210364_Attach6_Liquidated_Damages.pdf

149 KB Posted

Attached to
TINKER AFB MAC BOA WWYK210364 Construct Loading Dock & Dock Leveler, B3113
Solicitation number
WWYK210364
Issued by

About this file

Written by GovTribe AI ·

This document is a Liquidated Damages form for Project WWYK210364, titled "Construct Loading Dock & Dock Leveler, B3113". The document details the calculation of daily liquidated damages at $227.75 per calendar day of contract delay, broken down by engineering and government personnel hourly rates. The engineering personnel calculation includes roles such as Engineering Manager, Project Manager, Engineering Tech/Inspector, Project Engineers, and Clerical staff, totaling $122.36. The government personnel calculation includes FAS (GS-12/5), Legal (GS-13/5), and Contracting (GS-12/5) roles, totaling $105.39. The liquidated damages assessment is based on the contractor having complete control of work pace, the contract providing for damages for each calendar day of delay, and the assessment rate being deemed reasonable.

View the file

Other files

File Type Posted
210364_Pre Bid RFI Questions.pdf PDF
Solicitation Amendment FA813725R00510002 SF 30.pdf PDF
210364_Attach7_Wage Determination.txt TXT text file
Solicitation Amendment FA813725R00510001 SF 30.pdf PDF
Solicitation - FA813725R0051 (1).pdf PDF
210364_Attach3_DN.pdf PDF
210364_Attach1_SOW.pdf PDF
210364_Attach4_Submittal_Register.pdf PDF
210364_Attach2_Drawings.pdf PDF
210364_Attach5_RMDF-Signed.pdf PDF
210364_Attach7_Wage Determination.pdf PDF
Show all 11

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

PROJECT NUMBER & TITLE: WWYK210364 Construct Loading Dock & Dock Leveler, B3113

FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$

ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$

SUBTOTAL 122.36$

GOVERNMENT TITLE Hrs RATE TOTAL

FAS (GS-12/5) 0.5 39.19$ 19.60$

Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$

SUBTOTAL 105.39$

TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$

Contracting Officer (Signature)

Contracting Officer (Print)

Date:

LIQUIDATED DAMAGES

In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:

a. The contractor has complete control of the pace of work.

b. The contract provides for LDs for delay of work for each calendar day of the contract.

c. Considering the requirement, the rate of assessment is reasonable.

Sheet1

2025-09-08T13:27:02-0500
HINDS.SARA.MUSE.1150957075

File details come from the government source that posted it. Updated .