250063_ATT 8_Liquidated Damages.pdf
PDF 82 KB Posted
- Solicitation number
- FA813727R0002
About this file
This is a Liquidated Damages assessment document for federal contract WWYK250063, which concerns the installation of a REACT VII Facility at Building B9001, POST V19. The document establishes a daily liquidated damages rate of $227.75 per calendar day for contractor delays in completing work on this delivery order, in accordance with FAR 36.206 and DFARS 236.206.
The liquidated damages calculation is composed of two components: engineering labor costs totaling $122.36 per day and government labor costs totaling $105.39 per day. The engineering component includes 0.5 hours from an Engineering Manager ($28.85), 1 hour from a Project Manager ($36.06), 1 hour from an Engineering Tech/Inspector ($28.52), 0.5 hours from Project Engineers ($19.23), and 0.5 hours from Clerical staff ($9.71). The government component includes 0.5 hours from a FAS GS-12/5 employee ($19.60), 1 hour from Legal GS-13/5 ($46.60), and 1 hour from Contracting GS-12/5 ($39.19). The document indicates that the contractor maintains complete control over work pace and that the assessment rate is reasonable given the project requirements. A signature block for the Contracting Officer and date field are provided but remain unsigned.
View the file
Other files
Show 40 more
50 files listed here. See the rest on GovTribe.
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PROJECT NUMBER & TITLE: WWYK250063 - INSTALL REACT VII FACILITY, B9001, POST V19
FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$
ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$
SUBTOTAL 122.36$
GOVERNMENT TITLE Hrs RATE TOTAL
FAS (GS-12/5) 0.5 39.19$ 19.60$
Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$
SUBTOTAL 105.39$
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$
Contracting Officer (Signature)
Contracting Officer (Print)
Date:
LIQUIDATED DAMAGES
In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work.
b. The contract provides for LDs for delay of work for each calendar day of the contract.
c. Considering the requirement, the rate of assessment is reasonable.
Sheet1
File details come from the government source that posted it. Updated .