A001.pdf

PDF 1 MB Posted Aug 19, 2025

Attached to: NM FS 220(1), Romero Creek Bridge Federal contract opportunity
Solicitation number: 6982AF25B000012
Issued by: Department of Transportation Federal Highway Administration

About this file

Written by GovTribe AI · Aug 19, 2025

This document is an Amendment of Solicitation/Modification of Contract (Standard Form 30) for a federal highway construction project in New Mexico, issued by the Federal Highway Administration's Central Federal Lands Highway Division. The project covers highway construction work in multiple New Mexico counties, including Catron, Chaves, Curry, and others, with an estimated price range between $700,000 and $2,000,000.

Key details include a contract completion date of November 5, 2026, with the contractor required to commence work within 10 calendar days of receiving the notice to proceed. The amendment (A001) updates pages A-3 and D-1, which include information about bid submission, performance bonds, and wage determinations. Technical and general information inquiries should be submitted via email to CFLContracts@dot.gov. The solicitation notes that amendments will be posted to https://sam.gov, and failure to acknowledge amendments may result in bid rejection.

View the file

Other files for this federal contract opportunity

Other files attached to NM FS 220(1), Romero Creek Bridge, newest first.
File	Type	Posted
BidTabulationReport NM FS 220(1) Romero Creek Bridge LK.pdf	PDF	Oct 31, 2025
6982AF25B000012 Bid Opening Summary.pdf	PDF	Sep 16, 2025
SAM.gov Interested Vendors 09.15.25.pdf	PDF	Sep 15, 2025
20110101_220-7.325_BridgeGeometry.pdf	PDF	Sep 8, 2025
QnA _09.08.25.pdf	PDF	Sep 8, 2025
20180829_220-7.5_Inspection_report.pdf	PDF	Sep 8, 2025
NM FS 220(1) Plan Update 7-3-2025.pdf	PDF	Aug 15, 2025
Final Hydraulics Report January 14 2021.pdf	PDF	Aug 15, 2025
NM FS 220 1 Borrow Pits.pdf	PDF	Aug 15, 2025
11.12.4 Design Physical Data and Reports.zip	ZIP file	Aug 15, 2025
FINAL Geotechnical Report March 2023.pdf	PDF	Aug 15, 2025
6982AF25B000012.pdf	PDF	Aug 15, 2025
Technical Memorandum Pavement Materials Recommendations - November 9 2025.pdf	PDF	Aug 15, 2025

Show all 13

On GovTribe

Work with this file on GovTribe

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

A001

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

IFB

Remove and replace page A-3 with the attached corresponding page.

Remove and replace page D-1 with the attached corresponding page.

*FAILURE TO ACKNOWLEDGE THIS AMENDMENT IN BLOCK 19 OF THE SF 1442 BY THE DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY RESULT IN REJECTION OF YOUR BID (REFER TO ITEM 11.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS HIGHWAY DIVISION

12300 WEST DAKOTA AVENUE, SUITE 360

LAKEWOOD, COLORADO 80228

ATTENTION: LAURA SLAUTER

HFLCEO250287PR

6982AF25B000012

NM FS 220(1)

1 3

08/19/2025

08/15/2025

Item 8:

Item 9:

Item 11:

LOCATION OF PUBLIC BID OPENING: Offers must be received by designated date and time as stated in Item 13A.

FOR GENERAL INFORMATION: E-mail us at CFLContracts@dot.gov.

FOR TECHNICAL INFORMATION (plans and specifications): Questions must be submitted in writing by e-mail at CFLContracts@dot.gov .

COMPLETION DATE: The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than November 5, 2026, subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by November 03, 2025. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

Work shall be completed on or before the date specified above, subject to such extensions as may be authorized by the terms of the contract and the specifications made a part thereof. .

Item 12A: PERFORMANCE AND PAYMENT BONDS: See FAR Clause 52.228-15 Performance and Payment Bonds-Construction (Clauses begin on Page C-1) and Subsection 102.06 of the FP-14.

Item 13B: BID BOND AMOUNT: See FAR Provision 52.228-1 Bid Guarantee (Provisions begin on Page B-1) and Subsection 102.03 Bid Guarantee of the FP-

14. All bid guarantees must have original signatures with original corporate seals.

Item 19: ACKNOWLEDGMENT OF AMENDMENTS: FAILURE TO

ACKNOWLEDGE AMENDMENTS, IN ITEM 19 OF THE SF-1442, BY THE

DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY

RESULT IN REJECTION OF YOUR BID. If amendments are issued, they will be posted to https://sam.gov.

Item 24: SUBMITTING INVOICES: See Subsection 109.08 Progress Payments of the

FP-14.

ESTIMATED

PRICE: The price range of the project work is between $700,000 and $2,000,000.

A-3 A001

8/19/2025 mailto:CFLContracts@dot.gov mailto:CFLContracts@dot.gov https://sam.gov/

/%0�%123�"-��#.4"#0-��5.-6+"#��7�!

8� ��9��

��9��

�'��8 ��8�

��2 ��)��-��?/5��

)��'��8�

��2

��8�

��.��2 ��'��@�"A.��/�7�<7�</BBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBC0;��'��

��C/�+!�

��)��-��CC��

��;��6��$��(��C��&��$��

��'��CC��(�

��C��

�/��CC��

��!��7�/&/(��C/�#'��

��$��CC

��C��

�D��CC�;��6��$��(��C��E�F/F��'

��7

��CC��C��'��

�� &��CC��C��

��'�� &��CC��C��

�(��;��CC��C��'�&'��<�;

��CC��C��;

��'��CC��C��

��/��CCBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBCBBBBBBBBBBBBBBBBBBBBBBBBBBBBBCC0;��'��

�C/�+!�

��)��-��?��CC

�� 6��$��(��C��&��$��

��'��CC6��$��@(��(��'��C��

�/��CC

��C/�#'��

��$��CC�!��

��;��6��$��C��

�D��CC��(��C��E��/��'

��7

��'��CC��C��

�� &��CC��C��

�(CC��C��;��'�&'��<�;

��CC��C��'

��CC��C��'��

��/��CCBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBCBBBBBBBBBBBBBBBBBBBBBBBBBBBBBC#'�� )��-�� &�� 8��$/�0;��'��

�D�

��>��/2��

�D��

Executive Order 14026 (Increasing the Minimum Wage for Federal Contractors) was rescinded on March 14, 2025. Consult with the Department of Labor for guidance related to the wage determinations.

https://www.dol.gov/agencies/whd/ government-contracts/eo14026

D-1 A001 8/19/2025

File details come from the government source that posted it. Updated Aug 19, 2025.