Amendment A001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A001 10/31/2025 N/A TX NP MULTI PMS(1),

Pavement Preservation Texas

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

69056725R000006

9B. DATED (SEE ITEM 11)

10/10/2025

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A

N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

(__ ) is extended, ( x ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D OTHER (Specify type of modification and authority)

N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

TX NP MULTI PMS(1),Pavement Preservation Texas

See page 2

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A001, dated 10/31/2025 TX NP MULTI PMS(1), Solicitation No. 69056725R000006 Pavement Preservation Texas

REVISIONS ARE AS FOLLOWS:

SF 1442, SOLICITATION, OFFER, AND AWARD (Pen & Ink change)

Page A-5, Block 11. Revises completion date to 09/03/2026

SOLICITATION PROVISIONS

SPECIAL CONTRACT REQUIREMENTS

Page E-20, Subsection 107.10(c), adds language.

Page E-20, Subsection 107.10(e)(12), adds language.

Page F-10, Table 409-2, revises information on table.

ENCLOSURES

Pages:

A-5

E-20

E-23

F-10

A-5

Continuation SF 1442

Project: TX NP MULTI PMS(1), Pavement Preservation Texas

Block 9 FOR GENERAL INFORMATION, call 360.619.7520 from the hours of 8:00 a.m. to

4:00 p.m. local time or e-mail us at wfl.contracts@dot.gov.

FOR TECHNICAL INFORMATION (plan and specification questions only), requests for technical information about this project will only be accepted in writing.

Submit questions via e-mail at wfl.plans-spec@dot.gov.

QUESTIONS/ANSWERS POSTED ONLINE. You can view questions and answers on the Contract Opportunities Website SAM.gov.

• Insert the solicitation number in search box.

• Scroll to the project.

• Make sure you are on the most recent view and look in the right section of the page for the most recent Q&A document.

Block 11

Block 12A

Block 13B

FOR DAVIS-BACON WAGE RATE INFORMATION go to the U.S. Department of

Labor, Branch of Construction Wage Determinations Website:

https://www.dol.gov/agencies/whd/government-contracts/state-assignments.

FOR PHYSICAL DATA, See Subsection 102.02a in the Special Contract Requirements for listing of available data. Physical Data will be posted with the solicitation on

SAM.gov website.

COMPLETION DATE: The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 09/03/2026, subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 01/12/2026. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

Work shall be completed on or before the date specified above, subject to such extensions as may be authorized by the terms of the contract and the specifications made a part thereof..

PERFORMANCE & PAYMENT BONDS: See FAR Clause, 52.228-15, Performance and Payment Bonds - Construction (clauses begin on page C-1) and Subsection 102.06 of the Standard Specifications for Construction of Roads and Bridges on Federal Highway

Projects, FP-14, U.S. Customary Units.

BID BOND AMOUNT: See FAR Clause 52.228-1, Bid Guarantee (clauses begin on page C-1).

ADDITIONAL INFORMATION: See Subsections 102.03 and 102.04 of Standard

Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP-

14, U.S. Customary Units.

Revised by Amendment A001 mailto:wfl.contracts@dot.gov mailto:wfl.plans-spec@dot.gov https://sam.gov/content/home https://www.dol.gov/agencies/whd/government-contracts/state-assignments http://www.sam.gov/

E-20 DIVISION 100

Special Contract Requirements

Project: TX NP MULTI PMS(1), Pavement Preservation Texas

(1) AMIS — Carol Black, Facility Manager, 830-775-7492 x 2219 (O);

(2) BITH — Marty Nogues, Facility Manager, 409-951-6702 (O) or 409-659-0452 (C);

(3) CHAM — Alejandro Tapia, Facility Manager, 915-532-7273 x 119 (O) or

915-312-1438 (C);

(4) FODA — James (Doug) Olds, Facility Manager, 432-426-3094;

(5) GUMO — Jason Hardy, Facilities Manager, 432-940-0191 (C) or 915-828-3251 x2200

(O);

(6) LYJO — Rebecca Renaud, Facility Manager, 830-868-7128 x 238 (O);

(7) PAAL — Guillermo Delgado, Facility Manager, 956-346-6663;

(8) PAIS — Brian Slate, Facility Manager, 361-949-8173 x 240 (O); and

(9) SAAN — David Vekasy, Facility Manager, 210-534-8875 x 246 (O).

(c) Dirt, plant, and foreign material. Delete the text of the first paragraph and substitute the following:

Remove dirt, plant, and foreign material from vehicles and equipment before entry into each park unit. Prevent introduction of noxious weeds and non-native plant species into the work site. Follow applicable Federal land management agency requirements and state requirements.

Maintain cleaning and inspection records. Clean hauling vehicles before their initial entry at each park; subsequent entries will not require cleaning unless requested. Notify the CO a minimum of 48 hours before entry to allow for inspection.

Clean all vehicles and equipment to remove all visible traces of soil, plant material, debris, and petroleum from wheels, tires, tracks, drive mechanisms, undercarriages, etc. Only materials and equipment free of toxic pollutants may be placed within wetlands and waters.

(d) Clearances for Contractor-selected, noncommercial areas. Delete this subsection and substitute the following:

(d) Requirements for noncommercial Contractor-located sources outside construction limits. Activities outside the construction limits include, but are not limited to the following;

material sources, waste sites, haul roads, staging areas, and water sources. Provide the following documents to the CO and anticipate a minimum of 60 days for approvals. Do not use sites or sources until approved by CO.

The requirements (1) through (6) below do not apply to Government designated sites or sources or commercial sites or sources that are established, have provided material over the last two years, have appropriate Federal, State and local permits, and do not require expansion outside their currently established and permitted area.

Revised by Amendment A001

E-23 DIVISION 100

Project: TX NP MULTI PMS(1), Pavement Preservation Texas

(9) Follow posted speed limits. Reduce speed by 5 miles per hour during dawn and dusk.

Maximum nighttime speed for all construction related traffic is limited to 25 miles per hour if the posted speed is 30 miles per hour or greater.

(10) Install and maintain mufflers and sound attenuation devices on all equipment and vehicles. Unmuffled engine braking is not allowed.

(11) When performing nighttime operations according to Subsection 156.08, only downcast lighting and fixture shielding to prevent light from extending beyond work area will be allowed in night lighting systems. Night work is only allowed where specified.

(12) Orientation sessions. Notify the CO at least two weeks before starting work so an orientation session can be coordinated. All Contractor and subcontractor employees are required to attend a park orientation session before commencing work. Orientation sessions will include information about park values, regulations, penalties, inadvertent discovery response, and appropriate housekeeping. It will be the responsibility of the prime Contractor to orient all new subcontractors on Park policies. The CO is to be notified of all orientations that are being conducted.

F-10 DIVISION 400

Project: TX NP MULTI PMS(1), Pavement Preservation Texas

T a b le

-2

S a m p li n g T es ti n g a n d A cc ep ta n c e

R eq u ir em e n ts

R em a rk s

S o u rc e

N o t re q u ir ed w h en u si n g p re

-c ru sh ed co m m er ci al so u rc

P ro d u ct io

T es te d b y

G v er n m en t

(1

A p p li es t o e ac h a g g re g at e g ra d e fu rn is h ed

(2

A p p li es t o e ac h a sp h al t m at er ia l fu rn is h ed

R ep o rt in im

B ef d u ci h o rs rp o ra ti to w rk h o rs rp o ra ti w rk li t

S a m le

Y

-q u ar t sa m p le s

-q u ar t sa m p le s in t o f

S a m p li u rc e o f m at er ia l

C ru sh er el t (d u ri d u ct io n

P o in t o f sh ip m en t o r d el iv ck p il e

P o in t o f sh ip m en t o r d el iv

D is tr ib u to r tr ck m p li

F q u en cy at er ia l ty p e p er d ay st ck p il e at er ia l ty p e

,0 y t le ss t an er p ar k p er ay

M im is tr ib u to r tr ck t M et h o d s

S p ec if ic a ti o n s

S u b se ct

.1

A

S H

O

T b se ct

.0

S H

O

T b se ct

.0

(b

C te g ry

C a ra ct er is ti c

Q al it ra d at

Q al ra d at io n ee ab le

-8 f o r ap p li ca le si ev es

Q u al la ce m en t te m p er at p e o f

A cc ep ta ce

(S b se c ti o n

M ea su re d a te ed f o r co n fo rm

.0

P ro ce ss c o n tr o l

(1

.0

M ea su re d a ed f o r co n fo rm

.0

S ta ti st ic al

.0

M ea su re d a ed f o r co n fo rm

.0

P ro ce ss c o n tr o l

(1

.0

M a te r ia l o r

P ro d ct

(S b se c ti o n

M ic ro s u rf ac ag re g at e fo r

S u rf ac e m ix tu re

(1

P o ly m er m o d if ie ls if as h al t(2

M ic ro s u rf ac ag re g at e fo r

S u rf ac e m ix tu re

(1

P o ly m er m o d if ls if as h al t(2