Att 02_140P8420R0003_Project Specifications.pdf

PINNACLES NATIONAL PARK

PACIFIC WEST

REHABILITATE THE PEAKS VIEW PARKING AREA

PINN

PMIS NO. 198912

100% FINAL PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

DENVER SERVICE CENTER

12/18/2019

PINN - 198912 1

091015 TABLE OF CONTENTS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 27 00 Definition of Contract Line Items

01 31 00 Project Management and Coordination

01 32 16 Construction Schedule 01 32 33 Photographic Documentation

01 33 23 Submittal Procedures

01 35 23 Safety Requirements 01 35 50 Natural, Cultural, and Physical Resources Protection

01 40 00 Quality Requirements

01 40 00B Structural Statement

01 42 00 Reference Standards 01 50 00 Temporary Facilities and Controls

01 57 19.12 Noise and Acoustics Management

01 57 23 Under-An-Acre Pollution Prevention 01 73 40 Execution

01 74 19 Construction Waste Management and Disposal

01 77 00 Closeout Procedures

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 11 10 Wood Framing

DIVISION 07 – THERMAL-MOISTURE PROTECTION

07 41 13 Metal Roofing Panels

DIVISION 13 – SPECIAL CONSTRUCTION

13 34 00 Vault Toilet

DIVISION 31 – EARTHWORK

31 11 00 Clearing and Grubbing 31 23 00 Site Excavation and Grading

31 23 16 Structure Excavation and Grading

31 23 33 Utility Trenching and Backfilling

32 11 23 Aggregate Base 31 12 16 Bituminous Concrete Pavement

32 13 20 Site Concrete

32 17 23 Pavement Markings 32 17 26 Detectable Warning Tactile Panels

33 05 26 Utility Line Marking

33 10 00 Site Water Distribution 33 21 15 Disinfection of Water Distribution System

PINN - 198912 01 11 00 - 1

091015 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Work phases.

3. Work under other contracts.

4. Government Furnished Materials.

5. Contractor use of premises.

6. Public use of site.

7. Occupancy requirements for buildings.

8. Work Restrictions.

9. Special Construction Requirements.

10. Soils Investigation Report.

11. Additional Reports.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Pinnacles National Park, CA, Peaks View Parking Lot. The parking lot is located on the East side of Pinnacles National Park, along the Park Entrance Road, approximately 3.3 miles west of Highway 25.

B. The Work consists of the following:

1. The Work includes the regrading, repaving, and restriping of the Peaks View parking lot area, the construction of various walkways, and the installation of a vault toilet among other amenities.

C. Project will be constructed under a single prime contract.

1.3 WORK UNDER OTHER CONTRACTS

A. General: Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the Work of this Contract with work performed under separate contracts.

B. Concurrent Work: Government has awarded a separate contract for the following construction operations at Project site. Those operations will be conducted simultaneously with work under this

Contract.

1. PINN-198668: A separate contract has been awarded to for the replacement of the East Entrance Station located in Pinnacles National Park, San Benito, CA.

PINN - 198912 01 11 00 - 2

1.4 CONTRACTOR USE OF SITE

A. General: Contractor shall have full use of the site for construction operations during the construction period. Contractor's use of the site is limited only by the Government's right to perform work or to retain other contractors on portions of Project.

B. Site Access: The contractor shall access the project site as outlined on the project plans. Do not drive vehicles off road or access non-project areas without permission from the contracting officer or park superintendent.

C. Storage of Materials: Confine storage of materials identified on the project plans or as established at the preconstruction meeting.

D. Park Regulations: Ensure all personnel (contractors, subcontractors, and vendors) entering or working in the park are familiar with and obey all park regulations. Law enforcement rangers will intervene if they perceive any unsafe or unlawful activity.

E. No Smoking Policy: Smoking is prohibited inside or outside within 25 feet of any buildings in the park. This applies to existing buildings, buildings under construction, and buildings under renovation. Discarding of tobacco products or debris anywhere other than into designated tobacco receptacles is considered littering and subject to fines.

F. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

G. Construction Camp: Establishment of a camp within the park will not be permitted.

H. Parking: The contractor shall park vehicles and heavy equipment in designated areas for contractor use or as established at the preconstruction meeting. Vehicles are not permitted within long-term or overnight parking along roads or in associated overlooks/pull-outs.

1.5 PUBLIC USE OF SITE

A. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public.

1.6 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. New Buildings

1. Government Occupancy of Completed Areas of Construction: Government reserves the right to occupy and to place and install equipment in completed areas of building, PINN - 198912 01 11 00 - 3 provided such occupancy does not interfere with completion of the Work. Such placement of equipment and partial occupancy shall not constitute acceptance of the entire project.

a. Contracting Officer will prepare a Beneficial Occupancy letter for each specific portion of the Work to be occupied before Government occupancy.

b. Obtain a Certificate of Occupancy from the NPS before Government occupancy.

c. Before partial Government occupancy, mechanical and electrical systems shall be fully operational, and required tests and inspections shall be successfully completed. On occupancy, Government will operate and maintain mechanical and electrical systems serving occupied portions of building.

d. On occupancy, Government will assume responsibility for maintenance and custodial service for occupied portions of building.

1.7 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 48 hours in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.8 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of

7:00 a.m. to 6:00 p.m., Monday through Friday, except when otherwise indicated.

1. If weekend, evening or early morning hours are needed to complete the project on schedule, Contractor shall obtain approval for proposed hours from COR.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

PINN - 198912 01 11 00 - 4

1. Notify Contracting Officer not less than 14 days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.9 SPECIAL CONSTRUCTION REQUIREMENTS

A. Contractor shall adhere to the mitigation measures identified in “Section 01 35 50 Natural, Cultural, and Physical Resources Protection” attached in the end of this section, where Contractor is listed as the responsible party.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

PINN - 198912 01 27 00 - 1

082714 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 1 Mobilization, Site Prep, & Demolition

1. This item consists of all costs associated with the contractors pre and post construction activities including mobilization, demobilization, completion of all required site clearing, material disposal, and removal and disposal of swing gate at entrance of parking lot. The government shall consider that mobilization is sixty (60) percent and demobilization is forty (40) percent of the total cost and effort for Mobilization and Demobilization.

2. No separate measurement will be made.

3. Payment will be made at the contract lump sum price.

B. Contract Line Item No. 2 Grading, Paving, & Amenities

1. This price item includes providing all labor, materials, and equipment required for the construction of a fully functional trailhead parking area in accordance with the project plans and specifications. This Work includes, but is not limited to, the installation of all required traffic control, temporary stormwater pollution prevention measures, completion of all rough and fine grading inclusive of any necessary soil import or export, furnish, place and compact all base materials, asphalt concrete paving surfaces and appurtenances, the construction all concrete surfacing improvements, installation of all necessary signage and striping, relocation of various boulders, relocation of existing periscopes, and relocation of picnic benches.

2. No separate measurement will be made.

3. Payment will be made at the contract lump sum price.

C. Contract Line Item No. 3 Drinking Fountain/Bottle Filling Station

PINN - 198912 01 27 00 - 2

082714 DEFINITION OF CONTRACT LINE ITEMS

1. This price item includes providing all labor, materials, and equipment required for the installation of the specified freeze resistant tri-head water fountain and associated new water service lateral and leach line in the locations shown on the plans. This includes, but is not limited to the completion of all required trenching, installation of all required bedding material, installation of all aggregate fill, installation of all sanitary sewer appurtenances, installation of all water appurtenances and fittings, trench backfill and compaction, and installation of the specified freeze resistant tri-head water fountain in accordance with the manufacturer’s recommendations.

2. No separate measurement will be made.

3. Payment will be made at the contract lump sum price.

D. Contract Line Item No. 4 Vault Toilet-Standard Precast w/No porch

1. This price item includes providing all labor, materials, and equipment required for the installation of a double fully precast building (CXT Double Cascadian or equivalent) in the location shown on the plans. This includes, but is not limited to, the completion of all required excavation, the installation of all required bedding material, installation of the vault toilet tankage and structure in accordance with the manufacturer’s recommendations, completion of the building improvements for a fully functional vault toilet facility, completion of all required backfilling around the tank and structure, and completion of all finish grading necessary to incorporate the vault toilet into the adjoining concrete pathways and parking lot ensuring that the installation meets accessibility requirements.

2. No separate measurement will be made.

3. Payment will be made at the contract lump sum price.

E. Contract Line Item No. 5-Bid Additive 1 Vault Toilet-Custom Built Building in Lieu of

Standard

1. This price item is a bid additive to Contract Line Item No. 4 Vault Toilet and includes providing all labor, materials, and equipment required for the installation of the specified

Vault Toilet facility in the location shown on the plans. This includes, but is not limited to, the completion of all required excavation, the installation of all required bedding material, installation of the vault toilet tankage and structure in accordance with the manufacturer’s recommendations, completion of the building improvements for a fully functional vault toilet facility with custom timber framed porch, completion of all required backfilling around the tank and structure, and completion of all finish grading necessary to incorporate the vault toilet into the adjoining concrete pathways and parking lot ensuring that the installation meets accessibility requirements.

2. No separate measurement will be made.

3. Payment will be made at the contract lump sum price.If Options are included in the contract that consist of multiple items under a single Option use the following format

END OF SECTION 01 27 00

PINN - 198912 01 31 00 - 1

091015 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Coordination Drawings.

5. Requests for Information (RFIs).

6. Project meetings.

7. Environmental Coordination.

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

PINN - 198912 01 31 00 - 2

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Project closeout activities.

8. Commissioning activities.

1.3 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to

Proceed will not be issued, and the Contracting Officer will consider other contractual remedies.

Work shall not commence until written Notice to Proceed has been issued.

1.4 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

PINN - 198912 01 31 00 - 3

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.5 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

PINN - 198912 01 31 00 - 4

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. Acceptance/rejection of work.

17. Progress meetings.

18. Submittal procedures.

19. NPS Final Accessibility Inspection.

20. Environmental requirements.

21. Permit requirements.

22. As-constructed drawings/operation and maintenance (O&M) manuals.

23. Saturday, Sunday, holiday and night work.

24. Reference materials.

25. Value engineering.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and

PINN - 198912 01 31 00 - 5

installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of agency(ies) with jurisdiction.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

PINN - 198912 01 32 16 - 1

031414 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

PINN - 198912 01 32 16 - 2

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be submitted by email to the Contracting Officer, provided in the native electronic file format. It is the intent of the

Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. CPM Reports: Concurrent with CPM schedule, submit three paper copies of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of predecessor and successor tasks for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of all activities sorted in ascending order of total float.

E. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

F. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision submit two paper copies of a Time Impact Analysis. Each Time Impact Analysis shall include a Fragmentary Network (Fragnet), incorporated into the currently accepted Construction

Schedule, demonstrating how the Contractor proposes to incorporate a modification, change, delay, or Contractor request.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

PINN - 198912 01 32 16 - 3

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including work stages.

4. Review delivery dates for Government-furnished products.

5. Review schedule for work of separate Government contracts.

6. Review time required for review of submittals and re-submittals.

7. Review requirements for tests and inspections by independent testing and inspecting agencies.

8. Review time required for completion and startup procedures.

9. Review time required for obtaining and activating permits.

10. Review and finalize list of construction activities to be included in schedule.

11. Review baseline schedule comments, resolve issues and progress on incorporating them

12. Review procedures for updating schedule.

13. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

B. Contractor's Schedule Representative: Before or at the preconstruction conference, designate an authorized representative to be responsible for the preparation and maintenance of the

Construction Schedule. A resume outlining the qualifications of the Scheduler shall be submitted to the Contracting Officer for acceptance. The Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency in the use of scheduling software. The authorized representative will be responsible for preparing the Baseline Schedule, all required updates, revisions, Time Impact

Analyses, and preparation of reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule

PINN - 198912 01 32 16 - 4

submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting

Officer before the first progress payment is processed.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 30 days after date established for the Notice of Award.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary CPM network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the CPM schedule within the limitations of the Contract Time.

4. The Construction Baseline Schedule as developed shall show the sequence and interdependence of activities required for complete performance of the work. Ensure all work sequences are logical and the Construction Baseline Schedule shows a coordinated plan of the work.

5. Resource loading of each activity shall include all personnel by labor category and equipment type and capacity proposed to complete the activity in the duration shown.

PINN - 198912 01 32 16 - 5

6. Consider seasonal weather conditions in planning and scheduling all work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of all work within the contract time.

7. Time Frame: Proposed duration assigned to each activity shall be the Contractor's best estimate of time required to complete the activity considering the scope and resources planned for the activity.

a. An early finish date may be shown but the late finish date must be the same date as the last day of the contract period. An early completion schedule must contain the following:

1) Insert an activity titled “Project Float” as a successor to the last activity in the early project completion schedule network.

2) Add a milestone titled “Contract End Date” as a successor to the activity

“Project Float”.

3) Add duration to the activity “Project Float” as required so the milestone

“Contract End Date” equals the last day of the Contract Period.

b. Contract completion date shall not be changed by submission of a schedule that shows an early completion date.

c. The Contractor shall limit use of lead or lag duration’s between schedule activities.

d. Project Calendars: Develop and incorporate the following calendars:

1) Administrative Calendar: Include a calendar that is based on a 7 day week to be used on any activities that are based on calendar days. Apply this calendar to administrative tasks or any other tasks that are not affected by non-working days (Federal Holidays, weather, etc.).

2) Project Calendar: Include a calendar that is based on the planned work week for the project. Include Federal Holidays, weekends, and any other non-work days indicated in the contract documents. Apply this calendar to activities which are not anticipated to be affected by weather.

3) Weather Calendar: Utilize the Project Calendar and show anticipated normal downtime related to weather as non-working time. Weather days shall be based on data for the local area from a reliable source like the National

Oceanic and Atmospheric Administration (NOAA), National Park Service records, or source acceptable to the Contracting Officer. Apply this calendar to activities that are anticipated to be affected by weather.

e. Activity Duration: Define activities so no activity is longer than 15 days, except for non-construction activities including mobilization, shop drawings and submittals, fabrication and delivery of materials and equipment.

f. Procurement Activities: Include procurement process activities for the following long lead items and major items, requiring a cycle of more than 60 calendar days, as separate activities in the schedule. Procurement cycle activities include, but are not limited to, submittals, approvals, purchasing, fabrication, and delivery.

g. Submittal Review Time: Include review and re-submittal times indicated.

Coordinate submittal review times in Construction Baseline Schedule.

h. Startup and Testing Time: Include not less than 5 days for startup and testing and commissioning activities.

PINN - 198912 01 32 16 - 6

i. Substantial Completion: Allow time for Government administrative procedures necessary for certification of Substantial Completion. (For more information, refer to Division 01 Specification 01 77 00 Closeout Procedures.)

8. Constraints: Include constraints and work restrictions indicated in the Contract

Documents and as follows in schedule, and show how the sequence of the Work is affected.

a. Phasing: Arrange list of activities on schedule by phase.

b. Work under More Than One Contract: Include a separate activity for each contract.

c. Work Restrictions: Show the effect of the following items on the schedule:

1) Coordination with existing construction.

2) Provisions for future construction.

3) Seasonal variations.

4) Environmental control.

d. Work Stages: Indicate important stages of construction for each major portion of the Work.

1) Subcontract awards.

2) Submittals.

3) Purchases.

4) Fabrication.

5) Sample testing.

6) Deliveries.

7) Installation.

8) Tests and inspections.

9) Adjusting.

10) Curing.

9. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed, Substantial Completion, and

Commissioning.

C. Joint Review, Revision, and Acceptance:

1. Within seven calendar days of receipt of the Contractor's proposed Construction Baseline Schedule, the Contracting Officer and Contractor shall meet for joint review, correction, or adjustment of the initial Construction Baseline Schedule. Any areas which, in the opinion of the Contracting Officer, conflict with timely completion of the project shall be subject to revision by the Contractor.

2. Within seven calendar days after the joint review between the Contractor and Contracting

Officer, the Contractor shall revise and resubmit the Construction Baseline Schedule in accordance with agreements reached during the joint review.

3. In the event the Contractor fails to define any element of work, activity, or logic, and the

Contracting Officer review does not detect this omission or error, such omission or error, when discovered by the Contractor or Contracting Officer, shall be corrected by the Contractor within seven calendar days and shall not affect the contract period.

PINN - 198912 01 32 16 - 7

4. Upon acceptance of the Construction Baseline Schedule by the Contracting Officer, save the schedule as a baseline and update on a monthly basis. The construction schedule update will be used to evaluate the Contractor's monthly applications for payment based upon information developed at the monthly Construction Schedule update meeting.

D. Recovery Schedule: When periodic schedule update indicates the Work is 14 or more calendar days behind the current accepted schedule, a separate recovery schedule indicating means by which Contractor intends to regain compliance with the schedule must also be submitted.

Indicate changes to working hours, working days, crew sizes, and equipment required to achieve compliance, and date by which recovery will be accomplished.

E. Computer Software: Prepare schedules using a program that has been developed specifically to manage construction schedules.

PART 3 - EXECUTION

3.1 CONSTRUCTION SCHEDULE UPDATES

A. Progress Meeting Updates: Provide a three week look-ahead schedule, derived from the currently accepted schedule, before each weekly progress meeting. Utilize the look-ahead schedule to facilitate and take notes on discussions held during the progress meeting.

B. Monthly Schedule Updates:

1. General: Update the Construction Schedule on a monthly basis to reflect actual construction progress and activities throughout the entire contract period and until project substantial completion. The status date of each schedule update shall be the 7th day preceding the progress payment request date.

2. Procedure: The Contractor shall meet with the Contracting Officer each month at a

Construction Schedule update meeting to review actual progress made through the status date of the Construction Schedule update, including dates activities were started and/or completed and the percentage of work completed on each activity started and/or completed.

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

f. Changes in total float or slack time.

g. Changes in the Contract Time.

4. Narrative: The report shall include a brief description of the actual progress made during the update period; actual and potential delaying activities; any impediments to progress;

issues related to inclement weather; progress toward established milestones and project float. The report shall include a brief description of the work anticipated to be performed

PINN - 198912 01 32 16 - 8

in the next month. Any minor revisions to the schedule should be identified so they can be evaluated and accepted or rejected.

5. As the Work progresses, indicate Actual Completion percentage for each activity.

6. If the schedule update shows a late finish date after the contract completion date, at a minimum, include the following in the narrative with your submission:

a. Any known delays.

b. Actions that will be taken to get back on schedule.

c. Pending modifications.

d. Impediments or constraints affecting progress.

7. Progress Payments: The monthly updating of the currently accepted Construction

Schedule shall be an integral part of the process upon which progress payments will be made under this contract. If the Contractor fails to provide schedule updates or revisions, then a portion of the monthly payment may be retained until such corrections have been made.

C. Distribution: Distribute copies of accepted schedule to Contracting Officer, Contracting Officers Representative, Construction Management Representative, Subcontractors, testing and inspecting agencies, and other parties identified by Contractor with a need-to-know schedule responsibility.

1. Post copies in Project meeting rooms and temporary field offices.

2. When revisions are made, distribute updated schedules to the same parties and post in the same locations. Delete parties from distribution when they have completed their assigned portion of the Work and are no longer involved in performance of construction activities.

D. Construction Schedule Revisions:

1. Required Revisions: If, as a result of the monthly schedule update, it appears the currently accepted Construction Schedule no longer represents the actual prosecution and progress of the work, the Contracting Officer will request, and the Contractor shall submit, a revision to the Construction Schedule. The Contractor may also request reasonable revisions to the currently accepted Construction Schedule in the event the Contractor's planning for the work is revised. If the Contractor desires to make changes, the Contractor shall notify the Contracting Officer in writing, stating the reason for the proposed revision. Accepted revisions will be incorporated into the currently accepted

Construction Schedule for the next monthly schedule update.

2. Procedure: If revision to the currently accepted Construction Schedule is contemplated, the Contractor or Contracting Officer shall so advise the other in writing at least seven calendar days prior to the next monthly schedule update meeting, describing the revision and reasons for the revision. Government-requested revisions will be presented in writing to the Contractor, who shall respond in writing within seven calendar days.

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

PINN - 198912 01 32 16 - 9

f. Changes in total float or slack time.

3.2 TIME IMPACT ANALYSIS FOR CONTRACT MODIFICATIONS CHANGES DELAYS

AND CONTRACTOR REQUESTS:

1. Requirements: When contract modifications or changes are initiated, delays are experienced, or the Contractor desires to revise the currently accepted Construction Schedule, the Contractor shall submit to the Contracting Officer a written time impact analysis illustrating the influence of each modification, change, delay, or Contractor request on the contract time.

2. Time Extensions: Activity delays, which result in projecting a late completion date, shall not automatically mean that an extension of the contract time is warranted or due the

Contractor. It is possible that a modification, change, or delay will not affect existing critical path activities or cause non-critical activities to become critical. A modification, change, or delay may result in only absorbing a part of the available total float that may exist within an activity chain of the Schedule, thereby not causing any effect on the contract time. Time extensions will be granted in accordance with the terms of the contract.

3. Extension of the contract time will be granted only to the extent the equitable time adjustments to the activity or activities affected by the modification, change, or delay exceeds the total (positive or zero) float available on a particular activity.

4. Procedure: Each time impact analysis shall be submitted within the time period stated in a request for proposal, or the time period designated under the clauses entitled Changes or Default. In cases where the Contractor does not submit a written request for extension of time and a time impact analysis within the designated time, it is mutually agreed that the particular modification, change, delay, or Contractor request does not require an extension of the contract time. Upon acceptance, the time impact analysis shall be incorporated into the currently accepted Construction Schedule at the next monthly schedule update.

5. Contract Modifications: For each proposed contract modification and concurrent with its submission, prepare a time-impact analysis using fragnets to demonstrate the effect of the proposed change on the overall Construction Schedule.

END OF SECTION 01 32 16

PINN - 198912 01 33 23 - 1

031414 SUBMITTAL PROCEDURES

SECTION 01 33 23 - SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative and procedural requirements for submitting Shop

Drawings, Product Data, Samples, and other submittals.

1.2 DEFINITIONS

A. Action Submittals: Written, graphic information, and physical samples that require

Government’s responsive action.

B. Informational Submittals: Written information that does not require Government’s responsive action. Submittals may be rejected for not complying with the requirements.

C. File Transfer Protocol (FTP): Communications protocol that enables transfer of files to and from another computer over a network and that serves as the basis for standard Internet protocols. An FTP site is a portion of a network located outside of network firewalls within which internal and external users are able to access files.

D. Portable Document Format (PDF): An open standard file format licensed by Adobe Systems used for representing documents in a device-independent and display resolution-independent fixed-layout document format.

1.3 GENERAL SUBMITTAL PROCEDURES

A. General: Prepare and submit submittals required by individual Specification Sections. Types of submittals are indicated in individual specific sections.

1. Contracting Officer reserves the right to require submittals in addition to those called for in individual sections.

B. Coordination: Coordinate preparation and processing of submittals with performance of construction activities.