A003 .pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

1 3

2. AMENDMENT/MODIFICATION NUMBER

A003 OK FW SQH T501(1)

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS HIGHWAY DIVISION

12300 WEST DAKOTA AVENUE, SUITE 360

LAKEWOOD, COLORADO 80228

ATTENTION: LAURA SLAUTER

6905001

9A. AMENDMENT OF

SOLICITATION NUMBER

6982AF25B00021

9B. DATED (SEE ITEM 11)

10/20/2025

0*

*See Item 14

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

INVITATION FOR BID

*FAILURE TO ACKNOWLEDGE THIS AMENDMENT IN BLOCK 19 OF THE SF 1442 BY THE DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY RESULT IN REJECTION OF YOUR BID (REFER TO ITEM 11.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

11/19/2025

1.Remove and replace page A-1 with the corresponding page.

2.Remove and replace page A-3 with the corresponding page.

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration or Repair)

1. SOLICITATION NO.

6982AF25B000021

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

10/20/2025

PAGE OF

PAGES

IMPORTANT - THE "OFFER SECTION ON THE REVERSE MUST BE FULLY COMPLETED BY OFFEROR.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

HFLCEO250379PR

6. PROJECT NO.

OK FW SQH T501(1)

7. ISSUED BY:

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS DIVISION

12300 WEST DAKOTA AVENUE, SUITE 167

LAKEWOOD, COLORADO 80228

CODE: 69050001 8. ADDRESS OFFER TO:

Laura Slauter, Contract Specialist Federal Highway Administration Central Federal Lands Division Office 12300 W. Dakota Avenue Lakewood, CO 80228

9. FOR INFORMATION CALL

SEE PAGE A-3

A. NAME:

SEE PAGE A-3

B. TELEPHONE NO. (Include area code)

SEE PAGE A-3

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS:

ROADWAY CONSTRUCTION PROJECT IN STRICT ACCORDANCE WITH:

1. FEDERAL ACQUISITION AND TRANSPORATION ACQUISITION REGULATIONS (FAR & TAR)

2. DEPARTMENT OF LABOR, CONSTRUCTION WAGE RATE REQUIREMENT RATES

3. SPECIAL CONTRACT REQUIREMENTS

4. PLANS

5. BID SCHEDULE

6. STANDARD SPECIFICATIONS FOR CONSTRUCTION OF ROADS AND BRIDGES ON FEDERAL HIGHWAY

PROJECTS, FP-14, U.S. CUSTOMARY UNITS

See Subsection 104.04 of the FP-14 for governing order of precedence

11. The Contractor shall begin performance within 10 calendar days and complete it within * calendar days after receiving award notice to proceed. The performance period is mandatory negotiable. *See Page A-3

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.) YES NO

12B. CALENDAR DAYS

B. An offer guarantee is is not required.

C. All offers are subject to the (1) work requirements and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA

FAR (48 CFR) 53.236-1(d)

X

X

X

X

X

A-1 A003

11/19/2025

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 0 copies to perform the work required are due at the place specified in Item 8. by 2:00 p.m. (hour) local time on 11/21/25 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

Item 8:

Item 9:

Item 11:

LOCATION OF PUBLIC BID OPENING: Offers must be received by designated date and time as stated in Item 13A.

FOR GENERAL INFORMATION: E-mail us at CFLContracts@dot.gov.

FOR TECHNICAL INFORMATION (plans and specifications): Questions must be submitted in writing by e-mail at CFLContracts@dot.gov .

COMPLETION DATE: The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than See SCR Section 108.01, subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by January 5, 2026. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

Work shall be completed on or before the date specified above, subject to such extensions as may be authorized by the terms of the contract and the specifications made a part thereof.

Item 12A: PERFORMANCE AND PAYMENT BONDS: See FAR Clause 52.228-15 Performance and Payment Bonds-Construction (Clauses begin on Page C-1) and Subsection 102.06 of the FP-14.

Item 13B: BID BOND AMOUNT: See FAR Provision 52.228-1 Bid Guarantee (Provisions begin on Page B-1) and Subsection 102.03 Bid Guarantee of the FP-

14. All bid guarantees must have original signatures with original corporate seals.

Item 19: ACKNOWLEDGMENT OF AMENDMENTS: FAILURE TO

ACKNOWLEDGE AMENDMENTS, IN ITEM 19 OF THE SF-1442, BY THE

DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY

RESULT IN REJECTION OF YOUR BID. If amendments are issued, they will be posted to https://sam.gov.

Item 24: SUBMITTING INVOICES: See Subsection 109.08 Progress Payments of the

FP-14.

ESTIMATED PRICE: The price range of the project work is between $700,000 and $2,000,000.

A-3 A003

11/19/2025 mailto:CFLContracts@dot.gov mailto:CFLContracts@dot.gov https://sam.gov/