SF 30 - 70LGLY26QGLB00049 P00006.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

P00006

70LGLY

The purpose of this notice is to provide responses to questions submitted by potential contractors.

70LGLY

DEPARTMENT OF HOMELAND SECURITY FEDERAL LAW

ENFORCEMENT TRAINING CENTERS 1131 CHAPEL

CROSSING RD GLYNCO GA

DEPARTMENT OF HOMELAND SECURITY FEDERAL LAW

ENFORCEMENT TRAINING CENTERS 1131 CHAPEL

CROSSING RD GLYNCO GA

26CSO0013

70LGLY26QGLB00049

09/01/2026

08/24/2026

1 2

Question # 1 - Please clarify whether this requirement may be satisfied by a qualified proposed small-business manufacturer/subcontractor facility located within the required 35-mile radius, with (contractors name) remaining the prime contractor and fully responsible for performance, or whether the prime offeror itself must own, lease, or otherwise directly operate the qualifying facility.

Answer #1 - Yes. The 35-mile facility requirement may be satisfied through a qualified proposed small-business manufacturer/subcontractor facility located within the required radius, provided that [Contractor Name] remains the prime contractor and retains full responsibility for all contract performance requirements, including timely delivery. The prime contractor is responsible for ensuring that all signs comply with the contract specifications and pass Government inspection and acceptance. The Government will not be liable for any costs, charges, rework, replacement, transportation, or other expenses resulting from signs that fail inspection or are not accepted. Any costs associated with correcting deficiencies or otherwise achieving inspection and Government acceptance shall be the sole responsibility of the prime contractor.

The prime contractor is further advised that the required delivery date remains unchanged.

All required signs must be delivered, inspected, and accepted by the Government no later than September 30, 2026. Any use of a subcontractor or third-party facility must not delay performance or affect the Government’s required delivery schedule. The risk of any production, quality-control, transportation, rework, or acceptance delays remains solely with the prime contractor.