697DCK-24-R-00463 7.3.24.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

FEDERAL AVIATION ADMINISTRATION

AAQ-500 - REGIONAL ACQUISITIONS

2300 E. DEVON AVENUE

DES PLAINES IL 60018-4696

AAQ520CHI-AFN

Karen Czerwiec CTR x 73

PURCHASE REQUEST NO.

697DCK-24-R-00463

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Project: Roof Repair and Refurbish at OAKA, OAKQ, OAKZ

This is a competitive, unrestricted procurement/solicitation.

A non-mandatory site visit will be offered on 7/18/24 at 10am.

Questions related to this solicitation must be sent via email to angela.layman@faa.gov and Karen.V-CTR.Czerwiec@faa.gov no later than 2pm Pacific time on 7/22/24.

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

10 60 calendar days and complete it within ________________ ________________ calendar days after receiving

1 1400

AMS 3.2.2.3.-71

07/26/2024 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

Angela Layman

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 73

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

697DCK-24-R-00463

(A) (B) (C) (D) (E) (F)

00001 Repair and refurbish roof, remove and replace doors at OAKQ ASR

Electronic & IT: 03

00002 Repair and refurbish Oakland RTR (OAKZ RTR) Roof

Electronic & IT: 03

00003 Repair and refurbish OAKA NASEB Roof

Electronic & IT: 03

Section B - Supplies or Services/Prices Section B - Schedule

In response to this request for offers, the offeror shall furnish all labor, materials and equipment, transportation, supervision, coordination and all related incidentals necessary to provide the services in accordance with the statement of work and contract requirements included herein.

CLIN 00001 Refurbish Roof and Replace Doors, OAK ASR

CLIN 00001 OFFER: $________________________________

CLIN 00002 Refurbish and Repair OAKZ RTR Roof

CLIN 00002 OFFER: $_________________________________

CLIN 00003 Refurbish and Repair OAK NASEB Roof

CLIN 00003 OFFER: $_________________________________

TOTAL COST, CLINs 00001, 00002, 00003 $ _________________________________

The offeror shall provide a detailed cost breakdown for each item listed showing labor hours/rate, materials, quantity/unit price, etc. The final contract cost shall separately indicate the prime contractor's overhead and profit rates as separate line items.

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

The Contractor shall provide all necessary labor, materials, equipment and other serviced needed to complete the work described below:

Remove and Replace Roof and Refurbish Building at the OAKQ NASEB (ASR)

The Oakland National Airspace System Equipment Building (NASEB) is located at the SW of the Oakland Airport between Runway 30 in the south field and San Francisco Bay. The site is suited within secured boundary of the Oakland Airport approximately 2 miles from the entrance gate.

This building is constructed of CMU 60 feet long, 24 feet wide and 10 feet high. The building is comprised of 2 sections: the ASR Equipment/UP and EG room sections.

The roof is gable type with very low slop which is covered with PVC roofing material which is over hanged all around the building and aprons. The soffit panels and metal fascia have sign of corrosion. The building includes 3 metal doors - one is a 60” wide double swing door for the EG room and 2-36” swing doors; one door is installed on the east and other on west wall into the ASR equipment/UPS room. The door into the E/G room and the westside door into the Equipment/UPS are badly corroded with wide cracks and fissures.

Contractor shall resurface the roof, remove, replace the corroded fascia and soffits, remove and replace 3 corroded exterior metal doors.

The work under this contract includes but is not limited to:

A- Clean the roof surface and recover the roof with one tier of ½ ” thick Insulation Board, one tier of ½” thick Fiber Board and one layer of fully adhered 60 mil thick Duro-Last membrane over the fiber board and steel drip edge. The roof shall be installed per manufacturer recommended method - inspected by their inspector and provide a warrantee for a minimum of ten (15) years.

B- Remove and replace the roof fascia and soffit panels and replace with new vinyl materials.

C- Remove and replace rain gutters with 6” aluminum gutter.

D- Remove and replace one 60” wide double swing doors into the EG room and 2-36” wide doors into the equipment room on the east/west wall with new steel doors. The doors shall be 1-3/4” galvanized Steel 18 Gage with polystyrene core. The doors shall comply with codes, specifications of the American National Standards Institute, and for he hardware ANSI A-115: a collection of A115.1-A-115.17, Series). The steel door must be fabricated in method which will be rigid, neat in appearance, and free from defects, warp, or buckles. No clearance shall be more than1/8 inch at the jamb’s heads, and bottom. The finish works must comply with recommendations of NAAMMs “metal Finish Manual. The doors and all other accessories shall be installed in accordance with manufacturer recommended methods and must be fitted accurately. The doors will be installed in secure building in coastal zone subject to saltwater vapor. Therefore, they must be tamper proof and corrosion resistance. The locking system must be heavy duty - Best Locks products (no core), or approved equal with comparability with the Best Lock cores.

E- Upon completion of the project the area shall be cleaned, and all trashes and debris generated for this project be removed from site and disposed of per state and local requirement NOTES: the roof does not have a parapet; therefore, the contractor must provide the appropriate fall protection for workers. The fall protection plan must be included in the contractors Health and Safety plan and submitted to the FAA for review (see Division 1).

1- Site does not have a water source. Contractor must supply all water required for the project.

2- The Contractor shall provide suitable on-site sanitary conveniences with proper enclosures for the use of all workers. Keep such conveniences clean and properly ventilated. Install, secure and maintain in conformity with requirements of all laws and ordinances governing such installation. Locations shall be subject to the RE's approval.

Remove such conveniences from the site at the completion of project.

3- The contractor vehicles must have the company name and/or logo fixed to the vehicle.

Refurbish Roof at the OAKZ RTR

Provide all necessary labor, materials, equipment, transportation and other services required to repair and refurbish the roof at the OAKZ RTR building located at 1209 Grumman Street in Oakland, CA.

The roof is comprised of 3 separated but connected building. approximately 22,000 SF. The roof surfaces is a flat with low slop structure and is an asphalt based roofing system with Styrene-Butadiene- System (SBS) Roofing Membrane and or Modified Bitumen/Asphalt Roofing either torchdown or mopped on the asphalt which has tear and wear, cracks, and bubbling on the roof surface and on parapets corner. The parapet is approximately 18” high with sheet metal wrapping.

Contractor shall refurbish the roof as described below:

• Remove and dispose of walking pads.

• Prior to start of the work all rubbish, waste shall be removed and leave the workplace in a clean and proper condition acceptable to the COR.

• Cut all abandoned in-place antenna posts on the roof surface.

• Inspect the roof deck for any soft spot and repair (Approximately 40 Marked Spots - but the actual number may be higher which must be field verified).

• Provide and install one layer of ½” insulation board over entire roof surfaces.

• Provide and install one layer of ½” dens deck board over insulation and mechanically fastened.

• Provide and install 60 white DuraLast membrane over the roof sand parapets and fully adhered to, and entire seems shall be examined for complete bond.

• Provide and install curb flashing and pipe boot flashing.

• Provide and install walking pads from the hatches to and or around equipment and antenna posts,

• Provide and install overflow drainage ducts.

In Addition, the contractor shall provide and install required accessories needed for the parapet and watertight roof, and compression metal at parapet.

The contractor may use the other equal brand and quality.

Roof Repairs and Refurbishment at the OAKA NASEB

Contractor shall repair and refurbish the roof at the OAKA NASEB building located at 1027 Grumman Street in Oakland California.

The roof is comprise of a rectangular shape approximately 12,000 SF. The roof surfaces is a flat with low slop structure and is an asphalt based roofing system with Styrene- Butadiene- System (SBS) Roofing Membrane and or Modified Bitumen/Asphalt Roofing either torch- down or mopped on the asphalt which has tear and wear, cracks, and bubbling on the roof surface, and on parapets corner. The parapet is approximately 18” high with sheet metal wrapping.

Contractor provides all necessary labor, materials, equipment and other services needed to refurbish the roof as described below:

• Remove and dispose of walking pads.

• Prior to start of the work all rubbish, waste shall be removed and leave the workplace in a clean and proper condition acceptable to the COR.

• Cut all abandoned in-place antenna posts on the roof surface.

• Inspect the roof surface for any soft spot and repair approximately 42 marked Spots – the size of soft spots varies from 4 to 8 sf – averaging 6 sf.

• Provide and install one layer of ½” insulation board over entire roof surfaces.

• Provide and install one layer of ½” dens deck board over insulation and mechanically fastened.

• Provide and install 60 white DuraLast membrane over the roof sand parapets and fully adhered to, and entire seems shall be examined for complete bond.

• Provide and install curb flashing and pipe boot flashing.

• Provide and install walking pads from the hatches to and or around equipment and antenna posts, Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.4-1 CONTRACTOR INSPECTION REQUIREMENTS (APR 1996)

3.10.4-2 INSPECTION OF SUPPLIES - FIXED PRICE (NOV 1997)

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

(a) 'Work' includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, without additional charge, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer.

The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless the Government determines that it is in the public interest to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may:

(1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or

(2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(j) In the absence of any formal disputes, a project will be deemed physically and financially complete within one year after final acceptance and excess funds will be deobligated at that time.

(End of clause)

3.10.4-11 INSPECTION - DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS

(APR 1996)

(a) Unless otherwise designated by the specifications, all workmanship performed under the contract is subject to Government inspection at all times and places where dismantling or demolition work is being performed. The Contractor shall furnish promptly and without additional charge all reasonable facilities, labor, and materials necessary for safe and convenient inspection by the Government. The Government shall perform inspections in a manner that will not unduly delay the work.

(b) The Contractor is responsible for damage to property caused by defective workmanship. The Contractor shall promptly segregate and remove from the premises any unsatisfactory facilities, materials, and equipment used in contract performance, and promptly replace them with satisfactory items. If the Contractor fails to proceed at once in a workmanlike manner with performance of the work or with the correction of defective workmanship, the Government may:

(1) by contract or otherwise, replace the facilities, materials, and equipment or correct the workmanship and charge the cost to the Contractor and

(2) terminate for default the Contractor's right to proceed.

The Contractor and any surety shall be liable, to the extent specified in the contract for any damage or cost of repair or replacement.

(End of clause)

Section F - Deliveries or Performance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

SA13 HOLIDAYS

The following Federal holidays are observed by the Federal Aviation Administration.

New Year's Day January 1st

Martin Luther King's Birthday Third Monday in January

Presidents Day Third Monday in February

Memorial Day Last Monday in May

Juneteenth June 19

Independence Day July 4th

Labor Day First Monday in September

Columbus Day Second Monday in October

Veterans Day November 11th

Thanksgiving Day Fourth Thursday in November

Christmas Day December 25th

SA35 FAA HOLIDAY MORATORIUM

No work shall be scheduled or take place during the week of and the weekend preceding the following holidays:

Thanksgiving, Christmas and New Year's Day. Only emergency work to restore critical services to the facility will be considered and a moratorium waiver must be submitted and approved. The moratorium period will not be counted against the contract construction duration for the project.

(End of Clause)

Section G - Contract Administration Data Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within [Enter number of days] calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

Section H - Special Contract Requirements Clause List

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JAN 2022)

(a) Definitions.

(1) "The Act," as used in this clause, means section 1352, title 31, United States Code.

(2) "Agency," as used in this clause, means executive agency, within the meaning of 5 U.S.C. 101, 102, and 104(I), and any wholly owned Government corporation within the meaning of 31 U.S.C. 9101.

(3) "Covered Federal action," as used in this clause, means any of the following Federal actions:

(i) The awarding of any Federal contract.

(ii) The making of any Federal grant.

(iii) The making of any Federal loan.

(iv) The entering into of any cooperative agreement.

(v) The extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

(4) "Indian tribe" and "tribal organization," as used in this clause, have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 5304) and include Alaskan Natives.

(5) "Influencing or attempting to influence," as used in this clause, means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

(6) "Local government," as used in this clause, means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

(7) "Officer or employee of an agency," as used in this clause, includes the following individuals who are employed by an agency:

(i) An individual who is appointed to a position in the Government under title 5, United States Code, including a position under a temporary appointment.

(ii) A member of the uniformed services, as defined in subsection 101(3), title 37, United States Code.

(iii) A special Government employee, as defined in section 202, title 18, United States Code.

(iv) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, title 5, United States Code, appendix 2.

(8) 'Person,' as used in this clause, means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(9) 'Reasonable compensation,' as used in this clause, means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

(10) 'Reasonable payment,' as used in this clause, means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

(11) 'Recipient,' as used in this clause, includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(12) 'Regularly employed,' as used in this clause, means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person must be considered to be regularly employed as soon as he or she is employed by such person for 130 working days.

(13) 'State,' as used in this clause, means a State of the United States, the District of Columbia, the Commonwealth of Puerto Rico, a territory or possession of the United States, an agency or instrumentality of a State, and multi- State, regional, or interstate entity having governmental duties and powers.

(b) Prohibitions. The offeror, by signing its offer, hereby certifies to the best of his or her knowledge and belief that:

(1) No Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement;

(2) If any funds other than Federal appropriated funds (including profit or fee received under a covered Federal action) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the screening information request (SIR), the offeror must complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and

(3) He or she will include the language of this clause in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 must disclose accordingly.

(4) This certification and disclosure is a prerequisite for making or entering into this contract imposed by the Act.

Any person who makes a prohibited expenditure or fails to file or amend a disclosure form, must be subject to a civil penalty of not less than $10,000 and not more than $100,000, for each such failure.

(c) The prohibitions of the Act do not apply under the following conditions:

(1) Agency and legislative liaison by its own employees.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of a payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action if the payment is for agency and legislative liaison activities not directly related to a covered Federal action.

(ii) For purposes of subdivision (c)(1)(i) of this clause, providing any information specifically requested by an agency or Congress is permitted at any time.

(iii) The following agency and legislative liaison activities are permitted at any time where they are not related to a specific solicitation for any covered Federal action:

(A) Discussing with an agency the qualities and characteristics (including individual demonstrations) of the person's products or services, conditions or terms of sale, and service capabilities.

(B) Technical discussions and other activities regarding the application or adaptation of the person's products or services for an agency's use.

(iv) The following agency and legislative liaison activities are permitted where they are prior to Screening Information Request (SIR) of any covered Federal action:

(A) Providing any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;

(B) Technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and

(C) Capability presentations by persons seeking awards from an agency pursuant to the provisions of a law authorizing such actions;

(v) Only those services expressly authorized by subdivision (c)(1)(i) of this clause are permitted under this clause.

(2) Professional and technical services.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of:

(A) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.

(B) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.

(ii) For purposes of subdivision (c)(2)(i) of this clause, 'professional and technical services' must be limited to advice and analysis directly applying any professional or technical discipline. For example, drafting of a legal document accompanying a submittal/offer by a lawyer is allowable. Similarly, technical advice provided by an engineer on the performance or operational capability of a piece of equipment rendered directly in the negotiation of a contract is allowable. However, communications with the intent to influence made by a professional (such as a licensed lawyer) or a technical person (such as a licensed accountant) are not allowable under this section unless they provide advice and analysis directly applying their professional or technical expertise and unless the advice or analysis is rendered directly and solely in the preparation, submission or negotiation of a covered Federal action. Thus, for example, communications with the intent to influence made by a lawyer that do not provide legal advice or analysis directly and solely related to the legal aspects of his or her client's submittal/offer, but generally advocate one proposal over another are not allowable under this section because the lawyer is not providing professional legal services.

Similarly, communications with the intent to influence made by an engineer providing an engineering analysis prior to the preparation or submission of a submittal/offer are not allowable under this section since the engineer is providing technical services but not directly in the preparation, submission or negotiation of a covered Federal action.

(iii) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.

(iv) Only those services expressly authorized by subdivisions (c)(2)(i) and (ii) of this clause are permitted under this clause.

(v) The reporting requirements herein must not apply with respect to payments of reasonable compensation made to regularly employed officers or employees of a person.

(d) Disclosure.

(1) If the Contractor, who requests or receives from an agency a Federal contract, has made or has agreed to make any payment using non-appropriated funds (to include profits from any Covered Federal action), to any person for the purpose of influencing or attempting to influence an officer or employee of any Agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with a Covered Federal action, the Contractor must file with that agency a disclosure form, OMB Standard Form LLL, Disclosure of Lobbying Activities..

(2) The Contractor must file a disclosure form at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the information contained in any disclosure form previously filed by such person under subparagraph (d)(1) of this clause. An event that materially affects the accuracy of the information reported includes:

(i) A cumulative increase of $25,000 or more in the amount paid or expected to be paid for influencing or attempting to influence a covered Federal action; or

(ii) A change in the person(s) or individual(s) influencing or attempting to influence a covered Federal action; or

(iii) A change in the officer(s), employee(s), or Member(s) contacted to influence or attempt to influence a covered Federal action.

(3) The Contractor must require the certification, and if required, a disclosure form by any person who requests or receives any subcontractor exceeding $150,000 under the Federal contract.

(4) All subcontractor disclosure forms must be forwarded from tier to tier until received by the prime Contractor.

The prime Contractor must submit all disclosures to the Contracting Officer at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor.

(e) Agreement. The Contractor agrees not to make any payment prohibited by this clause.

(f) Penalties.

(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or fails to file or amend the disclosure form to be filed or amended by paragraph (b) must be subject to civil penalties as provided for by 31 U.S.C. 1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.

(2) Contractors may rely without liability on the representations made by their subcontractors in the certification and in the disclosure form.

(g) Cost allowability. Nothing in this clause makes allowable or reasonable any costs which would otherwise be unallowable or unreasonable. Conversely, costs made specifically unallowable by the requirements in this clause will not be made allowable under any other provision.

(End of clause)

3.8.2-17 KEY PERSONNEL AND FACILITIES (JUL 2019)

(a) The personnel and/or facilities as specified below are considered essential to the work being performed hereunder and may, with the consent of the contracting parties, be changed from time to time during the course of the contract.

(b) Prior to removing, replacing, or diverting any of the specified personnel and/or facilities, the Contractor must notify in writing, and receive consent from, the Contracting Officer reasonably in advance of the action and must submit justification (including proposed substitutions) in sufficient detail to permit evaluation of the impact on this contract.

(c) No diversion will be made by the Contractor without the written consent of the Contracting Officer.

(d) The key personnel and/or facilities under this contract are:

Superintendent

Project Manager Major Subcontractors

(End of clause)

SA15 INSURANCE REQUIREMENTS SCHEDULE

"(See Section I, Clause 3.4.1-10, Insurance--Work on Federal Aviation Administration Installation)

During the term of the contract, the Contractor and each subcontractor shall at their own expense, purchase and maintain the following minimum insurance requirements in companies properly licensed and satisfactory to the Contracting Officer:

Automobile and Truck Liability

$200,000 - bodily injury per person, not to exceed $500,000 per occurrence.

$100,000 - property damage per occurrence.

Comprehensive General Liability

$500,000 - Combined bodily injury and property damage per occurrence.

Workmen's Compensation

$100,000 or statutory, whichever is greater.

Umbrella or Excess Liability

$1,000,000 combined single limits bodily injury and property damage.

Insurance certificates shall contain a provision that coverages afforded under the policies will not be canceled until at least 30 days prior written notice has been given to the Contracting Officer at the following address:

Federal Aviation Administration

ATTN: Angela Layman Contracting Officer, AAQ- 5A0 angela.layman@faa.gov

It is agreed that the Federal Aviation Administration, the property owner(s) and their representatives will be held harmless by the Contractor for any loss or damage to sheds, tools, equipment, property and materials of the Contractor, and his subcontractors, their servants and employees, it being understood that the Contractor may at his expense carry any insurance which may be required to provide the necessary protection against such loss or damage.

The Contractor shall not commence work under the contract until he has obtained all the insurance required hereunder and such insurance has been approved by the Contracting Officer. Approval of the insurance by the Contracting Officer shall not relieve or decrease the liability of the Contractor.

The policy shall name "The United States of America, acting by and thought the Federal Aviation Administration" as an additional insured with respect to operations performed under this contract.

SA42 WARRANTY COVERAGE

The warranty provisions of clause 3.10.1-20 Warranty -Construction are hereby incorporated into the subject contract as representing the minimum period of coverage and terms under the contract. This minimum coverage period does NOT represent the extended warranty period applicable and required for certain items and deliverables as covered in the specifications. For example, the contractual warranty period for roofing is 20 years. In the event of any discrepancy between warranty coverage as set forth in the specifications and the warranty provisions of the above referenced clause, under no circumstances shall the warranty period by interpreted to be less than one (1) year, nor the rights and remedies available to the government be any less than as provided by FAA AMS clause 3.10.1-20.

(End of Clause)

WA0002 INTERPRETATION OF CONTRACT: (NOTICE OF AMBIGUITIES)

This written contract and any and all identified writings or documents incorporated by reference herein or physically attached hereto, constitute the parties' complete agreement and no other prior or contemporaneous agreements either written or oral shall be considered to change, modify or contradict it. Any ambiguity in the contract will not be strictly construed against the drafter of the contract language, but shall be resolved by applying the most reasonable interpretation under the circumstances, giving full consideration to the intentions of the parties at the time of contracting.

It is the obligation of the Contractor to exercise due diligence to discover and to bring to the attention of the Contracting Officer at the earliest possible time, any ambiguities, discrepancies, inconsistencies, or conflicts in or between the specifications and the applicable drawings or other documents incorporated by reference herein. Failure to comply with such obligations may be deemed a waiver and release of any and all claims for extra costs or delays arising out of such ambiguities, discrepancies, inconsistencies and conflicts.

WA0008 SAVE HARMLESS AND INDEMNITY AGREEMENT

The Contractor must save and keep harmless and shall indemnify the Government against any and all liability, claims, demands, and costs, of whatever kind and nature, for injury to or death of an person or persons and for loss or damage to any property (Government or otherwise) occurring in connection with or in any way incident to or arising out of performance of the Contractor, or any subcontractor, or any employee, agent, or representative of the Contractor or any subcontractor.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-8 AUDIT AND RECORDS (JUL 2010)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 2021)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (JUL 2018)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT

1996)

3.4.2-7 FEDERAL, STATE, AND LOCAL TAXES - FIXED-PRICE, NONCOMPETITIVE

CONTRACT (OCT 2019)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED, WOMEN-OWNED, SERVICE-

DISABLED VETERAN OWNED, AND HUBZONE SMALL BUSINESS CONCERNS (JAN 2021)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2021)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JUL 2023)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME

COMPENSATION (OCT 2018)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (JUL 2023)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (OCT 2018)

3.6.2-18 DAVIS BACON ACT (JUL 2023)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2023)

3.6.2-20 PAYROLLS AND BASIC RECORDS (JUL 2023)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JUL 2023)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (JUL 2023)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JUL 2023)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (JUL 2023)

3.6.2-39 TRAFFICKING IN PERSONS (JUL 2023)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JUL 2023)

3.6.2-46 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JUL 2023)

3.6.2-47 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER 14026

(JUL 2023)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-17 EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (JAN 2020)

3.6.3-19 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-21 EFFICIENCY IN WATER CONSUMING PRODUCTS AND SERVICES (JAN 2020)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.3-25 AEROSOLS (OCT 2016)

3.6.3-26 FOAMS (OCT 2016)

3.6.4-8 BUY AMERICAN ACT AND FAA BUY AMERICAN PREFERENCE - USMCA

IMPLEMENTATION ACT - BALANCE OF PAYMENTS PROGRAM (JAN 2024)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8…