Amendment 006.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

(SF-30) FAA Template No. 11 (8/97)

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

OMB Control No. 2120-0595

p. 1

AAQ530ANM-AFN

The following is hereby added to the subject SIR:

Revision to a question previously answered in Amendment 003. This answer supercedes that response.

Clarifications, see page 2.

FEDERAL AVIATION ADMINISTRATION

AAQ-500 - REGIONAL ACQUISITIONS

2200 S. 216TH STREET

DES MOINES WA 98198-6547

697DCK-19-R-00353

1 2

06/17/2019

05/15/2019

Q. We would like to submit a hardcopy of our financials separate from the other Volume I requirements

(which we will submit electronically). If this is permitted, where and who should we send the hardcopy financials?

A. Yes, you may submit a hard copy of your Financials only. Be advised, they must arrive on our before the due date of June 26, 2019. The address is as follows, FEDERAL AVIATION ADMINISTRATION

2200 S. 216TH STREET

DES MOINES WA 98198-6547

ATTN: DARREN ODEGARD, AAQ-550

Please provide tracking information: to: Darren.odegard@faa.gov

Q. Will there be liquidated damages?

A. Yes.

3.2.2.8-5 LIQUIDATED DAMAGES - CONSTRUCTION (APR 1996)

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay to FAA as liquidated damages, the sum of $3,300.00 for each day of delay.

(b) If FAA terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work, together with any increased costs to FAA in completing the work.

(c) If FAA does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damages until the work is completed or accepted.

(End of clause)

Clarification on BIM requirement. A BIM model is no longer a requirement for this project. BIM may be used at the DBE’s discretion.

mailto:Darren.odegard@faa.gov