(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

NEGOTIATED (RFP) REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF

SEALED BID (IFB) INVITATION FOR BID

9. FOR

INFORMATION CALL

PAGES

140P2026R0011

NPS, DSC Contracting Services Div 1 Denver Federal Center, Building 50 P.O. Box 25287 Denver CO 80225-0287

See Section "L" Instructions

0044039145 GLCA 318878

PDS

Tony Jasper 3039692789

06/17/2026

07/15/2026

10 549 Section H - Special Req 4

GLCA 318878 - Glen Canyon Low Water Ramps - Hite District

a) This acquisition is being conducted as a Total Small Business Set-Aside. The North American

Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-B in section "K" of this solicitation.

b) Refer to section "L" for information regarding a pre-proposal site visit.

c) Information and requirements stated in sections "B" through "J" & attachments noted in section

"J" apply to this solicitation and the subsequent contract.

d) Refer to section "L" for proposal submittal requirements.

e) Offerors shall submit proposals and questions, and acknowledge solicitation amendments as stated in section "L" of this solicitation.

f) All Physical Data, Reports, and or information has been attached in Section J.

g) Notice to Proceed will be issued shortly after contract award, upon receipt of bonds.

1 74

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Continued...

AMENDMENT

NUMBER

DATE.

NPS, DSC Contracting Services Div 1 Denver Federal Center, Building 50 P.O. Box 25287 Denver CO 80225-0287

PDS

Tony Jasper

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

140P2026R0011

00010 Hite Small Boat Launch Design Build (Fin

Product/Service Code: Z2QA

Product/Service Description: REPAIR OR

ALTERATION

OF RESTORATION OF REAL PROPERTY (PUBLIC OR

PRIVATE)

00020 Hite Small Boat Launch Design Build

Product/Service Code: Z2QA

Product/Service Description: REPAIR OR

ALTERATION

OF RESTORATION OF REAL PROPERTY (PUBLIC OR

PRIVATE)

Date

6/17/2026 Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

Page

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKAGING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-4 INSPECTION OF SERVICES-FIXED-PRICE (AUG 1996)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING PLATFORM

SYSTEM (FEB 2021)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S - INTERMOUNTAIN

REGION (JUN 2009)

SPECIAL REQUIREMENT 2: PERFORMANCE OF WORK BY THE CONTRACTOR

SPECIAL REQUIREMENT 3: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE

ITEMS

SPECIAL REQUIREMENT 4: COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

SPECIAL REQUIREMENT 5: KEY PERSONNEL

SPECIAL REQUIREMENT 6: RESPONSIBILITY OF THE ARCHITECT-ENGINEER CONTRACTOR

SPECIAL REQUIREMENT 7: WORK OVERSIGHT IN ARCHITECT-ENGINEER CONTRACTS

CONSTRUCTION CONTRACT ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B)

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.204-2 [RESERVED]

52.204-23 [RESERVED]

52.204-25 [RESERVED]

52.204-30 [RESERVED]

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN

CERTIFIED OR PRICING DATA-MODIFICATIONS (NOV 2021)

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEVIATION JAN 2026)

52.222-55 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER 14026.

DEVIATION (DEVATION MAY 2026)

52.223-2 REPORTING OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2024) (DEVIATION FEB 2025)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (DEVIATION

MAY 2026)

52.223-10 [RESERVED]

52.223-11 OZONE-DEPLETING SUBSTANCES (DEVIATION MAY 2026)

52.223-23 SUSTAINABLE PRODUCTS (DEVIAITION MAY 2026)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

52.228-11 INDIVIDUAL SURETY - PLEDGE OF ASSETS (FEB 2021) (DEVIATION MAY 2023 SEE DOI-

AAAP-0165, V02)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020) (DEVIATION MAY

2023 SEE DOI-AAAP-0165, V02)

52.236-2 DIFFERING SITE CONDITIONS (DEVIATION JAN 2026)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (DEVIATION JAN 2026) 42

52.236-5 MATERIAL AND WORKMANSHIP (DEVIATION JAN 2026)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (DEVIATION JAN 2026)

52.236-7 PERMITS AND RESPONSIBILITIES (DEVIATION JAN 2026)

(a) The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

(b) The Contractor shall be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence

(c) The Contractor shall be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract

52.236-8 OTHER CONTRACTS (DEVIATION JAN 2026)

(a) The Government may award other contracts for work at or near the site of the work under this contract.

The Contractor shall cooperate and coordinate with—

(1) Other contractors; and

(2) Government employees

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (DEVIATION JAN 2026)

52.236-10 OPERATIONS AND STORAGE AREAS (DEVIATION JAN 2026)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (DEVIATION JAN 2026)

52.236-12 CLEANING UP (DEVIATION JAN 2026)

52.236-13 ACCIDENT PREVENTION (DEVIATION JAN 2026)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (DEVIATION JAN 2026)

52.236-17 LAYOUT OF WORK. (DEVIATION JAN 2026)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (DEVIATION JAN 2026)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984) .. 49

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.201-1 ACQUISITION 360: VOLUNTARY SURVEY (SEP 2023)

52.204-8 [RESERVED]

52.204-24 [RESERVED]

52.204-26 [RESERVED]

52.204-29 [RESERVED]

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2025)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION

(DEVIATION MAY 2026)

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (DEVIATION JAN 2026)

52.223-1 BIOBASED PRODUCT CERTIFICATION MAY 2024 (DEVIATION MAY 2026)

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS—NOTICE AND REPRESENTATION (JUN

2020)

52.236-28 [RESERVED]

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.216-1 TYPE OF CONTRACT (APR 1984)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY 2014)

52.228-1 BID GUARANTEE (SEP 1996)

52.228-17 INDIVIDUAL SURETY – PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.232-38 SUBMISSION OF ELECTRONIC FUNDS TRANSFER INFORMATION WITH OFFER (JUL

2013)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996) (DEVIATION)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

SPECIAL INSTRUCTION: SITE VISIT

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION – COMPETITIVE

SOURCE SELECTION – TWO PHASE PROCESS

SECTION M – EVALUATION FACTORS FOR AWARD

SPECIAL PROVISION 1: EVALUATION OF OPTIONS

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

End of Section A

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION B – BID SCHEDULE

CONTRACT BID SCHEDULE

SOLICITATION NUMBER: 140P2026R0011

PARK - PMIS: GLCA 318878

PROJECT TITLE: Low Water Ramps – Hite District

Offerors are required to submit, at a minimum, one (1) Firm-Fixed-Price (FFP) offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Please complete Contract Price Schedule in the Proposal Submission Package. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. Refer to section “H” of this solicitation for additional information regarding contract options.

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

End of Section B

Contract Line Item Number

(CLIN)

Contract Line Item (CLI) Title Quantity Unit of Measure Unit Price Total Price

BASE - DESIGN - 35-foot wide concrete launch ramp servicing lake elevation 3700 to 3490 with a 18-ft wide gravel access road connecting Hite Marina Rd to the ramp, one 5.25-acre upper parking area, and one 0.7-acre lower parking area, both for boat and passenger vehicles, including accommodations complying with Architectural Barriers Act Accessibility Standards

(ABAAS)

Clarification: The full design under CLIN 1, Ramp Servciing elevations 3700 to 3490 and a width of 35 feet, allows for extrapolation of design data as needed to support scalable construction options including construction elevation 3565'(CLIN 2- BASE), 3550' (CLIN 3 - OPTION A) and 3535 (CLIN 4 OPTION B). CLIN 5 is Gravel Surfacing for a 5.2 Arce Parkign Area

CLIN 2

BASE - CONSTRUCTION - 35-ft wide concrete launch ramp servicing elevation 3700 to 3565-ft along a 16% grade (matching the 3490 Design (CLIN 1)), daylight at a 2% Grade (Native Surface) from elevation 3565 to the channel;

- 18-ft wide gravel access road connecting Hite Marina Rd to the launch ramp; .

- Grading only (No Surfacing) for a 5.25-acre gravel upper boat trailer and passenger vehicle parking area;

and

- 0.7-acre gravel lower boat trailer and passenger vehicle parking area connecting to the top of the launch ramp.

1 Lump Sum (LS) $ -

TOTAL BASE PRICE (Contract Line Item Number 1 through 2) ---------------------------------------------------------------------- $0.00

CLIN 3

OPTION A - CONSTRUCTION - 35-ft wide concrete launch ramp servicing elevation 3565 to 3550-ft along a 16% grade (matching the 3490 Design (CLIN 1)), daylight at a 2% Grade (Native Surface) from elevation 3550 to the channel;

- 18-ft wide gravel access road connecting Hite Marina Rd to the launch ramp; .

- Grading only (No Surfacing) for a 5.25-acre gravel upper boat trailer and passenger vehicle parking area;

and

- 0.7-acre gravel lower boat trailer and passenger vehicle parking area connecting to the top of the launch ramp.

1 Lump Sum (LS) $ -

CLIN 4

OPTION B - CONSTRUCTION - 35-ft wide concrete launch ramp servicing elevation 3565 to 3535-ft along a 16% grade (matching the 3490 Design (CLIN 1)), daylight at a 2% Grade (Native Surface) from elevation 3565 to the channel;

- 18-ft wide gravel access road connecting Hite Marina Rd to the launch ramp; .

- Grading only (No Surfacing) for a 5.25-acre gravel upper boat trailer and passenger vehicle parking area;

and

- 0.7-acre gravel lower boat trailer and passenger vehicle parking area connecting to the top of the launch ramp.

1 Lump Sum (LS) $ -

CLIN 5

Option C - CONSTRUCTION (GRAVEL UPPER PARKING LOT) - Gravel Surfacing for 5.25 Acre Parking Area

1 Lump Sum (LS) $ -

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item 3 through 5) ------------------------------------------------------------------ $0.00

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Number 1 through 5) --------- $0.00

All measurement and payment information is included in Division 01 Specifications Section 01 27 00 Definition of Contract Line Items.

CLIN 1 1 Lump Sum (LS) $ -

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION C – SPECIFICATIONS / DRAWINGS

The work of this contract is for the construction of: GLCA 318878 – Low Water Ramps – Hite District

Glen Canyon Recreation Area, Utah

This project will address low-water lake access at Hite based upon the relocation of the launch ramp to a new deep pool location. The work includes, but is not limited to, gravel access road, a new concrete launch ramp and parking lots.

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

End of Section C

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION D – PACKAGING AND MARKING

Section Does Not Apply

End of Section D

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION E – INSPECTION AND ACCEPTANCE

52.246-4 INSPECTION OF SERVICES-FIXED-PRICE (AUG 1996)

(a) Definition. "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may-

(1) Require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and

(2) Reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may-

(1) By contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service; or

(2) Terminate the contract for default.

(End of clause)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

(ii) Attention to such factors as organization, planning work instructions, documentation control, and advanced metrology.

(End of clause)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph

(i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer.

The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary.

The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its Subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction.

However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

End of Section E

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION F – DELIVERIES OR PERFORMANCE

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of _$2,511___for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION JAN 2026)

(a)

(1) Within five days after the work commences on the contract or another period of time determined by the

Contracting Officer, the Contractor shall prepare and submit to the Contracting Officer for approval a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the

Contractor contemplates starting and completing the work (including acquiring materials, plant, and equipment).

(2) The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period.

(3) If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall continually update the actual progress in the schedule and shall submit it to the Contracting

Officer by the means prescribed in the contract for transmittals or as directed by the Contracting Officer.

(c)

(1) If the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to recover lost time and execute in accordance with the approved schedule, without additional cost to the Government.

(2) Such steps may include increasing the number of shifts, overtime operations, days of work, and/or the amount of construction plant.

(3) The Contractor shall submit, for approval, supplementary schedule(s) that demonstrate how the lost time will be recovered.

(d) If the Contractor does not recover the lost time, the Contracting Officer may determine that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20-days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

End of Section F

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the Contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3-days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30-days to any notice made under paragraph (d) of this clause.

A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose.

The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in CPARS for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30-days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60-days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60-calendar days after receipt of the CPAR. On day 15, the evaluation will become available in CPARS marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60-days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the Contractor on (date). The Contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven (7)-days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING

PLATFORM SYSTEM (FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

The Contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the Contractor. If the CMR recommends acceptance, the Contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP);

2. Completed copy of the Pay Estimate Form (including signed certification of Subcontractor payments);

3. Completed copy of the Limitations on Subcontracting Report

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts;

5. A copy of the current construction schedule (refer to project specification section 013216); and

6. A copy of the current Schedule of Values. (refer to project specification section 013216).

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email Invoice Processing Platform - Contact Us (treasury.gov) or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause)

End of Section G

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S -

INTERMOUNTAIN REGION (JUN 2009)

The Contractor is prohibited from utilizing All-Terrain Vehicles (ATV)s on National Park Service lands. ATV is defined as:

A motorized off-highway vehicle (OHV) traveling on four or more low-pressure tires, having a seat to be straddled by the operator and a handlebar for steering control.

Use of Utility Terrain Vehicles (UTVs) are permitted. UTV (also called a side-by-side) is defined as: A motorized OHV having four or more low pressure tires, designed with side-by-side seats, seatbelts, steering wheel, and optional cab, brush cage, or ROPS.

(End of Local Clause)

SPECIAL REQUIREMENT 2: PERFORMANCE OF WORK BY THE CONTRACTOR

The Contractor shall perform on the site, and with its own organization, work equivalent to at least __15_____ percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction, and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of Local Clause)

SPECIAL REQUIREMENT 3: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED

LINE ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the Contractor within _549__-days after contract award. Performance of added line-item tasks shall be at the price negotiated in the contract Schedule.

(End of Local Clause)

SPECIAL REQUIREMENT 4: COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

The Contractor shall be required to (a) commence work under this contract within _549___calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than __549 calendar days____________.* The time stated for completion shall include final cleanup of the premises.

(End of Local Clause)

SPECIAL REQUIREMENT 5: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Design Build Project Manager: _______________________

Designer of Record Project Manager:___________________

Site Superintendent: ___________________________

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

Site Quality Control/Safety Manager: ______________________

(b) During the first _120___days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15-calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial __120___-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15-days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer.

Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15-calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

SPECIAL REQUIREMENT 6: RESPONSIBILITY OF THE ARCHITECT-ENGINEER CONTRACTOR

(a) The Contractor shall be responsible for the professional quality, technical accuracy, and the coordination of all design, drawings, specifications, and other services furnished by the Contractor under this contract. The Contractor shall, without additional compensation, correct or revise any errors or deficiencies in its designs, drawings, specifications, and other services.

(b) Neither the Government’s review, approval or acceptance of, nor payment for, the services required under this contract shall be construed to operate as a waiver of any rights under this contract or of any cause of action arising out of the performance of this contract, and the Contractor shall be and remain liable to the Government in accordance with applicable law for all damages to the Government caused by the Contractor’s negligent performance of any of the services furnished under this contract.

(c) The rights and remedies of the Government provided for under this contract are in addition to any other rights and remedies provided by law.

(d) If the Contractor is comprised of more than one legal entity, each such entity shall be jointly and severally liable hereunder.

(End of Special Requirement)

SPECIAL REQUIREMENT 7: WORK OVERSIGHT IN ARCHITECT-ENGINEER CONTRACTS

The extent and character of the work to be done by the Contractor shall be subject to the general oversight, supervision direction, control, and approval of the Contracting Officer.

(End of Special Requirement)

SPECIAL REQUIREMENT 8: REQUIREMENTS FOR REGISTRATION OF DESIGNERS

Architects or engineers registered to practice in the particular professional field involved in a State, the District of Columbia, or an outlying area of the United States the state where the construction work shall be performed shall prepare or review and approve the design of architectural, structural, mechanical, electrical, civil, or other architectural and engineering features of the work.

SPECIAL REQUIREMENT 9: PUBLICITY

Solicitation No.

140P2026R0011

National Park Service (NPS) – Denver Service Center (DSC) Design-Build GLCA 318878 – Low Water Ramps - Hite

(a) Except with the prior approval of the Contracting Officer, the consultant shall not release for publication any drawing, rendering, perspective, sketch, photograph, report, specification, cost estimate, or other material of any nature pertaining to the facilities for which services are performed under the terms of this contract.

(b) The provision of this article shall extend also to the release of any such material to any person not so authorized by the Contracting Officer.

SPECIAL REQUIREMENT 10: ORGANIZATIONAL CONFLICTS OF INTEREST

(a) Purpose. The purpose of this clause is to ensure that the contractor and its subcontractors:

(1) are not biased because of their financial, contractual, organizational, or other interests which relate to the work performed under this contract, and

(2) Do not obtain any unfair competitive advantage over other parties by virtue of their performance of this contract.

(b) Scope. The restrictions described herein shall apply to performance or participation by the contractor, its parents, affiliates, divisions and subsidiaries, and successors in interest (hereinafter collectively referred to as “contractor”) in the activities covered by this clause as a prime contractor, subcontractor, co-sponsor, joint venturer, consultant, or in any similar capacity. for the purpose of this clause, affiliation occurs when a business concern is controlled by or has the power to control another or when a third party has the power to control both.

(c) No contract for the construction of a project shall be awarded to the firm (including its subsidiaries or affiliates) that designed the supplied 30% design bridging documents for the project (except with the approval of the head of the agency or authorized representative).

(d) Warrant and Disclosure. The warrant and disclosure requirements of this paragraph apply with full force to both the contractor and all subcontractors. the contractor warrants that, to the best of the contractor's knowledge and belief, there are no relevant facts or circumstances which would give rise to an organizational conflict of interest, as defined in far subpart 9.5, and that the contractor has disclosed all relevant information regarding any actual or potential conflict. the contractor agrees it shall make an immediate and full disclosure, in writing, to the contracting officer of any facts that may cause a reasonably prudent person to question the contractor's impartiality because of the appearance or existence of bias or an unfair competitive advantage.