657A4-24-105 Updated Specifications FluoroXray.pdf

PDF 2 MB Posted

Attached to
Z2DA--657A4-24-105, Site Prep for Fluoro and Xray, PB
Solicitation number
36C25525R0013
Issued by

About this file

This file contains specifications and requirements for site preparation work to facilitate replacement of X-ray equipment at two VA medical facilities in Missouri. The project involves preparing Room 2030 at John J. Pershing VA Medical Center for a new Philips Fluoro & Xray Easy Diagnostic system and Room 137 at West Plains VA Clinic for a new GE Definium 5000 system.

The specifications detail extensive safety, documentation, and procedural requirements including development of an Accident Prevention Plan, Activity Hazard Analyses, and various work plans. The contractor must comply with USACE EM 385-1-1 safety standards, OSHA regulations, and VA facility requirements. Key submittals include monthly safety reports, lift plans, confined space permits, hot work permits, and various certifications. The work requires coordination with ongoing medical center operations, dust control measures, infection control, and tuberculosis screening for workers. The contractor must maintain detailed documentation of safety meetings, inspections, and any incidents or near-misses that occur during the project.

View the file

Other files

Show all 17

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

06-01-24

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20 00 11 21 Request for Proposal to Design Build 09-21

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-21 01 32 16.01 Architectural and Engineering CPM Schedules 03-20 01 32 16.13 Network Analysis Schedules – Major Construction Project

Design-Bid-Build 05-22

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 01-24 01 32 16.16 Network Analysis Schedules (Design-Build Only) 05-22 01 32 16.17 Network Analysis Schedules – Major Design/Build

Projects 06-19

01 33 23 Shop Drawings, Product Data, and Samples 11-23 01 35 26 Safety Requirements for Major Projects 05-24 01 42 19 Reference Standards 11-20 01 45 00 Quality Control 02-21 01 45 29 Testing Laboratory Services 11-18 01 45 35 Special Inspections 06-21 01 57 19 Temporary Environmental Controls 01-21 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 04-22 01 81 13 Sustainable Construction Requirements 10-17 01 81 13.02 Sustainability Certification Requirements – LEED V4

BD+C: New Construction and Major Renovation 04-23

01 81 13.03 Sustainability Certification Requirements – LEED V4 BD+C: Healthcare

04-23

01 81 13.12 Sustainability Certification Requirements – LEED V4.1 BD+C: New Construction and Major Renovation

04-23

01 81 13.13 Sustainability Certification Requirements – LEED V4.1:

Healthcare

04-23

01 81 13.14 Sustainability Certification Requirements – LEED V4.1 BD+C: Data Centers

04-23

01 81 13.15 Sustainability Certification Requirements – LEED V4.1 BD+C: Warehouses and Distribution Centers

04-23

01 81 13.21 Sustainability Certification Requirements – GREEN

GLOBES

01-21

01 91 00 General Commissioning Requirements 04-22 01 91 00.01 DVA/USACE Projects General Commissioning Requirements 08-19

DIVISION 02 – EXISTING CONDITIONS

02 21 13 Site Surveys 12-23

00 01 10-2

SECTION NO DIVISION AND SECTION TITLES DATE

02 41 00 Demolition 08-17 02 65 00 Underground Storage Tank Removal 01-21 02 82 11 Traditional Asbestos Abatement 01-21 02 82 13.13 Glovebag Asbestos Abatement 01-21 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 01-21 02 82 13.21 Asbestos Roofing Abatement 01-21 02 82 13.31 Asbestos Transite Abatement 01-21 02 82 13.41 Asbestos Abatement for Total Demolition Project 01-21 02 83 33.13 Lead-Based Paint Removal and Disposal 01-21

DIVISION 03 – CONCRETE

03 23 00 Stressing Tendons 01-21 03 30 00 Cast-in-Place Concrete 01-21 03 30 53 (Short-Form) Cast-in-Place Concrete 01-21 03 37 13 Shotcrete 01-21 03 41 13 Precast Concrete Hollow Core Planks 01-21 03 41 33 Precast Structural Pretensioned Concrete 01-21 03 45 00 Precast Architectural Concrete 01-21 03 51 13 Cementitious Wood Fiber Decks 01-21 03 51 16 Gypsum Concrete Roof Decks 01-21 03 52 00 Lightweight Concrete Roof Insulation 01-21 03 55 11 Gypsum Concrete Floor Decks 01-21

DIVISION 04 – MASONRY

04 01 00 Maintenance of Masonry 01-21 04 05 13 Masonry Mortaring 10-17 04 05 16 Masonry Grouting 01-21 04 20 00 Unit Masonry 08-17 04 72 00 Cast Stone Masonry 01-21

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 11-18 05 21 00 Steel Joist Framing 11-18 05 31 00 Steel Decking 01-21 05 36 00 Composite Metal Decking 01-21 05 40 00 Cold-Formed Metal Framing 01-21 05 50 00 Metal Fabrications 08-18 05 51 00 Metal Stairs 01-21

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17 06 16 63 Cementitious Sheathing 01-21 06 20 00 Finish Carpentry 01-21

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 01 50.19 Preparation for Re-Roofing 01-21

00 01 10-3

SECTION NO DIVISION AND SECTION TITLES DATE

07 08 00 Facility Exterior Closure Commissioning 01-21 07 08 00.01 DVA/USACE Projects Facility Exterior Closure

Commissioning 08-19

07 11 13 Bituminous Dampproofing 01-21 07 12 00 Built-Up Bituminous Waterproofing 01-21 07 13 00 Sheet Waterproofing 01-21 07 13 52 Modified Bituminous Sheet Waterproofing 01-21 07 14 21 Latex Mastic Deck Covering 01-21 07 18 13 Pedestrian Traffic Coatings 01-21 07 21 13 Thermal Insulation 01-21 07 21 23 Loose-Fill Insulation 01-21 07 22 00 Roof and Deck Insulation 01-21 07 24 00 Exterior Insulation and Finish Systems 01-21 07 27 26 Fluid-Applied Membrane Air Barrier, Vapor Permeable 01-21 07 27 27 Fluid-Applied Membrane Air Barrier, Vapor Retarding 01-21 07 31 13 Asphalt Shingles 02-21 07 31 26 Slate Shingles 01-21 07 31 29.13 Wood Shingles 01-21 07 32 13 Clay Roof Tiles 01-21 07 40 00 Roofing and Siding Panels 01-21 07 51 00 Built-Up Bituminous Roofing 12-21 07 51 13.11 Hot-Applied Built-Up Asphalt Roofing 12-21 07 51 13.13 Cold-Applied Built-Up Asphalt Roofing 12-21 07 52 16.11 Cold Adhesive Styrene-Butadiene-Styrene Modified

Bituminous Membrane Roofing 12-21

07 52 16.12 Hot-Mopped Styrene-Butadiene-Styrene Modified Bituminous Membrane Roofing

12-21

07 53 23 Ethylene-Propylene-Diene-Monomer Roofing 01-21 07 54 16 Ethylene Interpolymer (KEE) Roofing 01-21 07 54 19 Polyvinyl-Chloride (PVC) Roofing 12-18 07 54 23 Thermoplastic Polyolefin (TPO) Roofing 01-21 07 56 00 Fluid-Applied Roofing 01-21 07 57 13 Sprayed Polyurethane Foam Roofing 12-21 07 60 00 Flashing and Sheet Metal 01-21 07 61 16 Batten Seam Copper Roofing 01-21 07 71 00 Roof Specialties 01-21 07 72 00 Roof Accessories 01-21 07 81 00 Applied Fireproofing 07-23 07 84 00 Firestopping 01-21 07 92 00 Joint Sealants 04-22 07 95 13 Expansion Joint Cover Assemblies 01-21

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 01-21 08 11 73 Sliding Metal Fire Doors 01-21 08 14 00 Interior Wood Doors 01-21 08 17 10 Integrated Door Assemblies 01-21 08 31 13 Access Doors and Frames 04-22 08 32 13 ICU Sliding Glass Doors 01-21 08 33 00 Coiling Doors and Grilles 01-21

00 01 10-4

SECTION NO DIVISION AND SECTION TITLES DATE

08 33 13 Coiling Counter Doors 01-21 08 34 53 Security Doors and Frames 01-21 08 34 59 Vault Doors and Day Gates 01-21 08 35 13.13 Accordion Folding Doors 01-21 08 36 13 Sectional Doors 01-21 08 38 16 Flexible Traffic Doors 01-21 08 41 13 Aluminum-Framed Entrances and Storefronts 01-21 08 42 33 Revolving Door Entrances 01-21 08 44 13 Glazed Aluminum Curtain Walls 04-20 08 51 13 Aluminum Windows 01-21 08 51 13.11 Side-Hinged Aluminum Windows 01-21 08 51 23 Steel Windows 01-21 08 51 69.11 Aluminum Storm Windows 01-21 08 56 19 Pass Windows 01-21 08 56 53 Blast Resistant Windows 01-21 08 56 59 Service and Teller Window Units 01-21 08 56 66 Detention Window Screens 01-21 08 63 00 Metal-Framed Skylights 01-21 08 71 00 Door Hardware 03-24 08 71 13 Automatic Door Operators 01-21 08 71 13.11 Low Energy Power Assist Door Operators 01-21 08 80 00 Glazing 01-21 08 90 00 Louvers and Vents 01-21

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 01-21 09 06 00 Schedule for Finishes 01-21 09 22 16 Non-Structural Metal Framing 06-18 09 23 00 Gypsum Plastering 01-21 09 24 00 Portland Cement Plastering 01-21 09 26 00 Veneer Plastering 01-21 09 29 00 Gypsum Board 04-20 09 30 13 Ceramic/Porcelain Tiling 01-21 09 51 00 Acoustical Ceilings 12-18 09 54 23 Linear Metal Ceilings 01-21 09 63 13 Brick Flooring 01-21 09 63 40 Stone Flooring 01-21 09 65 13 Resilient Base and Accessories 01-21 09 65 16 Resilient Sheet Flooring 06-22 09 65 19 Resilient Tile Flooring 05-18 09 66 13 Portland Cement Terrazzo Flooring 01-21 09 66 16 Terrazzo Floor Tile 01-21 09 67 23.20 Resinous Epoxy Base With Vinyl Chip Broadcast (RES 2) 12-21 09 67 23.30 Resinous (Epoxy Resin Composition) Mortar Flooring

(RES-3)

05-24

09.67.23.40 Resinous Poured In Place Resilient Flooring (RES-4) 01-21 09 67 23.50 Resinous Terrazzo Flooring (RES-5) 01-21 09 67 23.60 Resinous Urethane and Epoxy Mortar Flooring (RES-6A and

RES 6B)

01-21

09 68 00 Carpeting 01-21

00 01 10-5

SECTION NO DIVISION AND SECTION TITLES DATE

09 68 21 Athletic Carpeting 01-21 09 69 00 Access Flooring 01-21 09 72 16 Vinyl-Coated Fabric Wall Covering 01-21 09 72 31 Polypropylene Fabric Wall Covering 01-21 09 78 23 Phenolic Interior Wall Paneling 01-21 09 84 33 Sound-Absorbing Wall Units 01-21 09 91 00 Painting 01-21 09 94 19 Multicolor Interior Finishing 01-21 09 96 59 Resinous Specialty Glazed Coating Systems for Walls, Ceilings, Wallboard, and Block CMU (RES-W1, RES-W2) 01-21

DIVISION 10 – SPECIALTIES

10 11 13 Chalkboards and Markerboards 01-21 10 11 23 Tackboards 01-21 10 11 33 Glassboards (Magnetic & Non-Magnetic) 01-21 10 13 00 Directories 01-21 10 14 00 Signage 01-21 10 21 13 Toilet Compartments 01-21 10 21 16 Shower and Dressing Compartments 01-21 10 21 23 Cubicle Curtain Tracks 01-21 10 22 13 Wire Mesh Partitions 01-21 10 22 19 Demountable Partitions 01-21 10 22 26.13 Accordion Folding Partitions 01-21 10 25 13 Patient Bed Service Walls 05-23 10 26 00 Wall and Door Protection 01-21 10 28 00 Toilet, Bath, and Laundry Accessories 01-21 10 44 13 Fire Extinguisher Cabinets 08-18 10 75 00 Flagpoles 01-21

DIVISION 11 – EQUIPMENT

11 05 12 General Motor Requirements for Equipment 01-21 11 12 00 Parking Control Equipment 01-21 11 17 36 Package Transfer Units 01-21 11 26 00 Unit Kitchens 01-21 11 40 11 Custom Fabricated Food Service Equipment 01-21 11 40 21 Food Service Equipment-Utility Distribution System 01-21 11 41 00 Food Storage Equipment 01-21 11 41 21 Walk-In Coolers and Freezers 01-21 11 44 00 Food Cooking Equipment 01-21 11 48 00 Cleaning and Disposal Equipment 01-21 11 53 13 Laboratory Fume Hoods 01-21 11 53 23 Laboratory Refrigerators 01-21 11 53 53 Biological Safety Cabinets Laminar Airflow Stations 01-21 11 53 61 Custom Fabricated Laboratory Equipment 01-21 11 53 71 Solution Warming Cabinets 01-21 11 71 01 Medical Washing and Sterilizing Equipment 01-21 11 71 02 Laboratory Washing and Sterilizing Equipment 01-21 11 73 00 Ceiling Mounted Patient Lift System 08-20 11 78 00 Mortuary Equipment 01-21

00 01 10-6

SECTION NO DIVISION AND SECTION TITLES DATE

11 78 13 Mortuary Refrigerators 01-21 11 79 13 Hydrotherapy Equipment 01-21 11 82 19 Packaged Incinerators 01-21

DIVISION 12 – FURNISHINGS

12 22 16 Drapery Track and Accessories 01-21 12 24 00 Window Shades 08-17 12 24 21 Lightproof Shades 01-21 12 31 00 Manufactured Metal Casework 01-21 12 32 00 Manufactured Wood Casework 01-21 12 34 00 Manufactured Plastic Casework 01-21 12 35 70.21 Medication Cabinet 01-21 12 36 00 Countertops 12-23 12 56 70.11 Suspended Table 01-21

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural

Components 01-21

13 17 23 Therapeutic Pools 01-21 13 17 23.11 Therapeutic Pool Accessories 01-21 13 19 13 Kennel Enclosures and Gates 01-21 13 21 29 Constant Temperature Rooms 01-21 13 21 49 Audiology Booth 01-21 13 34 19 Metal Building Systems 01-21 13 49 00 Radiation Protection 01-21

DIVISION 14– CONVEYING EQUIPEMENT

14 12 11 Traction and Winding Drum Dumbwaiter 04-24 14 21 00 Traction Elevator – New 04-24 14 21 10 Traction Elevator – Modernization 04-24 14 21 11 Traction Cartlift 04-24 14 24 00 Hydraulic Elevator – New 04-24 14 24 10 Hydraulic Elevator – Modernization 04-24 14 24 11 Hydraulic Cartlift 04-24 14 91 33 Gravity Soiled Linen Chutes 09-23 14 91 82 Gravity Trash Chutes 09-23 14 92 00 Pneumatic Tube System 09-23

DIVISION 21- FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16 21 08 00.01 DVA/USACE Projects Commissioning of Fire Suppression

Systems 08-19

21 12 00 Manual Dry Standpipe Systems 06-15 21 13 13 Wet-Pipe Sprinkler Systems 06-15 21 13 16 Dry-Pipe Sprinkler Systems 01-15 21-22-00 Clean Agent Fire Suppression Systems 05-15 21-30-13 Electric-Driven, Fire Pumps 05-15

00 01 10-7

SECTION NO DIVISION AND SECTION TITLES DATE

21-30-16 Diesel-Driven, Fire Pumps 05-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 01-23 22 05 12 General Motor Requirements for Plumbing Equipment 09-20 22 05 19 Meters and Gages for Plumbing Piping 09-20 22 05 23 General-Duty Valves for Plumbing Piping 09-20 22 05 33 Heat Tracing for Plumbing Piping 09-20 22 07 11 Plumbing Insulation 09-19 22 08 00 Commissioning of Plumbing Systems 11-16 22 08 00.01 DVA/USACE Projects Commissioning of Plumbing Systems 08-19 22 11 00 Facility Water Distribution 05-21 22 11 23 Domestic Water Pumps 09-15 22 12 16 Facility Elevated, Potable-Water Storage Tanks 09-15 22 13 00 Facility Sanitary and Vent Piping 09-20 22 13 23 Sanitary Waste Interceptors 09-20 22 13 29 Sanitary Sewerage Pumps 09-20 22 13 29.13 Wet-Pit Mounted, Vertical Sewerage Pumps 09-20 22 13 33 Packaged, Submersible Sewerage Pump Units 09-20 22 14 00 Facility Storm Drainage 09-15 22 14 29 Sump Pumps 09-15 22 14 33 Packaged, Pedestal Drainage Pump Units 09-15 22 14 36 Packaged, Submersible, Drainage Pump Units 09-15 22 15 00 General Service Compressed-Air Systems 09-20 22 31 11 Water Softeners 09-15 22 33 00 Electric Domestic Water Heaters 09-20 22 34 00 Fuel-Fired Domestic Water Heaters 09-20 22 35 00 Domestic Water Heat Exchangers 09-20 22 40 00 Plumbing Fixtures 05-24 22 42 26 Commercial Disposers 09-15 22 61 13.74 Dental Compressed-Air Piping 05-23 22 61 19.74 Dental Compressed-Air Equipment 09-20 22 62 00 Vacuum Systems for Laboratory and Healthcare Facilities 05-23 22 62 19.74 Dental Vacuum and Evacuation Equipment 09-15 22 63 00 Gas Systems for Laboratory and Healthcare Facilities 05-23 22 66 00 Chemical-Waste Systems for Laboratory and Healthcare

Facilities 09-20

22 67 19.16 Reverse-Osmosis Water Equipment 09-15 22 67 21 Water Dealkalizing System 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 10 Common Work Results for Boiler Plant and Steam

Generation 06-24

23 05 11 Common Work Results for HVAC 03-23 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 03-23

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

03-23

00 01 10-8

SECTION NO DIVISION AND SECTION TITLES DATE

23 05 51 Noise and Vibration Control for Boiler Plant 03-22 23 05 93 Testing, Adjusting, and Balancing for HVAC 03-23 23 05 93.01 DVA/USACE Projects Testing, Adjusting, and Balancing for HVAC 11-21

23 07 11 HVAC and Boiler Plant Insulation 02-20 23 08 00 Commissioning of HVAC Systems 03-23 23 08 00.01 DVA/USACE Projects Commissioning of HVAC Systems 08-19 23 08 11 Demonstrations and Tests for Boiler Plant 04-20 23 09 11 Instrumentation and Control for Boiler Plant 04-24 23 09 23 Direct-Digital Control System for HVAC 03-23 23 10 00 Facility Fuel Systems 04-20 23 11 23 Facility Natural-Gas Piping 04-20 23 21 11 Boiler Plant Piping Systems 03-24 23 21 13 Hydronic Piping 03-23 23 21 23 Hydronic Pumps 03-23 23 22 13 Steam and Condensate Heating Piping 03-24 23 22 23 Steam Condensate Pumps 04-20 23 23 00 Refrigerant Piping 03-24 23 25 00 HVAC Water Treatment 03-23 23 31 00 HVAC Ducts and Casings 03-23 23 34 00 HVAC Fans 03-23 23 36 00 Air Terminal Units 03-23 23 37 00 Air Outlets and Inlets 03-23 23 38 13 Commercial-Kitchen Hoods 03-23 23 40 00 HVAC Air Cleaning Devices 03-23 23 50 11 Boiler Plant Mechanical Equipment 03-22 23 51 00 Breechings, Chimneys, and Stacks 04-20 23 52 25 Low-Pressure Water Heating Boilers 09-23 23 52 28 Low-Pressure Steam Boilers 09-23 23 52 33 Water Tube Boilers 11-23 23 52 39 Fire Tube Boilers 09-23 23 56 00 Solar Energy Heating System 03-23 23 57 33 Geothermal Energy – Direct Use 03-23 23 64 00 Packaged Water Chillers 03-24 23 65 00 Cooling Towers 03-23 23 72 00 Air-to-Air Energy Recovery Equipment 03-24 23 73 00 Indoor Central-Station Air-Handling Units 03-23 23 74 13 Packaged, Outdoor, Central-Station Air-Handling Units 03-23 23 81 00 Decentralized Unitary HVAC Equipment 03-24 23 81 23 Computer-Room Air-Conditioners 03-24 23 81 43 Air-Source Unitary Heat Pumps 03-23 23 81 46 Water-Source Unitary Heat Pumps 03-23 23 81 49 Ground-Source Heat Pump 03-23 23 82 00 Convection Heating and Cooling Units 03-23 23 82 16 Air Coils 03-24 23 84 00 Humidity Control Equipment 03-24

DIVISION 25 – INTEGRATED AUTOMATION

25 10 10 Advanced Utility Metering System 02-10

00 01 10-9

SECTION NO DIVISION AND SECTION TITLES DATE

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 11-22 26 05 13 Medium-Voltage Cables 11-22 26 05 19 Low-Voltage Electrical Power Conductors and Cables 11-22 26 05 26 Grounding and Bonding for Electrical Systems 11-22 26 05 33 Raceway and Boxes for Electrical Systems 11-22 26 05 36 Wireways for Radiology Equipment 11-22 26 05 39 Underfloor Raceways for Electrical Systems 11-22 26 05 41 Underground Electrical Construction 11-22 26 05 73 Overcurrent Protective Device Coordination Study 11-22 26 08 00 Commissioning of Electrical Systems 11-22 26 08 00.01 DVA/USACE Projects Commissioning of Electrical Systems 08-19 26 09 23 Lighting Controls 11-22 26 11 16 Secondary Unit Substations 11-22 26 12 19 Pad-Mounted, Liquid-Filled, Medium-Voltage Transformers 11-22 26 13 13 Medium-Voltage Circuit Breaker Switchgear 11-22 26 13 16 Medium-Voltage Fusible Interrupter Switches 11-22 26 20 11 Isolated Power Systems 11-22 26 22 00 Low-Voltage Transformers 11-22 26 23 00 Low-Voltage Switchgear 11-22 26 23 13 Generator Paralleling Controls 11-22 26 24 13 Distribution Switchboards 11-22 26 24 16 Panelboards 11-22 26 24 19 Motor Control Centers 11-22 26 25 11 Busways 11-22 26 26 00 Power Distribution Units for Static Uninterruptible

Power Systems 11-22

26 27 26 Wiring Devices 11-22 26 29 11 Motor Controllers 11-22 26 29 21 Enclosed Switches and Circuit Breakers 11-22 26 32 13 Engine Generators 11-22 26 33 53 Static Uninterruptible Power Supply 11-22 26 35 26 Harmonic Filters 11-22 26 36 23 Automatic Transfer Switches 11-22 26 41 00 Facility Lightning Protection 11-22 26 42 00 Cathodic Protection 11-22 26 43 13 Surge Protective Devices 11-22 26 51 00 Interior Lighting 03-24 26 55 71 Medical and Surgical Lighting Fixtures 11-22 26 56 00 Exterior Lighting 11-22

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 10-18 27 05 61 Leased Space, Communication Equipment and Systems 06-15 27 08 00 Commissioning of Communications Systems 11-16 27 08 00.01 DVA/USACE Projects Commissioning of Communications

Systems 08-19

00 01 10-10

SECTION NO DIVISION AND SECTION TITLES DATE

27 10 00 Control, Communication and Signal Wiring 06-15 27 11 00 Telecommunications Room Fittings 06-15 27 15 00 Communications Structured Cabling 01-16 27 31 00 Voice Communications Switching and Routing Equipment 06-15 27 31 31 Voice Communications Switching and Routing Equipment -

Extension 06-15

27 32 41 Two-Way Radio Equipment and Systems 10-18 27 41 31 Master Antenna Television Equipment and Systems 06-15 27 51 16 Public Address and Mass Notification Systems 11-22 27 51 23 Intercommunications and Program Systems 06-15 27 52 23 Nurse Call and Code Blue Systems 10-18 27 52 41 Miscellaneous Medical Systems 06-15 27 53 19 Distributed Radio Antenna (Within Building) Equipment and System 10-18

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

28 05 26 Grounding and Bonding for Electronic Safety and Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16 28 08 00.01 DVA/USACE Projects Commissioning of Electronic Safety and Security Systems 08-19

28 13 00 Physical Access Control System 10-11 28 13 16 Physical Access Control System and Database Management 09-11 28 13 53 Security Access Detection 09-11 28 16 00 Intrusion Detection System 10-11 28 23 00 Video Surveillance 09-11 28 26 00 Electronic Personal Protection System 09-11 28 31 00 Fire Detection and Alarm 10-11 28 52 31 Emergency Call System 06-15

DIVISION 31 – EARTHWORK

31 20 00 Earthwork 08-23 31 20 11 Earthwork (Short Form) 10-12 31 23 19 Dewatering 10-12 31 23 23.33 Flowable Fill 10-12 31 32 23 Pressure Grouting Soil Stabilization 10-12 31 62 00 Driven Piles 10-12 31 63 16 Auger Cast Grout Piles 10-12 31 63 26 Drilled Caissons 10-12

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 05 23 Cement and Concrete for Exterior Improvements 08-16 32 12 16 Asphalt Paving 09-15

00 01 10-11

SECTION NO DIVISION AND SECTION TITLES DATE

32 14 16 Brick Unit Paving 08-16 32 17 23 Pavement Markings 08-16 32 31 13 Chain Link Fences and Gates 06-18 32 31 40 High Security Fences and Gates 08-16 32 84 00 Planting Irrigation 08-16 32 90 00 Planting 08-16

DIVISION 33 – UTILITIES

33 08 00 Commissioning of Site Utility Systems 11-16 33 08 00.01 DVA/USACE Projects Commissioning of Site Utility

Systems 08-19

33 10 00 Water Utilities 03-17 33 30 00 Sanitary Sewer Utilities 06-13 33 40 00 Storm Sewer Utilities 12-17 33 46 13 Foundation Drainage 10-11 33 51 00 Natural-Gas Distribution 10-11 33 63 00 Steam Energy Distribution 02-24

DIVISION 34 – TRANSPORTATION

34 71 13 Passive Vehicle Barriers 04-18 34 75 13.13 Active Vehicle Barriers 08-16

DIVISION 48 – Electrical Power Generation

48 14 00 Solar Energy Electrical Power Generation System 07-23 48 15 00 Wind Energy Electrical Power Generation System 07-23

11-01-21

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

GENERAL

1.1 SAFETY REQUIREMENTS

A. Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for Project:

657A4-24-105 Site prep to Receive Fluoro & Xray as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the Medical Center Engineering Officer.

C. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection.

Such prior notice shall be not less than three workdays unless otherwise designated by the COR.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

01 00 00 -2

1.3 STATEMENT OF BID ITEM(S)

ITEM I, GENERAL CONSTRUCTION: Contractor shall provide Poplar Bluff VA Medical Center with site preparations for the replacement of the Phillips Fluoro & Xray Easy Diagnost and provide West Plains VA Clinic with site preparations for the replacement of the GE Definium 5000.

Contractor shall review any as-built drawings, specifications and field verifications in conjunction with the performance of this project. Contractor will submit field drawings and materials as required by the specifications. The site preparations will comply to industry standards, VHA Design Criteria, ASME, NFPA, and any additional applicable VHA Directives for radiological safety. The contractor shall provide mechanical and electrical systems as required by Site Prep Documents and meet VA requirements. All physicist testing and reporting will be provided by the VA.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at

Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice

01 00 00 -3 is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer. Patients and staff are not to be photographed at any time.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the

Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall //install all permanent cores at completion of the work// turn over all permanent lock cylinders to the VA locksmith for permanent installation //.

See Section 08 71 00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub

Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or

“Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting

Officer upon request.

01 00 00 -4

4. These security documents shall not be removed or transmitted from the project site without the written approval of

Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the

VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an

Engineering Document Management Software (EDMS).

Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

“Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted

24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. Permits shall be issued for General Contractor and its employees for parking in designated areas only. Contractor to coordinate with VA Medical Center Facility Manager.

1.6 OPERATIONS AND STORAGE AREAS (FAR 52.236-10)

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

01 00 00 -5

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the

Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the

Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the

Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the COR.

E. Workers are subject to rules of Medical Center applicable to their conduct.

F. Execute work to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

01 00 00 -6

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by

Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to

Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

G. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

All such actions shall be coordinated with the COR or Utility

Company involved:

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

H. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate dates on which the Contractor intends to accomplish work in each specific area of site, 01 00 00 -7 building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such dates to ensure accomplishment of this work in successive phases mutually agreeable to

Medical Center Director, COR and Contractor as follows:

I. Building(s) No.(s) 1 at John J. Pershing Medical Facility & West

Plains Clinic will be occupied during performance of work; but immediate areas of alterations will be vacated.

1. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical

Centers operations will not be hindered. Contractor shall permit access to Department of Veterans Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and staff access. Coordinate alteration work in areas occupied by

Department of Veterans Affairs so that Medical Center operations will continue during the construction period.

2. Immediate areas of alterations not mentioned in preceding

Subparagraph 1 will be temporarily vacated while alterations are performed.

J. Construction Fence: Before construction operations begin, Contractor shall provide a chain link construction fence, 2.1m

(seven feet) minimum height, around the construction area indicated on the drawings. Provide gates as required for access with necessary hardware, including hasps and padlocks. Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum

01 00 00 -8

375mm (15 inches). Bottom of fences shall extend to 25mm (one inch) above grade. Remove the fence when directed by COR.

K. When a building and/or construction site is turned over to

Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C

(40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company

(Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from Contractor's employee or watchman.

L. Utilities Services: Maintain existing utility services for

Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR.

Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the

Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11

REQUIREMENTS FOR COMMUNICATIONS INSTALLATIONS and 28 05 00, 01 00 00 -9

COMMON WORK RESULTS FOR ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center

Cemetery. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

M. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, shall be removed back to their source. Those which are indicated to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

N. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

01 00 00 -10

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

1.7 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are or noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by

COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be

01 00 00 -11 reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems

(including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4) and "DIFFERING SITE CONDITIONS"

(FAR 52.236-2).

1.11 LAYOUT OF WORK

A. The Contractor shall lay out the work from Government established base lines and bench marks, indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work.

The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the

Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through

01 00 00 -12

Contractor's negligence before their removal is authorized, the

Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the

Contractor.

1.12 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR] within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.13 WARRANTY MANAGEMENT

A. Warranty Management Plan: Develop a warranty management plan which contains information relevant to FAR 52.246-21 Warranty of

Construction at least 30 days before the planned pre-warranty conference, submit 2 sets of the warranty management plan.

Include within the warranty management plan all required actions and documents to assure that the Government receives all warranties to which it is entitled. The plan must be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesman, or of engineering background, not necessarily familiar with this contract. The term “status” as indicated below must include due date and whether item has been submitted or was approved.

Warranty information made available during the construction phase must be submitted to the Contracting Officer for approval prior to each monthly invoice for payment. Assemble approved

01 00 00 -13 information in a binder and turn over to the Government upon acceptance of the work. The construction warranty period will begin on the date of the project acceptance and continue for the product warranty period. A joint 4 month and 9 month warranty inspection will be conducted, measured from time of acceptance, by the Contactor and the Contracting Officer. Include in the warranty management plan, but not limited to, the following:

1. Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers within the company of the Contractor, subcontractors, manufacturers or suppliers involved.

2. Furnish with each warranty the name, address and telephone number of each of the guarantor’s representatives nearest project location.

3. Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers and for all commissioned systems such as fire protection and alarm systems, sprinkler systems and lightning protection systems, etc.

4. A list for each warranted equipment item, feature of construction or system indicating:

a. Name of item.

b. Model and serial numbers.

c. Location where installed.

d. Name and phone numbers of manufacturers and suppliers.

e. Name and phone numbers of manufacturers or suppliers.

f. Names, addresses and phone numbers of sources of spare parts.

g. Warranties and terms of warranty. Include one-year overall warranty of construction, including the starting date of warranty of construction. Items which have extended warranties must be indicated with separate warranty expiration dates.

h. Starting point and duration of warranty period.

01 00 00 -14

i. Summary of maintenance procedures required to continue the warranty in force.

j. Cross-reference to specific pertinent Operation and Maintenance manuals.

k. Organizations, names and phone numbers of persons to call for warranty service.

l. Typical response time and repair time expected for various warranted equipment.

5. The plans for attendance at the 4 and 9-month post construction warranty inspections conducted by the government.

6. Procedure and status of tagging of all equipment covered by extended warranties.

7. Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

B. Performance & Payment Bonds: The Performance & Payment Bonds must remain effective throughout the construction period.

1. In the event the Contractor fails to commence and diligently pursue any construction warranty work required, the

Contracting Officer will have the work performed by others, and after completion of the work, will charge the remaining construction warranty funds of expenses incurred by the

Government while performing the work, including, but not limited to administrative expenses.

2. In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the contractor’s expenses, the Contracting Officer will have the right to recoup expenses from the bonding company.

3. Following oral or written notification of required construction warranty repair work, the Contractor shall respond in a timely manner. Written verification will follow oral instructions. Failure to respond will be cause for the

Contracting Officer to proceed against the Contractor.

C. Pre-Warranty Conference: Prior to contract completion, and at a time designated by the Contracting Officer, the Contractor shall

01 00 00 -15 meet with the Contracting Officer to develop a mutual understanding with respect to the requirements of this section.

Communication procedures for Contractor notification of construction warranty defects, priorities with respect to the type of defect, reasonable time required for Contractor response, and other details deemed necessary by the Contracting Officer for the execution of the construction warranty will be established/ reviewed at this meeting. In connection with these requirements and at the time of the Contractor’s quality control completion inspection, furnish the name, telephone number and address of a licensed and bonded company which is authorized to initiate and pursue construction warranty work action on behalf of the

Contractor. This point of contract will be located within the local service area of the warranted construction, be continuously available and be responsive to Government inquiry on warranty work action and status. This requirement does not relieve the

Contractor of any of its responsibilities in conjunction with other portions of this provision.

D. Contractor’s Response to Construction Warranty Service

Requirements:

E. Following oral or written notification by the Contracting

Officer, the Contractor shall respond to construction warranty service requirements in accordance with the “Construction

Warranty Service Priority List” and the three categories of priorities listed below. Submit a report on any warranty item that has been repaired during the warranty period. Include within the report the cause of the problem, date reported, corrective action taken, and when the repair was completed. If the

Contractor does not perform the construction warranty within the timeframe specified, the Government will perform the work and back charge the construction warranty payment item established.

1. First Priority Code 1. Perform onsite inspection to evaluate situation, and determine course of action within 4 hours, initiate work within 6 hours and work continuously to completion or relief.

01 00 00 -16

2. Second Priority Code 2. Perform onsite inspection to evaluate situation, and determine course of action within 8 hours, initiate work within 24 hours and work continuously to completion or relief.

3. Third Priority Code 3. All other work to be initiated within 3 work days and work continuously to completion or relief.

4. The “Construction Warranty Service Priority List” is as follows:

a) Code 1-Life Safety Systems Fire suppression systems.

Fire alarm system(s).

b) Code 1-Air Conditioning Systems Air conditioning leak in part of the building, if causing damage.

Air conditioning system not cooling properly.

c) Code 1 Doors

Overhead doors not operational, causing a security, fire or safety problem.

1) Interior, exterior personnel doors or hardware, not functioning properly, causing security, fire or safety problem.

d) Code 1-Electrical Power failure (entire area or any building operational after 1600 hours).

Security lights.

Smoke detectors.

e) Code 2-Electrical Power failure (no power to a room or part of building).

Receptacle and lights not operational (in a room or part of building).

f) Code 3-Electrical Exterior lights not operational.

g) Code 1-Gas Leaks and pipeline breaks.

h) Code 1-Heat

01 00 00 -17

Power failure affecting heat.

i) Code 1-Plumbing

Hot water heater…

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated .