PROJECT SPECIFICATIONS

DMVA PROJECT NO. 42240022

For

BLDG. 11-70

INTERIOR RENOVATION

AREA 11 – UTILITY ROAD

FORT INDIANTOWN GAP

ANNVILLE – LEBANON COUNTY – PENNSYLVANIA - 17003

COMMONWEALTH OF PENNSYLVANIA

DEPARTMENT OF MILITARY AND VETERANS’ AFFAIRS

ANNVILLE, PENNSYLVANIA

Josh Shapiro, GOVERNOR Major General John R. Pippy, THE ADJUTANT GENERAL

Date: 15, April 2026

DESIGN PROFESSIONALS

Office of Facilities and Engineering

Bureau of Design and Project Management Bldg. 0-10, Chapel Road, Ft. Indiantown Gap

Annville, Lebanon County, Pa. 17003 Phone: (717) 861-6487 Fax: (717) 861-8583

DMVA Project#: 42240022 0000002 - 1 BLDG. 11-70 Interior Renovation

DRAWING INDEX

The drawings which form a part of this project are indicated in the following list.

NUMBER DRAWING TITLE

G1.0 COVER SHEET

G1.1 PROJECT INFORMATION

G1.2 CODE ANALYSIS AND LEGENDS

A1.1 FLOOR PLANS

A2.1 EXTERIOR ELEVATIONS

A3.1 ENLARGED PLANS & DETAILS

A3.2 SECTIONS & DETAILS

A4.1 SCHEDULES & DETAILS

M0.1 MECHANICAL DEMO PLAN

M1.1 MECHANICAL FLOOR PLANS

M2.1 MECHANICAL SCHEDULES

P0.1 PLUMBING DEMO PLAN

P1.1 PLUMBING FLOOR PLAN

P2.1 PLUMBING DETAILS

E0.1 DEMOLITION PLANS

E1.1 LIGHTING & POWER PLANS

E2.1 SCHEDULES & DETAILS

The above is an exact list of the drawings included under DMVA Project No. 42240022 and shall be considered a part thereof.

As the work progresses, the Bureau of Design and Project Management may furnish supplemental drawings that may be required for further illustrating details of the work. However, these supplemental drawings will not include the shop drawings, all of which are to be prepared by the Contractor and submitted as hereinafter specified for approval before the work is started.

DMVA Project#: 42240022 0000003 - 1

TABLE OF CONTENTS

SECTION TITLE

DIVISION 01 GENERAL REQUIREMENTS

Section 010100 Summary of Work Section 010400 Coordination and Control Section 013100 Sequence of Construction & Milestones Section 013300 Submittals Form 66 – General Form 66 – HVAC Form 66 – Plumbing Form 66 – Electrical Section 014000 Quality Control Requirements DMVA Inspection Log Section 016350 DMVA Supplemental Provisions Section 017700 Closeout Procedures Section 017823 Operation and Maintenance Data Section 017839 Project Record Documents

GENERAL CONSTRUCTION (.1)

DIVISION 02 EXISTING CONDITIONS

Section 024120 Cutting & Patching

DIVISION 03 CONCRETE

Section 033000 Cast-In-Place Concrete

DIVISION 04 MASONRY

Section 040120.63 Brick Masonry Repair Section 042000 Concrete Unit Masonry

DIVISION 05 METALS

Section 054000 Load Bearing Metal Framing

DIVISION 06 WOOD, PLASTICS, AND COMPOSITES

Section 061000 Rough Carpentry Section 061600 Sheathing Section 061753 Roof Trusses

DIVISION 07 THERMAL AND MOISTURE PROTECTION

Section 072100 Thermal Insulation Section 074113 Metal Roof Panels Section 074600 Siding and Soffit Section 076200 Sheet Metal Flashing and Trim Section 077100 Gutters and Downspouts Section 079200 Joint Sealants

DMVA Project#: 42240022 0000003 - 2

DIVISION 08 OPENINGS

Section 081113 Metal Doors and Frames Section 083323 Overhead Coiling Doors Section 087111 Door Hardware

DIVISION 09 FINISHES

Section 092216 Non-Structural Metal Framing Section 097200 Fiberglass Reinforcement Panels Section 099113 Exterior Painting Section 099123 Interior Painting

HVAC CONSTRUCTION (.2)

DIVISION 23 HEATING VENTILATION AND AIR CONDITIONING

Section 230500 Common Work Results for HVAC Section 230510 HVAC Electrical Equipment and Wiring Requirements Section 230520 HVAC Specialties Section 230553 Mechanical Identification Section 230593 Testing, Adjusting and Balancing for HVAC Section 230713 HVAC Duct Insulation Section 231123 Natural Gas Piping Section 233110 Ductwork, Accessories and Sheetmetal Section 233423 HVAC Power Ventilators Section 233713 Diffusers and Grilles Section 237413 Packaged, Outdoor, Roof-Top Air-Handling Units

PLUMBING CONSTRUCTION (.3)

DIVISION 22 PLUMBING

Section 220500 Common Work Results for Plumbing Section 221110 Plumbing Piping Section 221316 Sanitary Waste and Vent Piping Section 223400 Plumbing Equipment

ELECTRICAL CONSTRUCTION (.4)

DIVISION 26 ELECTRICAL

Section 260500 Common Work Results for Electrical Section 260510 Electrical Equipment Wiring Section 260519 Low-Voltage Electrical Power Conductors & Cables Section 260526 Grounding & Bonding for Electrical Systems Section 260529 Hangers & Supports for Electrical Systems Section 260533 Raceway & Boxes for Electrical Systems Section 260553 Identification for Electrical Systems Section 260573 Overcurrent Protective Device Coordination Study

DMVA Project#: 42240022 0000003 - 3

Section 260923 Lighting Control Devices Section 262726 Wiring Devices Section 262813 Fuses Section 262816 Enclosed Switches and Circuit Breakers Section 265119 LED Interior Lighting

DMVA Project#: 42240022 010100 - 1

SECTION 010100

SUMMARY OF WORK

PART 1 – GENERAL

1.1 STIPULATIONS

A. The specifications “General Conditions of the Construction Contract”, “Special Conditions” and “Division 1 – General Requirements” form a part of this Section by this reference thereto and shall have the same force and effect as if printed herewith in full.

1.2 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.3 SCOPE OF WORK, GENERAL

A. The work under this Contract shall generally consist of, but not necessarily be limited to, providing all labor, material, devices, tools and equipment required for the 10,893 square feet interior renovation of Building 11-70 to include installation of a metal framed partition wall with coiling doors, a covered storage space, exterior door openings, the addition of an HVAC system to control humidity and associated electrical work located at Fort Indiantown Gap, Annville, PA and shall be in total accordance with the specifications and drawings and subject to the terms and conditions of all other Contract Documents.

1.4 PERFORMANCE PERIOD

A. Three-hundred sixty days (360) calendar days from Government granted Notice to Proceed.

1.5 WAGE SCALES

A. Wage Scales ARE REQUIRED to be paid on this Project.

1.6 QUESTIONS DURING BID PROCESS.

A. Direct all questions pertaining to the project as shown and described in the contract documents to both persons listed below.

Melanie A. Morris DMVA, Bureau of Military Construction & Engineering Bldg. 0-10, Fort Indiantown Gap Annville, PA 17003 Email: melmorris@pa.gov Ph.: 717.861.6487 Fax: 717.861.8683

DMVA Project#: 42240022 010100 - 2

Tina Rebuck DMVA, State Contracting Office Building 0-47, Fort Indiantown Gap Annville, PA 17003 Email: trebuck@pa.gov Ph.: 717.861.8794 Fax: 717.861.2932

B. Should the contractor submit an RFI via email, the subject line shall appear as follows:

1. DMVA Project#: 42240022_BLDG 11-70 Interior Renovation

2. Additional information can be included thereafter.

1.7 SUBMITTALS

A. See individual Sections and “SCHEDULE OF MATERIAL SUBMITTALS (AF FORM 66)” included within the project Design Documents

B. Submittals shall be forwarded to Department of Military & Veteran’s Affairs; Division of Engineering and Architecture, Building 0-10, Fort Indiantown Gap, Annville, Pa 17003

C. Each submittal shall include the following:

1. Project number

2. Contract number

3. Related specification section

4. Contractor’s approval stamp

5. Contractors initials and date

6. Area for DMVA-BMCE review stamp

D. All submittals must be approved by the discipline responsible, DMVA-BMCE Design Professional prior to incorporation into the project.

1.8 REQUIRED WARRANTIES

A. Contractor shall provide all required warranties as outlined within the Project Design Specifications and on all included Government AF Form 66’s.

PART 2 – OUTLINE OF REQUIRED WORK

2.1 The work of this project consists of but is not necessarily limited to the following. Detailed requirements of the work are described on the pertinent specification sections and/or shown on the drawings.

A. (GENERAL – POINT 1)

1. Prepare and submit all necessary pre-construction documentation as outlined within the project Design Documents.

2. Outline individual construction tasks/milestones.

3. Demolish items in accordance with the demolition notes listed on drawing A1.0.

DMVA Project#: 42240022 010100 - 3

4. Install all exterior site facility features, to include but not limited to concrete pads, sidewalks, perimeter landscaping, etc. as depicted within the Project Design Documents.

5. Install all exterior facility features, to include but not limited to, lean-to roof, personnel doors, gutter, downspouts, etc. as depicted within the Project Design Documents.

6. Install all interior facility features, to include but not limited to, wall partitions, blocking, doors, etc. as depicted within the Project Design Documents.

7. Complete Punch Lists and Final Cleaning.

8. Provide all required closeout documentation and training per the Project Design Documents prior to deeming/granting the project complete.

B. (HVAC – POINT 2)

1. Prepare and submit all necessary pre-construction documentation as outlined within the project Design Documents.

2. Outline individual construction tasks/milestones.

3. Relocation of unit heater

4. Removal of unit heaters no longer utilized.

5. Removal of exhaust fan and replacement of second exhaust fan.

6. Removal of abandoned vehicle exhaust system.

7. Installation of new ground mounted horizontal discharge Roof Top Unit.

8. Installation of new supply and return air duct distribution system.

9. Installation of new swing arm weld fume extraction system.

10. Installation of new swing arm fume extraction system.

11. Complete Punch Lists and Final Cleaning.

12. Provide all required closeout documentation and training per the Project Design Documents prior to deeming/granting the project complete.

C. (PLUMBING – POINT 3)

1. Prepare and submit all necessary pre-construction documentation as outlined within the project Design Documents.

2. Outline individual construction tasks/milestones.

3. Removal of existing oil water separator.

4. Cleaning of existing oil water separator pit.

5. Installation of new oil water separator.

6. Installation of new gas piping to ground mounted new roof top unit.

7. Installation of new emergency shower/eye wash with water piping extension.

8. Complete Punch Lists and Final Cleaning.

9. Provide all required closeout documentation and training per the Project Design Documents prior to deeming/granting the project complete.

D. (ELECTRICAL – POINT 4)

1. Prepare and submit all necessary pre-construction documentation as outlined within the project Design Documents.

DMVA Project#: 42240022 010100 - 4

2. Outline individual construction tasks/milestones.

3. Provide selective demolition.

4. Provide branch circuit rough-ins.

5. Provide door bell system.

6. Provide lighting fixtures.

7. Provide lighting controls.

8. Provide wiring devices.

9. Provide Fault Current/Coordination Study and label all equipment.

10. Complete Punch Lists and Final Cleaning.

11. Provide all required closeout documentation and training per the Project Design Documents prior to deeming/granting the project complete.

END OF SECTION 010100

DMVA Project#: 42240022 011200 - 1

SECTION 011200

COORDINATION AND CONTROL

PART 1 - GENERAL

1.1 STIPULATIONS

A. The specifications “General Conditions of the Construction Contract”, “Special Conditions” and “Division 1 – General Requirements” form a part of this Section by this reference thereto and shall have the same force and effect as if printed herewith in full.

1.2 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.3 SUMMARY

A. Section includes a summary of each contract, including responsibilities for coordination and temporary facilities and controls that govern the performance of the work to complete this project.

B. Specific requirements for work of each contract are also indicated in individual Specification Sections and on Drawings.

1.4 PRIME CONTRACTS FOR CONSTRUCTION

A. Point 1 – General (Lead)

B. Point 2 – HVAC

C. Point 3 – Plumbing

D. Point 4 – Electrical

1.5 WORK HOURS

A. Regular work hours will be Monday through Friday, 7:00 am to 4:30 pm.

B. Holidays: No work will be allowed on holidays observed by the State and Federal Government.

C. Weekends: No work will be allowed on weekends.

D. Exceptions: If deemed necessary, exceptions to the above can be made. Prime Contractors must submit, in writing, justification for such an exception and approval from the Department must be obtained prior to commencement of any work.

1. Fort Indiantown Gap: Any and all work that takes place outside of the working hours as listed herein, shall be coordinated with the DMVA-FTIG Construction Manager. Contractor(s)

DMVA Project#: 42240022 011200 - 2 performing work on approved dates shall submit, in writing, a list of all employees that will be on site for the days approved. This list of employees will be submitted to the Fort Indiantown Gap Police Dept. by the DMVA-FTIG Construction Manager.

1.6 COORDINATION

A. The General Contractor shall be responsible for coordination between all contracts.

1. Construction operations shall be coordinated to ensure efficient and orderly installation of each part of the work.

2. Coordinate installation of different components with other Contractors to ensure accessibility for required construction operations.

3. Make necessary provisions to accommodate items scheduled for later installation.

PART 2 - TEMPORARY FACILITIES AND EQUIPMENT

2.1 GENERAL

A. It shall be the responsibility of each Contractor to provide, maintain, and remove all facilities and equipment necessary for construction operations for individual Contracts.

1. These items include, but are not limited to:

a. Costs and use charges associated with the facility.

b. Plug-in cords, power cords, and extension cords, power tools.

c. Task lighting and special lighting necessary for construction operations.

d. Storage and fabrication structures/areas.

e. Temporary enclosures for construction activities.

f. Hoisting equipment for construction activities.

g. Waste disposal facilities, including collection and legal disposal of its own waste materials.

h. Daily cleaning of work area.

i. Secure lockup of tools, materials, and equipment.

j. Construction aids, services, and facilities necessary for individual construction activities.

2.2 FIELD OFFICES

A. CONTRACTOR TRAILERS/OFFICES

1. The Prime Contractor(s) shall provide and maintain, at their cost, a suitable office on the premises.

Trailer/offices shall be located based on the either the staging area depicted on the Project Design Documents and/or the location determined during the Pre-Construction Coordination Meeting.

The Contractor shall provide and maintain all necessary services and utilities for their respective offices and/or trailers, to include, but not limited to; electrical services, sanitary and water services, heating and cooling, telephone/fax and internet services.

B. SANITARY FACILITIES

DMVA Project#: 42240022 011200 - 3

1. Portable Toilets (Porta Johns) – Point 1 General Contractor (Lead), at their costs, shall be responsible for providing and maintaining any and all temporary toilet facilities. Toilets are to be utilized by all persons (Contractors, Sub-Contractors, DMVA Personnel, etc.) associated with the project.

a. Cleaning, Pumping and Maintenance of the portable toilets shall be the responsibility of the Point 1 General Contractor.

PART 3 - TEMPORARY SERVICES/UTILITIES DURING CONSTRUCTION

3.1 CONTRACTOR RESPONSIBILTIES

A. The General Contractor shall be responsible for all temporary heating, cooling, ventilation, power, lighting and water/sewer. This shall include, unless otherwise indicated, utility-use charges, temporary meters, and temporary connections, necessary during construction operations.

B. The designated Contractor shall install, operate, protect and maintain the respective temporary services as specified herein during the duration of the entire project.

C. Temporary connections to new and/or existing permanent service lines shall be made at locations as directed by the Department, and when the temporary service lines are no longer required, they shall be removed by the Contractor. Any part or parts of the permanent service lines, grounds and building, disturbed and damaged by the installation and/or removal of the temporary service lines, shall be restored to their original condition by the Contractor responsible for the temporary installation.

D. If the Contractor fails to carry out its responsibility in supplying temporary services as set forth in this contract it is responsible for such failure and the Department may take such action as it deems proper for the protection and conduct of the work and shall deduct the cost involved from the amount due the Contractor. Only those temporary utilities required for construction need to be extended to the work area(s).

3.2 INTERRUPTION OF SERVICES

A. Each Prime Contractor shall have all needed equipment and material to complete planned work at the site prior to shutting down any system.

B. No additional compensation or time will be given to the Contractor if work must be performed on State or National Holidays or on weekends or on overtime. See Paragraph 1.4 on ‘Working Hours’.

3.3 WELDING

A. Any Contractor using electrical power for welding on the site shall use self-contained engine generating units.

3.4 FIRE EXTINGUISHERS

A. Each Contractor shall provide UL listed, NFPA approved fire extinguishers (ten (10) lb. minimum) at the construction site during operations, suitable for all types of fires in accordance with OSHA.

DMVA Project#: 42240022 011200 - 4

PART 4 - RESTORATION AND REPAIRS

4.1 RESTORATION

A. All restoration required due to contract operations, shall be the responsibility of each individual Contractor for their location/area of operation, at no expense to the Department.

4.2 REPAIRS

A. Each individual Contractor shall be responsible for any and all repairs to work areas, to include repairs to both existing finishes and completed work.

B. Individual Contractors will not be responsible for damages resulting from on-going work, neglect and/or carelessness of other contractors and/or their associated sub-contractors. Parties responsible for any damages, no matter the circumstances, will be required to repair all damages at no expense to the Department.

END OF SECTION 011200

DMVA Project#: 42240022 013100 - 1

SECTION 013100

SEQUENCE OF CONSTRUCTION AND MILESTONES

Part 1 GENERAL

A. The specifications “General Conditions of the Construction Contract”, “Special Conditions” and “Division 1 – General Requirements” form a part of this Section by this reference thereto and shall have the same force and effect as if printed herewith in full.

1.2 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.3 GENERAL REQUIREMENTS

A. Before beginning work, the Contractor will be required to prepare a schedule in consultation with the Department. The work must be carried out in full accordance with the schedule. The Contractor shall arrange without any unnecessary interference with the Institution’s operation.

1.4 CRITICAL MATERIALS AND EQUIPMENT

A. The Contractor is cautioned that all necessary and required critical materials and equipment shall be ordered as quickly as possible, in order that the shipping will not delay the progress of the work or completion of the project.

1.5 CRITICIAL ITEMS TO BE NOTED AS MILESTONES

A. Refer to the General Conditions regarding construction progress Milestones to be established by the Lead Contractor.

B. The Lead Contractor shall submit a construction schedule, for the total project, including all prime contractors critical path work items. The schedule shall be submitted at the pre-construction meeting.

The schedule will be reviewed and approved by the designer and the using agency to confirm compliance with construction sequencing and Using Agency training schedule.

1. GENERAL CONSTRUCTION (.1)

a. Construction Sequencing

1) Submittals

DMVA Project#: 42240022 013100 - 2

2) Mobilization

3) Site Clearing and Excavation

4) Concrete - Slab

5) Concrete - Stoops

6) Exterior Walls - Masonry

7) Roof – Trusses

8) Roof – Sheathing

9) Roof - Metal Panels

10) Interior Walls - Metal Studs

11) Insulation – Wall Cavity

12) Interior Walls - Plywood

13) Doors - Exterior (Incl. Hardware)

14) Doors - Interior (Incl. Hardware)

15) Painting - Interior & Exterior

16) Final Cleaning, Puch List Items, Close-Out Documents

2. HVAC (.2)

a. Construction Sequencing

1) Submittals

2) Mobilization

3) Concrete Pads

4) Metal Ductwork

5) Duct Insulation

6) Duct Accessories & VVT System

7) Diffusers and Grilles

8) Power Ventilators & Louver

9) Wall unit Heaters

10) Instrumentation and Controls

11) Air handlers & Condenser Units

12) Duct Furnace & Vents

13) Testing, Adjusting & Balancing

14) Interior Gas Lines & Valves

15) Exterior Gas Lines & Regulator

16) Excavation & Backfill for Gas Line

3. PLUMBING (.3)

a. Construction Sequencing

1) Submittals

2) Mobilization

3) Excavations & Installation of Sanitary Waste

4) Indoor Sanitary Waste and Vent Line Installation

5) Plumbing Fixtures Installation and Rough-Ins

6) Indoor Domestic Water Line installation and related Insulation

7) Installation of Tankless water heater and Venting

8) Excavation & Installation of Domestic Water Service

9) Testing and Adjusting

10) Final Cleaning, Puch List Items, Close-Out Documents

4. ELECTRICAL (.4)

a. Construction Sequencing

1) Submittals

2) Mobilization

3) Branch Circuit Rough-Ins

DMVA Project#: 42240022 013100 - 3

4) Branch Circuit Wiring

5) Installation of Lighting

6) Installation of devices and outlets

7) Testing and Adjusting

8) Final Connections

9) Final Cleaning, Punchlist Items, and Close-Out Documentation.

END OF SECTION 013100

DMVA Project#: 42240022 013000 - 1

SECTION 013300

SUBMITTALS

Part 1 GENERAL

A. The specifications “General Conditions of the Construction Contract”, “Special Conditions” and “Division 1 – General Requirements” form a part of this Section by this reference thereto and shall have the same force and effect as if printed herewith in full.

1.2 RELATED DOCUMENTS

A. Drawings and general provision of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.3 SUMMARY

A. Included in this section of the specifications is a list of approvals required for all materials incorporated into the project. The Department reserves the right to require additional approvals if necessary. No material, equipment or supplies listed herein shall be incorporated into the work until the Contractor has obtained prior approval from the Department.

B. Submittals required by each prime contract are indicated within AF Form 66 “Schedule of Material Submittals” attached to the end of Section 01300.

1.4 SUBMITTAL PROCEDURES

A. Refer to ‘Submittals’ of the General Conditions.

B. Comply with the following or resubmission will be required:

1. Indicate contract number, specification section and building number (as shown on the drawings) on each item submitted.

2. Signify approval by stamp, initialing and dating each item prior to submission to the Professional.

C. Items requiring testing shall be forwarded directly to the approved laboratory. The Contractor shall pay all costs associated with testing.

D. Expedite critical materials, equipment and shop drawings, and other required submissions.

E. Incomplete submissions will be returned for resubmission.

F. Use of substitutions for materials or details shown on the contract drawings or called for in these specifications require written approval from the Department. See General Conditions.

1.5 PRODUCT DATA

DMVA Project#: 42240022 013000 - 2

A. Manufacturer's printed directions and manufacturer's standard specifications showing all dimensions, cuts, finishes, etc., as well as catalog cuts and ratings of all material will be required and shall be submitted in advance prior to application and/or installation.

1.6 TESTS

A. Refer to ‘Tests’ of the General Conditions.

B. Submit required reports listing items tested, tests conducted and results obtained as specified.

1.7 CERTIFICATIONS

A. Submit required certifications in written form identifying authorized representative, manufacturer, systems designer and other required data as specified.

1.8 WARRANTIES

A. Refer to Specifications for required warranties. Copies of proposed warranties specified for products shall accompany the designated submittal of that product.

1.9 OPERATION AND MAINTENANCE MANUALS

A. Manual Format (Use 3-ring binder):

1. Title page with the following information for each system covered:

a. Project Title and DMVA Contract Number (in capital letters)

b. Name of Company

c. Name of the individual to be called

d. Normal telephone numbers

e. Contractor's account number for project

2. Index listing all sections of the Manual.

3. Warranties for equipment furnished in contract. (Index tabbed)

4. Complete system circuit diagrams, block diagrams, copies of all approved shop drawings, which shall clearly illustrate how all the components relate and how they are interconnected and a point wiring diagram.

5. Reports, testing analysis.

6. Operating instructions and maintenance instructions for all equipment and finish materials furnished.

1.10 SUBMITTALS LIST

A. See attached AF FORM 66 “Schedule of Material Submittals” organized by prime contract.

END OF SECTION 013000

AF FORM 66, OCT 89 (COMPUTER GENERATED) PREVIOUS EDITION WILL BE USED 1 of 2

SCHEDULE OF MATERIAL SUBMITTALS

(.1 GENERAL)

PROJECT NUMBER

DMVA/BDPM -

42240022

PROJECT TITLE

BLDG. 11-70

Interior Renovation

SOLICITATION/CONTRACT NUMBER

TO BE COMPLETED BY PROJECT ENGINEER

TO BE COMPLETED BY CONTRACT ADMINISTRATOR

LI

N

E N

U M

B

ER

ITEM OR DESCRIPTION OF

ITEM, CONTRACT

REFERENCE, TYPE OF

SUBMITTAL

(DWG’s.) SPEC SECTION

NUMBER OF COPIES REQUIRED

R

EQ

U

IR

ED

S

U B

M

IS

SI

O

N

D A

TE

TE

R

EC

EI

V

ED

IN

C

N

TR

A C

TI

G

TE

T

O C

IV

IL

EN

IN

EE

R

ET

U R

N S

U

SP

EN

SE

D

SU

M

IT

TA

L

N U

M B

S

DATE

CONTRACTOR

NOTIFIED

C O

N

TR

A C

TO

ES

U

B M

IT

TA

L

FI

N A

L A

PP

R

O V

L

REMARKS

ER

TI

FI

C A

TE

O

F C

O M

PL

IA

N C

E

SH

O

P D

R A

W

IN

G S

SA

M

PL

LO

R

S

EL

EC

TI

M

N U

FA

C

TU

R

ER

S R

EC

O

M M

EN

D

A

TI

O N

S

M A

N U

FA

C

TU

R

ER

S W

A R

R A

TY

TA

LO

G D

TA

S-

B U

IL

T

D R

A W

IN

G

S

O

M M

A N

U

LS

PE

R A

TI

O

N S

D

EM

O N

ST

R

A

TI

APPROVED

DIS-

033000 Stone Base X X

Rebar & WWF X X X

Concrete / Mix Designs X X

042000 Unit Masonry X X X X

054000 Cold-Formed Metal Framing

X X X X

061000 Rough Carpentry

X X X

061600 Sheathing

X X

061753 Roof Trusses

X X X

072100 Thermal Insulation

X X

074113 Metal Roof Panels X X X X X

076200 Metal Flashing / Trim X X X X X

077100 Gutters / Downspouts X X X X X

079200 Joint Sealants X X X

081113 Metal Doors / Frames X X X X

AF FORM 66, OCT 89 (COMPUTER GENERATED) PREVIOUS EDITION WILL BE USED 2 of 2

(.1 GENERAL)

PROJECT NUMBER

DMVA/BMCE-

42240022

PROJECT TITLE

BLDG. 11-70

Interior Renovation

SOLICITATION/CONTRACT NUMBER

TO BE COMPLETED BY PROJECT ENGINEER

TO BE COMPLETED BY CONTRACT ADMINISTRATOR

N

E N

U M

REFERENCE, TYPE OF

SUBMITTAL

(DWG’s.) SPEC SECTION

NUMBER OF COPIES REQUIRED

EQ

U

IR

ED

S

U B

M

IS

SI

TE

R

EC

EI

V

N

TR

A C

TI

TE

T

O C

IV

IL

IN

EE

R

U R

N S

U

SP

EN

SE

D

M

IT

TA

L

N U

M B

NOTIFIED

C O

N

TR

A C

TO

R

R

ES

U B

M

IT

TA

L

FI

N

A L

A

PP

R O

V

REMARKS

ER

TI

FI

C A

TE

O

F C

O M

PL

IA

N C

E

SH

O

P D

R A

W

IN

G S

SA

M

LO

R

S

EL

EC

TI

N U

FA

C

TU

R

ER

S R

EC

O

M M

EN

D

A

TI

O N

S

M A

N U

FA

C

TU

R

ER

S W

A R

R A

TA

LO

G D

S-

B U

IL

T

D R

A W

IN

G

S

O

M M

A N

U

LS

R A

TI

O

N S

D

EM

O N

ST

R

A

TI

15 083323 OH Coiling Doors X X X X X

16 087111 Door Hardware X X

Insulated Metal Panel X X X X

097200

FRP X X X X

099113 Exterior Paint X X X X

099123 Interior Paint X X X X

As-Built dwgs., CAD

X

AF Form 66

HVAC Contract*

PROJECT NUMBER

DMVA 42250134

PROJECT TITLE

Renovation to Lickdale VMCO

TO BE COMPLETED BY PROJECT ENGINEER TO BE COMPLETED BY CONTRACT ADMINISTRATOR

LI

N

E N

U M

REFERENCE, TYPE OF

SUBMITTAL

NUMBER OF COPIES REQUIRED

R

EQ

U

IR

ED

S

U B

M

IS

SI

O

N D

TE

R

EC

EI

V

N

TR

A C

TI

TE

T

O M

EC

H

A N

IC

IN

EE

R

U R

N S

U

SP

EN

SE

D

M

IT

TA

L

N U

M B

ER

S

DATE

CONTRACTOR

NOTIFIED

C O

N

TR

A C

TO

R

R

ES

U B

M

IT

TA

L

FI

N

A L

A

PP

R O

V A

L

REMARKS

ST

EE

L C

ER

TI

FI

C

A

TE

O F

C O

M

PL

IA

N

C E

SH

O

P D

R A

W

IN

G S

SC

H

ED

U

LE

S

C O

LO

R

S

EL

EC

TI

N U

FA

C

TU

R

ER

S R

EC

O

M M

EN

D

A

TI

O N

S

M A

N U

FA

C

TU

R

ER

S W

A R

R A

TA

LO

G D

R A

TI

ST

R U

C

TI

O

EP

O

TS

EL

EG

A

TE

D

D

ES

IG

1 230510 - Control Wiring, Starters, Disconnects, etc. 5 5 NTP

+10

2 230553-Mechanical Identification 5 5 NTP

+10

3 230593-Testing, Adjusting and Balancing 5

4 230713-Duct Insulation 5 5 NTP +10

5 233113- Metal Ducts 5 5 NTP +10

6 233300-Air Duct Accessories 5 5 5 NTP

+10

7 233423 – HVAC Power Ventilators 5 5 5 5 NTP

+10

8 237413 – Packaged Rooftop Units 5 5 5 5 NTP

+10

9 233713-Diffusers and Grilles 5 5 NTP +10

10 Various – Equipment Training, O&M Manuals 3 3

11 017839 – Hard Copy of As- Built Drawings 3

12 017839 – CDRom of As- Built Drawings in AutoCAD

DMVA Project#: 42220119 FTIG BLDG 4-101 WW2 Renovation AF Form 66

SCHEDULE OF MATERIAL SUBMITTALS

PLUMBING (.3)

FED. PROJECT #

DMVA/BMCE-

42220119

PROJECT TITLE

Building 04-101

D.G.S PROJECT NUMBER:

N/A

TO BE COMPLETED BY PROJECT ENGINEER TO BE COMPLETED BY CONTRACT ADMINISTRATOR

LI

N

E N

U M

REFERENCE, TYPE OF

SUBMITTAL

NUMBER OF COPIES REQUIRED

R

EQ

U

IR

ED

S

U B

M

IS

SI

O

N D

TE

R

EC

EI

V

N

TR

A C

TI

TE

T

O M

EC

H

A N

IC

IN

EE

R

U R

N S

U

SP

EN

SE

D

M

IT

TA

L

N U

M B

ER

S

DATE

CONTRACTOR

NOTIFIED

C O

N

TR

A C

TO

R

R

ES

U B

M

IT

TA

L

FI

N

A L

A

PP

R O

V A

L

REMARKS

ST

EE

L C

ER

TI

FI

C

A

TE

O F

C O

M

PL

IA

N

C E

SH

O

P D

R A

W

IN

G S

SC

H

ED

U

LE

S

C O

LO

R

S

EL

EC

TI

N U

FA

C

TU

R

ER

S R

EC

O

M M

EN

D

A

TI

O N

S

M A

N U

FA

C

TU

R

ER

S W

A R

R A

TA

LO

G D

R A

TI

R U

C

TI

O

EP

O

EL

EG

A

TE

D

D

ES

IG

1 221110 – Plumbing Insulation 5 NTP

+30 A,B

2 221110 – Domestic Water Piping 5 NTP

+30 A,B

221110 – Domestic Water Piping Valves and Specialties (balancing, check, ball, arresters)

5 NTP

+30 A,B

4 221110 – Sanitary Waste and Vent Piping 5 NTP

+30 A,B

221310 – Sanitary Waste Piping Specialties (floor drains, cleanouts)

5 NTP

+30 A,B

223400 – Plumbing Equipment, Water/Oil Separator x 5 x x NTP +30 A,B

14 Various – O&M Manuals 2 A,B

15 017839 – Hard Copy of As- Built Drawings 3 A,B

017839 – CDRom of As- Built Drawings in AutoCAD format

2 A,B

A. No deviations, substitutions or changes of materials, to be incorporated into this project, shall be made after approval by the Department, except for written direction by and the approval of the manufacturer of a specific item and re-approval by the Department.

B. The Department retains the right to require additional items not specifically denoted to be submitted for approval and/or additional clarification.

DMVA FORM 66, OCT 08 (EF) PREVIOUS EDITION IS OBSOLETE Page 1 of 1

Electrical Submittals *

PROJECT NUMBER

DMVA 42240022

PROJECT TITLE

BLDG. 11-70 Interior Renovation

IT

EM

N U

M

REFERENCE, TYPE OF

SUBMITTAL

NUMBER OF COPIES REQUIRED

R

EQ

U

IR

ED

S

U B

M

IS

SI

TE

R

EC

EI

V

N

TR

A

CT

TE

T O

E N

G

IN

EE

R

D

A R

C H

IT

EC

TU

R

E D

A

TE

T O

C O

N

TR

A C

TI

FR

M E

NOTIFIED

RESUBMITTAL

REMARKS

C

ER

TI

FI

C A

TE

O

F C

O M

PL

IA

CE

SH

P D

R A

W

IN

G S

SA

M

LO

R

S

EL

EC

TI

N U

FA

C

TU

RE

R

S R

EC

O

M M

EN

D

A

TI

O N

S M

A N

U

FA

C

TU

RE

R

S

W A

R R

A

TA

LO

G D

R A

TI

N

G

IN

ST

R

U

CT

IO

N

S

R

EP

O

TC

H

S

PS

EE

L C

ER

TI

FI

C

A

TI

O N

S

D A

TE

O

F R

ES

U

BM

IT

TA

N

TR

A

CT

TE

O F

R

ES

U

BM

IT

TA

E&

TE

O

F R

ES

U

BM

IT

TA

LT

N

TR

A

CT

IN

G

F R

O M

E

TE

O

F

FI

N A

L A

PP

R

O V

A L

A C

C

EP

C

EP

TE

D

A S

N O

EV

IS

E

U

BM

IT

T A

C C

EP

260519 – Low-Voltage Electrical Power Conductors & Cables, Conductors and Cables, and Connectors & Splices

X NTP

+10

260526 – Grounding & Bonding for Electrical Systems, Grounding Conductors, Connectors, Grounding Electrodes, & Conduit Ground Bushings

X NTP

+10

260529 – Hangers & Supports for Electrical Systems, Support, Anchorage & Attachment Components

X X NTP

+10

260533 – Raceway and Boxes for Electrical Systems, Metal Conduit and Tubing

X X NTP

+10

260533 – Raceway and Boxes for Electrical Systems, Boxes, Enclosures, Cabinets, and Sleeves for Raceway

X X NTP

+10

260553 – Identification for Electrical Systems, Identification Materials

X NTP

+10

7 260573 – Overcurrent Protective Device Coordination Study X NTP

+30 Submit after coordination with all distribution equipment.

8 260923 – Lighting Control Devices

9 262726 – Wiring Devices X NTP +10

10 262813 – Fuses X X NTP +30

Submit after coordination with Overcurrent Protective Device Coordination Study

11 262816 – Enclosed Switches and Circuit Breakers X X X X NTP

+30 Submit after coordination with Overcurrent Protective Device Coordination Study

12 265119 – LED Interior Lighting X X X NTP +10

* NOTE: This form is provided for contract compliance and does not alleviate any requirements stated in the specifications. “NTP” – Notice to Proceed. Combine submittals where appropriate, line items are shown for control only.

DMVA Project#:42240022

014000 - 1

SECTION 014000

QUALITY CONTROL REQUIREMENTS

PART 1 - GENERAL

1.1 STIPULATIONS

A. The specifications “General Conditions of the Construction Contract”, “Special Conditions” and “Divi-sion 1 – General Requirements” form a part of this Section by this reference thereto and shall have the same force and effect as if printed herewith in full.

1.2 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.

1.3 SUMMARY

A. Section includes administrative and procedural requirements for quality assurance and quality control.

B. Testing and inspecting services are required to verify compliance with requirements specified or indicated. These services do not relieve Contractor of responsibility for compliance with the Contract Document requirements.

1. Specific quality-assurance and -control requirements for individual construction activities are specified in the Sections that specify those activities. Requirements in those Sections may also cover production of standard products.

2. Specified tests, inspections, and related actions do not limit Contractor's other quality-assurance and -control procedures that facilitate compliance with the Contract Document requirements.

3. Requirements for Contractor to provide quality-assurance and -control services required by the Department of Military and Veterans’ Affairs or authorities having jurisdiction are not limited by provisions of this Section.

4. Specific test and inspection requirements are not specified in this Section.

1.4 DEFINITIONS

A. Quality-Control Services: Tests, inspections, procedures, and related actions during and after execution of the Work to evaluate that actual products incorporated into the Work and completed construction comply with requirements. Services do not include contract enforcement activities performed by Government Design Professionals. All Quality Control Services shall be at the Contractor's cost, which shall be included proportionally in all items of payment or contained in any Base Bid or Unit Price on the Proposal.

B. Preconstruction Testing: Tests and inspections performed specifically for Project before products and materials are incorporated into the Work, to verify performance or compliance with specified criteria.

C. Product Testing: Tests and inspections that are performed by an NRTL, an NVLAP, or a testing agency qualified to conduct product testing and acceptable to authorities having jurisdiction, to establish product performance and compliance with specified requirements.

014000 - 2

D. Source Quality-Control Testing: Tests and inspections that are performed at the source, e.g., plant, mill, factory, or shop.

E. Field Quality-Control Testing: Tests and inspections that are performed on-site for installation of the Work and for completed Work.

F. Testing Agency: An entity engaged by the contractor to perform specific tests, inspections, or both.

Testing laboratory shall mean the same as testing agency.

G. Government Required Inspections: All inspections deemed necessary per the DMVA Inspection Form, will require oversight and verification by DMVA-Bureau of Design and Project Management personnel.

H. Installer/Applicator/Erector: Contractor or another entity engaged by Contractor as an employee, Subcontractor, or Sub-subcontractor, to perform a particular construction operation, including installation, erection, application, and similar operations.

1. Use of trade-specific terminology in referring to a trade or entity does not require that certain construction activities be performed by accredited or unionized individuals, or that requirements specified apply exclusively to specific trade(s).

I. Experienced: When used with an entity or individual, "experienced" means having successfully completed a minimum of five previous projects similar in nature, size, and extent to this Project; being familiar with special requirements indicated; and having complied with requirements of authorities having jurisdiction.

1.5 CONFLICTING REQUIREMENTS

A. Referenced Standards: If compliance with two or more standards is specified and the standards establish different or conflicting requirements for minimum quantities or quality levels, comply with the most stringent requirement. Refer conflicting requirements that are different, but apparently equal, to the Government Design Professional(s) for a decision before proceeding.

B. Minimum Quantity or Quality Levels: The quantity or quality level shown or specified shall be the minimum provided or performed. The actual installation may comply exactly with the minimum quantity or quality specified, or it may exceed the minimum within reasonable limits. To comply with these requirements, indicated numeric values are minimum or maximum, as appropriate, for the context of requirements. Refer uncertainties to the Government Design Professional(s) for a decision before proceeding.

1.6 TESTING SUBMITTALS

A. Schedule of Tests: Testing submittals shall include the following:

1. Specification Section number and title.

2. Entity responsible for performing tests and inspections.

3. Description of test and inspection.

4. Identification of applicable standards.

5. Identification of test and inspection methods.

6. Number of tests and inspections required.

7. Time schedule or time span for tests and inspections.

8. Requirements for obtaining samples.

9. Unique characteristics of each quality-control service.

014000 - 3

1.7 CONTRACTOR'S QUALITY-CONTROL PLAN

A. Quality-Control Plan, General: Submit quality-control plan within ten (10) days of Notice to Proceed, and not less than five (5) days prior to preconstruction conference. Submit in format acceptable to Government Design Professional. Identify personnel, procedures, controls, instructions, tests, records, and forms to be used to carry out Contractor's quality-assurance and quality-control responsibilities.

Coordinate with Contractor's construction schedule.

B. Quality-Control Personnel Qualifications: Engage qualified personnel trained and experienced in managing and executing quality-assurance and quality-control procedures similar in nature and extent to those required for Project.

1. Project quality-control manager may also serve as Project superintendent.

C. Testing and Inspection: In quality-control plan, include a comprehensive schedule of Work requiring testing or inspection, including the following:

1. Contractor-performed tests including subcontractor-performed tests. Include required tests and inspections and Contractor-elected tests and inspections.

D. Continuous Inspection of Workmanship: Describe process for continuous inspection during construction to identify and correct deficiencies in workmanship in addition to testing and inspection specified.

Indicate types of corrective actions to be required to bring work into compliance with standards of workmanship established by Contract requirements and approved mockups.

E. Monitoring and Documentation: Maintain testing and inspection reports including log of approved and rejected results. Include work Government Design Professional and/or Project Manager has indicated as nonconforming or defective. Indicate corrective actions taken to bring nonconforming work into compliance with requirements. Comply with requirements of authorities having jurisdiction.

1.8 REPORTS AND DOCUMENTS

A. Test and Inspection Reports: Prepare and submit certified written reports specified in other Sections.

Include the following:

1. Date of issue.

2. Project title and number.

3. Name, address, and telephone number of testing agency.

4. Dates and locations of samples and tests or inspections.

5. Names of individuals making tests and inspections.

6. Description of the Work and test and inspection method.

7. Identification of product and Specification Section.

8. Complete test or inspection data.

9. Test and inspection results and an interpretation of test results.

10. Record of temperature and weather conditions at time of sample taking and testing and inspecting.

11. Comments or professional opinion on whether tested or inspected Work complies with the

Contract Document requirements.

12. Name and signature of laboratory inspector.

13. Recommendations on retesting and re-inspecting.

B. Manufacturer's Technical Representative's Field Reports: Prepare written information documenting manufacturer's technical representative's tests and inspections specified in other Sections. Include the following:

1. Name, address, and telephone number of technical representatives making report.

2. Statement on condition of substrates and their acceptability for installation of product.

014000 - 4

3. Statement that products at Project site comply with requirements.

4. Summary of installation procedures being followed, whether they comply with requirements and, if not, what corrective action was taken.

5. Results of operational and other tests and a statement of whether observed performance complies with requirements.

6. Statement whether conditions, products, and installation will affect warranty.

7. Other required items indicated in individual Specification Sections.

C. Factory-Authorized Service Representative's Reports: Prepare written information documenting manufacturer's factory-authorized service representative's tests and inspections specified in other Sections. Include the following:

1. Name, address, and telephone number of factory-authorized service representative making report.

2. Statement that equipment complies with requirements.

3. Results of operational and other tests and a statement of whether observed performance complies with requirements.

4. Statement whether conditions, products, and installation will affect warranty.

5. Other required items indicated in individual Specification Sections.

D. Permits, Licenses, and Certificates: For Government’s records, submit copies of permits, licenses, certifications, inspection reports, releases, jurisdictional settlements, notices, receipts for fee payments, judgments, correspondence, records, and similar documents, established for compliance with standards and regulations bearing on performance of the Work.

1.9 QUALITY ASSURANCE

A. General: Qualifications paragraphs in this article establish the minimum qualification levels required;

individual Specification Sections specify additional requirements.

B. Manufacturer Qualifications: A firm experienced in manufacturing products or systems similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capacity to produce required units.

C. Fabricator Qualifications: A firm experienced in producing products similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capacity to produce required units.

D. Installer Qualifications: A firm or individual experienced in installing, erecting, or assembling work similar in material, design, and extent to that indicated for this Project, whose work has resulted in construction with a record of successful in-service performance.

E. Manufacturer's Technical Representative Qualifications: An authorized representative of manufacturer who is trained and approved by manufacturer to observe and inspect installation of manufacturer's products that are similar in material, design, and extent to those indicated for this Project.

F. Factory-Authorized Service Representative Qualifications: An authorized representative of manufacturer who is trained and approved by manufacturer to inspect installation of manufacturer's products that are similar in material, design, and extent to those indicated for this Project.

1. Testing Agency Responsibilities: Submit a certified written report of each test, inspection, and similar quality-assurance service to Government Design Professional, with copy to Contractor.

Interpret tests and inspections and state in each report whether tested and inspected work complies with or deviates from the Contract Documents.

014000 - 5

1.10 QUALITY CONTROL

A. Government Responsibilities: Where quality-control services are indicated as Government’s responsibility, the Government will engage qualified Government personnel and/or an independent testing agency to perform these services.

1. Government will furnish Contractor with names, addresses, and telephone numbers of personnel or testing agencies engaged and a description of types of testing and inspecting they are engaged to perform.

B. Contractor Responsibilities: All testing requirements outlined within the Project Design Documents and/or requested by the Government Project Representatives, are to be the Contractor's responsibility.

Perform additional quality-control activities required to verify that the Work complies with requirements, whether specified or not.

1. Where services are indicated as Contractor's responsibility, engage a qualified testing agency to perform these quality-control services.

a. Contractor shall not employ same entity engaged by the Government, unless agreed to in writing by Government.

2. Where quality-control services are indicated as Contractor's responsibility, submit a certified written report, in duplicate, of each quality-control service.

3. Testing and inspecting requested by Contractor and not required by the Contract Documents are Contractor's responsibility.

4. Submit additional copies of each written report directly to authorities having jurisdiction, when they so direct.

C. Manufacturer's Field Services: Where indicated, engage a factory-authorized service representative to inspect field-assembled components and equipment installation, including service connections. Report results in writing as specified in Section 013300 "Submittal Procedures."

D. Manufacturer's Technical Services: Where indicated, engage a manufacturer's technical representative to observe and inspect the Work. Manufacturer's technical representative's services include participation in preinstallation conferences, examination of substrates and conditions, verification of materials, observation of Installer activities, inspection of completed portions of the Work, and submittal of written reports.

E. Retesting/Re-inspecting: Regardless of whether original tests or inspections were Contractor's responsibility, provide quality-control services, including retesting and re-inspecting, for construction work that failed to comply with the Contract Documents.

F. Coordination: Coordinate sequence of activities to accommodate required quality-assurance and -control services with a minimum of delay and to avoid necessity of removing and replacing construction to accommodate testing and inspecting.

1. Schedule times for tests, inspections, obtaining samples, and similar activities.

1.11 TESTS AND INSPECTION PROCEDURES

A. Required Tests: Contractors shall refer to the Project Specifications for all testing requirements pertaining to individual aspects of the project.

B. Notification of Inspections and Tests: Contractor shall notify the DMVA-BDPM Project Manager of a required or specified inspection and/or inform them of an upcoming test. Contractor shall refer to the

014000 - 6

DMVA Inspection Log for the required allowance of notification (in business days) for requesting inspections and/or observations of tests.

1. Notification of required inspections or tests shall not be less than 48 hours prior to the inspection and/or test. Weekends and Observed Government Holidays shall not be factored into notifications and are not considered as business days.

C. Upon the completion of an inspection or test. The Government Design Professional or Project Manager will approve or dis-approve the work in question and sign and date the Inspection Log within forty-eight

(48) hours of the test or inspection being completed.

D. At no time shall any work of any type outlined within the DMVA Inspection Log be covered-up or concealed from view until all required inspections and/or tests have been conducted and the Department has approved it.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 REPAIR AND PROTECTION

A. General: On completion of testing, inspecting, sample taking, and similar services, repair damaged construction and restore substrates and finishes.

1. Provide materials that comply with installation requirements specified in corresponding Specification Sections or matching existing substrates and finishes. Restore patched areas and extend restoration into adjoining areas with durable seams, that show no visible signs of damage or repair.

B. Protect construction exposed by or for quality-control service activities.

C. In the event of work being deemed unacceptable due to poor workmanship, code violations, failure to meet design intent or following of the design documents, etc., corrective actions will be provided to the contractor along with a timeframe in which the contractor will have to complete the corrective actions.

Communication to the contractor(s) regarding corrective actions will be in the form of meeting minute comments and/or formal (email or written) correspondence provided by the Government Contracting Office.

D. Repair and protection are Contractor's responsibility, regardless of the assignment of responsibility for quality-control services.

E. Failure of the contractor to correct work of any type deemed to be unacceptable, could result in the Government taking actions as outlined within the Project General Conditions.

END OF SECTION 014000

REQ. INSPECTION

NOTICE

(Business

Days)

DEPARTMENT

REPRESENTATIVE (SIGNATURE)

DATE

ACCEPTED

NO WORK MAY BE CONCEALED FROM VIEW, UNTIL THE DEPARTMENT HAS APPROVED IT.

Project Name:

Project Location:

DMVA - BUREAU OF DESIGN AND PROJECT MANAGEMENT

INTERNATIONAL BUILDING CODE INSPECTION LOG

Phone Number:Project Manager:

Email:

DMVA Project#: 42240022 016350-1

SECTION 016350

DEPARTMENT OF MILITARY & VETERANS AFFAIRS

SUPPLEMENTAL PROVISIONS

PART 1 – GENERAL

A. The specifications “General…