12f SF30 - Amendment 00007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 3

2. AMENDMENT/MODIFICATION NO.

00007

3. EFFECTIVE DATE

11/21/2024

4. REQUISITION/PURCHASE REQ. 5. PROJECT NO. (If applicable)

16191810

6. ISSUED BY CODE 51283 7. ADMINISTERED BY (If other than Item 6) CODE 51283

Contracting Officer USCG Civil Engineering Unit Providence 475 Kilvert St., Suite 100 Warwick, RI 02886

8. NAME AND ADDRESS OF CONTRACTOR (NO., STREET, COUNTY, STATE AND ZIP CODE)

TO ALL POTENTIAL OFFERORS

AMENDMENT MUST BE ACKNOWLEDGED

9A. AMENDMENT OF SOLICITATION NO.

70Z0G125BSYN00190

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE 834953036 FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ ] The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE REFERENCED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (SPECIFY TYPE OF MODIFICATION AND AUTHORITY)

E. IMPORTANT: Contractor is not, is required to sign this document and return __ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this Amendment 00007 is to address questions received as follows:

Q11. The spec states that the contractor will be responsible to apply for a 5G3 permit. Does the USCG anticipate any additional permits in order to conduct work for this project (i.e. demolition permit, SESC permit, etc.)

A11. No other permits are anticipated based on the current scope of work.

(CONTINUED ON PAGE 2)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or Print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B UNITED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C. DATE SIGNED

NSN 7540-01-152-8070 STANDARD FORM 30 (Rev. 10-83) PREVIOUS EDITION UNUSABLE Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 00007 Repair Buoy Yard November 21, 2024

Q12. Do any of the structures slated for demolition require any asbestos abatement and or asbestos survey?

A12. The structures specified for demolition are primarily pre-fab with no sheet rock and no risk for asbestos.

Q13. Do you foresee the existing manholes/catch basins within the LOD needing height adjustment relative to the proposed grades? It is understood that the grading plan will be prepared by a licensed engineer retained by the contractor.

A13. The preliminary proposed contours shown on Contract Drawing C-101 were generated assuming no change to the existing grate elevation for the catch basin located between the Cutter Support Building and Crane Building along the LOD. However, height adjustment may be proposed based on input from the licensed professional engineer and pending USCG approval. With respect to the existing electrical handholes/manholes, some height adjustment may be necessary for these structures to meet proposed grade.

Q14. Should the contractor assume that the USCG will relocate all buoys, concrete blocks, and other structures and equipment not including the structures that are proposed to be reused, or will the contractor be responsible to move all USCG property in order to perform the work?

A.14. USCG ANT New York personnel will be responsible for relocating all buoys, concrete blocks, chain, and other structures and equipment not including the structures that are proposed to be reused. The Contractor shall provide a minimum of 30 days’ notice prior to commencing work for Phases 1 and 2 to allow sufficient time for the Unit to relocate.

Q15. We are classified as a Small Business Enterprise. Does our company's worth have to be $45.0 million and we have to have more than 500 employees?

A15. No. Business over these size standards cannot bid on this IFB.

Q16. Please confirm this project is subject to Liquidated Damages. If so, please indicate the daily amount of Liquidated Damages.

A16. There are no liquidated damages. However, actual damages will be charged if incurred as a result of delay or damage by the Contractor.

Q17. The following abbreviations are not included in the list on sheet G-002. Please provide description:

a. R&D

b. S&S

c. P&M

d. R&S

e. S&D

(CONTINUED ON PAGE 3)

Amendment 00007 Repair Buoy Yard November 21, 2024

A17. RESPONSE: See highlighted portions of the screenshot below from Contract DWG G-002, Abbreviations.

Q18. I'm wondering if it would be possible to schedule a site visit so that my contractor can get in there and take a look around so that we can supply you with the most accurate and competitive quote we can.

A18. An organized site visit was scheduled was scheduled for November 14, 2024 per Amendment 00001 posted on SAM.gov. No other site visits will be scheduled at this time.

AS A REMINDER, BIDS ARE DUE ON TUESDAY, DECEMBER 3, 2024 AT 2:00P.M. EST.

(End)