-specific procedures and management plans:

a. Construction Waste Management

b. Indoor Air Quality (IAQ) Management

c. Noise and Acoustics Management

d. Under an Acre Pollution Prevention

4. Pollution Prevention (P2) practices: Submit evidence of P2 training.

5. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR (Code of Federal Regulations) employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution Prevention Plan.

1.9 EMERGENCY PROCEDURES

A. In the event of an emergency, Contractor shall call 911 and immediately notify the Park Safety Officer. Contractor shall also notify the CO within 24 hours of any emergency contact.

1. Park Safety Officer, EMT: Metney Jensen, office (208)527-1325, cell phone (208)490-

2. Outside Agency Resource List:

EMERGENCY RESPONSE 911

Gooding County SHERIFF OFFICE (non-emergency)

208-934-4421

Thousand Springs VC Main Line 208-837-4505

POISON CONTROL

1-800-222-1222

HAFO 314578 01 31 00 - 10

Idaho Dept. of Fish and Game (208) 324-4359 Hagerman Animal Control Officer (City Hall) Bob Bonning

Monday-Friday: (208) 837-6636 After Hours/Weekend: (208) 324-

1.10 PERMITS

A. General:

1. Permits and Responsibilities: Contractor shall, without additional expense to the Government, be responsible for obtaining necessary licenses and permits, and for complying with Federal, State and municipal laws, codes, and regulations applicable to the performance of the work.