Attachment_1_Specifications_072022.pdf

U.S. Department of the Interior SPECIFICATIONS Bureau of Reclamation Western Colorado Area Office Grand Junction, Colorado July 2022

WATERCRAFT ANS

DECONTAMINATION FACILITY

AT VALLECITO RESERVOIR

Pine River Project – Colorado

WATERCRAFT ANS DECONTAMINATION FACILITY

AT VALLECITO RESERVOIR

Pine River Project - Colorado

Vallecito, CO

FOREWORD

This solicitation involves constructing a watercraft decontamination facility at Vallecito

Reservoir. The watercraft decontamination station is intended to prevent the spread of aquatic native species (ANS) such as zebra and quagga mussels.

A PREBID SITE VISIT WILL BE HELD ON SEPTEMBER 8, 2022, BEGINNING AT

1:00 PM (MDT). ATTENDEES TO MEET AT THE VALLECITO RESERVOIR

BOAT RAMP PARKING LOT LOCATED 16 MILES NORTH OF BAYFIELD,

COLORADO.

PLEASE REGISTER FOR THE SITE VISIT BY NOTIFYING THE CONTRACTING

OFFICER (DWANE D. ESPLIN) VIA EMAIL AT DESPLIN@USBR.GOV.

FOR INFORMATION REGARDING BUREAU OF RECLAMATION'S PUBLICATION

"RECLAMATION SAFETY AND HEALTH STANDARDS" INCLUDING REVISIONS AT

https://intra.usbr.gov/safety/rshs/ WHICH IS APPLICABLE TO WORK UNDER THIS

CONTRACT, SEE CLAUSE AT "WBR 1452.223-81 SAFETY AND HEALTH."

mailto:DESPLIN@USBR.GOV

Watercraft ANS Decontamination Facility at Vallecito Reservoir

Table of Contents

00 01 10 - 1

SECTION C - DESCRIPTION / SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 14 10 Use of Site 01 14 12 Work Restrictions and Limitations 01 31 19 Project Management and Coordination 01 33 00 Submittals 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 21 Removal from Work 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 51 00 Temporary Utilities 01 55 00 Vehicular Access and Parking 01 55 20 Traffic Control 01 56 10 Protection of Existing Installations 01 56 15 Protection of Existing Utilities 01 56 32 Temporary Safety Fence 01 57 20 Environmental Controls 01 57 30 Water Pollution Control 01 57 60 Protected Species 01 60 00 Product Requirements 01 71 20 Surveying 01 74 00 Cleaning and Waste Management 01 78 30 Project Record Documents

DIVISION 02 - EXISTING CONDITIONS

02 41 07 Removal and Disposal of Existing Features

DIVISION 03 - CONCRETE

03 11 10 Concrete Forming 03 20 00 Concrete Reinforcing 03 30 00 Cast-In-Place Concrete 03 62 20 Nonshrink Grout for Equipment and Metalwork

DIVISION 04 - MASONRY

Not Used

Table of Contents 00 01 10 - 2

DIVISION 05 - METALS

05 50 00 Metal Fabrications

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 Rough Carpentry

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 40 Batt and Blanket Insulation

DIVISION 08 - OPENINGS

08 11 10 Steel Doors and Frames 08 36 13 Overhead Doors 08 71 00 Door Hardware

DIVISION 09 - FINISHES

09 29 00 Gypsum Board 09 65 10 Resilient Wall Base 09 96 20 Coatings

DIVISION 10 – SPECIALTIES

10 28 13 Toilet Accessories

DIVISION 11 - EQUIPMENT

11 11 26 Watercraft Decontamination Equipment

DIVISION 12 - 21

Not Used

DIVISION 22 - PLUMBING

22 11 16 Domestic Water Piping 22 13 19 Sanitary Waste and Vent Piping and Toilets 22 40 00 Plumbing Fixtures

00 01 10 - 3

DIVISION 23 - 25

DIVISION 26 - ELECTRICAL

26 05 02 Basic Electrical Materials and Methods 26 05 10 Conductors and Cables 26 05 20 Grounding and Bonding 26 05 33 Electrical Conduit 26 24 16 Distribution Panelboards 26 27 10 Meter Socket

DIVISION 27 - 30

DIVISION 31 - EARTHWORK

31 11 00 Clearing and Grubbing 31 23 02 Compacting Earth Materials 31 23 11 Earthwork 31 23 39 Disposal of Excavated Materials

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 17 10 Parking Curbs 32 17 20 Painted Traffic Lines and Markings 32 28 46 Signage

00 01 10 - 4

DIVISION 33 - UTILITIES

33 05 31 Precast Concrete Manholes and Structures

DIVISION 33 – 42

Not Used

DIVISION 43 - PROCESS GAS AND LIQUID HANDLING, PURIFICATION, AND

STORAGE EQUIPMENT

43 41 14 Propane Gas Piping System

DIVISION 44 – 50

Not Used

DIVISION 51 – INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors

DIVISION 52 - DRAWINGS

52 00 00 Drawings

DIVISION 53 - GEOLOGIC INVESTIGATIONS AND RECORDS

END OF CONTENTS

Summary of Work 01 11 00 - 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.01 LOCATION

A. Work is located approximately 16 miles north of Bayfield, Colorado in La Plata County.

1.02 PRINCIPAL COMPONENTS OF WORK

A. Performing site work which includes, but not limited to:

1. Removal of existing features including the restrooms and accessible parking slab.

B. Placing cast-in-place concrete for the:

1. ANS Decontamination Equipment and Restroom Building

2. Wash Pad

3. Propane Tank Slab

4. Accessible Parking Slab and Sidewalk

C. Furnishing and installing a precast manhole.

D. Constructing a ANS Decontamination Equipment and Restroom Building

E. Furnishing and installing watercraft decontamination equipment.

F. Providing required utilities for the new building including an upgraded electrical service and furnishing a propane tank and required piping.

G. Connecting the new building to the existing and water and sewer systems.

1.03 SCHEDULE

A. All work shall be completed by May 1.

1.04 SPECIFICATIONS REQUIREMENTS

A. Requirements in Division 1, General Requirements, apply to Divisions 2 through 52.

B. Imperative statements in these specifications are Contractor requirements, unless otherwise stated.

C. Where specifications are written in streamlined form, words “shall be” are included by inference where a colon (:) is used within sentence or phrase.

Summary of Work 01 11 00 - 2

1.05 DEFINITIONS

A. When specifications use a word or term defined in Federal Acquisition Regulations (FAR), definition of the word or term shall be in accordance with FAR sections in effect at the time solicitation was issued.

1.06 ACRONYMS

A. The following acronyms apply to specifications Divisions 1 through 52:

1. ANS: Aquatic Native Species

2. CO: Contracting Officer.

3. COR: Contracting Officer’s Representative.

4. CPW: Colorado Parks and Wildlife

5. PRID: Pine River Irrigation District.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

END OF SECTION

at Vallecito Reservoir .

Use of Site 01 14 10 - 1

SECTION 01 14 10

USE OF SITE

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. Cleaning Manual-2012 Inspection and Cleaning Manual for

Equipment and Vehicles to Prevent the Spread of Invasive Species (Technical memorandum No. 86-68220-07-05) 2012 Edition Available online at:

http://www.usbr.gov/mussels/prevention

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 14 10-1, Land Use and Landscape Rehabilitation Plan:

1. For each Contractor use site on Government land.

a. Show use location and extent of impact. Uses include but are not limited to the following:

1) Buildings and service areas including offices, shops, warehouses, storage areas, fuel and oil storage areas, and fabrication yards.

2) Parking areas, temporary roads, and haul routes.

3) First-aid and medical facilities.

4) Areas for processing, storing, and disposing of waste materials from construction operations.

5) Temporary fences.

1.04 PROJECT CONDITIONS

A. Government land as shown on Drawing No. 191-417-2 may be used for required construction facilities.

http://www.usbr.gov/mussels/prevention

Use of Site 01 14 10 - 2

B. When private land is used for construction facilities, or other construction purposes, make necessary arrangements associated with use of private land.

C. Location, construction, operation, maintenance, and removal of construction facilities on Government land will be subject to approval of COR.

D. Do not interfere with work of other contractors or the Government in vicinity, or with reservations made by the Government for use of such land.

E. Housing for construction personnel will not be permitted on Government land, except housing for guards or watchmen as may be approved by COR.

1.05 INTERUPTION OF SERVICE

A. Contractors shall provide and maintain four portable toilets for public. The portable toilets shall be available prior to beginning the demolition of the existing restroom until the time the new restroom is completed and accepted by the COR.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 CLEANING

A. Construction equipment:

1. Before bringing on site, clean construction equipment to remove dirt, vegetation, and other organic material to prevent introduction of noxious weeds, and invasive plant and animal species.

2. Contractor cleaning procedures shall result in equipment being cleaned as well or better than the procedures described in Cleaning Manual.

3. COR will inspect construction equipment following procedures described in Cleaning Manual before allowing equipment onsite.

3.02 CLEANING FOR AQUATIC NUISANCE SPECIES

A. Any equipment used for pumping, including suction lines, pumps and discharge hoses, shall be inspected and, if needed, decontaminated prior to use at Vallecito Reservoir.

B. The contractor shall notify the COR at least 3-working days before needing pumping equipment inspected.

C. The COR will arrange inspection of pumping equipment with Colorado Parks and Wildlife staff at Vallecito Reservoir

Use of Site 01 14 10 - 3

3.03 RESTORATION

A. Restore Contractor use areas to pre-construction condition.

B. After completion of work, regrade and scarify Government land used for construction purposes and not required for completed installation so that surfaces blend with natural terrain and are in a condition that will facilitate revegetation, provide proper drainage, and prevent erosion.

Use of Site 01 14 10 - 4

This page intentionally left blank.

Work Restrictions and Limitations 01 14 12 - 1

SECTION 01 14 12

WORK RESTRICTIONS AND LIMITATIONS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include cost of work restrictions and limitations in prices offered in the Price

Schedule for other items of work.

1.02 RESTRICTIONS, LIMITATIONS, AND WORK SCHEDULES

A. Construction Period: Date of Notice to Proceed by COR through May 1.

B. Hours of Work

1. Onsite construction activities shall only be performed between the hours of 7 am and 6 pm unless authorized by COR.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Work Restrictions and Limitations 01 14 12 - 2

Project Management and Coordination 01 31 19 - 1

SECTION 01 31 19

PROJECT MANAGEMENT AND COORDINATION

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include project management in prices offered in the price schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. RSHS-2009 Reclamation Safety and Health Standards

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 PROJECT COORDINATION

A. The following meetings are considered significant, but do not relieve the Contractor from the responsibility of other meetings required by the specifications.

3.02 PRECONSTRUCTION MEETING

A. Meet with COR prior to the start of construction. The Contractor shall provide as a minimum the Project Manager or Project Superintendent for the Preconstruction Meeting.

Review will include, but may not be limited to:

1. Use of premises by Contractor, Government and PRID.

2. Construction facilities and controls.

3. Access to the work and haul routes.

4. Temporary utilities.

5. Survey layout.

6. Housekeeping procedures.

7. Schedules and sequence of work.

8. Work restrictions.

Project Management and Coordination

01 31 19 - 2

9. Procedures for testing including quality assurance and quality control.

10. Procedures for maintaining record documents.

11. Roles and responsibilities:

a. Bureau of Reclamation organization and personnel.

b. Contractor organization and personnel.

c. Subcontractors.

d. Proposed work schedule.

12. Contract requirements:

a. Progress payments.

b. Invoices.

c. Differing site conditions.

d. Changes.

e. Superintendence by the Contractor.

f. Payment for mobilization and preparatory work.

g. Submittal procedures.

3.03 SAFETY PROGRAM REVIEW MEETING

A. Meet with COR prior to the start of construction. Review will include but may not be limited to:

1. Safety requirements.

2. Monthly joint safety policy meetings.

3. Weekly toolbox safety meetings.

4. Contractor’s safety program.

5. Job hazard analysis.

6. Required safety inspections.

7. Government will monitor Contractor’s operations for compliance with RSHS.

3.04 PROGRESS MEETINGS

A. Meet weekly with COR at work site project office to review work, progress made, difficulties in performing work, and resolution necessary to meet specifications requirements.

B. Meetings will include review of construction schedule.

Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal Inch Drawing Sheet Size and

Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-14 United States National CAD Standards, Version 6

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittal Types, as listed in Table 01 33 00A - List of Submittals:

1. A - Action:

a. Government will respond as to adequacy of submittal.

b. Action submittals are considered to be “shop drawings” within terms of clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I - Informational:

a. Government will acknowledge receipt of Informational submittals.

b. Government may reject an Informational submittal when submittal does not satisfy contract requirements. Contractor shall correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational submittals are considered to be “shop drawings” within terms of clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

01 33 00 - 2

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title, and RSN.

3. Measurement Units: US Customary Units.

4. Provide a unique transmittal number for each submittal.

C. Drawings:

1. Minimum Identification in Title Block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3- by 3-inch space next to title block for review stamps.

3. Size: D size (22 inches by 34 inches) as defined by ASME Y14.1.

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified.

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AUTOCAD, Version

2018 or later.

3) Compile using “eTransmit” utility in AUTOCAD.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings Designated as “Government Format” in Specifications:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on standard drawing 40-D-7102.

2) Government will supply template.

3) Government will supply specific title block information to be used.

6. Final Drawings:

a. Computer drafted.

01 33 00 - 3

b. Government will supply electronic AutoCAD format template.

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

7. Electronic Files: On CD or DVD discs.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets.

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submittals shall be electronic, unless CO requests a hard copy or are files larger than 25 megabytes. When files are larger than 25 megabytes, submit via flash drive.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

01 33 00 - 4

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 14 days after receiving comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

F. A separate transmittal letter shall be used for each individual RSN.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 14 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of 2 or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract, and

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR

52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Return of Submittals:

1. Action Submittals: One set of submittals required for action will be returned either approved, approved with comments, or not approved.

a. Revise and resubmit submittals not approved.

01 33 00 - 5

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

2. Informational Submittals: Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they satisfy contract requirements.

b. Informational submittals that do not satisfy contract requirements may be returned for resubmittal or additional information may be requested.

1.07 TRANSMITTAL

A. Addresses for codes listed in Table 01 33 00A - List of Submittals:

1. CO, Bureau of Reclamation, Name and address will be provided in the

Solicitation.

2. COR, Bureau of Reclamation, Attention: Josh Dunham, Suite 221, 445 West

Gunnison Avenue, Suite 221 Grand Junction, CO 81501, email jdunham@usbr.gov.

3. At pre-construction conference, the COR will provide names and email addresses for other individuals responsible for additional contract administration and requiring receipt of RSNs.

B. Send original transmittal letter with required documents to individual listed in “Send to” column in Table 01 33 00A - List of Submittals.

C. Submittals required by specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

mailto:jdunham@usbr.gov

01 33 00 - 6

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Send to:

CO COR

I-1 Bonds

52.228-15 Performance and Payment Bonds

Within 10 calendar days after award

A 1 paper

I-2 Insurance-work on a Government Installation

(WBR 1452.228-

70)

1) Written certification that the required insurance has been obtained

2) Current certification of insurance for each subcontractor

At least 28 days before commencing onsite work

A

I-3 Liability Insurance

(WBR 1452.228-

70)

Acceptable Certificate of Liability Insurance

Before commencement of work under the contract

A 1 0

I-4 Equal Opportunity 52.222-26

Information required by Executive Order

112246 (SF-100)

Within 30 days following award

A 1

I-5 Release of Claims

(WBR 1452.204-

70)

Release of Claims (DI-137) against the Government

After completion of the work and before final payment

A 1 0

I-6 Labor Standards Data 52.222-11

1) List of subcontractors

2) Statement and acknowledgemen t Form (SF- 1413) for each subcontract

Within 14 days after award of contract

I-7 Payrolls 52.222-08 Copies of all payrolls

Statement of Compliance

Weekly for each week of contract performance

Weekly for each week of contract performance

I-8 Schedules for Construction Contracts

(FAR 52.236-15)

Baseline Schedule

Within 5 days after receipt of Notice to Proceed

A 1 1

I-9 Schedules for Construction Contracts

(FAR 52.236-15)

Updated Schedule

With monthly requests for progress payments, at least 28 days before onsite mobilizations, and as requested by the

CO

A 1 1

01 33 00 - 7

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Send to:

CO COR

01 14 10-1 Use of Site Land Use and

Landscape Rehabilitation Plan

At least 28 days before use of Government land

A 1 1

01 35 10-1 Safety Data Sheets Complete LHM and SDS

At least 14 days before jobsite delivery of hazardous material

I 1 1

01 35 10-2 Safety Data Sheets Updated LHM and SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

I 1 1

01 35 20-1 Safety and Health

WBR 1452.223-81

Safety Program Submitted and accepted at least 28 days before mobilization

A 1 1

01 35 20-2 Safety and Health

WBR 1452.223-81

Monthly Accident Summary Report

Monthly A 1 1

01 55 20-1 Traffic Control Traffic control plan (if construction impacts public recreational traffic)

If required by COR.

Determined based on conditions and impacts to public traffic and general safety of visitors.

A 1 1

01 57 30-1 Water Pollution Control

Water Management Plan

At least 14 days before commencing construction activities

A 1 1

01 57 30-2 Water Pollution Control

Spill Prevention, Control, and Countermeasure (SPCC) Plan

At least 14 days before delivery or storage of oil

A 1 1

01 71 20-1 Surveying Accuracy Check Results

At least 14 days before beginning work on site.

A 1 1

01 71 20-2 Surveying Coordinates and Inlet Pipe Elevation of Existing Septic Tank

Prior to beginning demolition of existing restroom.

A 1 1

01 74 00-1 Cleaning and Waste Management

Certification of hazardous waste disposal (if applicable)

Within 14 days of completion of work

A 1 1

01 78 30-1 Project Record Documents

Final As-Built Drawings

At least 14 days after completing the work

A 1 1

03 20 00-1 Concrete Reinforcing

Reinforcement Diagrams and Lists

At least 14 days before fabrication or procurement

I 1 1

03 30 00-1 Cast-in-Place Concrete

Approval Data At least 14 days before placing concrete

01 33 00 - 8

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Send to:

CO COR

03 62 20-1 Nonshrink Grout for Equipment and Metalwork

Packaged Nonshrink Grout Data

At least 14 days before placing grout

A 1 1

06 10 00-1 Rough Carpentry Approval Design Data

At least 14 days before procuring I-Joists

A 1 1

06 10 00-2 Rough Carpentry Approval Product Data including color charts

At least 14 days before procuring steel sheeting

A 1 1

08 36 13-1 Overhead Doors Manufacturer’s standard color chart for color selection

At least 21 days before procurement

A 1 1

08 36 13-2 Overhead Doors Manufacturer’s storage, handling, installation, and maintenance instructions.

At least 21 days before procurement

A 1 1

09 29 20-1 Gypsum Board Manufacturer’s data for MRP including installation and maintenance instructions.

At least 21 days before procurement

A 1 1

09 96 20-1 Coatings Approval Data At least 21 days before procurement

A 1 1

10 28 13-1 Toilet Accessories Product data for Equipment listed under articles 1.03.A.1

At least 21 days before procurement

A 1 1

11 11 26-1 Watercraft Decontamination Equipment

Product Data for Equipment listed under articles 1.02.B.1 and 2.

At least 21 days before procurement

A 1 1

26 05 02-1 Basic Electrical Materials and Method

Names of licensed electricians

At least 14 days before performing electrical work

A 1 1

26 05 02-1 Basic Electrical Materials and Method

Product Dara for Equipment listed under articles 1.03.A.1 and 2.

At least 14 days before performing electrical work

A 1 1

26 05 02-2 Basic Electrical Materials and Method

Drawings At least 14 days before performing electrical work

A 1 1

26 05 02-3 Basic Electrical Materials and Method

Final As-Built Drawings

At least 14 days before submitting final Progress Payment

01 33 00 - 9

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Send to:

CO COR

33 05 31-1 Precast Manholes and Structures Shop drawings At least 21 days before procurement of precast structures

A 1 1

33 05 13-2 Precast Manholes and Structures

Manufacturer’s product information

At least 21 days before procurement of precast structures

01 33 00 - 10

Safety Data Sheets

01 35 10 - 1

SECTION 01 35 10

SAFETY DATA SHEETS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 DEFINITIONS

A. LHM: List of Hazardous Materials.

B. SDS: Safety Data Sheet.

1. Referred to as Material Safety Data Sheets in the clause at 52.223-3, Hazardous

Material Identifications and Material Safety Data - Alternate 1.

1.03 APPLICATION

A. For the purposes of this contract, “delivered under this contract” in paragraph (b) of the clause at FAR 52.223-3, Hazardous Material Identification and Material Safety Data - Alternate 1, includes:

1. Materials delivered to Government.

2. Materials incorporated into work.

3. Materials used by the Contractor during contract performance at the jobsite.

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 35 10-1, Complete LHM and SDS.

C. RSN 01 35 10-2, Updated LHM and SDS:

1. Comply with paragraph (e) of clause at FAR 52.223-3, Hazardous Material

Identification and Material Safety Data - Alternate 1.

1.05 DELIVERY

A. Do not deliver hazardous materials to jobsite which are not included on original or previously updated LHM and SDS before receipt of updated LHM and SDS by COR.

Safety Data Sheets

01 35 10 - 2

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Safety and Health

01 35 20 - 1

SECTION 01 35 20

SAFETY AND HEALTH

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in the prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. RSHS Reclamation Safety and Health Standards including revisions posted at http://www.usbr.gov/ssle/safety/RSHS/rshs.

html

2. FIST 1-1 (2012) Hazardous Energy Control Program available at:

www.usbr.gov/power/data/fist_pub.html

B. Applicable Tribal and State Safety and Health Regulations for Construction.

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 35 20-1, Safety Program:

1. Written safety program in accordance with of RSHS.

2. Cover aspects of on site and applicable offsite operations and activities associated with this contract.

3. Follow the outline in Appendix B of RSHS

4. Will not be accepted for review by the COR unless it addresses, in order, lettered and numbered per Appendix B, a narrative for each applicable item in the outline.

For items in the outline that do not apply to this contract write “Not applicable to Contract” next to the number/letter.

5. A generic company safety program is not acceptable. Safety Program must be site specific for this contract.

6. Submitted and accepted prior to commencing onsite work, including mobilization.

http://www.usbr.gov/ssle/safety/RSHS/rshs.html

01 35 20 - 2

C. RSN 01 35 20-2, Monthly Accident Summary Report:

1. In accordance of RSHS.

1.04 SAFETY AND HEALTH

A. Provide and maintain a work environment and procedures that:

1. Safeguard the public and Government's personnel, and Contractor employees exposed to Contractor operations and activities.

2. Avoid interruptions of site operations and delays in project completion dates.

3. Control costs in contract performance.

B. Do not begin on site work, including mobilization, until the COR accepts the Safety Program.

C. Participate in Contractor Safety Program Review meeting prior to mobilization.

D. Minimum work crew shall consist of no less than two (2) people, unless approved by

COR.

E. Develop Job Hazard Analyses for each distinct phase of work under the contract:

1. Do not begin a phase of work until a JHA has been prepared and shared with construction employees.

2. Activities involving hazardous materials shall have the appropriate Safety Data

Sheet(s) attached to the JHA.

F. Comply with RSHS, 29 CFR 1926, and FAR 52.236-13. Reclamation Safety and Health Standards promulgated by the Secretary of Labor may be obtained from any regional or area office of the Occupational Safety and Health Administration of the U.S. Department of Labor.

G. Correct safety and health violations identified by the CO or the COR.

H. When the Contractor fails or refuses to correct a compliance directive, the CO may issue an order to stop all or part of the work:

1. When satisfactory corrective action is taken, an order to resume work will be issued.

2. The Contractor shall not be entitled to extension of time, to claim for damage, or to additional compensation by reason of either the directive or stop order.

3. Failure of the CO to order discontinuance of the Contractor’s operations shall not relieve the Contractor of the responsibility for the safety of personnel and property.

I. Maintain accurate record of and report to CO the following occurrences during performance of this contract:

01 35 20 - 3

1. Death.

2. Occupational disease.

3. Traumatic injury to employees or the public.

4. Property damage in excess of $2,500.

J. The rights and remedies of the Government provided in this section are in addition to any other rights and remedies provided by law or under this contract:

1. In the event there is a conflict between requirements contained in RSHS, specification paragraphs, Contractor’s approved Safety Program, referenced safety and health codes, and standards, or the U.S. Department of Labor Construction Safety and Health Standards promulgated under Section 107 of the Contract Work Hours and Safety Standards Act (40 U.S.C. 327 et seq.), as amended, the more stringent requirement shall prevail.

K. Provide appropriate safety barricades, signs, and signal lights.

L. Perform training as required by Federal, State, and local regulations prior to any activity that requires it:

1. Training records must be submitted to the COR upon request.

2. In no case shall an employee perform work until required training is complete.

M. Do not require persons employed in performance of this contract, including subcontracts, to work under conditions which are unsanitary, hazardous, or dangerous to the employee’s health or safety.

1.05 MEDICAL SERVICES AND FIRST AID

A. Provide medical services and first aid in accordance with RSHS Section 5.

B. Make facilities and services available for emergency aid to employees, subcontractor employees, and Government employees:

1. Provide services free of charge to Government employees injured on job.

2. Government employees not injured on job may be charged fees for rendered services based on reasonable and established fee rates.

C. Ambulance Service:

1. Arrange for dependable ambulance service in accordance with RSHS paragraph

5.4.

2. On site ambulance is not required.

3. Ambulance Operators: Certified to render first aid/CPR and competent to operate vehicle.

01 35 20 - 4

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Removal from Work

01 35 21 - 1

SECTION 01 35 21

REMOVAL FROM WORK

PART 1 GENERAL

1.01 REMOVAL FROM WORK

A. If, in the opinionn of the CO, an employee refuses or repeatedly fails to comply, or supervisors fail to enforce compliance with the safety requirements contained in the "Accident Prevention" clause and the "Safety and Health - Bureau of Reclamation" clause in Section I of this contract, the CO may require, in accordance with paragraph (c) of the "Material and Workmanship" clause in Section E, that the individual be removed from the work, and the site if necessary.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Removal from Work

01 35 21 - 2

Reference Standards

01 42 10 - 1

SECTION 01 42 10

REFERENCE STANDARDS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Referenced editions of standard specifications, codes, and manuals form a part of this specification to the extent referenced.

B. These specifications take precedence when conflicting requirements occur between specifications and referenced standard.

1.03 JOBSITE REFERENCE STANDARDS

A. Maintain at fabrication site, access to referenced standard specifications, codes, and manuals required for work in progress at fabrication site. Make available for use by the Government.

B. Maintain onsite, access to referenced standard specifications, codes, and manuals required for onsite work in progress. Make available for use by the Government.

1.04 AVAILABILITY

A. Code of Federal Regulations (CFR):

1. Available online, authorized by the National Archives and Records

Administration (NARA) and the Government Printing Office (GPO), at http://www.gpo.gov/fdsys/search/home.action

B. Federal Specifications, Standards, and Commercial Item Descriptions; and Military Specifications:

1. Copies of Federal Specifications, Standards, and Commercial Item Descriptions may be obtained from GSA Federal Supply Service, see the provision at FAR 52.211-1, Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29.

2. Copies of Military Specifications may be obtained from Department of Defense, see the provision at FAR 52.211-2, Availability of Specifications, Standards, and Data Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST).

http://www.gpo.gov/fdsys/search/home.action

01 42 10 - 2

C. Bureau of Reclamation Documents:

1. Reclamation Safety and Health Standards (RSHS) may be downloaded at www.usbr.gov/ssle/safety/RSHS/rshs.html.

a. Hard copies of RSHS, stock number 024-003-00204-6, may be purchased from The Superintendent of Documents at the U.S. Government Printing Office (GPO), phone number 202-512-1800. Hard copies of RSHS are subject to revisions posted on the site shown above.

1) GPO online bookstore:

http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber= 024-003-00204-6.

2. Bureau of Reclamation manuals and other publications including significant scientific, technical, and engineering works are available from the National Technical Information Service (NTIS). Information regarding availability and pricing may be obtained by contacting NTIS at the following address:

United States Department of Commerce National Technical Information Service 5285 Port Royal Road Springfield, VA 22161 Telephone: 703-487-4650 or 1-800-553-6847

D. Industrial and Governmental Documents:

1. When a reference has a joint designation (e.g. ANSI/IEEE) these specifications generally cite the proponent organization (e.g. IEEE).

2. Addresses for obtaining industrial and governmental (other than Federal and

Bureau of Reclamation specifications and standards) specifications, standards, and codes are listed in Table 01 42 10A - Addresses for Specifications, Standards, and Codes.

Table 01 42 10A - Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

AASHTO American Association of State Highway and Transportation Officials 444 North Capitol Street, NW., Suite 249 Washington, DC 20001 www.aashto.org

202-624-5800 800-231-3475

ACI American Concrete Institute 38800 Country Club Dr.

Farmington Hills, MI 48331-3439 https://www.concrete.org/home.aspx”

248-848-3700 http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber=024-003-00204-6 http://bookstore.gpo.gov/actions/GetPublication.do?stocknumber=024-003-00204-6 http://www.aashto.org/ https://www.concrete.org/home.aspx

01 42 10 - 3

Table 01 42 10A - Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

AEIC Association of Edison Illuminating Companies PO Box 2641 Birmingham, AL 35291-0992 http://aeic.org/

205-257-3839

AGC Associated General Contractors of America 333 John Carlyle Street, Suite 200 Alexandria, VA 22314 www.agc.org

703-548-3118

AISC American Institute of Steel Construction One East Wacker Drive, Suite 3100 Chicago, IL 60601-2001 www.aisc.org

312-670-2400

ANSI American National Standards Institute 1819 L. Street, NW.

Washington, DC 20036 www.ansi.org

202-293-8020

APA/EWA APA-The Engineered Wood Association P.O. Box 11700 Tacoma, WA 98411-0700 www.apawood.org

253-565-6600

ASTM ASTM International P.O. Box C700 100 Barr Harbor Drive West Conshohocken, PA 19428-2959 www.astm.org

610-832-9585

AWS American Welding Society 550 NW LeJeune Road Miami, FL 33126 www.amweld.org

800-443-9353 305-443-9353

ICRI International Concrete Repair Institute 1000 Westgate Drive, Suite 252 | St. Paul, Minnesota 55114 http://www.icri.org/

651-366-6095

NACE NACE International 1440 South Creek Drive Houston, TX 77084 www.nace.org

281-228-6200 http://aeic.org/ http://www.agc.org/ http://www.aisc.org/ http://www.ansi.org/ http://www.apawood.org/ http://www.astm.org/ http://www.amweld.org/ http://www.icri.org/ http://www.nace.org/

01 42 10 - 4

Table 01 42 10A - Addresses for Specifications, Standards, and Codes

Acronym Name and Address Telephone

SSPC SSPC: The Society for Protective Coatings 40 24th Street, 6th Floor Pittsburgh, PA 15222-4656 www.sspc.org

800-837-8303 412-281-2331

UL Underwriters Laboratories, Inc.

333 Pfingsten Road Northbrook, IL 60062-2096 www.ul.com

847-272-8800

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

http://www.sspc.org/ http://www.ul.com/

Watercraft ANS Decontamination Facility at Vallecito Reservoir

Quality Procedures 01 46 00 - 1

SECTION 01 46 00

QUALITY PROCEDURES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 DEFINITIONS

A. Government Contract Quality Assurance: (from FAR 46.101) Various functions, including inspection, performed by the Government to determine whether a contractor has fulfilled the contract obligations pertaining to quality and quantity.

B. Contractor Quality Assurance / Quality Control (QA/QC): Activities performed by the Contractor to ensure work conforms to contract requirements.

1. The clause at FAR 52.246-12 - Inspection of Construction, requires the

Contractor to establish an inspection system to ensure quality.

2. Contractor QA/QC includes activities in addition to specified Contractor Quality

Testing to ensure work conforms to contract requirements.

C. Contractor Quality Testing: Specified tests shall be performed by the Contractor.

1. The Government will evaluate results of these tests when determining acceptability of work.

2. The Contractor may use the test results as part of Contractor QA/QC.

a. The Government anticipates that these tests will be part of the Contractor’s QA/QC program, however the tests do not relieve the Contractor of maintaining adequate quality system in accordance with the clause at FAR 52.246-12 - Inspection of Construction.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Watercraft ANS Decontamination Facility at Vallecito Reservoir

Quality Procedures 01 46 00 - 2

Temporary Utilities

01 51 00 - 1

SECTION 01 51 00

TEMPORARY UTILITIES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the price schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Institute of Electrical and Electronics Engineers (IEEE)

1. IEEE C2-12 National Electrical Safety Code (NESC)

1.03 TEMPORARY ELECTRICITY

A. Provide electric power required for construction.

B. Provide generators, transmission lines, distribution circuits, transformers, and other electrical equipment and facilities required for obtaining power and distributing power to points of use.

C. Comply with IEEE C2 clearances and spacing for temporary communications and supply lines.

1.04 TEMPORARY WATER

A. Provide water required for construction purposes.

B. Water can be pumped from Vallecito Reservoir provided the equipment is inspected for aquatic nuisance species. See Specifications Section 01 14 10 – Use of Site.

C. Use water which meets specified requirements for water used in concrete, soil-cement, masonry, grouting, and other permanent work.

D. Provide means of conveying water to points of use.

1.05 TELEPHONE

A. Cellular service signal at the reservoir varies with providers and may not be available at all times.

1.06 SANITARY FACILITIES

A. Contractor shall provide sanitary facilities for employees.

Temporary Utilities

01 51 00 - 2

B. Contractors shall provide and maintain four portable toilets for public. The portable toilets shall be available prior to beginning the demolition of the existing restroom until the time the new restroom is completed and accepted by the COR.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 REMOVAL

A. Remove temporary equipment and facilities upon completion of work under this contract.

Vehicular Access and Parking

01 55 00 - 1

SECTION 01 55 00

VEHICULAR ACCESS AND PARKING

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REGULATORY REQUIREMENTS

A. Meet requirements established by jurisdictional authority for use of existing roadways and haul routes; including seasonal or other limitations or restrictions, payment of excess size and weight fees, and posting of bonds conditioned upon repair of damage.

B. Comply with applicable regulations for haul routes over public highways, roads, or bridges.

1.03 SITE CONDITIONS

A. Rights-of-way for access to work from existing roads are shown on Drawings 191-417-2.

1. In accordance with clause at FAR 52.236-10, Operations and Storage Areas, use only established roadways, parking areas, and haul routes; or temporary roadways, parking areas, or haul routes constructed by Contractor when and as authorized by CO.

2. Subject to clause at FAR 52.249-10, Default (Fixed-Price Construction), unavailability of transportation facilities or limitations thereon shall not become a basis for claims for damages or extension of time for completion of work.

PART 2 PRODUCTS

2.01 MATERIALS

A. Materials to maintain and repair existing roadways, parking areas, and haul routes: In accordance with requirements of jurisdictional authority.

B. Materials to construct, maintain, and repair temporary roadways, parking areas, and haul routes: As approved by COR.

C. Materials to maintain roadways and parking areas constructed under this contract and used by Contractor for construction work: In accordance with specified requirements for construction of those roadways and parking areas.

01 55 00 - 2

D. As determined by the COR, if the contractor’s construction traffic is depositing debris on the paved surfaces, the contractor shall provide track pads to clean the tires of vehicles.

1. Track Pads:

a. 2-inch screened aggregate.

b. 6-inch minimum layer.

c. 50 linear feet minimum.

d. Modify track pads as directed by COR if debris is deposited on adjacent paved roads.

e. Commercial products for cleaning tires of construction traffic can be submitted to COR for consideration.

f. Remove track pads upon completion of construction, unless otherwise permitted to remain by COR.

PART 3 EXECUTION

3.01 EXAMINATION

A. Investigate condition of available public or private roads for clearances, restrictions, bridge-load limits, bond requirements, and other limitations that affect or may affect access and transportation operations to and from jobsite.

3.02 ESTABLISHED ROADWAYS AND PARKING AREAS

A. Established roadways and parking areas shown on Drawing No. 191-417-2 are available for Contractor's use subject to existing restrictions and approval of the COR.

3.03 HAUL ROUTES

A. Perform work on rights-of-way established by Government as necessary to construct and maintain any roads, bridges, or drainage structures required for establishment and use of haul routes for construction operations.

B. Use existing available public highways, roads, or bridges as haul routes subject to applicable local regulations.

C. Minimize interference with or congestion of local traffic.

D. Provide barricades, flaggers, and other necessary precautions for safety of public where haul routes cross public highways or roads.

3.04 MAINTENANCE

A. Maintain roadways, parking areas, and haul routes in a sound, smooth condition.

01 55 00 - 3

B. Maintain roadbed, side slopes, structures, and surfacing of roads and parking areas until completion and acceptance of all work under this contract. As approved by COR, defer until latest practicable date within specified completion period, placement of surfacing on roads or parking areas subject to heavy and deteriorating use by Contractor's construction operations or equipment.

C. Maintain surfacing of gravel-surfaced roads and parking areas in a smooth condition until completion and acceptance of work under this contract.

D. Snow removal for convenience of Contractor or to facilitate work operations of Contractor is considered to be normal required maintenance.

3.05 REPAIR

A. Promptly repair ruts, broken pavement, potholes, low areas with standing water, and other deficiencies to maintain road surfacing and drainage in original or specified condition.

3.06 REMOVAL

A. Remove materials used to construct temporary roadways, parking areas, and haul routes prior to contract completion. Recycle salvageable materials as approved by COR.

01 55 00 - 4

Traffic Control

01 55 20 - 1

SECTION 01 55 20

TRAFFIC CONTROL

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost: Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Federal Highway Administration, Department of Transportation

1. MUTCD, Part 6 Part 6, Temporary Traffic Control, Manual on Uniform Traffic Control Devices, 2009 Edition with Revisions 1 and 2, (http://mutcd.fhwa.dot.gov/kno_2009r1r2.ht m)

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 55 20-1, Traffic control plan (if construction impacts public traffic on County Road 501).

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 TRAFFIC CONTROL

A. Meet requirements of MUTCD, Part 6.

B. Provide cones, delineators, concrete safety barriers, barricades, flasher lights, danger signals, signs, and other temporary traffic control devices as required to protect work and public safety.

C. Provide flaggers and guards as required to prevent accidents and damage or injury to passing traffic.

D. Do not begin work along public or private roads until proper traffic control devices for warning, channeling, and protecting motorists are in place in accordance with approved traffic control plan.

Traffic Control

01 55 20 - 2

E. Maintain traffic flow and conduct construction operations to minimize obstruction and inconvenience to public traffic.

F. Provide unobstructed, smooth, and dustless passageway for recreational traffic through construction operations.

G. Construct temporary connections for recreational traffic between existing roadways and new construction.

H. Maintain convenient access to driveways, houses, and buildings along line of work.

I. Protect roads closed to traffic with effective barricades and warning signs. Illuminate barricades and obstructions from sunset to sunrise.

J. Remove traffic control devices when no longer needed.

Protection of Existing Installations

01 56 10 - 1

SECTION 01 56 10

PROTECTION OF EXISTING INSTALLATIONS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work, except as specified.

2. Costs for repair of installations damaged by the Contractor's operations are the

Contractor's responsibility.

1.02 PROJECT CONDITIONS

A. Drawings included in these specifications show items of existing materials and equipment but may not show all equipment and materials existing at the jobsite.

B. Obtain the location of embedded conduit, pipe, cable, ground mat, and other buried items before performing any excavation, demolition, drilling or cutting of concrete.

C. Protect existing septic tank shown on Drawing No. 191-417-2.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 PROTECTION

A. Provide protection for personnel and existing facilities from harm due to the Contractor's operations. Protection shall be subject to approval of the Government.

B. Arrange protective installations to permit operation of existing equipment and facilities by the Government while work is in progress.

3.02 REMOVAL OF PROTECTIVE INSTALLATIONS

A. Remove protective installations after purpose has been served. Materials furnished by the Contractor to provide protection remain property of the Contractor.

Protection of Existing Installations

01 56 10 - 2

3.03 REPAIR

A. Repair, at Contractor's expense, damage to existing installations due to Contractor's operations or Contractor's failure to provide proper protection. At the Government's option, damage may be repaired by the Government, and the Contractor will be backcharged repair costs.

Protection of Existing Utilities

01 56 15 - 1

SECTION 01 56 15

PROTECTION OF EXISTING UTILITIES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. RSHS-2009 Reclamation Safety and Health Standards

B. Institute of Electrical and…