3. 80GSFC26R7004 XRIS Draft RFP.pdf

80GSFC26R7004

PART I – THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

B-1

1852.216-78 FIRM-FIXED-PRICE. (DEVIATION) (DEC 2025)

The total firm-fixed-price and time & materials of this contract is $[TBP].

CLIN DESCRIPTION FIRM FIXED PRICE

001 Flight Instrument $[TBP]

002 Post Delivery Support $[TBP]

TOTAL FIRM FIXED PRICE: $[TBP]

The total Time & Materials (T&M) ceiling price of this contract is $350,000.

CLIN DESCRIPTION T&M CEILING PRICE

003 Special Studies $350,000

TOTAL T&M CEILING PRICE: $350,000

CLIN = Contract Line-Item Number

(End of clause)

GSFC 52.211-90 SUPPLIES AND/OR SERVICES TO BE PROVIDED. (APR 2023)

The Contractor shall provide all resources (except as may be expressly stated in the contract as furnished by the Government) necessary to deliver and/or perform the items below in accordance with the incorporated Attachment A - Statement of Work (SOW), Attachment B – Specification

(SPEC); Attachment C - Contract Deliverables Requirements List (CDRL), Attachment D –

Mission Assurance Requirements (MAR) and Attachment E - Radiation Hardness Assurance

Requirements Document (RHARD).

Item Description Reference Schedule Delivery

Method/Addresses

1 Services and

Deliverables in accordance with

Attachment A, SOW

As Defined in

Attachment A - SOW;

Attachment B - SPECs;

Attachment C - CDRL, Attachment D - MAR, and

Attachment E - RHARD

As Defined in

Attachment A - SOW;

Attachment B - SPECs;

Attachment C - CDRL, Attachment D - MAR, and

Attachment E – RHARD

As Defined in

Attachment A - SOW;

Attachment B - SPECs;

Attachment C - CDRL, Attachment D - MAR, and

Attachment E - RHARD

B-2

Item Description Reference Schedule Delivery

Method/Addresses

2 XRIS

Flight Model 1

(FM-1)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 1.1 and Section 6

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

3 XRIS

Flight Model 2

(FM-2)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 1.1 and Section 6

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

4 Engineering

Development

Unit (EDU)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 6.1.1

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

5 Spares

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 6.2

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

6 Two (2) sets of

Electrical

System Test

Equipment

(ESTE)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 7.1.1

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

7 Four (4)

XRIS

Emulators

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 7.1.2

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

8 Ground

Processing

Development

Systems (1)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 7.3

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

9 Additional

XRIS

Instrument

Mechanical and Electrical

Ground

Support

Equipment

(MGSE and

EGSE)

(CLIN 001)

As Defined in

Attachment A, SOW;

Section 7.2 and

Section 7.1.4

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

B-3

Method/Addresses

10 Reports of

Work

Section C

GSFC 52.235-91

Section H

NFS 1852.235-73

(DEVIATION)

As Required in Clause

GSFC 52.235-91

As specified in Clause

GSFC 52.235-91

11 Post Delivery

Support, Tests, and Reviews

(CLIN 002)

As Defined in

Attachment A, SOW;

Sections 9 and 10

As Defined in

Attachment C, CDRL

As Defined in

Attachment C, CDRL

12 Task Plans

(CLIN 003)

Section I

NFS 1852.216-80

(DEVIATION)

As Defined in

Attachment A, SOW;

Section 11

As Required in Clause

NFS 1852.216-80

(DEVIATION)

As specified in individual task orders

Material

Inspection and

Receiving

Reports

(MIRR)

(DD Form

250)

Section E

NFS 1852.246-72

(DEVIATION)

GSFC 52.246-94

At Time of Delivery Hard copy/CO, COR, and

Receiving & Inspection

14 Foreign Travel

Requests and

Foreign Travel

Reports

Section G

NFS 1852.242-71

(DEVIATION)

Foreign Travel Requests–30 days in Advance of Travel

Foreign Travel Reports–

Due within 10 business days of the completion of travel.

As specified in CO’s travel approval

15 Requests for

Government

Property

Section G

NFS 1852.245-70

30 Days Prior to Acquire

Date

Electronic Format/CO

16 Physical

Inventory of

Capital

Personal

Property

Reporting

Section G

NFS 1852.245-78

(DEVIATION)

Within 10 Days of Annual

Physical Inventory

Property Administrator

B-4

Method/Addresses

17 Reporting of

Inventions

Section G

NFS 1852.227-72

NFS 1852.227-70

Section I

FAR 52.227-11

Interim Reports Every 12

Months (or sooner to preserve Patent Rights) and

Final Report within 3

Months after Contract

Completion

Electronic Format /

New Technology Reporting

System (e-NTR), https://invention.nasa.gov/

18 Small Business

Subcontracting

Plan Reporting

Section H

GSFC 52.219-90

Section I

NFS 1852.219-75

ISR–Semi-Annual

(April 30th and October

30th) and

Final SSR–Annual

(October 30th)

Electronic Format/

Electronic Subcontract

Reporting System (eSRS), http://www.esrs.gov

19 Safety &

Health

Reporting

Section H

NFS 1852.223-70

NFS 1852.223-75

GSFC 52.223-91

Monthly/Quarterly Reports and As Required

NASA Mishap Information

System (NMIS)

20 Organizational

Conflicts of

Interest (OCI)

Plan

Section I

NFS 1852.237-72

Section J

Attachment O

30 Days after Contract

Effective Date

Electronic Format/CO

21 Subcontract

Notification

Section I

FAR 52.244-2

30 Days Prior to

Subcontract Award Date

Electronic Format/CO

22 Information

System

Security Plan

Section I

NFS 1852.240-76

Section J

Attachment I

30 Days after Contract

Effective Date & Annual

Updates As Required

Electronic Format/CO

NOTE: Unless otherwise specified, “day” means “calendar day”.

GSFC 52.216-95 HOURLY RATES AND CONTRACT CEILING PRICE. (SEP 2017)

The hourly rates for computation of payment and the contract ceiling price referred to in FAR clause 52.232-7, "Payments Under Time-and-Materials and Labor-Hour Contracts" of this contract https://invention.nasa.gov/ http://www.esrs.gov/

B-5 are set forth in Attachment L. This clause only applies to Section 11 - SPECIAL STUDIES (CLIN

003) of the Statement of Work.

The ceiling price of this T&M section of the contract is $350,000.

(End of clause)

GSFC 52.217-91 OPTION FOR INCREASED QUANTITY. (SEP 2013)

In accordance with the Option for Increased Quantity--Separately Priced Line Item clause of this contract, the Government may increase the quantity of items as follows:

PRE-PRICED CHANGE OPTIONS (PPC) (CLIN 002)

Option Description Period of Performance Firm Fixed Price Amount

1 PPC 1:

Observatory Delivery Delay per

SOW, Section 10.1.1

First 30-day delivery delay $[TBP]

Second 30-day delivery delay $[TBP]

Third 30-day delivery delay $[TBP]

Fourth 30-day delivery delay $[TBP]

Fifth 30-day delivery delay $[TBP]

Sixth 30-day delivery delay $[TBP]

2 PPC 2:

Observatory Environmental

Testing Support Delay per

SOW, Section 10.1.2

First 15-day testing delay $[TBP]

Second 15-day testing delay $[TBP]

Third 15-day testing delay $[TBP]

Fourth 15-day testing delay $[TBP]

Fifth 15-day testing delay $[TBP]

Sixth 15-day testing delay $[TBP]

3 PPC 3:

Pre-Priced Change Option 3:

Launch Delay, Observatory

Storage, and Post-Storage

Testing per SOW, Section

10.1.3

First delay

(14 – 90 days)

$[TBP] (daily rate)

Second delay

(14 – 90 days)

$[TBP] (daily rate)

Third delay

(14 – 90 days)

$[TBP] (daily rate)

Fourth delay

(14 – 90 days)

$[TBP] (daily rate)

4 PPC 4:

Extended Launch Delay, Observatory Storage, and Post-

Storage Testing per SOW, Section 10.1.4

First delay

(6 months – 12 months)

$[TBP] (monthly rate)

Second delay

(6 months – 12 months)

$[TBP] (monthly rate)

Third delay

(6 months – 12 months)

$[TBP] (monthly rate)

Fourth delay

(6 months – 12 months)

$[TBP] (monthly rate)

B-6

SPECIAL STUDIES OPTIONS (CLIN 003)

Option Description Period of Performance Price

1 Special Studies Option 1 per SOW, Section 11

When needed $50,000

2 Special Studies Option 2 per SOW, Section 11

When needed $50,000

3 Special Studies Option 3 per SOW, Section 11

When needed $50,000

4 Special Studies Option 4 per SOW, Section 11

When needed $50,000

5 Special Studies Option 5 per SOW, Section 11

When needed $50,000

6 Special Studies Option 6 per SOW, Section 11

When needed $50,000

7 Special Studies Option 7 per SOW, Section 11

When needed $50,000

This option may be exercised by the Contracting Officer by written notice to the Contractor within the time period specified in FAR clause 52.217-7, "Option for Increased Quantity--Separately

Priced Line Item" of this contract.

[END OF SECTION B]

80GSFC26R7004B

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C-1

GSFC 52.211-91 SCOPE OF WORK. (FEB 2016)

The Contractor shall provide the personnel, materials, and facilities, except as otherwise specified in this contract, necessary to perform the work and to furnish the items specified in the Supplies and/or Services To Be Provided clause of this contract in accordance with the following:

• Attachment A – Statement of Work (SOW)

• Attachment B – Specifications (SPEC)

• Attachment C – Contract Deliverable Requirements List (CDRL)

• Attachment D – Mission Assurance Requirements (MAR)

• Attachment E – Radiation Harness Assurance Requirements Document (RHARD)

• Attachment H – Safety and Health Plan

• Options issued hereunder

GSFC 52.227-90 LIMITED RIGHTS DATA OR RESTRICTED COMPUTER

SOFTWARE. (MAR 2008)

In accordance with the delivery requirements of this contract, all software data rights shall be delivered in accordance with the Rights in Data – General clause, specified elsewhere in this contract, except for the following: NONE.

(End of clause)

GSFC 52.235-91 REPORTS OF WORK (CORE). (MAR 2022)

(a) Monthly progress reports. The Contractor shall submit monthly progress reports of all work accomplished during each month of contract performance. Reports shall address the accomplishments and progress of all work performed the month being reported. The report shall be in narrative form and brief in content. The report shall include a description of technical accomplishments and status of deliverables. Also, the report shall provide a quantitative description of overall progress and identify any risks or problems, which may impede performance and proposed corrective actions. Also the report shall have a discussion of the projected work activities to be performed during the next monthly reporting period.

(b) Final Report. The Contractor shall submit a final report that summarizes the results of the entire contract, including recommendations and conclusions based on the experience and results

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C-2 obtained. The final report should include, as appropriate, tables, graphs, diagrams, curves, sketches, photographs, and drawings in sufficient detail to comprehensively explain the results achieved under the contract.

(c) Submission. The Contractor shall submit the reports required by this clause as follows:

Copies Report Type Addressee Mail Code

1 M, F Contracting Officer (CO) 171

1 M, F Contracting Officer's Representative (COR) 490

[M=Monthly Report, F=Final Report]

(d) Submission dates. Monthly reports shall be submitted by the 15th day of the month following the month being reported. If the contract is awarded beyond the middle of a month, the first monthly report shall cover the period from award until the end of the following month. The final report shall be submitted within 30 days after completion of the contract.

[END OF SECTION C]

SECTION D - PACKAGING AND MARKING

D-1

1852.245-74 IDENTIFICATION AND MARKING OF GOVERNMENT EQUIPMENT.

(DEVIATION) (DEC 2025)

(a) The Contractor must identify all equipment to be delivered to the Government using NASA

Technical Handbook (NASA-HDBK) 6003, Application of Data Matrix Identification Symbols to

Aerospace Parts Using Direct Part Marking Methods/Techniques, and NASA Standard (NASA-

STD) 6002, Applying Data Matrix Identification Symbols on Aerospace Parts or through the use of commercial marking techniques that: (1) are sufficiently durable to remain intact through the typical lifespan of the property: and, (2) contain the data and data format required by the standards.

This requirement includes deliverable equipment listed in the schedule and other equipment when no longer required for contract performance and NASA directs physical transfer to NASA or a third party. The Contractor must identify property in both machine and human readable form unless the use of a machine readable-only format is approved by the NASA Industrial Property Officer.

(b) Equipment must be marked in a location that will be human readable, without disassembly or movement of the equipment, when the items are placed in service unless such placement would have a deleterious effect on safety or on the item's operation.

(c) Concurrent with equipment delivery or transfer, the Contractor must provide the following data in an electronic spreadsheet format:

(1) Item Description.

(2) Unique Identification Number (License Tag).

(3) Unit Price.

(4) An explanation of the data used to make the unique identification number.

(d) For equipment no longer needed for contract performance and physically transferred under paragraph (a) of this clause, the following additional data is required:

(1) Date originally placed in service.

(2) Item condition.

(e) The data required in paragraphs (c) and (d) of this clause must be delivered to the NASA center receiving activity listed below:

NASA Goddard Space Flight Center

Building 35, Code 279

Greenbelt MD 20771

SECTION D - PACKAGING AND MARKING

D-2

(f) The contractor must include the substance of this clause, including this paragraph (f), in all subcontracts that require delivery of equipment.

[END OF SECTION D]

SECTION E - INSPECTION AND ACCEPTANCE

E-1

Clauses incorporated by reference:

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1):

52.246-6 INSPECTION- TIME-AND-MATERIAL AND LABOR HOURS. (MAY 2001)

ALTERNATE I (APR 1984)

52.246-7 INSPECTION OF RESEARCH AND DEVELOPMENT - FIXED-PRICE. (AUG

1996)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT. (DEC 2014)

[Paragraph (a): ISO 9001 compliant, Aerospace Standard (AS) 9001 compliant]

52.246-16 RESPONSIBILITY FOR SUPPLIES. (APR 1984)

(End of by reference clauses)

1852.246-71 GOVERNMENT CONTRACT QUALITY ASSURANCE FUNCTIONS.

(DEVIATION) (SEP 2025)

In accordance with the inspection clause of this contract, the Government intends to perform the following functions at the locations indicated:

ITEM QUALITY ASSURANCE FUNCTION LOCATION

As specified in Attachment D – Mission Assurance Requirements

1852.246-72 MATERIAL INSPECTION AND RECEIVING REPORT. (DEVIATION)

(SEP 2025)

(a) At the time of each delivery to the Government under this contract, the Contractor shall prepare and furnish a Material Inspection and Receiving Report (DD Form 250 series). The form(s) must be prepared and distributed as follows:

E-2

1. Via e-mail and marked "Advance Copy", one copy each to the Contracting Officer, the

Contracting Officer's Representative (if designated in the contract), and to the cognizant

Administrative Contracting Officer, if any.

2. Via e-mail, the original and 1 copy (unfolded) to the shipment address (delivery point) specified in Section F of this contract. Mark the exterior of the envelope "CONTAINS DD

FORM 250". This must arrive prior to the shipment.

3. With shipment in waterproof envelope (one copy) for the consignee.

4. If the shipment address is not directly to the Goddard Space Flight Center (Greenbelt) or

GSFC/Wallops Flight Facility (Wallops) central receiving areas, then one copy of the DD Form

250 must be provided (via mail) to the following address:

Receiving and Inspection (Code 279)

Goddard Space Flight Center

Greenbelt, MD 20771.

(b) The Contractor must prepare the DD Form 250 in accordance with NASA FAR Supplement

1846.6. The Contractor must enclose the copies of the DD Form 250 in the package or seal them in a waterproof envelope, which must be securely attached to the exterior of the package in the most protected location.

(c) When more than one package is involved in a shipment, the Contractor must list on the DD

Form 250, as additional information, the quantity of packages and the package numbers. The

Contractor must forward the DD Form 250 with the lowest numbered package of the shipment and print the words “CONTAINS DD FORM 250” on the package.

(End of clause)

GSFC 52.246-93 ACCEPTANCE -- LOCATION(S). (APR 2022)

The Contracting Officer or authorized representative will accomplish acceptance at the following location(s):

Item No. Deliverable Location Authorized

Representative

2 XRIS Flight Model 1

(FM-1)

Spacecraft Contractor’s Facility Contracting Officer’s

Representative (COR)

E-3

Item No. Deliverable Location Authorized

Representative

3 XRIS Flight Model 2

(FM-2)

Goddard Spaceflight Center

(Greenbelt, MD)

Contracting Officer’s

Representative (COR)

4 Engineering

Development Unit

(EDU)

Instrument Contractor’s Facility Contracting Officer’s

Representative (COR)

5 Spares and built up and test sub-assemblies

Instrument Contractor’s Facility Contracting Officer’s

Representative (COR)

6 Two (2) sets of

Electrical System Test

Equipment (ESTE)

Instrument Contractor’s Facility Contracting Officer’s

Representative (COR)

7 Four (4)

XRIS Emulators Instrument Contractor’s Facility (1 unit)

Spacecraft Contractor’s Facility (3 units)

Contracting Officer’s

Representative (COR)

8 Ground Processing

Development Systems (1)

Instrument Contractor’s Facility Contracting Officer’s

Representative (COR)

9 Additional XRIS

Instrument Mechanical and Electrical Ground

Support Equipment

(MGSE and EGSE)

Instrument Contractor’s Facility Contracting Officer’s

Representative (COR)

10 Reports of Work NASA/GSFC Contracting Officer’s

Representative (COR)

11 Post Delivery Support, Tests, and Reviews

NASA/GSFC Contracting Officer’s

Representative (COR)

12 Task Plans NASA/GSFC Contracting Officer (CO)

13 Material Inspection and

Receiving Reports

(MIRR) (DD Form 250)

NASA/GSFC Contracting Officer’s

Representative (COR)

14 Foreign Travel Requests and Foreign Travel

Reports

NASA/GSFC Contracting Officer (CO)

15 Requests for

Government Property

NASA/GSFC Contracting Officer (CO)

16 Physical Inventory of

Capital Personal

Property Reporting

NASA/GSFC Property Administrator

E-4

Item No. Deliverable Location Authorized

Representative

17 Reporting of Inventions New Technology Reporting System

(e-NTR), https://invention.nasa.gov

New Technology

Representative or Patent

Representative

18 Small Business

Subcontracting Plan

Reporting

Electronic Subcontract Reporting

System (eSRS), https://www.esrs.gov

Contracting Officer (CO)

19 Safety & Health

Reporting

NASA Mishap Information System

(NMIS)

GSFC Safety Division, Code 360

20 Organizational Conflicts of Interest (OCI) Plan

NASA/GSFC Contracting Officer (CO)

21 Subcontract Notification NASA/GSFC Contracting Officer (CO)

22 Information System

Security Plan

NASA/GSFC Contracting Officer (CO)

The Contracting Officer reserves the right to designate other Government agents as authorized representatives. The Contractor will be notified by a written notice or by a copy of the delegation letter if other agents are authorized.

(End of clause)

GSFC 52.246-94 MATERIAL INSPECTION AND RECEIVING REPORT NOT

REQUIRED. (APR 1989)

NASA FAR Supplement clause 1852.246‑72 of this contract requires the furnishing of a Material

Inspection and Receiving Report (MIRR) (DD Form 250 series) at the time of each delivery under this contract. However, a MIRR is not required for the following deliverable items: 10 – 22.

(End of clause)

GSFC 52.246-102 INSPECTION SYSTEM RECORDS. (APR 2013)

The Contractor shall maintain records evidencing inspections in accordance with the Inspection clause of this contract for six (6) years after delivery of all items and/or completion of all services called for by the contract.

(End of clause)

[END OF SECTION E]

https://invention.nasa.gov/ https://www.esrs.gov/

SECTION F - DELIVERIES OR PERFORMANCE

F-1

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1):

52.242-15 STOP-WORK ORDER. (AUG 1989)

52.242-17 GOVERNMENT DELAY OF WORK. (APR 1984)

52.247-34 F.O.B. DESTINATION. (JAN 1991)

(End of by reference clauses)

GSFC 52.217-92 PERIOD OF PERFORMANCE (JAN 2014)

The period of performance of this contract shall be for a period starting from the contract effective date of [TBD] through January 2034.

a) The first delivery date is November 2029, with an anticipated launch date of October 2032.

b) The second delivery date is May 2030.

(End of clause)

GSFC 52.247-95 SHIPPING INSTRUCTIONS--NON-CENTRAL RECEIVING. (FEB

2016)

Shipment of the items required under this contract shall be to:

Item Deliverable Quantity Address Marked For

2 XRIS Flight Model 1 (FM-1) 1 Spacecraft Contractor’s Facility

(Boulder, CO)

Code 490

3 XRIS Flight Model 2 (FM-2) 1 Goddard Spaceflight Center

(Greenbelt, MD)

Code 490

4 Engineering Development

Unit (EDU)

1 Instrument Contractor’s Facility Code 490

5 Spares 1 Lot Instrument Contractor’s Facility Code 490

SECTION F - DELIVERIES OR PERFORMANCE

F-2

Item Deliverable Quantity Address Marked For

6 Electrical System Test

Equipment (ESTE)

2 Instrument Contractor’s Facility Code 490

7 XRIS Emulators 4 Instrument Contractor’s Facility

(1 unit); Spacecraft Contractor’s

Facility (3 units)

Code 490

8 Ground Processing

Development Systems

1 Instrument Contractor’s Facility Code 490

9 Additional XRIS Instrument

Mechanical and Electrical

Ground Support Equipment

(MGSE and EGSE)

1 Lot Instrument Contractor’s Facility Code 490

Compliance with this clause is necessary to assure verification of delivery and acceptance and prompt payment.

If any of the above shipping addresses are to the Goddard Space Flight Center, Greenbelt, Maryland, delivery personnel must first stop at Receiving Officer Building 35 to provide a copy of the receiving report (DD 250) to Receiving personnel before making delivery to the on-site location(s) specified above. If this is a fixed price type contract, failure to provide the DD 250 to

Receiving may result in reduction or non-payment by the Government of any interest penalty under the Prompt Payment Act.

[END OF SECTION F]

SECTION G - CONTRACT ADMINISTRATION DATA

G-1

NASA FAR SUPPLEMENT (48 CFR CHAPTER 18) CLAUSES:

1852.227-70 NEW TECHNOLOGY—OTHER THAN A SMALL BUSINESS FIRM OR

NONPROFIT ORGANIZATION. (APR 2015)

1852.227-72 DESIGNATION OF NEW TECHNOLOGY REPRESENTATIVE AND

PATENT REPRESENTATIVE. (APR 2015)

1852.242-71 TRAVEL OUTSIDE OF THE UNITED STATES. (DEVIATION) (DEC 2025)

1852.245-70 CONTRACTOR REQUESTS FOR GOVERNMENT-FURNISHED

PROPERTY. (DEVIATION) (DEC 2025)

1852.245-75 PROPERTY MANAGEMENT CHANGES. (DEVIATION) (DEC 2025)

1852.245-78 PHYSICAL INVENTORY OF CAPITAL PERSONAL PROPERTY.

(DEVIATION) (DEC 2025)

(End of by reference clauses)

1852.232-80 SUBMISSION OF VOUCHERS FOR PAYMENT. (APR 2018)

(a) The designated payment office is the NASA Shared Services Center (NSSC) located at FMD

Accounts Payable, Bldg. 1111, Jerry Hlass Road, Stennis Space Center, MS 39529.

(b) Except for classified vouchers, the Contractor shall submit all vouchers and invoices using the steps described at NSSC's Vendor Payment information Web site at:

https://www.nssc.nasa.gov/vendorpayment.

Please contact the NSSC Customer Contact Center at 1-877-NSSC123 (1-877-677-2123) with any additional questions or comments.

(c) Payment requests.

(1) The payment periods are stipulated in the payment clause(s) contained in this contract.

https://www.nssc.nasa.gov/vendorpayment

G-2

(2) Vouchers submitted under cost type contracts and invoices submitted under fixed-price contracts shall include the items delineated in FAR 32.905(b) supported by relevant back-up documentation. Back-up documentation shall include at a minimum, the following information:

(i) Vouchers.

(A) Breakdown of billed labor costs and associated contractor generated supporting documentation for billed direct labor costs to include rates used and number of hours incurred.

(B) Breakdown of billed other direct costs (ODCs) and associated contractor generated supporting documentation for billed ODCs.

(C) Indirect rate(s) used to calculate the amount of billed indirect expenses.

(D) Progress reports, as required.

(ii) Invoices.

(A) Description of goods and services delivered as part of the contract's terms and conditions, including the dates of delivery/performance.

(B) Progress reports, as required.

(C) Date goods and services were performed.

(iii) Fee vouchers.

(A) Listing of all provisionally billed fee by period or date earned since contract award.

(B) A reconciliation of all billed and earned fee.

(C) A clear explanation of the fee calculations.

(d) Non-electronic payment requests. The Contractor may submit a non-electronic voucher/invoice using the steps for non-electronic payment requests described at:

https://www.nssc.nasa.gov/vendorpayment when any of the following conditions are met:

(1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor.

(2) The contract includes provisions allowing the contractor to submit vouchers or invoices using the steps for non-electronic payment. In such instances the Contractor agrees to submit non-electronic payment requests using the method or methods specified in Section G of the contract.

https://www.nssc.nasa.gov/vendorpayment

G-3

(e) Improper vouchers/invoices. The NSSC Payment Office will notify the contractor of any apparent error, defect, or impropriety in a voucher/invoice within seven calendar days of receipt by the NSSC Payment Office. Inquiries regarding requests for payment should be directed to the

NSSC as specified in paragraph (b) of this section.

(f) Other payment clauses. In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payment requests.

(g) In the event that amounts are withheld from payment in accordance with provisions of this contract, a separate payment request for the amount withheld will be required before payment for that amount may be made.

(End of clause)

1852.245-76 LIST OF GOVERNMENT PROPERTY FURNISHED PURSUANT TO FAR

52.245–1. (DEVIATION) (DEC 2025)

For performance of work under this contract, the Government will make available Government property identified in Attachment G of this contract on a no charge-for-use basis pursuant to the clause at FAR 52.245–1, Government Property, as incorporated in this contract. The Contractor must use this property in the performance of this contract at the Contractor’s facility and at other location(s) as may be approved by the Contracting Officer. Under FAR 52.245–1, the Contractor is accountable for the identified property.

[END OF SECTION G]

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H-1

NASA FAR SUPPLEMENT (48 CFR CHAPTER 18) CLAUSES:

1852.223-70 SAFETY AND HEALTH MEASURES AND MISHAP REPORTING. (DEC

2015)

1852.223-75 MAJOR BREACH OF SAFETY OR SECURITY. (FEB 2002)

1852.228-78 CROSS-WAIVER OF LIABILITY FOR SCIENCE OR SPACE

EXPLORATION ACTIVITIES UNRELATED TO THE INTERNATIONAL SPACE

STATION. (DEVIATION) (SEP 2025)

1852.235-73 FINAL SCIENTIFIC AND TECHNICAL REPORTS. (DEVIATION) (SEPT

2025)

(End of by reference clauses)

1852.225-70 EXPORT LICENSES. (DEVIATION) (DEC 2025)

(a) The contractor shall comply with all U.S. export control laws and regulations, including the

International Traffic in Arms Regulations (ITAR), 22 CFR parts 120-130, and the Export

Administration Regulations (EAR), 15 CFR parts 730-799, in the performance of this contract. In the absence of available license exemptions/exceptions, the contractor shall be responsible for obtaining the appropriate licenses or other approvals, if required, for exports of hardware, technical data, and software, or for the provision of technical assistance.

(b) The contractor shall be responsible for obtaining export licenses, if required, before utilizing foreign persons in the performance of this contract, including instances where the work is to be performed on-site at NASA Goddard Space Flight Center, where the foreign person will have access to export-controlled technical data or software.

(c) The contractor shall be responsible for all regulatory record keeping requirements associated with the use of licenses and license exemptions/exceptions.

(d) The contractor shall be responsible for ensuring that the provisions of this clause apply to its subcontractors.

H-2

1852.232-77 LIMITATION OF FUNDS (FIXED-PRICE CONTRACT). (MAR 1989)

(a) Of the total price of contract line-item number 1 (CLIN 001 Flight Instrument), the sum of

$TBD is presently available for payment and allotted to this contract. Of the total price of contract line item number 2 (CLIN 002 Post Delivery Support), the sum of $TBD is presently available for payment and allotted to this contract. It is anticipated that from time-to-time additional funds will be allocated to the contract in accordance with the following schedule, until the total price of said items is allotted:

Funds shall be allotted in accordance with Attachment F - Funding Profile and Attachment M

–Milestone Payment Events, Performance-Based Payment Schedule, and Completion

Criteria.

(b) The Contractor agrees to perform or have performed work on the items specified in paragraph (a) of this clause up to the point at which, if this contract is terminated pursuant to the Termination for

Convenience of the Government clause of this contract, the total amount payable by the

Government (including amounts payable for subcontracts and settlement costs) pursuant to paragraphs (f) and (g) of that clause would, in the exercise of reasonable judgment by the

Contractor, approximate the total amount at the time allotted to the contract. The Contractor is not obligated to continue performance of the work beyond that point. The Government is not obligated in any event to pay or reimburse the Contractor more than the amount from time to time allotted to the contract, anything to the contrary in the Termination for Convenience of the Government clause notwithstanding.

(c) (1) It is contemplated that funds presently allotted to this contract will cover the work to be performed until TBD.

(2) If funds allotted are considered by the Contractor to be inadequate to cover the work to be performed until that date, or an agreed date substituted for it, the Contractor shall notify the

Contracting Officer in writing when within the next 60 days the work will reach a point at which, if the contract is terminated pursuant to the Termination for Convenience of the Government clause of this contract, the total amount payable by the Government (including amounts payable for subcontracts and settlement costs) pursuant to paragraphs (f) and (g) of that clause will approximate 75 percent of the total amount then allotted to the contract.

(3) (i) The notice shall state the estimated date when the point referred to in paragraph (c)(2) of this clause will be reached and the estimated amount of additional funds required to continue performance to the date specified in paragraph (c)(1) of this clause, or an agreed date substituted for it.

H-3

(ii) The Contractor shall, 60 days in advance of the date specified in paragraph (c)(1) of this clause, or an agreed date substituted for it, advise the Contracting Officer in writing as to the estimated amount of additional funds required for the timely performance of the contract for a further period as may be specified in the contract or otherwise agreed to by the parties.

(4) If, after the notification referred to in paragraph (c)(3)(ii) of this clause, additional funds are not allotted by the date specified in paragraph (c)(1) of this clause, or an agreed date substituted for it, the Contracting Officer shall, upon the Contractor's written request, terminate this contract on that date or on the date set forth in the request, whichever is later, pursuant to the Termination for Convenience of the Government clause.

(d) When additional funds are allotted from time to time for continued performance of the work under this contract, the parties shall agree on the applicable period of contract performance to be covered by these funds. The provisions of paragraphs (b) and (c) of this clause shall apply to these additional allotted funds and the substituted date pertaining to them, and the contract shall be modified accordingly.

(e) If, solely by reason of the Government's failure to allot additional funds in amounts sufficient for the timely performance of this contract, the Contractor incurs additional costs or is delayed in the performance of the work under this contract, and if additional funds are allotted, an equitable adjustment shall be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the items to be delivered, or in the time of delivery, or both.

(f) The Government may at any time before termination, and, with the consent of the Contractor, after notice of termination, allot additional funds for this contract.

(g) The provisions of this clause with respect to termination shall in no way be deemed to limit the rights of the Government under the default clause of this contract. The provisions of this Limitation of Funds clause are limited to the work on and allotment of funds for the items set forth in paragraph (a). This clause shall become inoperative upon the allotment of funds for the total price of said work except for rights and obligations then existing under this clause.

(h) Nothing in this clause shall affect the right of the Government to terminate this contract pursuant to the Termination for Convenience of the Government clause of this contract.

H-4

1852.235-74 ADDITIONAL REPORTS OF WORK—RESEARCH AND DEVELOPMENT.

(DEVIATION SEPT 2025)

In addition to the final report required under this contract, the Contractor shall submit the following report(s) to the Contracting Officer:

(a) Monthly progress reports. The Contractor shall submit separate monthly reports of all work accomplished during each month of contract performance. Reports shall be in narrative form, brief, and informal. They shall include a quantitative description of progress, an indication of any current problems that may impede performance, proposed corrective action, and a discussion of the work to be performed during the next monthly reporting period.

(b) Quarterly progress reports. The Contractor shall submit separate quarterly reports of all work accomplished during each three-month period of contract performance. In addition to factual data, these reports should include a separate analysis section interpreting the results obtained, recommending further action, and relating occurrences to the ultimate objectives of the contract.

Sufficient diagrams, sketches, curves, photographs, and drawings should be included to convey the intended meaning.

(c) Submission dates. Monthly and quarterly reports shall be submitted by the 15th day of the month following the month or quarter being reported. If the contract is awarded beyond the middle of a month, the first monthly report shall cover the period from award until the end of the following month. No monthly report need be submitted for the third month of contract effort for which a quarterly report is required. No quarterly report need be submitted for the final three months of contract effort since that period will be covered in the final report. The final report shall be submitted within 30 days after the completion of the effort under the contract.

(End of clause)

GSFC 52.211-100 CONTRACTOR PROPOSED ENHANCEMENTS. (SEP 2013)

The Contractor shall provide the enhancements that are described in Attachment P. These enhancements, which are over and above the requirements required by the contract terms and conditions, Statement of Work and other contract attachments, were proposed by the Contractor in the proposal submitted in response to the Request for Proposal (RFP) 80GSFC26R7004 for X-Ray

Irradiance Sensor (XRIS). The incorporation of these enhancements does not relieve the Contractor from the responsibilities of meeting all other contract terms and conditions and requirements in the

Statement of Work and other contract attachments. The Contractor shall perform these enhancements on all work performed, unless specifically waived by the Contracting Officer in writing.

H-5

GSFC 52.219-90 SMALL BUSINESS SUBCONTRACTING PLAN AND REPORTS. (NOV

2021)

a. Subcontracting Plan (Contractor)

FAR clause 52.219‑9, "Small Business Subcontracting Plan", is included in this contract. The agreed to Subcontracting Plan required by the clause is included as Attachment K to the contract.

b. Subcontracting Plan (Subcontractors)

In accordance with FAR clause 52.219‑9 Small Business Subcontracting Plan, the Contractor must require that certain subcontractors adopt a plan similar to the Plan agreed to between the Contractor and the Government.

c. Individual Subcontract Reports (ISRs)

The Contractor shall prepare and submit their Individual Subcontract Reports (ISRs) (formerly known as the Standard Form 294), in accordance with the instructions listed in the Electronic

Subcontract Reporting System (eSRS), available at http://esrs.gov.

ISRs must be submitted electronically in eSRS on a semi-annual basis. This report must be received no later than April 30 and October 30 each year for the reporting periods ending March

31 and September 30, respectively. Reports are required when due, regardless of whether there has been any subcontracting activity since the inception of the contract or since the last reporting period.

A final ISR must be submitted after contract completion. The final ISR submittal must be received no later than the due date for what would have been the next semi-annual report.

d. Summary Subcontract Reports (SSRs)

The Contractor shall prepare and submit Summary Subcontract Reports (SSRs) (formerly known as the Standard Form 295), in accordance with the instructions listed in the eSRS, available at http://esrs.gov and in accordance with FAR clause 52.219-9 Small Business Subcontracting Plan of this contract.

The SSRs must be submitted electronically in eSRS on an annual basis. This report must be submitted no later than October 30 each year for the twelve month period ending September 30.

e. Subcontractor Reporting

FAR clause 52.219‑9 Small Business Subcontracting Plan requires that the Contractor ensure that

ISR and SSR reports are submitted by those subcontractors that have been required to adopt a

Subcontracting Plan under the terms of the clause. These subcontractor reports must be submitted http://esrs.gov/ http://esrs.gov/

H-6 as required by paragraphs (c) and (d) above. The reports may be submitted through the Contractor or submitted directly. Regardless, the Contractor is responsible for ensuring proper and timely submittal of the required reports.

(End of clause)

GSFC 52.223-91 SAFETY AND HEALTH ADDITIONAL REQUIREMENTS. (NOV 2019)

In addition to compliance with all Federal, state, and local laws as required by paragraph (b) of

NFS clause 1852.223-70, the Contractor shall comply with the following:

(a) Incident Reporting: The immediate notification and prompt reporting requirement included in paragraph (d) of NFS clause 1852.223-70 shall be to Goddard Space Flight Center Safety Division, Code 360, Telephone 301-356-3224 and to the Contracting Officer (CO). This verbal notification should be confirmed in writing via E-Mail to the CO and GSFC-OccSafetyOffice@mail.nasa.gov and entered into the NASA Mishap Information System (NMIS) within 24 hours. This notification is also required for any unsafe or environmentally hazardous condition associated with

Government-owned property that is provided or made available for the performance of the contract.

(b) Submit a monthly safety and health report using NMIS. Specify incidents (mishaps and close calls) and man-hours worked/month. Access to NMIS must be requested through the NASA Access

Management System (NAMS) within 30 days of the contract effective date at https://idmax.nasa.gov. Until access is approved, use the Contractor Monthly Statistics Report

Template available at http://safety1st.gsfc.nasa.gov under Contractor Safety and e-mail the completed form to Christopher Quinn (christopher.d.quinn@nasa.gov).

(End of clause)

GSFC 52.227-93 APPLICABILITY OF RIGHTS IN DATA - SPECIAL WORKS. (MAR

2008)

The "Rights in Data - Special Works" clause of this contract applies to the following aspects (or items):

Any data requested by the Government for any legitimate government use.

https://idmax.nasa.gov/ http://safety1st.gsfc.nasa.gov/ mailto:christopher.d.quinn@nasa.gov

H-7

GSFC 52.227-99 RIGHTS IN DATA. (NOV 2018)

The default Data Rights clause under this contract is FAR 52.227-14 RIGHTS IN DATA-

GENERAL—Alternate II and Alternate III as modified by NASA FAR Supplement 1852.227-14 and GSFC 52.227-90. Any exceptions to this clause will be covered by FAR 52.227-17 RIGHTS

IN DATA--SPECIAL WORKS, if applicable, and GSFC 52.227-93.

(End of clause)

LAUNCH DELAYS.

The delivery schedule and/or period of performance of this contract is based upon a spacecraft launch date of October 2032. In the event of a Government-directed delay of the launch date, the

Contracting Officer may inform the Contractor, in writing or by exercising the Pre-Priced Change

Option as priced out in Section B. If the Government does not exercise a Pre-Priced Change Option and utilizes the authority of this clause, the Government will allow the Contractor to submit a proposal for the effect of this delay on the cost, delivery schedule, or other terms of the contract.

This may result in an equitable adjustment to the estimated cost, fee(s), if any, and delivery schedule or period of performance. Failure to agree to an adjustment shall be considered as a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as extended. In the event of a launch delay the Government reserves the right to exercise a launch delay option as stated in GSFC 52.217-91 Option for

Increased Quantity clause in Section B, the authority of this clause, or a combination of both during contract performance.

(End of text)

PERFORMANCE-BASED PAYMENT EVENTS AND COMPLETION CRITERIA.

In accordance with Section I clause 52.232-32 PERFORMANCE BASED PAYMENTS, upon successful completion of an event, the contractor may request performance-based payments. The performance-based payments shall be based on the major events and the interim events identified in Section J, Attachment M - Milestone Payment Events, Performance-Based Payment Schedule, and Completion Criteria. The percentages are based on the total value of the firm-fixed price contract (CLIN 001 and CLIN 002). The total percentage of payments for all events, both interim and major, shall not exceed 90%.

The Contracting Officer and Contracting Officer’s Representative shall unilaterally determine the

Contractor’s completion of each event. The determination of event completion will include, but is

H-8 not limited to, the completion criteria described in Attachment A - Statement of Work, Attachment

C – Contract Deliverable Requirements List, and the applicable completion criteria listed in

Section J, Attachment M - Milestone Payment Events, Performance-Based Payment Schedule, and

Completion Criteria. Completion of each milestone shall require that the Contractor continue to comply with the terms of the contract, including the Statement of Work. Determination of event completion and payment shall not be considered acceptance of work completed and shall not relieve the Contractor of responsibility for performance under the terms and conditions of this contract. Generally, payment events shall be paid in succession. All preceding payment events shall be successfully completed before payment will be made for the next payment event, unless the prior written consent of the Contracting Officer is obtained.

Special Studies (CLIN 003) are Time & Materials and are not included in Attachment M. Special

Studies will be invoiced separately and paid in accordance with Clause GSFC 52.216-95 - Hourly

Rates and Contract Ceiling Price.

(End of text)

[END OF SECTION H]

PART II – CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I-1

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1):

52.202-1 DEFINITIONS. (JUN 2020)

52.203-3 GRATUITIES. (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES. (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT.

(JUN 2020) ALTERNATE I (NOV 2021)

52.203-7 ANTI-KICKBACK PROCEDURES. (JUN 2020)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR

ILLEGAL OR IMPROPER ACTIVITY. (MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY.

(MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS. (JUN 2020)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT. (NOV 2021)

52.203-14 DISPLAY OF HOTLINE POSTER(S). (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS. (NOV 2023)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL

CONFIDENTIALITY AGREEMENTS OR STATEMENTS. (JAN 2017)

I-2

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER

SUBCONTRACT AWARDS. (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE. (OCT 2018)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS. (DEC 2014)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN

SUBCONTRACTING WITH CONTRACTORS DEBARRED, SUSPENDED, PROPOSED

FOR DEBARMENT, OR VOLUNTARILY EXCLUDED. (JAN 2025)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING

RESPONSIBILITY MATTERS. (OCT 2018)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS. (NOV 2015)

52.210-1 MARKET RESEARCH. (NOV 2021)

52.211-5 MATERIAL REQUIREMENTS. (AUG 2000)

52.211-15 DEFENSE PRIORITY AND ALLOCATION REQUIREMENTS. (APR 2008)

52.215-2 AUDIT AND RECORDS - NEGOTIATION. (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT. (OCT 1997)

52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING

DATA. (AUG 2011)

52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING

DATA - MODIFICATIONS. (JUN 2020)

52.215-12 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA. (JUN 2020)

I-3

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA -

MODIFICATIONS. (JUN 2020)

52.215-14 INTEGRITY OF UNIT PRICES. (NOV 2021)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS. (OCT 2010)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT

BENEFITS (PRB) OTHER THAN PENSIONS. (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES. (OCT 1997)

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA

OTHER THAN CERTIFIED COST OR PRICING DATA - MODIFICATIONS. (NOV

2021) ALTERNATE III (OCT 1997)

52.216-7 ALLOWABLE COST AND PAYMENT

52.217-2 CANCELLATION UNDER MULTIYEAR CONTRACTS. (OCT 1997)

52.217-8 OPTION TO EXTEND SERVICES. (NOV 1999)

[30 calendar days]

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS. (JAN 2025)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN. (JAN 2025)

52.219-16 LIQUIDATED DAMAGES - SUBCONTRACTING PLAN. (SEP 2021)

(DEVIATION)

52.219-28 POSTAWARD SMALL BUSINESS PROGRAM REREPRESENTATION. (JAN

2025) ALTERNATE I (MAR 2020)

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES. (FEB 1997)

I-4

52.222-3 CONVICT LABOR. (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS - OVERTIME

COMPENSATION. (MAY 2018)

52.222-19 CHILD LABOR—COOPERATION WITH AUTHORITIES AND REMEDIES.

(JAN 2025)

52.222-20 CONTRACTS FOR MATERIALS, SUPPLIES, ARTICLES, AND

EQUIPMENT. (JUN 2020)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS. (JUN 2020)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES. (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS. (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR

RELATIONS ACT. (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS. (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION. (JAN 2025)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY

DATA. (FEB 2021) ALTERNATE I (JUL 1995)

52.225-1 BUY AMERICAN - SUPPLIES. (OCT 2022)

52.225-8 DUTY-FREE ENTRY. (OCT 2010)

52.226-7 DRUG-FREE WORKPLACE. (MAY 2024)

I-5

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING

WHILE DRIVING. (MAY 2024)

52.227-1 AUTHORIZATION AND CONSENT. (JUN 2020) ALTERNATE I (APR 1984)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT

INFRINGEMENT. (JUN 2020)

52.227-11 PATENT RIGHTS - OWNERSHIP BY THE CONTRACTOR. (MAY 2014)

52.227-14 RIGHTS IN DATA - GENERAL. (MAY 2014)

52.227-17 RIGHTS IN DATA - SPECIAL WORKS. (DEC 2007)

52.227-21 TECHNICAL DATA DECLARATION, REVISION, AND WITHHOLDING OF

PAYMENT - MAJOR SYSTEMS. (MAY 2014)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES. (FEB 2013)

52.232-1 PAYMENTS. (APR 1984)

52.232-2 PAYMENTS UNDER FIXED-PRICE RESEARCH AND DEVELOPMENT

CONTRACTS. (APR 1984)

52.232-7 PAYMENTS UNDER TIME-AND-MATERIALS AND LABOR-HOUR

CONTRACTS. (NOV 2021)

52.232-8 DISCOUNTS FOR PROMPT PAYMENT. (FEB 2002)

52.232-9 LIMITATION ON WITHHOLDING OF PAYMENTS. (APR 1984)

52.232-11 EXTRAS. (APR 1984)

52.232-17 INTEREST. (MAY 2014)

I-6

52.232-18 AVAILABILITY OF FUNDS. (APR 1984)

52.232-23 ASSIGNMENT OF CLAIMS. (MAY 2014)

52.232-25 PROMPT PAYMENT. (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER - SYSTEM FOR AWARD

MANAGEMENT. (OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS. (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS. (MAR 2023)

52.233-1 DISPUTES. (MAY 2014)

52.233-3 PROTEST AFTER AWARD. (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM. (OCT 2004)

52.242-5 PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS. (JAN 2017)

52.242-13 BANKRUPTCY. (JUL 1995)

52.243-1 CHANGES - FIXED-PRICE. (AUG 1987) ALTERNATE II (APR 1984)

ALTERNATE V (APR 1984)

52.243-3 CHANGES - TIME-AND-MATERIALS OR LABOR-HOURS. (SEP 2000)

52.243-6 CHANGE ORDER ACCOUNTING. (APR 1984)

I-7

52.243-7 NOTIFICATION OF CHANGES. (JAN 2017)

[Paragraph (b): within 10 calendar days]

[Paragraph (d): within 14 calendar days]

52.244-2 SUBCONTRACTS. (JUN 2020)

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES. (FEB 2025) (DEVIATION)

52.245-1 GOVERNMENT PROPERTY. (SEP 2021)

52.245-9 USE AND CHARGES. (APR 2012)

52.246-23 LIMITATION OF LIABILITY. (FEB 1997)

52.246-26 REPORTING NONCONFORMING ITEMS. (AUG 2024)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-

PRICE). (APR 2012)

52.249-8 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE). (APR 1984)

52.249-9 DEFAULT (FIXED-PRICE RESEARCH AND DEVELOPMENT). (APR 1984)

52.253-1 COMPUTER GENERATED FORMS. (JAN 1991)

NASA FAR SUPPLEMENT (48 CFR CHAPTER 18) CLAUSES:

1852.203-70 DISPLAY OF INSPECTOR GENERAL HOTLINE POSTERS. (DEVIATION)

(SEP 2025)

I-8

1852.203-71 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER

RIGHTS.…