36C78624B0041.docx

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C78624B0041 X 07-03-2024

866CM3029/30

36C786 Department of Veterans Affairs National Cemetery Administration Contracting Services 18434 Joplin Road Triangle

VA

22172 Electronic Bid Submission and Opening See Section L: Virtual Bid Instructions

Trevor DiSimone 407-631-8782 Information on submitting bids can be found in the "Bid Instructions."

The Department of Veterans Affairs, National Cemetery Administration (NCA), anticipates awarding a Firm, Fixed Priced contract, in accordance with FAR Part 14, Sealed Bidding.

The Contractor shall provide all labor, supervision, material, and equipment necessary for Burial Expansion at:See bid i Natchez National Cemetery, 41 Cemetery Rd, Natchez, MS 39120, by providing General Construction in accordance with the Statement of Work (SOW), Drawings, Specifications and related attachments.

LINE ITEMS: ***See SOW attachment. Price them in Schedule B and Bidder shall complete S02_Attachment 10_IFB Contractor Cost Estimate Worksheet as part of the bid submission package.

See bid instructions in Section L of this solicitation for minimum list of required documents.

The total performance period for this project is 330 calendar days from issuance of the Notice to Proceed (NTP).

Per FAR 36.204(f)(2), Project Magnitude: Between $2,000,000and $5,000,000.

This acquisition is 100% set aside for Service-Disabled Veteran-Owned Small Businesses. Authority, 38 USC 8127(d).

The North American Industry Classification System (NAICS) code is 237990, Small Business Size Standard $45.0 Million.

A Site Visit will be held on Thursday, July 11th, 2024. See 52.236-27 Site Visit for site visit information.

Questions shall be submitted to: dimasalang.junio@va.gov and Trevor.DiSimone@va.gov no later than 10:00 a.m., EDT on 7-17-24.

Telephone inquiries will not be accepted. Questions received after this date and time will not be accepted.

The email must contain the following in the subject line: Solicitation Number, Project Name, Cemetery Name.

Prospective Offerors must also be registered in Vendor Information Pages (VIP) at https://www.vip.vetbiz.va.gov/ ;

Vets 4212 at https://www.dol.gov ; and System for Award Management (SAM) at https://www.sam.gov/SAM at the time of proposal submission AND at time of award.

ATTENDANCE on VIRTUAL BID OPENING IS NOT MANDATORY

X X 52.211-10 X

10:00 AM

EDT

08-02-2024 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

Offerors shall fill out Section B1 - Price/Cost Schedule.

and complete S02_Attachment 10_Contractor Cost Estimate worksheet as part of the bid package.

See Virtual Bid Instructions for details.

36C786 Department of Veterans Affairs National Cemetery Administration Contracting Services 18434 Joplin Road Triangle

VA

22172 http://www.tungsten-network.com/customer -campaigns/veterans-affairs/

1-877-752-0900 Trevor DiSimone

Table of Contents

SECTION B - SUPPLIES OR SERVICES AND PRICE/COSTS

B.1 PRICE/COST SCHEDULE

ITEM INFORMATION

866CM3029

GENERAL CONSTRUCTION: Burial Expansion

866CM3030

JB

866CM3030

NOTE-1: See Attachment 1 and Attachment 2 SOWs for full explanation of General Construction NOTE-2: Bidders shall complete and include Attachment 10 IFB Contractor Cost Estimate Worksheet as part of the bid package.

36C78624B0041 Section B

Page 1 of Page 1 of

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

36C78624B0041 Section C

Page 1 of Page 1 of

SECTION E - INSPECTION AND ACCEPTANCE

E.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far https://www.va.gov/oal/library/vaar/

(End of Clause)

Page 1 of Page 1 of

SECTION F - DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) ALTERNATE I (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 330 days after receipt of notice to proceed. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by . The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

36C78624B0041 Section F (End of Clause) Page 1 of Page 1 of

SECTION G - CONTRACT ADMINISTRATION DATA

CONTRACT ADMINISTRATION DATA

1. Contract Administration:

All contract administration matters will be handled by the following individuals:

a. CONTRACTOR: TBD

b. GOVERNMENT:

Contracting Officer: Trevor DiSimone Phone: 407-631-8782 Email: trevor.disimone@va.gov Contracting Officer Representative: TBD

2. CONTRACTOR REMITTANCE ADDRESS: All payments by the Government to the contractor shall be made in accordance with 52.232-34, Payment by Electronic Funds Transfer.

3. INVOICES: Invoices shall be submitted in arrears Monthly.

4. GOVERNMENT INVOICE ADDRESS:

All invoices from the contractor shall be sent electronically by following instruction as stated at website: http://www.fsc.va.gov/einvoice.asp See VAAR clause 852.232-72 Electronic Submission of Payment Requests (NOV 2012).

5. ACQUISITION: Total (100%) Service Disabled Veteran Owned Small Business Set-Aside: This is a solicitation for construction prepared in accordance with the format in FAR Part 14. The contract will be awarded by the Government to furnish those service and construction tasks as stated in the SOW, Specifications, Drawings and any other solicitation attachments. The Government anticipates awarding this solicitation as a fixed-price contract.

Historical Data:

Incumbent Contractor:

6. TYPE OF CONTRACT: This is a firm fixed-price contract in accordance with FAR 52.216-1 Type of Contract.

7. CONTRACT AWARD: The contract will become effective as soon as practical with no additional cost to the Government for any elapsed time from the original effective date. It is also, understood and agreed that the effective date of this contract will be contingent upon the availability of appropriated funds and in the event appropriations are not available.

8. AUTHORITIES OF GOVERNMENT PERSONNEL: Notwithstanding the Contractors responsibility for total management during the performance of this contract, the administration of the contract will require maximum coordination between the Government and the Contractor. The Government will provide, at the time of contract award, a list of Government personnel authorized to act as the Contracting Officer's Representatives (COR). Only the Contracting Officer has the authority to make changes to the contract.

9. CONTRACTOR’S FOREMAN/SUPERVISOR: Contractor must provide an English-speaking foreman/Supervisor at all times while performing the duties of the contract. This is to ensure proper communication between the Contractor and COR.

10. SITE VISIT: See 52.236-27 for site visit information.

11. PRE-CONSTRUCTION CONFERENCE: Prior to commencement of work, Contractor shall attend a pre-construction conference prior to the commencement of work to assure that all parties understand all contractual obligations and the role that each party serves.

12. FEDERAL HOLIDAYS:

January New Year’s Day, Martin Luther King’s Birthday February President’s Day May Memorial Day June Juneteenth July Independence Day September Labor Day October Columbus Day November Veterans Day, Thanksgiving Day December Christmas Day Including any other day specifically declared by the President of the United States to be a national holiday.

13. LIMITATIONS ON SUBCONTRACTING – MONITORING AND COMPLIANCE:

This contract includes (VAAR) 852.219-10, VA Notice of Total Service-Disabled Veteran-Owned Small Business Set- Aside. The Contractor is advised in performing contract administration functions, the CO may use the services of a support contractor(s) retained by VA to assist in assessing the contractor’s compliance with the limitations on subcontracting or percentage of work performance requirements specified in the clause. To that end, the support contractor(s) may require access to contractor’s offices where the contractor’s business records or other proprietary data are retained and to review such business records regarding the contractor’s compliance with this requirement. All support contractors conducting this review on behalf of VA will be required to sign an “Information Protection and Non-Disclosure and Disclosure of Conflicts of Interest Agreement” to ensure the contractor’s business records or other proprietary data reviewed or obtained in the course of assisting the CO in assessing the contractor for compliance are protected to ensure information or data is not improperly disclosed or other impropriety occurs. Furthermore, if VA determines any services the support contractor(s) will perform in assessing compliance are advisory and assistance services as defined in FAR 2.101, Definitions, the support contractor(s) must also enter into an agreement with the contractor to protect proprietary information as required by FAR 9.505-4, Obtaining Access to Proprietary Information, paragraph (b). The contractor is required to cooperate fully and make available any records as may be required to enable the CO to assess the contractor’s compliance with the limitations on subcontracting or percentage of work performance requirement.

14. RELEASE OF CLAIMS:

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relation to the contract. The Release of Claims form provided by the CO shall be used for this purpose. The form provides for exception of specified claims from the operation of release. Request a copy from the CO.

15. NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM:

a. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

b. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

c. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

d. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

e. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

1. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

2. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

3. All information provided should be reviewed for accuracy prior to submission.

4. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

5. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

6. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

f. The following guidelines apply concerning your use of the past performance evaluation:

1. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

2. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

g. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

h. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

36C78624B0041 Section G (End of Administration Data) Page 1 of Page 1 of

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 DIGNITY STANDARDS

1. Every action by contractor personnel at a National Cemetery must be performed with the special care, reverence, dignity, and respect that acknowledge the cemetery as the final resting place that commemorates the service and sacrifice those service members, Veterans, and their families made for our Nation. Critically important is the awareness, required of the contractor employees, of the remains buried in the grounds where the work is performed. The utmost care must be given to these remains and the headstones and flat grave markers that mark those gravesites and memorialize the service of individuals.

a. Contractors cannot walk, stand, lean, sit or jump on headstones or markers. Nor can they drive over them. Contractor personnel should use tools approved by the Contracting Officer Representative (COR), such as shovels, pry bars or pinch bars to lift flat markers out of the ground; pickaxes are not an acceptable tool.

b. No tools, equipment or other items will be placed or leaned on headstones or markers. Once headstones/markers are removed from the socket, do not place on dirt piles or mud; they should be carefully placed on each associated gravesite and protected in such a way as to prevent any soiling and be out of the way of any other work.

c. Headstones shall be removed from their sockets using wooden and/or metal clamps. If metal clamps are used, the area that contacts the headstone must be protected with a rigid fabric that will prevent damage to and marking of the headstone. Clamps may be attached to a skid steer loader (i.e., Bobcat®) or similar machine to extract the headstone from the socket. When headstones are removed from their sockets, they shall be carefully stored on each associated gravesite; do not lean headstones against each other. Use care not to scratch or damage headstones in any manner. The headstones shall be laid with front inscription side up while the headstone is lying horizontally on the ground. The headstone shall be protected from direct ground contact while lying horizontally. The protection method shall be as approved by the COR and shall be free of deterioration in weather. An approved method is to support each headstone with two wood 4X4’s. Alternate methods can be approved. Cardboard shall not be used. Wood or other suitable appropriate and attractive material shall be used to keep the headstones from contact with the soil while lying horizontally during the construction period. This also shows respect towards the families visiting the gravesites and the remains that are buried.

d. Contractor shall be responsible for replacing damaged headstones and markers and for restoring turf damaged during performance of this work.

e. Additionally, should any activity result in the exposure and/or damage to any remains, container for remains (i.e., casket or urn), or outer burial container, the Contractor must contact the COR, Director/Assistant Director, and Contracting Officer (CO) for guidance.

1. Any doubts as to proper procedures shall be brought to the attention of the COR, Director/Assistant Director, and CO for guidance or resolution.

1. The Contractor is required to discuss the guidance with their employees and have each employee sign a statement of compliance and deliver the signed statement to the COR before work may begin.

36C78624B0041 Section H

Page 1 of

Page 1 of

PART II - CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1 52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of Clause)

I.2 VAAR 852.201-70 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 2022)

The Contracting Officer reserves the right to designate representatives to act for him/her in furnishing technical guidance and advice or generally monitor the work to be performed under this contract. Such designation will be in writing and will define the scope and limitation of the designee’s authority. A copy of the designation letter shall be furnished to the Contractor.

(End of Clause)

I.3 VAAR 852.232-71 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (INCLUDING NAS– CPM) (NOV 2018) The clause FAR 52.232–5, Payments Under Fixed-Price Construction Contracts, is implemented as follows:

(a) Retainage.

(1) The Contracting Officer may retain funds—

(i) Where performance under the contract has been determined to be deficient or the Contractor has performed in an unsatisfactory manner in the past; or

(ii) As the contract nears completion, to ensure that deficiencies will be corrected and that completion is timely.

(2) Examples of deficient performance justifying a retention of funds include, but are not restricted to, the following—

(i) Unsatisfactory progress as determined by the Contracting Officer;

(ii) Failure to meet schedule in Schedule of Work Progress;

(iii) Failure to present submittals in a timely manner; or

(iv) Failure to comply in good faith with approved subcontracting plans, certifications, or contract requirements.

(3) Any level of retention shall not exceed 10 percent either where there is determined to be unsatisfactory performance, or when the retainage is to ensure satisfactory completion. Retained amounts shall be paid promptly upon completion of all contract requirements, but nothing contained in this paragraph (a)(3) shall be construed as limiting the Contracting Officer’s right to withhold funds under other provisions of the contract or in accordance with the general law and regulations regarding the administration of Government contracts.

(b) The Contractor shall submit a schedule of costs in accordance with the requirements of section ‘‘Network Analysis System—Critical Path Method (NAS–CPM)’’ to the Contracting Officer for approval within 90 calendar days after date of receipt of notice to proceed. The approved cost schedule will be one of the bases for determining progress payments to the Contractor for work completed.

(1) Costs as shown on this schedule must be true costs and the resident engineer may require the Contractor to submit its original estimate sheets or other information to substantiate the detailed makeup of the cost schedule.

(2) The total costs of all work activities/events shall equal the contract price.

(3) Insurance and similar items shall be prorated and included in each work activity/event cost of the critical path method (CPM).

(4) The CPM shall include a separate cost loaded activity for adjusting and testing of the systems listed in the table in paragraph (b)(5) of this clause. The percentages listed in paragraph (b)(5) will be used to determine the cost of adjust and test work activities/events and identify, for payment purposes, the value of the work to adjust, correct and test systems after the material has been installed.

(5) Payment for adjust and test activities will be made only after the Contractor has demonstrated that each of the systems is substantially complete and operates as required by the contract.

VALUE OF ADJUSTING, CORRECTING, AND TESTING SYSTEM

(c) In addition to this cost schedule, the Contractor shall submit such unit costs as may be specifically requested. The unit costs shall be those used by the Contractor in preparing its bid and will not be binding as pertaining to any contract changes.

(d) The Contracting Officer will consider for monthly progress payments material and/or equipment procured by the Contractor and stored on the construction site, as space is available, or at a local approved location off the site, under such terms and conditions as the Contracting Officer approves, including but not limited to the following—

(1) The materials or equipment are in accordance with the contract requirements and/or approved samples and shop drawings;

(2) The materials and/or equipment are approved by the resident engineer;

(3) The materials and/or equipment are stored separately and are readily available for inspection and inventory by the resident engineer;

(4) The materials and/or equipment are protected against weather, theft and other hazards and are not subjected to deterioration; and

(5) The Contractor obtains the concurrence of its surety for off-site storage.

(e) The Government reserves the right to withhold payment until samples, shop drawings, engineer’s certificates, additional bonds, payrolls, weekly statements of compliance, proof of title, nondiscrimination compliance reports, or any other requirements of this contract, have been submitted to the satisfaction of the Contracting Officer.

(f) The Contracting Officer will notify the Contractor in writing within 10 calendar-days of exercising retainage against any payment in accordance with FAR clause 52.232–5(e). The notice shall disclose the amount of the retainage in value and percent retained from the payment, and provide explanation for the retainage.

(End of Clause)

I.4 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause) I.5 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES DEVELOPED OR PROVIDED BY KASPERSKY LAB COVERED ENTITIES (DEC 2023)

(a) Definitions. As used in this clause—Kaspersky Lab covered article means any hardware, software, or service that—

(1) Is developed or provided by a Kaspersky Lab covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a Kaspersky Lab covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a Kaspersky Lab covered entity.

Kaspersky Lab covered entity means—

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab, including any change in name, e.g., ‘‘Kaspersky’’;

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115–91) prohibits Government use of any Kaspersky Lab covered article. The Contractor is prohibited from—

(1) Providing any Kaspersky Lab covered article that the Government will use on or after October 1, 2018; and

(2) Using any Kaspersky Lab covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement. (1) In the event the Contractor identifies a Kaspersky Lab covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:

(i) Within 3 business days from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: Any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a Kaspersky Lab covered article, any reasons that led to the use or submission of the Kaspersky Lab covered article, and any additional efforts that will be incorporated to prevent future use or submission of Kaspersky Lab covered articles.

(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

(End of Clause) I.6 52.204-30 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS—PROHIBITION (DEC 2023)

(a) Definitions. As used in this clause— Covered article, as defined in 41 U.S.C. 4713(k), means—

(1) Information technology, as defined in 40 U.S.C. 11101, including cloud computing services of all types;

(2) Telecommunications equipment or telecommunications service, as those terms are defined in section 3 of the Communications Act of 1934 (47 U.S.C. 153);

(3) The processing of information on a Federal or non-Federal information system, subject to the requirements of the Controlled Unclassified Information program (see 32 CFR part 2002); or

(4) Hardware, systems, devices, software, or services that include embedded or incidental information technology.

FASCSA order means any of the following orders issued under the Federal Acquisition Supply Chain Security Act (FASCSA) requiring the removal of covered articles from executive agency information systems or the exclusion of one or more named sources or named covered articles from executive agency procurement actions, as described in 41 CFR 201–1.303(d) and (e):

(1) The Secretary of Homeland Security may issue FASCSA orders applicable to civilian agencies, to the extent not covered by paragraph (2) or (3) of this definition. This type of FASCSA order may be referred to as a Department of Homeland Security (DHS) FASCSA order.

(2) The Secretary of Defense may issue FASCSA orders applicable to the Department of Defense (DoD) and national security systems other than sensitive compartmented information systems. This type of FASCSA order may be referred to as a DoD FASCSA order.

(3) The Director of National Intelligence (DNI) may issue FASCSA orders applicable to the intelligence community and sensitive compartmented information systems, to the extent not covered by paragraph (2) of this definition. This type of FASCSA order may be referred to as a DNI FASCSA order.

Intelligence community, as defined by 50 U.S.C. 3003(4), means the following—

(1) The Office of the Director of National Intelligence;

(2) The Central Intelligence Agency;

(3) The National Security Agency;

(4) The Defense Intelligence Agency;

(5) The National Geospatial-Intelligence Agency;

(6) The National Reconnaissance Office;

(7) Other offices within the Department of Defense for the collection of specialized national intelligence through reconnaissance programs;

(8) The intelligence elements of the Army, the Navy, the Air Force, the Marine Corps, the Coast Guard, the Federal Bureau of Investigation, the Drug Enforcement Administration, and the Department of Energy;

(9) The Bureau of Intelligence and Research of the Department of State;

(10) The Office of Intelligence and Analysis of the Department of the Treasury;

(11) The Office of Intelligence and Analysis of the Department of Homeland Security; or

(12) Such other elements of any department or agency as may be designated by the President, or designated jointly by the Director of National Intelligence and the head of the department or agency concerned, as an element of the intelligence community.

National security system, as defined in 44 U.S.C. 3552, means any information system (including any telecommunications system) used or operated by an agency or by a contractor of an agency, or other organization on behalf of an agency—

(1) The function, operation, or use of which involves intelligence activities; involves cryptologic activities related to national security; involves command and control of military forces; involves equipment that is an integral part of a weapon or weapons system; or is critical to the direct fulfillment of military or intelligence missions, but does not include a system that is to be used for routine administrative and business applications (including payroll, finance, logistics, and personnel management applications); or

(2) Is protected at all times by procedures established for information that have been specifically authorized under criteria established by an Executive order or an Act of Congress to be kept classified in the interest of national defense or foreign policy.

Reasonable inquiry means an inquiry designed to uncover any information in the entity’s possession about the identity of any covered articles, or any products or services produced or provided by a source. This applies when the covered article or the source is subject to an applicable FASCSA order. A reasonable inquiry excludes the need to include an internal or third-party audit.

Sensitive compartmented information means classified information concerning or derived from intelligence sources, methods, or analytical processes, which is required to be handled within formal access control systems established by the Director of National Intelligence.

Sensitive compartmented information system means a national security system authorized to process or store sensitive compartmented information.

Source means a non-Federal supplier, or potential supplier, of products or services, at any tier.

(b) Prohibition. (1) Unless an applicable waiver has been issued by the issuing official, Contractors shall not provide or use as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA orders as follows:

(i) For solicitations and contracts awarded by a Department of Defense contracting office, DoD FASCSA orders apply.

(ii) For all other solicitations and contracts DHS FASCSA orders apply.

(2) The Contractor shall search for the phrase ‘‘FASCSA order’’ in the System for Award Management (SAM) at https://www.sam.gov to locate applicable FASCSA orders identified in paragraph (b)(1).

(3) The Government may identify in the solicitation additional FASCSA orders that are not in SAM, which are effective and apply to the solicitation and resultant contract.

(4) A FASCSA order issued after the date of solicitation applies to this contract only if added by an amendment to the solicitation or modification to the contract (see FAR 4.2304(c)). However, see paragraph (c) of this clause.

(5)(i) If the contractor wishes to ask for a waiver of the requirements of a new FASCSA order…