* - A complete Defense Logistics Agency project number will be provided after award.

REQUEST FOR PROPOSAL (RFP)

DIVISION 01 SPECIFICATIONS

Design-Build Scope of Work

Solicitation No. W9128F-27-R-A045

Fueling System Repairs Project No.*

Mather AASF, California

October 2026

This page was intentionally left blank for duplex printing.

00 01 00 - 1 PROJECT TABLE OF CONTENTS

SPECIFICATIONS FOR DESIGN AND CONSTRUCTION

OF

FUELING SYSTEM REPAIRS AT

MATHER ARMY AVIATION SUPPORT FACILITY (AASF), CALIFORNIA

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PROJSIGN PROJECT SIGN DETAILS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

REGISTER SUBMITTAL REGISTER

01 33 00.32 DESIGN AND CONSTRUCTION DELIVERABLES/PROCEDURES

Attachment A DESIGN CERTIFICATION AND TRANSMITTAL LETTER Attachment B SUPPLEMENTAL DESIGN CERTIFICATION AND TRANSMITTAL FORM Attachment C SUBMITTAL PARAGRAPH REQUIREMENTS Attachment D TECHNICAL SCOPE OF WORK Attachment E RFP DRAWINGS (provided under separate cover) Attachment F POINTS OF CONTACT INFORMATION (provided after contract award) Attachment G DEFENSE LOGISTICS AGENCY (DLA) MEMORANDUM

01 33 29 SUSTAINABILITY REPORTING

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00 QUALITY CONTROL

01 45 00.15 10 RESIDENTIAL MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 36.00 24 WARRANTY OF CONSTRUCTION AND DESIGN

01 78 39.00 24 AS-BUILT DRAWINGS

01 78 39.00 24AT MODIFICATIONS AND TITLE BLOCK EXAMPLES

-- End of Project Table of Contents --

Fueling System Repairs - Mather AASF, California MTCA00100

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

02/25

PART 1 GENERAL

1.1 REFERENCES

1.2 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.3 DESIGN-BUILD CONSTRUCTION CONTRACTS (MAR 2019)

1.4 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.5 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.6 SEQUENCE OF DESIGN CONSTRUCTION

1.7 CONTRACTOR PERFORMANCE EVALUATIONS

1.8 REQUEST FOR PROPOSAL (RFP) DRAWINGS

1.9 SUBMITTALS

1.10 CONCURRENT CONSTRUCTION

1.11 PAYMENT

1.11.1 PROMPT PAYMENT ACT

1.11.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.12 AVAILABILITY OF UTILITY SERVICES

1.12.1 Utility Meters (for temporary connections)

1.12.2 Backflow Preventers

1.12.2.1 Backflow Tester Certificate

1.12.2.2 Backflow Prevention Training Certificate

1.12.2.3 Backflow Preventers Certificate

1.12.2.4 Reduced Pressure Backflow Preventers

1.13 UTILITY SERVICE INTERRUPTIONS

1.14 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.15 VIEW LOCATION MAP

1.16 INSURANCE REQUIRED

1.17 SUPERVISION

1.17.1 Superintendent Qualifications

1.17.2 Minimum Communication Requirements

1.17.3 Duties

1.17.4 Non-Compliance Actions

1.18 PRECONSTRUCTION CONFERENCE

1.18.1 Attendees

1.19 FACILITY TURNOVER PLANNING MEETINGS (Red Zone Meetings)

1.19.1 Red Zone Checklist

1.19.2 Meetings

1.20 SECURITY REQUIREMENTS

1.20.1 Contractor's Employee Identification

1.20.2 Activity Regulations

1.20.2.1 Subcontractors and Personnel Contacts

1.20.2.2 No Smoking Policy

1.21 CONTRACTOR QUALITY CONTROL (CQC)

1.22 NONDOMESTIC CONSTRUCTION MATERIALS

SECTION 01 30 00.24 Page 1

1.23 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.24 AS-BUILT DRAWINGS

1.25 SIGN

1.26 ACCOMMODATIONS FOR GOVERNMENT INSPECTORS

1.27 PARTNERING

1.27.1 Team-Led (Informal) Partnering

1.28 PROFIT

1.29 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.30 DRAWING SCALES

1.31 FEDERAL HOLIDAYS

1.32 BASE HOURS

1.33 CYBERSECURITY DURING CONSTRUCTION

1.33.1 Contractor Computer Equipment

1.33.1.1 Operating System

1.33.1.2 Anti-Malware Software

1.33.1.3 Passwords and Passphrases

1.33.1.4 Contractor Computer Cybersecurity Compliance Statements

1.33.2 Temporary IP Networks

1.33.2.1 Network Boundaries and Connections

1.33.3 Government Access to Network

1.33.4 Temporary Wireless IP Networks

1.33.4.1 Contractor Provided Wi-Fi Network

1.33.4.2 Temporary Wireless IP Networks Security

1.33.5 Passwords and Passphrases

1.33.6 Contractor Temporary Network Cybersecurity Compliance

Statements

1.34 ARMY AND ARMY NATIONAL GUARD REQUIREMENTS AND RESTRICTIONS

1.34.1 3Rs Explosive Safety Education Training Certificate

1.35 Additional Information and Requirements

1.35.1 Stakeholders Closeout Report Documents

PART 2 NOT USED

PART 3 NOT USED

ATTACHMENTS:

Project Sign Details

-- End of Section Table of Contents --

SECTION 01 30 00.24 Page 2

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

02/25

PART 1 GENERAL

Attachments:

Project Sign Details

1.1 REFERENCES

The publications listed below form a part of this section to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN WATER WORKS ASSOCIATION (AWWA)

AWWA C511 (2017; R 2021) Reduced-Pressure Principle Backflow Prevention Assembly

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety -- Safety and Occupational Health (SOH) Requirements

1.2 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.usace.army.mil/Cost-Engineering/EP1110-1-8/ .

1.3 DESIGN-BUILD CONSTRUCTION CONTRACTS (MAR 2019)

(a) Design-Build Contract Order of Precedence. The contract includes the standard contract clauses and schedules current at the time of contract award. It entails (1) the Solicitation in its entirety, including all drawings, cuts, and illustrations, and any amendments, and (2) the successful offeror’s accepted proposal. The contract constitutes and defines the entire agreement between the Contractor and the Government. No documentation shall be omitted which in any way bears upon the terms of that agreement.

(1) In the event of conflict or inconsistency between any portion of this contract, precedence shall be given in the following order:

i.Betterments: Any portions of the accepted proposal which both conform to and exceed the requirements of the Solicitation.

ii.The requirements of the Solicitation. (See also FAR 52.236-21, Specifications and Drawings for Construction)

SECTION 01 30 00.24 Page 3 iii.All other elements of the accepted proposal.

iv.Any design products including, but not limited to, plans, specifications, engineering studies and analyses, shop drawings, equipment installation drawings, etc. These are "deliverables" under the contract and are not part of the contract itself. Design products must conform to all provisions of the contract, in the order of precedence herein.

(b) Personnel, subcontractors, and outside associates or consultants. In connection with this contract, any in-house personnel, subcontractors, and outside associates or consultants will be limited to individuals or firms that were specifically identified in the Contractor's accepted proposal. The Contractor shall obtain the Contracting Officer's written consent before making any substitution for these designated in-house personnel, subcontractors, associates, or consultants. If the Contractor proposes a substitution, it shall submit the same type of information that was submitted in the accepted proposal to the Contracting Officer for evaluation and approval. The level of qualifications and experience submitted in the accepted proposal or that required by the Solicitation, whichever is greater, is the minimum standard for any substitution.

(c) Responsibility of the Contractor for Design. The Contractor shall be responsible for the professional quality, technical accuracy, and the coordination of all designs, drawings, specifications, and other non-construction services furnished by the Contractor under this contract.

The Contractor shall, without additional compensation, correct or revise any errors or deficiency in its designs, drawings, specifications, and other non-construction services and perform any necessary rework or modifications, including any damage to real or personal property, resulting from the design error or omission.

(1) The standard of care for all design services performed under this agreement shall be the care and skill ordinarily used by members of the architectural or engineering professions practicing under similar conditions at the same time and locality. Notwithstanding the above, in the event that the contract specifies that portions of the Work be performed in accordance with a performance standard, the design services shall be performed so as to achieve such standards.

(2) Neither the Government's review, approval or acceptance of, nor payment for, the services required under this contract, shall be construed to operate as a waiver of any rights under this contract or of any cause of action arising out of the performance of this contract. The Contractor shall be and remain liable to the Government in accordance with applicable law for all damages to the Government caused by the Contractor's negligent performance of any of these services furnished under this contract.

(3) The rights and remedies of the Government provided for under this contract are in addition to any other rights and remedies provided by law.

(4) If the Contractor is comprised of more than one legal entity, each entity shall be jointly and severally liable hereunder.

(d) Contractor's Role during the Design Process. The Contractor's construction management key personnel shall be actively involved during

SECTION 01 30 00.24 Page 4 the design process to effectively integrate the design and construction requirements of this contract. In addition to the typical required construction activities, the Contractor's involvement includes, but is not limited to actions such as: integrating the design schedule into the Master Schedule to maximize the effectiveness of fast-tracking design and construction (within the limits allowed in the contract), ensuring constructability and economy of the design, integrating the shop drawing and installation drawing process into the design, executing the material and equipment acquisition programs to meet critical schedules, effectively interfacing the design and construction quality control (QC) management programs with the design QC program, and maintaining and providing the design team with accurate, up-to-date redline and as-built documentation for eventual submission as Record Drawings.. The Contractor shall require and manage the active involvement of key trade subcontractors in the above activities.

(e) Deviating from the Accepted Design. The Contractor must obtain the approval of the Designer of Record and the Government's concurrence, in the form of supplemental agreement to the contract, for any Contractor-proposed revision to the professionally stamped-and-sealed and Government-reviewed final design that has been released for Construction before proceeding with the revision. The Government reserves the right to disapprove such a revision.

(1) The Government reserves the right to non-concur with any revision to the final design that has been released for construction, including those which may impact furniture, furnishings, equipment selections or operations decisions that were made, based on the reviewed design.

(2) Any Contractor-proposed revision to the design which deviates from the contract requirements (i.e., the Request for Proposal (RFP) and the accepted proposal), will require a bilateral modification (e.g. supplemental agreement) to the contract before any work commences.

(3) Unless the Government initiates a change to the contract requirements, or the Government determines that the Government furnished design criteria are incorrect and must be revised, any Contractor initiated proposed change to the contract requirements, which results in additional cost, shall strictly be at the Contractor's expense.

(4) The Contractor shall track all approved revisions to the reviewed and accepted design and shall incorporate them into the as-built design documentation, in accordance with agreed procedures. The Designer of Record shall document its professional concurrence on the as-builts for any revisions in the stamped and sealed drawings and specifications.

(f) Value Engineering after Award. In reference to Federal Acquisition Regulation (FAR) 52.248-3, Value Engineering - Construction, the Government may refuse to entertain a "Value Engineering Change Proposal" (VECP) for those "performance oriented" aspects of the Solicitation documents which were addressed in the Contractor's accepted contract proposal and which were evaluated in competition with other offerors for award of this contract.

(1) The Government may consider a VECP for those "prescriptive" aspects of the Solicitation documents, not addressed in the Contractor's accepted contract proposal or addressed but evaluated only

SECTION 01 30 00.24 Page 5 for minimum conformance with the Solicitation requirements.

(2) For purposes of this clause, the term "performance oriented" refers to those aspects of the design criteria or other contract requirements, which allow the offeror or Contractor certain latitude, choice of and flexibility to propose in its accepted proposal a choice of design, technical approach, design solution, construction approach or other approach to fulfill the contract requirements. Such requirements generally tend to be expressed in terms of functions to be performed, performance required or essential physical characteristics, without dictating a specific process or specific design solution for achieving the desired result.

(3) In contrast, for purposes of this clause, the term "prescriptive" refers to those aspects of the design criteria or other Solicitation requirements wherein the Government expressed the design solution or other requirements in terms of specific material, approaches, systems, and/or processes to be used. Prescriptive aspects typically allow the offerors little or no freedom in the choice of design approach, materials, fabrication techniques, methods of installation, or any other approach to fulfill the contract requirements.

(g) Warranty of Design. The Contractor warrants that the design shall be performed in accordance with the contract requirements. Design and design related construction not conforming to the Contract requirements shall be corrected at no additional cost to the Government.

The standard of care for design is defined in paragraph c of this clause, Responsibility of the Contractor for Design.

(1) The period of this warranty shall commence upon final completion and the Government's acceptance of the work, or in the case of the Government's beneficial occupancy of all or part of the work for its convenience, prior to final completion and acceptance, at the time of such occupancy.

(2) This design warranty shall be effective from the above event through the Statute of Limitations and Statute of Repose or host nation law, as applicable to the place of construction performance.

(3) The rights and remedies of the Government provided for under this clause are in addition to any other rights and remedies provided in this contract or by law.

(h) Government Re-Use of Design. In conjunction with the Defense Federal Acquisition Regulation Supplement (DFARS) 252.227-7022, Government Rights (Unlimited), the Government will not ask for additional originals or copies of the design works after the Contractor provides all required design documentation and record drawing documentation under the instant contract. Further, if the Government uses the design for other projects without additional compensation to the Contractor for re-use, the Government releases the Contractor from liability in the design on the other projects, due to defects in the design that are not the result of fraud, gross mistake as amounts to fraud, gross negligence or intentional misrepresentation.

(End of clause)

SECTION 01 30 00.24 Page 6

1.4 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a.Use a commercially available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. Use an electronic payroll service capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. Provide this durable record copy of data from the electronic payroll processing system to the Government during contract closeout.

d. Include all Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service in the Contractor's price for the overall work under the contract. Do not include the costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services as a separately bid or reimbursed item under this contract.

SECTION 01 30 00.24 Page 7

1.5 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.6 SEQUENCE OF DESIGN CONSTRUCTION

(a) After receipt of the Contract Notice to Proceed (NTP), the Contractor must initiate design, comply with all design submission requirements as covered in Division 01 General Requirements of the advertised Solicitation, and obtain Government review of each submission. No construction may be started until the Government reviews the 100 Percent Corrected Design submission and determines it satisfactory for purposes of beginning construction. The Government will not grant any time extension for any design resubmittal required when, in the opinion of the Contracting Officer, the initial submission failed to meet the minimum quality requirements as set forth in the Contract.

(b) If the Government allows the Contractor to proceed with limited construction based on pending minor revisions to the reviewed 100 Percent Corrected Design submission, no payment will be made for any in-place construction related to the pending revisions until they are completed, resubmitted and are satisfactory to the Government. Proceeding with limited construction requires written authorization by the Contracting Officer.

1.7 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased

SECTION 01 30 00.24 Page 8 from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.8 REQUEST FOR PROPOSAL (RFP) DRAWINGS

Fourteen (14) calendar days after Notice to Proceed, the Government will provide the successful Contractor an electronic copy containing editable RFP CAD file drawings (file format and general CAD requirements are defined in sections 01 33 00.32 DESIGN AND CONSTRUCTION DELIVERABLES/PROCEDURES and 01 78 39.00 24 AS-BUILT DRAWINGS) for use in preparation of design drawing deliverables. As-built drawing requirements are specified in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Contractor Computer Cybersecurity Compliance Statements ; G, RO

Contractor Temporary Network Cybersecurity Compliance Statements ;

G, RO

List Of Contact Personnel

VIEW LOCATION MAP

PROGRESS AND COMPLETION PICTURES

SD-03 Product Data

Backflow Preventers ; G, RO

SD-06 Test Reports

Backflow Preventer Tests

SD-07 Certificates

Backflow Tester Certification

Backflow Preventers Certificate of Full Approval

3Rs Explosive Safety Education Training Certificate (annual submission required)

1.10 CONCURRENT CONSTRUCTION

Construction work closely related to and/or located at the site of the

SECTION 01 30 00.24 Page 9 work under a concurrent contract may be in progress simultaneously with work under this contract. Cooperate with others as necessary in the interest of timely completion of all work. In the event of interference, notify the Contracting Officer immediately for final resolution.

1.11 PAYMENT

1.11.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.11.2 PAYMENT FOR MATERIALS STORED OFFSITE

a. As allowed under (FAR) 52.232-5 "Payments Under Fixed Price Construction Contracts", the Administrative Contracting Officer, at their discretion, may authorize progress payments for any material stored off-site provided:

(1) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract,

(2) Material is stored in such a manner to protect it from damage, fire, theft, etc .

(3) The Contractor provides evidence of insurance for material, and,

(4) Material is clearly identified and delineated by contract number for use on the applicable project.

b. The Administrative Contracting Officer reserves the right to inspect any off-site material prior to authorizing progress payments. Provide paid invoices listing the value of material and labor incorporated in the items.

1.12 AVAILABILITY OF UTILITY SERVICES

The Government will make available all reasonably required amounts of domestic water and electricity used for construction of this project and to make final tests of the completely installed items to the Contractor from existing system outlets and supplies without charge. Limit use of utilities to what is needed to perform work. The Government will not allow the charging of electric vehicles owned or operated by the Contractor or subcontractors at Government charging stations. The Contractor is responsible to, at their own expense, make all temporary connections and install distribution lines. Furnish to the Contracting Officer a complete system layout drawing showing type of materials to be used and method of installation for all temporary connections. Maintain all temporary lines in a workmanlike manner satisfactory to the Contracting Officer and remove in like manner prior to final acceptance of the construction. The Government will furnish normal quantities of

SECTION 01 30 00.24 Page 10 electricity and water needed to make final tests of completely installed systems.

1.12.1 Utility Meters (for temporary connections)

Equip all connections with appropriate utility meters complying with associated utility meter requirements defined in this Contract. Furnish and install approved metered reduced pressure backflow prevention assemblies on all connections to domestic water lines in a manner that does not contaminate or impact operation of base-wide water supply as specified below. Provide access to and readings for utility usage to the Government for accountability and recordkeeping. Meters on temporary connections will remain the property of the Contractor after disconnection.

1.12.2 Backflow Preventers

1.12.2.1 Backflow Tester Certificate

Prior to testing, submit to the Contracting Officer certification issued by the State or local regulatory agency attesting that the backflow tester has successfully completed a certification course sponsored by the regulatory agency. Tester must not be affiliated with a company participating in other phases of this Contract.

1.12.2.2 Backflow Prevention Training Certificate

Submit a certificate recognized by the State or local authority that states the Contractor has completed at least 10 hours of training in backflow preventer installations. The certificate must be current.

1.12.2.3 Backflow Preventers Certificate

Certificate of Full Approval from FCCCHR List, University of Southern California, attesting that the design, size and make of each backflow preventer has satisfactorily passed the complete sequence of performance testing and evaluation for the respective level of approval. Certificate of Provisional Approval is not acceptable.

Reduced pressure principle type conforming to the applicable requirements

AWWA C511.

1.12.2.4 Reduced Pressure Backflow Preventers

Perform backflow preventer tests using test equipment, procedures, and certification forms conforming to those outlined in the latest edition of the Manual of Cross-Connection Control published by the FCCCHR Manual.

Test and tag each reduced pressure backflow preventer upon initial installation (prior to continued water use) and quarterly thereafter. Tag must contain the following information: make, model, serial number, dates of tests, results, maintenance performed, and signature of tester.

Record test results on certification forms conforming to requirements cited earlier in this paragraph.

1.13 UTILITY SERVICE INTERRUPTIONS

Coordinate with appropriate POC (whose information will be provided after award).

SECTION 01 30 00.24 Page 11

1.14 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with FAR 52.249-10 "Default: (Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather-dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN - 7

FEB - 6

MAR - 8

APR - 4

MAY - 2

JUN - 1

JUL - 0

AUG - 0

SEP - 1

OCT - 3

NOV - 6

DEC - 7

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in

SECTION 01 30 00.24 Page 12 accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.15 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.16 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.17 SUPERVISION

1.17.1 Superintendent Qualifications

Provide project superintendent with a minimum of 8 years' experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

1.17.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract work. In addition, if a Quality Control (QC) representative is required on the Contract, then that individual must also have fluent English communication skills.

1.17.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent is required to attend Red Zone meetings, partnering meetings, and quality control meetings. The

SECTION 01 30 00.24 Page 13 superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.17.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time or excess costs or damages by the Contractor.

1.18 PRECONSTRUCTION CONFERENCE

Upon completion of design and design acceptance by the government, prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Conference . The purpose of this conference is to discuss and develop a mutual understanding of the administrative requirements of the Contract including but not limited to: daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, quality control, schedule of prices or earned value report, shop drawings, submittals, cybersecurity, prosecution of the work, government acceptance, final inspections and contract close-out. Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.18.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), Quality Control Manager and major subcontractors.

1.19 FACILITY TURNOVER PLANNING MEETINGS (Red Zone Meetings)

Meet with the Government to identify strategies to ensure the project is carried to expeditious closure and turnover to the Client. Start planning the turnover process at the Pre-Construction Conference meeting with a discussion of the Red Zone process and convene at regularly scheduled Red Zone Meetings beginning at approximately 75 percent of project completion. Include the following in the facility Turnover effort:

1.19.1 Red Zone Checklist

a. Contracting Officer's Technical Representative (COTR) will provide the Contractor a copy of the Red Zone Checklist template.

b. Prior to 75 percent completion, modify the Red Zone Checklist template by adding or deleting critical activities applicable to the project and assign planned completion dates for each activity. Submit the modified Red Zone Checklist to the Contracting Officer. The Contracting Officer may request additional activities be added to the Red Zone Checklist at any time as necessary.

SECTION 01 30 00.24 Page 14

1.19.2 Meetings

a. Conduct regular Red Zone Meetings beginning at approximately 75 percent project completion, or three to six months prior to Beneficial Occupancy Date (BOD), whichever comes first.

b. The Contracting Officer will establish the frequency of the meetings, which is expected to increase as the project completion draws nearer.

At the beginning, Red Zone meetings may be every two weeks then increase to weekly towards the final month of the project.

c. Using the Red Zone Checklist as a Plan of Action and Milestones (POAM) and basis for discussion, review upcoming critical activities and strategies to ensure work is completed on time.

d. During the Red Zone Meetings discuss with the COTR any upcoming activities that require Government involvement.

e. Maintain the Red Zone Checklist by documenting the actual completion dates as work is completed and update the Red Zone Checklist with revised planned completion dates as necessary to match progress.

Distribute copies of the current Red Zone Checklist to attendees at each Red Zone Meeting.

1.20 SECURITY REQUIREMENTS

1.20.1 Contractor's Employee Identification

The Contractor is responsible for furnishing to each employee and for requiring each employee engaged on the work to display such identification as may be approved and directed by the Contracting Officer. Upon release of any employees, deliver all prescribed identification immediately to the Contracting Officer for cancellation. When the contract involves work in restricted security areas, only employees who are U.S. citizens will be permitted to enter. Proof of U.S. citizenship is required prior to entry. When required by the Contracting Officer, obtain and submit fingerprints of all persons employed or to be employed on the project.

(Based on FAR 52.204-2)

1.20.2 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

1.20.2.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.20.2.2 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, SECTION 01 30 00.24 Page 15 except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.21 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00 QUALITY CONTROL.

1.22 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

1.23 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service. Submit written agenda/meeting minutes and proposed daily work schedule for the next two-week period for coordination and approval. Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFI's) and any other information that is needed in the minutes of the meeting. Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, also submit a schedule of proposed dates and times of all preparatory inspections to be performed during the next two weeks. Develop all schedules in accordance with Section 01 32 01.00 10 PROJECT SCHEDULE .

Accomplish coordination action by the Contracting Officer relative to these schedules during these weekly meetings. Complete and give daily reports to the Contracting Officer or Representative within 24 hours of work. Provide all official correspondence such as serial letters and RFI's, with attachments in one hardcopy original with original signatures and one electronic (Adobe pdf format) copy by email. The Government will consider the correspondence to be received when the official hardcopy or electronic copy is received by the designated office.

1.24 AS-BUILT DRAWINGS

See SECTION 01 78 39.00 24 - AS-BUILT DRAWINGS

1.25 SIGN

On commencement of work on this project, furnish and erect the temporary sign in the location selected by the Contracting Officer near the project site. Maintain the sign in good condition through the project construction period. Upon completion of the project remove the sign from the premises. Ensure the project sign conforms to standard drawing attached to this section. The Government will furnish a decal of the "Engineer Castle" to the Contractor upon request.

1.26 ACCOMMODATIONS FOR GOVERNMENT INSPECTORS

Provide adequate area for government inspectors within the Contractor provided job trailer to review plans, specifications, submittals, etc., when inspectors are onsite.

SECTION 01 30 00.24 Page 16

1.27 PARTNERING

To most effectively accomplish this Contract, the Contractor and Government must form a cohesive partnership with the common goal of drawing on the strength of each organization in an effort to achieve a successful project without safety mishaps, conforming to the Contract, within budget and on schedule. The partnering team must consist of personnel from both the Government and Contractor including project level and corporate level leadership positions. Key Personnel from the supported command, end user, Contractor, key subcontractors and the Designer of Record (DOR) (regardless of whether the contract is a design-build or a design-bid-build) are required to participate in the Partnering process.

1.27.1 Team-Led (Informal) Partnering

a. The Contracting Officer will coordinate the initial Team-Led (Informal) Partnering Session with key personnel of the project team, including Contractor and Government personnel. The Partnering Session will be co-led by the Government Construction Manager and Contractor's Project Manager.

b. The Initial Team-led Partnering session may be held concurrently with the meeting. Partnering sessions will be held at a location mutually agreed to by the Contracting Officer and the Contractor, typically at a conference room on-base or at the Contractor's temporary trailer.

c. The Initial Team-Led Partnering Session will be conducted and facilitated using electronic media (a video and accompanying forms) provided by Contracting Officer.

d. The Partners will determine the frequency of the follow-on sessions.

e. Participants will bear their own costs for meals, lodging and transportation associated with Partnering.

1.28 PROFIT

a. Use the alternate structured approach weighted guidelines method of determining profit on any equitable adjustment change order or modification issued under this contract. The profit factors are as follows:

Factor Rate Weight Value Degree of Risk 20 See Item Relative difficulty of work 15 b. below Size of Job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

b. Based on the circumstances of each procurement action, weight each of the above factors from 0.03 to 0.12 as indicated below. Obtain the value by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

SECTION 01 30 00.24 Page 17

(1) Degree of Risk. Where the work involves no risk or the degree of risk is very small, the weighting should be 0.03; as the degree of risk increases, the weighting should be increased up to a maximum of 0.12.

Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider:

the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work. A weight of 0.03 is appropriate for after the fact equitable adjustments and/or settlements.

(2) Relative Difficulty of Work. If the work is difficult and complex, the weighting should be 0.12 and should be proportionately reduced to 0.03 on the simplest of jobs. This factor is tied, to some extent, to the degree of risk. Some things to consider: the nature of the work, by whom it is to be done (i.e. subcontractors, consultants), etc.

(3) Size of Job. All work not in excess of $100,000 shall be weighted at 0.12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from 0.12 to 0.05. Work from $5,000,000 to $10,000,000 shall be weighted at 0.04. Work in excess of $10,000,000 shall be weighted at 0.03. It should be noted that control of fixed expenses generally improves with increased job magnitude.

(4) Periods of Performance. Jobs in excess of 24 months are to be weighted at 0.12. Jobs of lesser duration are to be proportionately weighted to a minimum of 0.03 for jobs not to exceed 30 days. No weight where additional time not required.

(5) Contractor's Investment. To be weighted from 0.03 to 0.12 on the basis of below average, average, and above average. Consider the amount of subcontracting, Government-furnished property or data (such as surveys), method of making progress payments, and any mobilization payment items.

(6) Assistance by Government. To be weighted from 0.12 to 0.03 on the basis of average to above average. Things to consider: use of Government-owned property, equipment and facilities, and expediting assistance.

(7) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent or more of the work is to be subcontracted, the weighting is to be 0.03 and such weighting proportionately increased to 0.12 where all the work is performed by the Contractor's own forces.

1.29 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

It is the position of the Department of Defense that the Davis-Bacon Act, 40 U.S.C. 276a is applicable to temporary facilities such as job headquarters, tool yards, batch plants, borrow pits, sandpits, rock quarries, and similar operations, provided they are dedicated exclusively, or nearly so, to performance of the contract or project, and provided they are adjacent or virtually adjacent to the site of the work and are established after receipt of the proposal or bid. Clause "Payrolls and Basic Records" of the GENERAL CONDITIONS (CONTRACT CLAUSES) is applicable to such operations.

SECTION 01 30 00.24 Page 18

1.30 DRAWING SCALES

All scales shown on the RFP project drawings are based on a standard drawing size of 22" x 34". If any other size drawings are furnished or plotted, adjust the scales accordingly. Advise subcontractors of the above.

1.31 FEDERAL HOLIDAYS

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If a wage determination applies the number of holidays specified on it, it has priority over this requirement.

1.32 BASE HOURS

Base operation hours are 6:00 a.m. to 6:00 p.m. daily (Monday through Friday), excluding federal holidays. Access to the base during other times must be requested in writing from the Contracting Officer and will be granted only for extenuating circumstances. Federal Holidays and weekends are considered as scheduled non-workdays.

1.33 CYBERSECURITY DURING CONSTRUCTION

{For Reference Only: This subpart (and its subparts) relates to AC-18, SA-3, CCI-00258.} Meet the following requirements throughout the construction process.

1.33.1 Contractor Computer Equipment

Contractor owned computers may be used for construction. When used, contractor computers must meet the following requirements:

1.33.1.1 Operating System

The operating system must be an operating system currently supported by the manufacturer of the operating system.