ATTACHMENT 1 - Specifications Volume 1.pdf

PROJECT MANUAL

OKLAHOMA CITY, OK VAMC

SPS EXPANSION

VA PROJECT NUMBER 635-3411

CLH PROJECT NUMBER 2013-28

VOLUME ONE (Specification Sections 0 – 14)

July 10, 2020

Calvin L. Hinz A R C H I T E C T S, P.C.

3705 North 200th Street Elkhorn, NE 68022

Tel: (402) 291-6941 Fax: (402) 291-9193

CLH

05-01-20

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

VOLUME ONE (Specification Sections 00 – 14)

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 03-20 01 23 00 Alternates --- 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 03-20 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 05-20 01 42 19 Reference Standards 09-19 01 45 00 Quality Control 03-19 01 45 29 Testing Laboratory Services 11-18 01 57 19 Temporary Environmental Controls 01-11 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 09-13 01 81 13 Sustainable Construction Requirements 10-17 01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17 02 82 13.19 Asbestos Floor Title and Mastic Abatement 01-21

DIVISION 03 – CONCRETE

03 30 00 Cast-in-Place Concrete 07-19 03 54 00 Self-Leveling Concrete Floor Underlayment ---

DIVISION 04 – MASONRY

04 05 13 Masonry Mortaring 10-17 04 05 16 Masonry Grouting 02-16 04 20 00 Unit Masonry 08-17

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 11-18 05 31 00 Steel Decking 02-16

00 01 10-2

SECTION NO. DIVISION AND SECTION TITLES DATE

05 36 00 Composite Metal Decking 10-15 05 40 00 Cold-Formed Metal Framing 05-16 05 50 00 Metal Fabrications 08-18 05 51 00 Metal Stairs 10-15

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17 06 16 63 Cementitious Sheathing 02-16 06 20 00 Finish Carpentry 08-16

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 01 50.19 Preparation for Re-Roofing 02-16 07 08 00 Facility Exterior Closure Commissioning 11-16 07 13 00 Sheet Waterproofing 04-13 07 21 13 Thermal Insulation 10-17 07 22 00 Roof and Deck Insulation 02-16 07 27 27 Fluid-Applied Membrane Air Barrier, Vapor Retarding 02-16 07 42 63 Prefabricated Brick Panel System --- 07 54 23 Thermoplastic Polyolefin (TPO) Roofing 08-16 07 60 00 Flashing and Sheet Metal 09-18 07 71 00 Roof Specialties 10-15 07 81 00 Applied Fireproofing 10-17 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17 07 95 13 Expansion Joint Cover Assemblies 02-16

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 14 00 Interior Wood Doors 02-16 08 17 10 Integrated Door Assemblies 02-16 08 31 13 Access Doors and Frames 02-16 08 51 13 Aluminum Windows 04-20 08 56 19 Pass Windows 02-16 08 71 00 Door Hardware 04-20 08 71 13.11 Low Energy Power Assist Door Operators 08-16 08 80 00 Glazing 10-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 06 00 Schedule for Finishes 04-15 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 04-20 09 30 13 Ceramic/Porcelain Tiling 10-15 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 02-16 09 65 19 Resilient Tile Flooring 05-18 09 68 00 Carpeting 10-15

00 01 10-3

SECTION NO. DIVISION AND SECTION TITLES DATE

09 91 00 Painting 01-16 09 96 59 Resinuous Specialty Glazed Coating Systems 07-14

DIVISION 10 – SPECIALTIES

10 21 13 Toilet Compartments 12-15 10 28 00 Toilet, Bath, and Laundry Accessories 02-16 10 44 13 Fire Extinguisher Cabinets 08-18 10 51 13 Metal Lockers ---

DIVISION 11 – EQUIPMENT

11 71 01 Medical Washing and Sterilizing Equipment 02-11

DIVISION 12 – FURNISHINGS

12 32 00 Manufactured Wood Casework 09-15 12 34 00 Manufactured Plastic Casework 10-15 12 36 00 Countertops 12-18

DIVISION 13 - SPECIAL CONSTRUCTION (NOT USED)

DIVISION 14– CONVEYING EQUIPMENT

14 21 00 Vertical Expansion of Electric Traction Elevator 10-19 14 91 33 Gravity Soiled Linen Chutes 03-20

VOLUME TWO (Specification Sections 21 – 28)

DIVISION 21- FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16 21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 05 19 Meters and Gages for Plumbing Piping 09-15 22 05 23 General-Duty Valves for Plumbing Piping 09-15 22 07 11 Plumbing Insulation 09-19 22 08 00 Commissioning of Plumbing Systems 11-16 22 11 00 Facility Water Distribution 11-19 22 11 23 Domestic Water Pumps 09-15 22 13 00 Facility Sanitary and Vent Piping 09-15 22 14 00 Facility Storm Drainage 09-15 22 15 00 General Service Compressed-Air Systems 09-15 22 35 00 Domestic Water Heat Exchangers 12-16 22 40 00 Plumbing Fixtures 09-15

00 01 10-4

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 02-20 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 02-20

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

02-20

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-20 23 07 11 HVAC and Boiler Plant Insulation 02-20 23 08 00 Commissioning of HVAC Systems 02-20 23 09 23 Direct-Digital Control System for HVAC 09-11 23 21 13 Hydronic Piping 02-20 23 21 23 Hydronic Pumps 02-20 23 22 13 Steam and Condensate Heating Piping 02-20 23 25 00 HVAC Water Treatment 02-20 23 31 00 HVAC Ducts and Casings 02-20 23 34 00 HVAC Fans 02-20 23 36 00 Air Terminal Units 02-20 23 37 00 Air Outlets and Inlets 02-20 23 40 00 HVAC Air Cleaning Devices 03-20 23 72 00 Air-to-Air Energy Recovery Equipment 03-20 23 73 00 Indoor Central-Station Air-Handling Units 03-20 23 74 13 Packaged, Outdoor, Central-Station Air-Handling Units 03-20 23 82 16 Air Coils 03-20

DIVISION 25 – INTEGRATED AUTOMATION (NOT USED)

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 05 73 Overcurrent Protective Device Coordination Study 01-18 26 08 00 Commissioning of Electrical Systems 11-16 26 09 23 Lighting Controls 01-18 26 22 00 Low-Voltage Transformers 01-18 26 24 16 Panelboards 01-18 26 27 26 Wiring Devices 01-18 26 29 11 Motor Controllers 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 41 00 Facility Lightning Protection 01-17 26 43 13 Surge Protective Devices 01-17 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 06-15

00 01 10-5

SECTION NO. DIVISION AND SECTION TITLES DATE

27 05 33 Raceways and Boxes for Communications Systems 10-18 27 08 00 Commissioning of Communications Systems 11-16 27 10 00 Control, Communication and Signal Wiring 06-15 27 11 00 Communications Equipment Room Fittings 06-15 27 15 00 Communications Structured Cabling 01-16

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

28 05 26 Grounding and Bonding for Electronic Safety and Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16 28 13 00 Physical Access Control System 10-11 28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK (NOT USED)

DIVISION 32 – EXTERIOR IMPROVEMENTS (NOT USED)

DIVISION 33 – UTILITIES (NOT USED)

DIVISION 34 – TRANSPORTATION (NOT USED)

DIVISION 48 – Electrical Power Generation (NOT USED)

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

GI001 COVER SHEET

GI002 INDEX SHEET

GI003 GENERAL NOTES

GI004 LIFE SAFETY PLAN-SIXTH FLOOR

GI005 LIFE SAFETY PLAN- SEVENTH FLOOR AND PENTHOUSE FLOOR

GI006 LIFE SAEFTY PLAN – EIGHTH FLOOR

STRUCTURAL

SS101 6TH AND 7TH FLOOR FRAMING PLANS

SS102 8TH FLOOR FRAMING PLAN

SS103 PENTHOUSE AND MACHINE ROOM FRAMING PLANS

SS104 ROOF FRAMING PLAN

SS105 DETAILS

SS106 DETAILS

SS107 GENERAL NOTES AND DETAILS

ARCHITECTURAL

AD101 ARCHITECTURAL FLOOR PLAN SIXTH FLOOR DEMOLITION

AD102 ARCHITECTURAL FLOOR PLAN SEVENTH FLOOR DEMOLITION

AD103 ARCHITECTURAL FLOOR PLAN EIGHTH FLOOR DEMOLITION

AD104 REFLECTED CEILING PLAN – SIXTH FLOOR DEMOLITION

AS101 ARCHITECTURAL FLOOR PLAN-SIXTH FLOOR

AS102 ARCHITECTURAL FLOOR PLAN-SEVENTH FLOOR

AS103 ARCHITECTURAL FLOOR PLAN-EIGHTH FLOOR

AS104 PENTHOUSE AND MACHINE ROOM PLAN

AS105 ROOF PLAN

AS106 FINISHED FLOORING PLAN SIXTH FLOOR

AS107 FINISHED FLOORING PLAN EIGHTH FLOOR

AS108 SIXTH FLOOR SPS - AREA A

AS109 SIXTH FLOOR SPS - AREA B

00 01 15 - 2

AS110 EIGHTH FLOOR - AREA A & B

AS201 EXTERIOR ELEVATIONS

AS202 EXTERIOR ELEVATIONS

AS301 BUILDING SECTIONS

AS302 ELEVATOR SECTIONS

AS303 STAIR 7 SECTIONS

AS304 STAIR 14 SECTIONS

AS401 WALL SECTIONS

AS402 WALL SECTIONS

AS403 WALL SECTIONS

AS404 WALL SECTIONS

AS405 WALL SECTIONS

AS500 WALL TYPES

AS501 WALL AND PLAN DETAILS

AS502 WALL DETAILS

AS503 WALL DETAILS

AS601 ROOM FINISH SCHEDULE

AS701 DOOR SCHEDULE

AS702 DOOR AND WINDOW TYPES

AS703 DOOR DETAILS

AS704 WINDOW DETAILS

AS800 FIFTH FLOOR REFLECTED CEILING PLAN

AS801 SIXTH FLOOR - REFLECTED CEILING PLAN

AS802 SEVENTH FLOOR - REFLECTED CEILING PLAN

AS803 EIGHTH FLOOR - REFLECTED CEILING PLAN

AS901 INTERIOR ELEVATIONS

AS902 INTERIOR ELEVATIONS

AS903 INTERIOR ELEVATIONS

AS904 INTERIOR ELEVATIONS

AS905 INTERIOR ELEVATIONS

AS906 CASEWORK & MISCELLANEOUS DETAILS

FIRE PROTECTION

FG101 FIRE SUPPRESSION SYMBOLS, LEGEND, SCHEDULE & GENERAL NOTES

FD101 SIXTH FLOOR FIRE PROTECTION DEMOLITION PLAN

FD102 SEVENTH FLOOR FIRE PROTECTION DEMOLITION PLAN

FD103 EIGHTH FLOOR FIRE PROTECTION DEMOLITION PLAN

FX101 SIXTH FLOOR FIRE PROTECTION PLAN

00 01 15 - 3

FX102 SEVENTH & EIGHTH FLOOR FIRE PROTECTION PLANS

PLUMBING

PD101 SIXTH FLOOR PLUMBING DEMOLITION PLAN

PD102 SEVENTH FLOOR PLUMBING DEMOLITION PLAN

PD103 EIGHTH FLOOR PLUMBING DEMOLITION PLAN

PL101 SIXTH FLOOR PLUMBING PLAN

PL102 SEVENTH FLOOR PLUMBING PLAN

PL103 EIGHTH FLOOR PLUMBING PLAN

P-401 PARTIAL PLUMBING PLANS

P-501 PLUMBING DETAILS & SCHEDULES

P-601 PLUMBING RISER DIAGRAMS

MECHANICAL

MG101 MECHANICAL SYMBOLS LEGEND AND GENERAL NOTES

MD101 SIXTH FLOOR HVAC DEMOLITION PLAN

MD102 SEVENTH FLOOR HVAC DEMOLITION PLAN

MD103 EIGHTH FLOOR HVAC DEMOLITION PLAN

MD104 SIXTH FLOOR HVAC PIPING DEMOLITION PLAN

MH101 SIXTH FLOOR HVAC PLAN

MH102 SEVENTH FLOOR HVAC PLAN

MH103 EIGHTH FLOOR HVAC PLAN

MH104 ROOF MECHANICAL PLAN

MP101 SIXTH FLOOR HVAC PIPING PLAN

MP102 EIGHTH FLOOR HVAC PIPING PLAN

M-501 MECHANICAL DETAILS

M-502 MECHANICAL DETAILS

M-503 MECHANICAL CONTROL DIAGRAMS

M-601 MECHANICAL SCHEDULES

M-602 MECHANICAL SCHEDULES

ELECTRICAL

EG101 GENERAL ELECTRICAL NOTES & SYMBOLS LEGEND

00 01 15 - 4

ED101 SIXTH AND SEVENTH FLOOR ELECTRICAL DEMOLITION PLAN

ED102 EIGHTH FLOOR ELECTRICAL DEMOLITION PLAN

EL101 SIXTH FLOOR LIGHTING PLAN

EL102 SEVENTH & EIGHTH FLOOR LIGHTING PLANS

EP100 BASEMENT POWER PLAN

EP101 SIXTH FLOOR POWER PLAN

EP102 SEVENTH & EIGHTH FLOOR POWER PLANS

EY101 SIXTH FLOOR SPECIAL SYSTEMS PLAN

EY102 SEVENTH & EIGHTH FLOOR SPECIAL SYSTEMS PLANS

E-501 ELECTRICAL DETAILS

E-601 POWER RISER DIAGRAM

E-602 ELECTRICAL SCHEDULES AND DETAILS

- - - END - -

03-01-20 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 NOT USED

1.12 PROFESSIONAL SURVEYING SERVICES

1.13 LAYOUT OF WORK

1.14 AS-BUILT DRAWINGS

1.15 WARRANTY MANAGEMENT

1.16 USE OF ROADWAYS

1.17 COR'S FIELD OFFICE: NOT REQUIRED

1.18 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.19 TEMPORARY USE OF EXISTING ELEVATORS

1.20 NOT USED

1.21 TEMPORARY TOILETS

1.22 AVAILABILITY AND USE OF UTILITY SERVICES

1.23 NEW TELEPHONE EQUIPMENT

1.24 TESTS

1.25 INSTRUCTIONS

1.26 GOVERNMENT-FURNISHED PROPERTY

ii

1.27 RELOCATED EQUIPMENT ITEMS

1.28 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

1.29 CONSTRUCTION SIGN

1.30 SAFETY SIGN

1.31 NOT USED

1.32 NOT USED

1.33 NOT USED

1.34 NOT USED

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for Project Number 635-3411 Expand

SPD as required by drawings and specifications.

B. Visits to the site by Bidders may be made in accordance with what is listed in solicitation and at the discretion of the Contracting

Officer.

C. Offices of CLH Architects, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. Before placement and installation of work subject to tests by testing laboratory retained by the contractor, the Contractor shall notify the

COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection.

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

F. The Key Personnel assigned by the contractor for the performance of work on this contract shall be acceptable to VA in terms of personal and professional conduct and technical knowledge. Should the assignment to this contract of any person by the contractor be deemed to conflict with the interests of VA, or in the event performance is deemed to be unsatisfactory at any time during the life of the contract, the Contracting Officer may notify the contractor and request the person be removed from the assignment. The reason for removal will be documented and a request to receive key personnel replacement within three (3) business days of the notification will be made. Replacement of key personnel qualifications shall be equal to or greater than those of the key personnel being replaced. Employment and staffing difficulties will not be justification for failure to meet established schedules. The contractor is required to submit a resume with qualifications for the proposed replacement which shall be approved by the COR and CO prior to the replacement starting work.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes general construction, alterations, mechanical and electrical work, utility systems, elevators and dumbwaiters, necessary removal of existing structures and construction and certain other items.

B. ALTERNATES: For Alternate Bid Items refer to Section 01 23 00-

Alternates.

C. PROJECT PHASING:

Phase 1: 8TH Floor new construction including, but not limited to:

A) Surgery Locker, Lounge and connecting Corridor C8-15 (shall stop at

Column Line F-10 in Phase 1).

At the southern end of Corridor C8-15 at Column Line F, construct exterior wall consistent with the exterior wall type and detailing, including roof system adaptation, as indicated for the new west wall to be constructed at this location.

b. Renovate / retrofit roof and flashing system in this area to drain to adjacent roof drainage inlets.

c. Defer installation of double-egress Door C8-14 in Corridor C8-

15 at Column Line F until Phase 3 Work.

B) Extension of P-11 Elevator and Stair 7.

C) Stair 14 enclosure from 8th floor up.

D) Removal of existing Stair 14 and construction / completion of Stair

14 from 7th floor to 8th floor.

Phase 2: 6th Floor renovation / construction of SPS Locker and expansion of SPS, plus any related work necessary in the 5th Floor interstitial space in conjunction with the 6th floor renovation work.

Phase 3: Construct Corridor C8-14 (between Column Lines F & G, including installation of double-egress Door C8-14 in Corridor C8-15 at Column

Line F. (Deduct Alternate: See Section 01 23 00 - Alternates)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Not Used

D. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including toolboxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

E. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of

“sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. Separate permits shall be issued for General Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the

Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

D. Working space and space available for storing materials shall be as determined by the COR.

E. Workmen are subject to rules of Medical Center applicable to their conduct. Execute work in such a manner as to interfere as little as possible with work being done by others. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times.

F. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not more than two workdays. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

G. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR. All such actions shall be coordinated with the COR or Utility Company involved:

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

H. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks.

To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to ensure accomplishment of this work in successive phases mutually agreeable to

Medical Center Director, COR and Contractor.

I. Building F in the immediate area will be vacated by Government in accordance with above phasing beginning immediately after date of receipt of Notice to Proceed and turned over to Contractor. The remainder of Building F will be occupied during performance of work;

but immediate areas of alterations will be vacated.

1. Certain areas of Building No. F will be occupied by Medical Center personnel for various periods during the Construction period.

Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered. Contractor shall permit access to Department of

Veterans Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and staff access.

Coordinate alteration work in areas occupied by Department of

Veterans Affairs so that Medical Center operations will continue during the construction period.

2. Immediate areas of alterations not mentioned in preceding

Subparagraph 1 will be temporarily vacated while alterations are performed.

J. Temporary Barricades: Comply with VA standards and code requirements for erection of barricades. Provide appropriate warning signs to inform personnel and the public of the hazard being protected against.

Where needed provide lighting, including flashing lights. Maintain egress routes as required. Coordinate with COR.

K. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

L. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR

1. No utility service such as water, gas, medical gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request for outage of any utility services to COR, in writing, 7 calendar days in advance of proposed utility outage for repair, replace, or tie-in. Request shall state reason, location, date, exact time of, and approximate duration of such outage.

3. Contractor will be advised (in writing) of approval of request, or of which other date, time, and location of such utility outage will cause least inconvenience to operations of Medical Center. Utility outage time approved by Medical Center may occur at other than

Contractor's normal working hours.

4. Major utility outage of any main supply utilities system to the

Medical Center must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

M. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

N. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

O. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR and a representative of VA Supply Service, of areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the Contracting Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur, and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR and/or Supply Representative, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by

Contractor with new items in accordance with specifications which will be furnished by Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE

CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR 52.243-4).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled, and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are identified by attached tags or noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

4. PCB Transformers and Capacitors: The Contractor shall be responsible for disposal of the Polychlorinated Biphenyl (PCB) transformers and capacitors. The transformers and capacitors shall be taken out of service and handled in accordance with the procedures of the

Environmental Protection Agency (EPA) and the Department of

Transportation (DOT) as outlined in Code of Federal Regulation

(CFR), Titled 40 and 49 respectively. The EPA's Toxic Substance

Control Act (TSCA) Compliance Program Policy Nos. 6-PCB-6 and 6-PCB-

7 also apply. Upon removal of PCB transformers and capacitors for disposal, the "originator" copy of the Uniform Hazardous Waste

Manifest (EPA Form 8700-22), along with the Uniform Hazardous Waste

Manifest Continuation Sheet (EPA Form 8700-22A) shall be returned to the Contracting Officer who will annotate the contract file and transmit the Manifest to the Medical Center's Chief.

a. Copies of the following listed CFR titles may be obtained from the Government Printing Office:

40 CFR 261........Identification and Listing of Hazardous Waste

40 CFR 262........Standards Applicable to Generators of Hazardous

Waste

40 CFR 263........Standards Applicable to Transporters of

Hazardous Waste

40 CFR 761........PCB Manufacturing, Processing, Distribution in

Commerce, and use Prohibitions

49 CFR 172........Hazardous Material tables and Hazardous

Material Communications Regulations

49 CFR 173........Shippers - General Requirements for Shipments and Packaging

49 CRR 173........Subpart A General

49 CFR 173........Subpart B Preparation of Hazardous Material for

Transportation

49 CFR 173........Subpart J Other Regulated Material; Definitions and Preparation

TSCA..............Compliance Program Policy Nos. 6-PCB-6 and 6-

PCB-7

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the

Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

D. Not Used

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4) and "DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.11 NOT USED

1.12 PROFESSIONAL SURVEYING SERVICES

A registered professional land surveyor or registered civil engineer whose services are retained and paid for by the Contractor shall perform services specified herein and in other specification sections.

The Contractor shall certify that the land surveyor or civil engineer is not one who is a regular employee of the Contractor, and that the land surveyor or civil engineer has no financial interest in this contract.

1.13 LAYOUT OF WORK

A. The Contractor shall lay out the work from Government established base lines and benchmarks, indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The

Contractor shall furnish, at Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them.

If such marks are destroyed by the Contractor or through Contractor's negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

(FAR 52.236-17)

B. Establish and plainly mark center lines for each building and corner of column lines and/or addition to each existing building, and such other lines and grades that are reasonably necessary to properly assure that location, orientation, and elevations established for each such structure and/or addition, are in accordance with lines and elevations shown on contract drawings.

C. Following completion of general mass excavation and before any other permanent work is performed, establish and plainly mark (through use of appropriate batter boards or other means) sufficient additional survey control points or system of points as may be necessary to assure proper alignment, orientation, and grade of all major features of work. Survey shall include, but not be limited to, location of lines and grades of footings, exterior walls, center lines of columns in both directions, major utilities and elevations of floor slabs:

1. Such additional survey control points or system of points thus established shall be checked and certified by a registered land surveyor or registered civil engineer. Furnish such certification to the COR before any work (such as footings, floor slabs, columns, walls, utilities and other major controlling features) is placed.

D. During progress of work, and particularly as work progresses from floor to floor, Contractor shall have line grades and plumbness of all major form work checked and certified by a registered land surveyor or registered civil engineer as meeting requirements of contract drawings.

Furnish such certification to the COR before any major items of concrete work are placed. In addition, Contractor shall also furnish to the COR certificates from a registered land surveyor or registered civil engineer that the following work is complete in every respect as required by contract drawings.

1. Lines of each building and/or addition.

2. Elevations of bottoms of footings and tops of floors of each building and/or addition.

3. Not Used

E. Whenever changes from contract drawings are made in line or grading requiring certificates, record such changes on a reproducible drawing bearing the registered land surveyor or registered civil engineer seal, and forward these drawings upon completion of work to COR.

F. The Contractor shall perform the surveying and layout work of this and other articles and specifications in accordance with the provisions of

Article "Professional Surveying Services".

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.15 WARRANTY MANAGEMENT

A. Warranty Management Plan: Develop a warranty management plan which contains information relevant to FAR 52.246-21 Warranty of Construction at least 30 days before the planned pre-warranty conference, submit four sets of the warranty management plan. Include within the warranty management plan all required actions and documents to assure that the

Government receives all warranties to which it is entitled. The plan must be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesman, or of engineering background, not necessarily familiar with this contract. The term “status” as indicated below must include due date and whether item has been submitted or was approved. Warranty information made available during the construction phase must be submitted to the Contracting Officer for approval prior to each monthly invoice for payment. Assemble approved information in a binder and turn over to the Government upon acceptance of the work. The construction warranty period will begin on the date of the project acceptance and continue for the product warranty period. A joint 4 month and 9-month warranty inspection will be conducted, measured from time of acceptance, by the Contactor and the Contracting Officer. Include in the warranty management plan, but not limited to, the following:

1. Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers within the company of the Contractor, subcontractors, manufacturers or suppliers involved.

2. Furnish with each warranty the name, address and telephone number of each of the guarantor’s representatives nearest project location.

3. Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers and for all commissioned systems such as fire protection and alarm systems, sprinkler systems and lightning protection systems, etc.

4. A list for each warranted equipment item, feature of construction or system indicating:

a. Name of item.

b. Model and serial numbers.

c. Location where installed.

d. Name and phone numbers of manufacturers and suppliers.

e. Name and phone numbers of manufacturers or suppliers.

f. Names, addresses and phone numbers of sources of spare parts.

g. Warranties and terms of warranty. Include one-year overall warranty of construction, including the starting date of warranty of construction. Items which have extended warranties must be indicated with separate warranty expiration dates.

h. Starting point and duration of warranty period.

i. Summary of maintenance procedures required to continue the warranty in force.

j. Cross-reference to specific pertinent Operation and Maintenance manuals.

k. Organizations, names and phone numbers of persons to call for warranty service.

l. Typical response time and repair time expected for various warranted equipment.

5. The plans for attendance at the 4 and 9-month post construction warranty inspections conducted by the government.

6. Procedure and status of tagging of all equipment covered by extended warranties.

7. Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

B. Performance Bond: The Performance Bond must remain effective throughout the construction period.

1. In the event the Contractor fails to commence and diligently pursue any construction warranty work required, the Contracting Officer will have the work performed by others, and after completion of the work, will charge the remaining construction warranty funds of expenses incurred by the Government while performing the work, including, but not limited to administrative expenses.

2. In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the contractor’s expenses, the Contracting Officer will have the right to recoup expenses from the bonding company.

3. Following oral or written notification of required construction warranty repair work, the Contractor shall respond in a timely manner. Written verification will follow oral instructions. Failure to respond will be cause for the Contracting Officer to proceed against the Contractor.

C. Pre-Warranty Conference: Prior to contract completion, and at a time designated by the Contracting Officer, the Contractor shall meet with the Contracting Officer to develop a mutual understanding with respect to the requirements of this section. Communication procedures for

Contractor notification of construction warranty defects, priorities with respect to the type of defect, reasonable time required for

Contractor response, and other details deemed necessary by the

Contracting Officer for the execution of the construction warranty will be established/ reviewed at this meeting. In connection with these requirements and at the time of the Contractor’s quality control completion inspection, furnish the name, telephone number and…