70Z03326Q201900012_Terms and Conditions.pdf

Construction

Section B - Supplies or Services and Prices/Cost

Item Supplies / Service Quantity Unit Unit Price Amount

Section C: Description/Specifications/Statement of Work

The contractor shall comply with the Statement of Work/Specifications.

Section D: Packaging and Marking

Section E: Inspection and Acceptance

U.S. Coast Guard Air Station Port Angeles 1 Ediz Hook Road Port Angeles, WA 98362

Primary Point of Contact/Technical Representative:

Name: LT Alec MacLeod Work: (206) 831-4302 E-mail: alexander.j.macleod@uscg.mil

Alternate Point of Contact Name: LT Jacob Sily Phone: 206-831-0396 E-mail: Jacob.K.Sily@uscg.mil

Section F: Deliveries or Performance

FAR 52.211-10 Commencement, Prosecution, and Completion of Work. Alt I. (Apr1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 40 days after award* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date

(End of clause) mailto:alexander.j.macleod@uscg.mil mailto:Jacob.K.Sily@uscg.mil

FAR 52.242-14 Suspension of Work. (Apr 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1)by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Section G: Contract Administration Data

The invoicing instructions are included as an attachment to this contract

Section H: Special Contract Requirement

Section I: Contract Clauses

TERMS AND CONDITIONS

(CLAUSES AND PROVISIONS)

FEDERAL ACQUISITION REGULATION (FAR) AND

HOMELAND SECURITY ACQUISITION REGULATION (HSAR) CLAUSES

IN ACCORDANCE WITH FEDERAL ACQUISITION CIRCULAR 2026-01 EFFECTIVE DATE

03/13/2026 System updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in agency solicitations. Examples include 52.222-25, Affirmative Action Compliance, and paragraph (d) of 52.212- 3, Offeror Representations and Certifications—Commercial Products and Commercial Services.

Additional examples include 52.212-5, Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Products and Commercial Services, and 52.213-4, Terms and Conditions—Simplified Acquisitions (Other Than Commercial Products and Commercial Services).

System updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in agency solicitations, including 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation, and paragraph (t) of 52.212-3, Offeror Representations and Certifications— Commercial Products and Commercial Services. Components shall not consider or use these representations.

FAR PROVISIONS

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (May 2014) 52.204-13 System for Award Management Maintenance. (AUG 2025) (DEVIATION 25-19) (effective November 28, 2025)

(End of provision)

52.204-19 Incorporation by Reference of Representations and Certifications. (Dec 2014) 52.211-10 Commencement, Prosecution, and Completion of Work. (Apr 1984) 52.222-3 Convict Labor (Jun 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION

(OCT 2025) (DEVIATION 26-10) (effective November 3, 2025) 52.222-7 Withholding of Funds. (May-2014) 52.222-8 Payrolls and Basic Records. (Jul-2021) 52.222-9 Apprentices and Trainees (July 2005) 52.222-10 Compliance with Copeland Act Requirements. (Feb-1988) 52.222-11 SUBCONTRACTS (LABOR STANDARDS) (OCT 2025) (DEVIATION 26-10) (effective November 3, 2025)

52.222-12 CONTRACT TERMINATION-DEBARMENT (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. (May-2014) 52.222-14 Disputes Concerning Labor Standards. (Feb-1988) 52.222-15 Certification of Eligibility. (May-2014) 52.222-20 Contracts for Materials, Supplies, Articles, and Equipment. (OCT 2025) (DEVIATION 26-10) (effective November 3, 2025) 52.222-50 Combating Trafficking in Persons. (Nov 2021) 52.222-62 Paid Sick Leave Under Executive Order 13706. (Jan 2022) 52.222-90 Addressing DEI Discrimination by Federal Contractors (APR 2026) (DEVIATION 26-10, Revision 2) (effective April 27, 2026) 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) 52.232-5 Payments under Fixed-Price Construction Contracts. (May 2014) 52.232-27 Prompt Payment for Construction Contracts. (Jan 2017) 52.232-39 Unenforceability of Unauthorized Obligations. (Jun 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (Mar 2023) 52.233-4 Applicable Law for Breach of Contract Claim (AUG 2025) (DEVIATION 25-25)

52.236-2 Differing Site Conditions (AUG 2025) (DEVIATION 25-15)) 52.236-3 Site Investigation and Conditions Affecting the Work (AUG 2025) (DEVIATION 25-15) 52.236-5 Material and Workmanship. (AUG 2025) (DEVIATION 25-15) 52.236-6 Superintendence by The Contractor (AUG 2025) (DEVIATION 25-15)) 52.236-7 Permits and Responsibilities. (AUG 2025) (DEVIATION 25-15) 52.236-8 Other Contracts (AUG 2025) (DEVIATION 25-15) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, And Improvements (AUG

2025) (DEVIATION 25-15)

52.236-10 Operations and Storage Areas (AUG 2025) (DEVIATION 25-15) 52.236-11 Use and Possession Prior To Completion (AUG 2025) (DEVIATION 25-15) 52.236-12 Cleaning Up (AUG 2025) (DEVIATION 25-15) 52.236-13 Accident Prevention (AUG 2025) (DEVIATION 25-15) 52.236-14 Availability and Use of Utility Services (AUG 2025) (DEVIATION 25-15) 52.236-21 Specifications and Drawings for Construction (AUG 2025) (DEVIATION 25-15) 52.242-14 Suspension of Work (Apr 1984) 52.243-5 Changes and Changed Conditions (JUNE 2025) (DEVIATION 25-09)

52.204-23 Prohibition on Contracting for Hardware, Software, And Services Developed or Provided by Kaspersky Lab Covered Entities (DEVIATION 20-05) (JUL 2024)

(a) Definitions. As used in this clause- Kaspersky Lab covered article means any hardware, software, or service that–

(1) Is developed or provided by a Kaspersky Lab covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a Kaspersky Lab covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a Kaspersky Lab covered entity.

Kaspersky Lab covered entity means–

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab, including any change in name, e.g., “Kaspersky”;

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any Kaspersky Lab covered article. The Contractor is prohibited from—

(1) Providing any Kaspersky Lab covered article that the Government will use on or after October 1, 2018; and

(2) Using any Kaspersky Lab covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractor identifies covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report, in writing, via email, to the Contracting Officer, Contracting Officer's Representative, and the Enterprise Security Operations Center (SOC) at NDAA Incidents@hq.dhs.gov, with required information in the body of the email. In the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the

Contractor shall report to the Enterprise SOC, Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) and Contracting Officer's Representative(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 3 business days from the date of such identification or notification: the contract number;

the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a Kaspersky Lab covered article, any reasons that led to the use or submission of the Kaspersky Lab covered article, and any additional efforts that will be incorporated to prevent future use or submission of Kaspersky Lab covered articles.

(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts, including subcontracts for the acquisition of commercial items.

(End of clause)

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021) The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision— Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from https://www.acquisition.gov/far/52.204-26#FAR_52_204_26 https://www.acquisition.gov/far/52.212-3#FAR_52_212_3 https://www.acquisition.gov/far/52.204-26#FAR_52_204_26 https://www.acquisition.gov/far/52.212-3#FAR_52_212_3 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that—

(1) It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that— It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable);

or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment— https://www.sam.gov/

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable);

or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 Covered Telecommunications Equipment or Services-Representation (Oct 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c)

(1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it

□ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS

AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021) (DEVIATION

20-05) (DEC 2020)

(a) Definitions. As used in this clause-

"Backhaul" means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

"Covered foreign country" means The People's Republic of China. "Covered telecommunications equipment or services" means-

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

"Critical technology" means-

(l) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of2018 (50 U.S.C. 4817).

"Interconnection arrangements" means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

"Reasonable inquiry" means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

"Roaming" means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

"Substantial or essential component" means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(l)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(l)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing-

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause in writing via email to the Contracting Officer, Contracting Officer's Representative, and the Network Operations Security Center (NOSC) at NDAA Incidents@hq.dhs.gov, with required information in the body of the email. In the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the NOSC, Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) and Contracting Officer's Representative(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.clod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(l) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

mailto:Incidents@hq.dhs.gov https://dibnet.dod.mil/ https://clod.mil/

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph

(e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

52.222-6 Construction Wage Rate Requirements (AUG 2018)(DEVIATION FEB 2025)

(a) Definition.—"Site of the work"—

(1) Means—

(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed; and

(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is-

(A) Located in the United States; and

(B) Established specifically for the performance of the contract or project;

(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided-

(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and

(ii) They are adjacent or virtually adjacent to the "primary site of the work" as defined in paragraph (a)(1)(i), or the "secondary site of the work" as defined in paragraph (a)(1)(ii) of this definition;

(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the "site of the work." Such permanent, previously established facilities are not a part of the "site of the work" even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.

(b) (1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR Part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work shall be effective from the first day on which work under the contract was performed at that site and shall be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work shall be paid in accordance with the wage determination applicable to the primary site of the work.

(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.

(3) Such laborers and mechanics shall be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein; provided that the employer’s payroll records accurately set forth the time spent in each classification in which work is performed.

(4) The wage determination (including any additional classifications and wage rates conformed under paragraph (c) of this clause) and the Construction Wage Rate Requirements (Davis-Bacon Act) poster (WH-1321) shall be posted at all times by the Contractor and its subcontractors at the primary site of the work and the secondary site of the work, if any, in a prominent and accessible place where it can be easily seen by the workers.

(c) (1) The Contracting Officer shall require that any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The Contracting Officer shall approve an additional classification and wage rate and fringe benefits therefor only when all the following criteria have been met:

(i) The work to be performed by the classification requested is not performed by a classification in the wage determination.

(ii) The classification is utilized in the area by the construction industry.

(iii) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination.

(2) If the Contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the Contracting Officer agree on the classification and wage rate (including the amount designated for fringe benefits, where appropriate), a report of the action taken shall be sent by the Contracting Officer to the Administrator of the:

Wage and Hour Division U.S. Department of Labor Washington, DC 20210 The Administrator or an authorized representative will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.

(3) In the event the Contractor, the laborers or mechanics to be employed in the classification, or their representatives, and the Contracting Officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the Contracting

Officer shall refer the questions, including the views of all interested parties and the recommendation of the Contracting Officer, to the Administrator of the Wage and Hour Division for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.

(4) The wage rate (including fringe benefits, where appropriate) determined pursuant to paragraphs (c)(2) and (c)(3) of this clause shall be paid to all workers performing work in the classification under this contract from the firstday on which work is performed in the classification.

(d) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof.

(e) If the Contractor does not make payments to a trustee or other third person, the Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program; provided, That the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Construction Wage Rate Requirements statute have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

(End of clause)

52.244-6 Subcontracts for Commercial Products and Commercial Services (SEP 2025)

(DEVIATION 25-34)

As prescribed in 44.403, insert the following clause:

Subcontracts for Commercial Products and Commercial Services (September 2025)

(a) Definitions. As used in this clause—

Commercial product, commercial service and non-developmental item have the meanings contained in Federal Acquisition Regulation (FAR) 2.101.

Subcontract has the meaning at FAR 44.401

(b) Requirements.

(1) To the maximum extent practicable, the Contractor shall incorporate, and require its subcontractors at all tiers to incorporate, commercial products, commercial services, or non-developmental items as components of items to be supplied under this contract.

(2) If a clause in the following table is included in the contract, the Contractor shall insert the clause in subcontracts for commercial products or commercial services and must flow down the requirements of the clause to subcontracts as indicated in the specific clause:

Number Title Date 52.203-13 Contractor Code of Business Ethics and Conduct NOV 2021 52.203-17 Contractor Employee Whistleblower Rights NOV 2023 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements JAN 2017 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.219-8 * Utilization of Small Business Concerns JAN 2025 52.222-35 Equal Opportunity for Veterans

JUN 2020

52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor Relations Act DEC 2010 52.222-41 Service Contract Labor Standards AUG 2018 52.222-50 Combating Trafficking in Persons NOV 2021 52.222-50 with Alt I Combatting Trafficking in Persons, with its Alternate I MAR 2015 52.222-51 Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Requirements MAY 2014 52.222-53 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services— Requirements MAY 2014 52.222-54 Employment Eligibility Verification JAN 2025 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.224-3 Privacy Training JAN 2017 52.224-3 with Alt I Privacy Training, with Alternate I JAN 2017 52.225-26 Contractors Performing Private Security Functions Outside the United States OCT 2016 52.232-40 Providing Accelerated Payments to Small Business Subcontractors MAR 2023 52.240-3 Security Prohibitions and Exclusions DATE 52.240-3 with Alt I Security Prohibitions and Exclusions, with its Alternate I 52.240-4 DATE Security Requirements DATE 52.240-4 with Alt II Security Requirements, with its Alternate II 52.247-64 DATE Preference for Privately Owned U.S. Flag Commercial Vessels NOV 2021

INVOICE INSTRUCTIONS

CONTRACTING OFFICER (KO) AUTHORITY

In the event the Contractor effects any change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price or delivery dates as a result thereof. The address and telephone number of the Contracting Officer(s) is:

Name: Ms. Crystal Miller Address: 1519 Alaskan Way South, Seattle, WA 98134 Office: Base Seattle (00033) (70Z033) Email: crystal.n.miller@uscg.mil

GOVERNMENT TECHNICAL POINT OF CONTACT:

mailto:crystal.n.miller@uscg.mil

Name: LT Alec MacLeod Address: 1 Ediz Hook Road, Port Angeles, WA 98362 Office: AIRSTA Port Angeles Email: alexander.j.macleod@uscg.mil

VENDOR PAYMENT INFORMATION

USCG FINANCE CENTER CUSTOMER SERVICE - Payment status can be provided from FINCEN Customer Service by phone, (757) 523-6940 (Option 1), or email, FIN-SMB-Customerservice@uscg.mil.

VENDORS please provide the following:

• PO# / Contract#

• Invoice#

• Invoice Amount

• Invoice Date

INVOICE INSTRUCTIONS

You will submit proper invoices associated with this award through the Invoice Processing Platform (IPP) at https://www.ipp.gov/. IPP is a secure web-based electronic invoicing system provided by the U.S.

Department of the Treasury’s Bureau of the Fiscal Service in partnership with the Federal Reserve Bank of St. Louis (FRSTL). IPP is available at no cost to any commercial vendor or independent contractor doing business with a participating government agency.

Actions to take:

If you are already enrolled in IPP:

If your company is already registered to use IPP, you will not be required to re-register and you do not need to contact IPP.

If you are NOT already enrolled in IPP:

The point of contact you provided in your SAM.gov registration will receive two emails from ipp.noreply@mail.eroc.twai.gov. Please note that emails from this email address may filter into your spam or junk folder:

1. The first email will have the IPP Logon ID and a link to the IPP application.

2. A second email, which will be sent within 24 hours of the first email, contains a temporary password.

Once your contact receives these emails, please ensure they log into IPP and complete the registration process.

Once registered to use IPP, your company may submit invoices electronically, receive e-mail notifications when requests are paid, view payment history, and access remittance downloads. The e-mail notification of payment is sent when a payment is distributed to your bank account and may include the following payment information: Date of payment, dollar amount, invoice number, paying agency, payee name, and ACH trace number.

Vendor training materials, including a first time login tutorial, are available on the https://www.ipp.gov/ website. Once you have logged in to the IPP application, you will have access to user guides that provide step-by-step instructions for all IPP capabilities, ranging from creating and submitting an invoice to setting up email notifications. Live webinars are held monthly and provide a great opportunity to learn the basic of the system and to call in and ask the IPP team questions about the IPP application.

mailto:alexander.j.macleod@uscg.mil mailto:FIN-SMB-Customerservice@uscg.mil https://www.ipp.gov/ mailto:ipp.noreply@mail.eroc.twai.gov https://www.ipp.gov/

IPP Customer Support is available to assist users of the system and can answer your questions related to accessing IPP or completing the registration process.

• Toll-free number: 866-973-3131

• Email address: IPPCustomerSupport@fiscal.treasury.gov

• Hours of operation: Monday through Friday (excluding bank holidays) from 8:00 am - 6:00 pm

ET

The contractor must email a copy of the invoice and supporting documentation to the personnel listed below, upon submission into the IPP platform. Failure to email the invoice and supporting documentation to the following contacts may result in invoice rejection or delay in payment:

Contracting Officer’s e-mail address: Crystal.N.Miller@uscg.mil

Electronic Submission of Payment Requests (FSMS Awards) JUL 2024

(a) Definitions. As used in these instructions -

(1) “Payment request” means a bill, voucher, invoice, or request for contract financing payment with associated supporting documentation. The payment request must: comply with the requirements identified in FAR 32.905(b), “Content of Invoices” and the applicable Payment clause included in this contract. In addition, discount offerings and small business status if available must be stated. If travel was allowable and approved, components in accordance with FAR 31.205-46 must be provided.

(b) Except as provided in paragraph (c) of this clause, the contractor must submit payment requests electronically using the Invoice Processing Platform (IPP). Information regarding IPP, including IPP Customer Support contact information, is available at www.ipp.gov or any successor site.

(c) The contractor may submit payment requests using a method other than IPP only when the contracting officer authorizes alternate procedures in writing in accordance with Coast Guard procedures.

(d) If alternate payment procedures are authorized, the contractor must include a copy of the contracting officer's written authorization with each payment request.

(e) IPP enrollment information is at https://www.uscg.mil/fincen/IPP/.

Section J – List of Attachments

20190PR260000141_SOW Self Help Replace Front Gate

70Z03326Q201900012_SF1442-22

Wage Determination # WA20260022

Section K - Representations, Certification, and other Statements of Offerors

FAR Clauses Incorporated by Reference mailto:Crystal.N.Miller@uscg.mil http://www.ipp.gov/ https://www.uscg.mil/fincen/IPP/

Number Title Effective Date

52.204-7 System for Award Management. (AUG 2025) (DEVIATION 25-19) (effective November 28, 2025)

Section L - Instrs., Conds., and Notices to Offerors

PROPOSAL PREPARATION INSTRUCTIONS

A. To ensure timely and equitable evaluation of proposal, offeror must follow the instructions contained herein. Proposal must be complete, self-sufficient, and respond directly to the requirements of this solicitation. The response shall consist of there (3) separate parts:

Part I - (SF 1442 front and back) Part II - Technical Proposal, Past Performance, Pricing Proposal breakdown, and Project Schedule Part III - Solicitation sections B thru K B. Specific Instructions:

1. PART I – TOTAL PRICE PROPOSAL - Submit documents via email as indicated below.

a. Complete blocks 14-20C of the RFP (SF 1442). In doing so, the offeror accedes to the contract terms and conditions as written in the RFP Sections A through K. These sections constitute the model contract.

This document shall be returned in its entirety (front and back) via email to Patrick R. Gittings (patrick.r.gittings@uscg.mil) by 3:00 P.M. PDT on 23 September 2026.

b. If email submission is rejected, offeror is required to call the Contracting Officer as soon as rejection is discovered to obtain Contracting Officer direction. Failure to provide the information to support rejection will result in offer being determined a late submission

2. PART II – TECHNICAL PROPOSAL Submit documents via email as indicated below.

a. The Technical Proposal shall not contain any pricing information. The Technical Proposal shall not exceed two (2) pages in length. It must provide a clear, concise narrative demonstrating the quoter’s understanding of and ability to meet the requirements of the Statement of Work (SOW). The proposal must include:

i. - Technical Approach: A step-by-step description of how the quoter will perform the work, including mobilization, installation, and inspection of the required equipment and materials.

ii. List of Major Materials and Equipment: A list of the key materials and equipment proposed for the project. This list is for technical evaluation purposes to ensure compliance with the SOW.

iii. Past Performance: Offerors shall provide three (3) recent and relevant contract references for projects completed or substantially completed within the past five (5) years] that involved work similar in scope and complexity to this requirement. Relevant experience includes installation, replacement, repair, commissioning, and testing of commercial, industrial, facility-access, sliding, cantilever, V-track, or automated gate systems. (3-pages maximum) separate from Technical and Pricing

iv. Price Proposal Breakdown: The offeror shall provide a price proposal that includes all costs necessary to perform the SOW. (No page limit) separate from pricing and past performance.

v. Project Schedule: A high-level timeline illustrating the project's major milestones. The schedule must start from the date of the Notice to Award (NTA) and demonstrate that all work, including performance verification and report submission, will be completed within the required Period of Performance, with a completion date of October 26th, 2026. This document shall be returned in its entirety (front and back) via email to Patrick R. Gittings (patrick.r.gittings@uscg.mil) by 3:00 P.M. PDT on 23 September 2026.

mailto:patrick.r.gittings@uscg.mil

b. If email submission is rejected, offeror is required to call the Contracting Officer as soon as rejection is discovered to obtain Contracting Officer direction. Failure to provide the information to support rejection will result in offer being determined a late submission. (2-pages maximum)

3. PART III – TERMS & CONDITIONS: fill-in sections b thru k - Submit documents via email as indicated below. Refer to Sections B through K of solicitation. Complete the necessary fill-ins and certifications in Sections B through K. This document shall be returned in its entirety (front and back) via email to Patrick R. Gittings (patrick.r.gittings@uscg.mil) by 3:00 P.M. PDT on 23 September 2026.

b) If email submission rejects, offeror is required to call the Contracting Officer as soon…