140R4025R0016_Attachment_1_3_-_00_00_01_NGWSP_PP1_AMD_No__003_Combined_Specs_0003.pdf

Navajo-Gallup Water Supply Project Amendment No. 003 San Juan Lateral – Pumping Plant No. 1 Solicitation No.

Revised Price Schedule

B - 1

CONTINUATION OF

SECTION B – SUPPLIES OR SERVICES AND PRICES

SAN JUAN LATERAL – PUMPING PLANT NO. 1

NAVAJO-GALLUP WATER SUPPLY PROJECT, NEW MEXICO

B.1 PRICE SCHEDULE

(a) Offers will be considered for award on the following Price Schedule, but no offer will be considered for award on only part of the Price Schedule.

(b) Offers are subject to the terms and conditions of this solicitation.

(c) Quantities in the Price Schedule are estimated quantities for comparison of offers only.

Except as provided in contract clause at FAR 52.211-18, Variation in Estimated Quantity, no claim shall be made against Government for overruns or underruns. Contract clause at FAR 52.211-18, Variation in Estimated Quantity does not apply to lump sum items.

(d) See contract clause at WBR 1452.232-81, Payment for Mobilization and Preparatory Work, for CLIN 1.

(e) Definitions:

(1) CLIN – Contract Line Item Number

(f) Note: In accordance with Section 7-9-3.3 of New Mexico Statutes Annotated (NMSA) 1978 and Section 402 of Navajo Nation’s Business Activity Tax Statute, it is Contractor’s responsibility to ensure that all applicable New Mexico Gross Receipts Tax and Navajo Nation Gross Receipts Tax are included in their price proposal.

(g) In accordance with FAR 52.232-5 (Payments under Fixed-Price Construction Contracts) (b)(2), payment may be approved for materials delivered to Contractor at locations other than the site if Contractor obtains CO approval prior to making arrangements for obtaining the materials. Contractor shall also be required to complete a “Materials on Hand Certificate” which will certify:

(1) Materials described for use on identified contract.

(2) Materials are clearly marked to identify that they belong to contract cited.

(3) Full title for those materials vested in Prime Contractor sited.

(4) Materials are free of liens and encumbrances.

(5) Materials are properly store, secured, and protected against loss or damage.

B - 2

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

1 WBR

1452.232-

Mobilization and Preparatory Work

For the lump sum of $

2 01 31 30 Contract Document Management System

For the lump sum of $

3 01 51 00 Construction Temporary Electric Power

12 months $ $

4 01 51 00 Testing and Commissioning Electric Power

1 month $ $

5 01 51 00 Construction Water 12 month $ $

6 01 56 15 Utility Crossing Investigation For the lump sum of $

7 01 78 30 As-Built Drawings For the lump sum of $

8 01 78 30 Final Drawings For the lump sum of $260,000

9 01 78 30 Operations and Maintenance (O&M) Manuals

For the lump sum of $260,000

10 01 80 15 Commissioning For the lump sum of $200,000

11 03 20 00 Concrete Reinforcing 170,000 lbs $ $

12 03 30 00 Concrete 1,450 cu yds $ $

13 03 35 10 Concrete Floor Hardener 13,500 sq ft $ $

14 03 48 00 Plant-Precast Concrete Structures

For the lump sum of $

15 04 22 10 Reinforced Concrete Unit Masonry Assemblies

For the lump sum of $

16 05 50 00 Metal Fabrications For the lump sum of $

17 06 82 10 Fiberglass Reinforced Plastic (FRP) Fabrications

For the lump sum of $

18 07 19 20 Silane Water Repellent For the lump sum of $

B - 3

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

19 10 14 00 Signage For the lump sum of $

20 10 44 20 Fire Extinguishers For the lump sum of $

21 13 34 21 Metal Building System For the lump sum of $

22 21 25 00 Hybrid Water Mist Fire Suppression System

For the lump sum of $

23 22 13 16 Plant Piping Systems For the lump sum of $

24 22 14 30 Sump Pumping Systems For the lump sum of $

25 23 00 00 Heating, Ventilating, and Air- Conditioning (HVAC) System

For the lump sum of $

26 25 00 01 System Control and Monitoring For the lump sum of $

27 26 05 10 Conductors and Cables 38,400 lin ft $ $

28 26 05 13 Medium-Voltage Power Cable 4,900 lin ft $ $

29 26 05 13 Medium-Voltage Power Cable Accessories

For the lump sum of $

30 26 05 20 Ground Cable 1,750 lin ft $ $

31 26 05 20 Ground Rods 4 ea $ $

32 26 05 20 Electrical Ground Resistance Test

For the lump sum of $

33 26 05 33 Electrical Conduit 9,500 lin ft $ $

34 26 05 33 Fabricated Sheet Steel Boxes, Wiring Troughs, and Precast Handholes

For the lump sum of $

35 26 05 36 Cable Trays 530 lin ft $ $

36 26 12 19 Pad Mounted Transformer (Installation Only)

For the lump sum of $

37 26 17 20 Metal-Clad Switchgear Assembly

For the lump sum of $

B - 4

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

38 26 18 39 Medium-Voltage Motor Controllers

For the lump sum of $

39 26 22 12 Dry-Type Transformer For the lump sum of $

40 26 24 13 Switchboards For the lump sum of $

41 26 24 41 Distribution Panelboards For the lump sum of $

42 26 26 10 Transformer Load Center For the lump sum of $

43 26 27 40 Wiring Devices For the lump sum of $

44 26 32 10 Diesel Engine-Generator Set For the lump sum of $

45 26 42 00 Corrosion System(s) For the lump sum of $

46 26 42 15 Galvanic Anode Cathodic Protection for Welded Steel Tanks

For the lump sum of $

47 26 51 00 Interior Lighting For the lump sum of $

48 26 52 00 Emergency and Exit Lighting For the lump sum of $

49 26 56 00 Exterior Lighting For the lump sum of $

50 27 30 01 Telephone System For the lump sum of $

51 28 10 01 Security and Surveillance System

For the lump sum of $

52 28 31 00 Fire Detection and Alarm For the lump sum of $

53 31 02 10 Water for Dust Abatement 140 Mgal $ $

54 31 02 30 Dust Palliative 3.0 acres $ $

55 31 03 33 Removal of Water from Excavation

For the lump sum of $

56 31 23 10 Common Excavation for Site and Structures

18,500 cu yd $ $

B - 5

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

57 31 23 10 Rock Excavation for Site and Structures

100 cu yd $ $

58 31 23 10 Compacted Backfill for Site and Structures

37,000 cu yd $ $

59 31 23 10 Processing of Site and Foundation Materials

18,500 cu yd $ $

60 31 23 15 Access Road Investigation and Design

For the lump sum of $

61 31 23 15 Access Road Construction For the lump sum of $

62 31 23 50 Earthwork for Roads For the lump sum of $

63 31 37 00 Riprap 570 cu yd $ $

64 32 15 10 Gravel Surfacing 1,200 cu yd $ $

65 32 31 01 Fence Grounding For the lump sum of $

66 32 31 10 Chain Link Fence 1,000 lin ft $ $

67 32 91 60 Erosion Control Blanket 2,300 sq yd $ $

68 32 92 20 Seeding 0.9 acre $ $

69 33 09 13 Flowmeter Systems For the lump sum of $

70 33 12 71 Vertical Turbine Pumping Units

6 ea $ $

71 33 16 14 Air Chambers and Air Compressors

For the lump sum of $

72 33 42 50 Reinforced Concrete Pipe Culvert (Refer to drawings)

For the lump sum of $

73 35 21 95 Steel Manifold Piping For the lump sum of $

74 35 22 14 Air Valves; 6-inch 2 ea $ $

75 35 22 14 Air Valves; 3-inch 13 ea $ $

B - 6

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

76 35 22 14 Air Valves; 3-inch; high pressure

6 ea $ $

77 35 22 14 Automatic Ball Drip Valves 3 ea $ $

78 35 22 14 Ball Valve; 18-inch 6 ea $ $

79 35 22 14 Ball Valve; 6-inch 3 ea $ $

80 35 22 14 Ball Valve; 3-inch 18 ea $ $

81 35 22 14 Ball Valve; 2-inch 11 ea $ $

82 35 22 14 Ball Valve; 3/4-inch 15 ea $ $

83 35 22 14 Butterfly Valve; 42-inch;

manual

2 ea $ $

84 35 22 14 Butterfly Valve; 20-inch;

manual

6 ea $ $

85 35 22 14 Butterfly Valve; 18-inch;

manual

5 ea $ $

86 35 22 14 Butterfly Valve; 18-inch;

motor operated

1 ea $ $

87 35 22 14 Butterfly Valve; 14-inch;

motor operated

2ea $ $

88 35 22 14 Butterfly Valve; 12-inch;

manual

4 ea $ $

89 35 22 14 Butterfly Valve; 6-inch;

manual handwheel

2 ea $ $

90 35 22 14 Butterfly Valve; 6-inch;

manual buried, Class 250B

3 ea $ $

91 35 22 14 Check Valve; 18-inch 6 ea $ $

92 35 22 14 Globe Valve; 2-inch 8 ea $ $

93 35 22 14 Pressure Sustaining Valve;

14-inch

1 ea $ $

B - 7

PRICE SCHEDULE

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

94 41 22 12 Gantry Crane For the lump sum of $

95 33 14 19 Fire Hydrants For the lump sum of $

TOTAL FOR PRICE SCHEDULE $_________________

END OF SUPPLIES OR SERVICES AND PRICES

B - 8

This page intentionally left blank.

Navajo-Gallup Water Supply Project Amendment No. 003

Revised Table of Contents

00 01 10 - 1

SECTION C - DESCRIPTION/SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 12 10 Other Contracts 01 14 10 Use of Site 01 14 12 Work Restrictions and Limitations 01 31 04 Partnering 01 31 19 Project Management and Coordination 01 31 30 Contract Document Management System 01 32 10 Construction Program 01 33 00 Submittals 01 33 26 Electrical Drawings and Data 01 33 28 Fire Alarm Drawings and Data 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 30 Contractor’s Onsite Safety Personnel 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 46 20 Testing Agency Services 01 46 25 Special Inspections 01 51 00 Temporary Utilities 01 52 10 Field Office 01 55 00 Vehicular Access and Parking 01 55 20 Traffic Control 01 56 15 Protection of Existing Utilities 01 56 20 Existing Fences 01 56 32 Temporary Safety Fence 01 57 10 Cross Drainage 01 57 20 Environmental Controls 01 57 30 Water Pollution Control 01 57 40 Pesticides 01 57 50 Tree and Plant Protection 01 57 60 Protected Species 01 57 90 Preservation of Historical and Archeological Data 01 60 00 Product Requirements 01 61 10 Buy American 01 64 40 Government Furnished Products 01 71 20 Surveying 01 74 00 Cleaning and Waste Management 01 78 30 Project Record Documents 01 80 15 Commissioning

Navajo-Gallup Water Supply Project Amendment No. 003

00 01 10 - 2

DIVISION 03 - CONCRETE

03 11 10 Concrete Forming 03 20 00 Concrete Reinforcing 03 20 60 Concrete Anchors 03 30 00 Cast-In-Place Concrete 03 35 10 Concrete Floor Hardener 03 48 00 Plant-Precast Concrete Structures 03 62 20 Nonshrink Grout 03 63 00 Epoxy Grout

DIVISION 04 - MASONRY

04 22 10 Reinforced Concrete Unit Masonry Assemblies

DIVISION 05 - METALS

05 12 10 Structural Steel 05 40 00 Cold-Formed Metal Framing 05 50 00 Metal Fabrications 05 51 30 Metal Ladders 05 52 20 Fall Protection Rail System

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 82 10 Fiberglass Reinforced Plastic (FRP) Fabrications

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 19 20 Silane Water Repellant 07 21 13 Sound Control Batt Insulation 07 21 20 Extruded Polystyrene Foam Insulation 07 21 50 Spray-Applied Polyurethane Foam Insulation 07 41 13 Insulated Metal Roof Panels 07 42 13 Insulated Metal Wall Panels 07 72 30 Roof Hatches 07 92 00 Joint Sealants and Masonry Joints

DIVISION 08 - OPENINGS

08 11 10 Steel Doors and Frames 08 31 25 Floor Access Hatches 08 33 20 Roll-Up Doors 08 41 10 Aluminum Framed Entrances and Storefronts 08 45 13 Structured-Polycarbonate Panel Assemblies 08 71 00 Door Hardware

DIVISION 09 - FINISHES

09 29 00 Gypsum Board 09 65 10 Rubber Wall Base

Navajo-Gallup Water Supply Project Amendment No. 003

00 01 10 - 3

09 96 20 Coatings

DIVISION 10 - SPECIALTIES

10 14 00 Signage 10 44 20 Fire Extinguishers

DIVISION 13 - SPECIAL CONSTRUCTION

13 34 21 Metal Building System

DIVISION 21 - FIRE SUPPRESSION

21 13 13 Automatic Fire Sprinkler Systems 21 25 00 Hybrid Water Mist Fire Suppression System

DIVISION 22 - PLUMBING

22 13 16 Plant Piping Systems 22 14 30 Sump Pumping Systems

DIVISION 23 - HEATING, VENTILATING, AND AIR-CONDITIONING (HVAC)

23 00 00 Heating, Ventilating and Air-Conditioning (HVAC) Systems 23 05 13 Common Motor Requirements for HVAC Equipment 23 05 29 Supports for HVAC Duct 23 05 53 Identification - HVAC 23 05 93 Testing, Adjusting, and Balancing for HVAC 23 09 00 Instrumentation and Control for HVAC 23 31 00 HVAC Ducts 23 33 00 Air Duct Accessories 23 34 00 HVAC Fans 23 37 00 Air Inlets and Outlets 23 73 13 Packaged Air-Conditioning Units 23 81 26 Split System Air Conditioners 23 82 39 Electric Heat Units

DIVISION 25 - INTEGRATED AUTOMATION

25 00 01 System Control and Monitoring

DIVISION 26 - ELECTRICAL

26 05 02 Basic Electrical Materials and Methods 26 05 10 Conductors and Cables 26 05 13 Medium-Voltage Power Cable System 26 05 20 Grounding and Bonding 26 05 33 Raceways and Boxes 26 05 36 Cable Trays 26 05 90 Wiring Checkout and Tests 26 12 19 Pad Mounted Transformer

Navajo-Gallup Water Supply Project Amendment No. 003

00 01 10 - 4

26 17 20 Metal-Clad Switchgear Assembly 26 18 39 Medium-Voltage Motor Controllers 26 22 12 Dry-Type Transformer 26 24 13 Switchboards 26 24 41 Distribution Panelboards 26 26 10 Transformer Load Center 26 27 40 Wiring Devices 26 32 10 Engine-Generator Sets 26 41 13 Lightning Protection for Buildings 26 42 00 Cathodic Protection Systems 26 42 15 Galvanic Anode Protection for Welded Steel Tanks 26 51 00 Interior Lighting 26 52 00 Emergency and Exit Lighting 26 56 00 Exterior Lighting

DIVISION 27 - COMMUNICATIONS

27 30 01 Telephone System

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 10 01 Security and Surveillance System 28 31 00 Fire Detection and Alarm

DIVISION 31 - EARTHWORK

31 02 10 Water for Dust Abatement 31 02 30 Dust Palliative 31 03 33 Removal of Water from Excavation 31 11 00 Clearing and Grubbing 31 14 10 Topsoil Stripping, Stockpiling and Placement 31 23 02 Compacting Earth Materials 31 23 10 Earthwork for Site and Structures 31 23 15 Access Road Improvements 31 23 22 Pipe Trench Earthwork 31 23 39 Disposal of Excavated Materials 31 23 50 Earthwork for Roads 31 23 70 Controlled Low Strength Material (CLSM) 31 31 30 Soil-Applied Herbicide 31 37 00 Riprap

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 12 22 Asphalt Concrete Pavement 32 15 10 Gravel Surfacing 32 31 01 Fence Grounding 32 31 10 Chain Link Fence 32 91 60 Erosion Control Blanket 32 92 20 Seeding

Navajo-Gallup Water Supply Project Amendment No. 003

00 01 10 - 5

DIVISION 33 - UTILITIES

33 09 13 Flowmeter Systems 33 12 71 Vertical Turbine Pumping Units 33 14 19 Fire Hydrants 33 16 14 Air Chambers 33 42 50 Reinforced Concrete Pipe Culvert

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 21 95 Steel Manifold Piping 35 22 14 Valves and Equipment

DIVISION 41 – MATERIAL PROCESSING AND HANDILING EQUIPMENT

41 22 12 Gantry Crane

DIVISION 51 - INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors 51 00 10 Permit Applications 51 00 20 I/O Points List 51 00 35 Site Specific Revegetation Plan for Navajo-Gallup Water Supply Project 51 00 50 Electronic Media Release Form 51 00 80 BLM Pesticides

DIVISION 52 - DRAWINGS

52 00 00 Drawings

DIVISION 53 - GEOLOGIC INVESTIGATIONS AND RECORDS

53 10 00 Geologic Investigations 53 20 00 Records of Geologic and Subsurface Investigations

END OF CONTENTS

Navajo-Gallup Water Supply Project Amendment No. 003

00 01 10 - 6

This page intentionally left blank.

Revised Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-2020 Decimal Inch Drawing Sheet Size and

Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-2014 United States National CAD Standards, Version 6

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittal Types, as listed in Table 01 33 00A – List of Submittals:

1. A – Action:

a. Government will respond as to adequacy of submittal.

b. Action submittals: Considered to be “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I – Informational:

a. Government will acknowledge receipt of Informational submittals.

b. Government may reject an Informational submittal when submittal does not comply with contract. Contractor shall correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational submittals: Considered to be “shop drawings” within terms of the clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

D. CDMS: Contract Document Management System.

01 33 00 - 2

E. Record As-built Drawings:

1. Set of full-size, hard-copy drawings that contain both Government drawings furnished with this contract and Contractor-produced drawings necessary to clearly identify as-built conditions of the completed project.

F. Final Drawings:

1. Complete electronic set of drawings produced by the Contractor as required by these specifications, updated to reflect all changes made in the field during construction.

G. Operations and Maintenance (O&M) Manuals:

1. Final documentation for functional elements, equipment and systems installed in the finished work, including all information necessary for Government personnel to operate, maintain, and troubleshoot such elements, equipment and systems in a safe, clear, effective, and efficient manner. Include instructions, final drawings and equipment certifications for each element of work.

H. Design Calculations:

1. Calculations and verifications specified in the Government-furnished contract documents. Design calculation and technical requirements are described in relevant specification sections.

2. Design calculations shall be certified by a registered professional.

I. Schedule of Values (SOV):

1. Detailed cost breakdown for construction products and execution activities for each lump sum Contract Line Item Number (CLIN) shown in the Section B Price Schedule. Include separate SOV line items for each major product purchase, execution activity, and/or sequential processes required to complete the work associated with each lump sum CLIN. Do not include costs associated with RSN preparation and submission. The SOV will be used to accurately assess and confirm progress payment amounts for each CLIN.

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number, title, and RSN.

3. Measurement units: US Customary Units.

4. Provide unique transmittal number for each submittal.

01 33 00 - 3

C. Drawings:

1. Minimum identification in title block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3- by 3-inch space next to title block for review stamps.

3. Print Size: D size (22- by 34-inches) as defined by ASME Y14.1.

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified:

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AutoCAD, Version 2018 or later.

3) Compile using “eTransmit” utility in AutoCAD.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings designated as “Government Format” in specifications:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on Standard Drawing 40-D-7102.

2) Government will provide template.

3) Government will provide specific title block information to be used.

01 33 00 - 4

6. Final Drawings:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

d. Electronic Files: On Reclamation issued USB Drive.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets:

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional:

a. Not required for non-design work.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

b. Electronic copies: Searchable Adobe .pdf on Reclamation issued USB

Drive:

1) Bookmark longer files to assist in navigating file.

2) Electronic files may be submitted as separate parts of a manual.

After each separate electronic file is approved, compile each approved electronic file to assemble an entire manual which shall be consistent with final manual submittal.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

01 33 00 - 5

d. As-built drawings, photographs, and test records or reports if required by specifications.

G. Photographs:

1. Digital files: In .jpeg or similar format.

H. Samples and Color Selection Submittals:

1. Label with complete manufacturer's product and color identification.

2. Include type and quantity of materials specified in the referenced section in each

“set” of samples.

3. Samples: Representative of product to be installed. Xerographic sheets for color selection are not acceptable.

4. Color Chips: Sample paint chips. Ink color reproductions are not acceptable.

5. Label each sample, sample kit, set of color chips, or color chart with contract number and title.

6. Government will select architectural color and pattern after product approval.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A – List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit sets specified in “Sets to be sent:” columns in Table 01 33 00A – List of Submittals:

1. Submittals identified with “CDMS” in “Sets to be sent” column shall be submitted electronically in accordance with Section 01 31 30 – Contract Document Management System.

2. Submittals identified with “CDMS” in the top row of the “Sets to be sent” column require approval (Action) or acknowledgement (Informational) before sending required sets of hardcopy submittals.

3. Submittals identified with “CDMS” in the bottom row of the “Sets to be sent” column require submittal of hardcopy submittals before finalizing submittal in

CDMS.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

01 33 00 - 6

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 28 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through digital signature date stamp and upload date in CDMS.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time:

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract, and

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR

52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Return of Submittals:

01 33 00 - 7

1. Return of submittals will be by CDMS response or hard copy, as applicable.

2. Action Submittals: One set of submittals required for action will be returned either approved, partially approved, approved subject to identified changes and resubmit, or not approved:

a. Submittals that are not approved shall be revised and resubmitted.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

c. Exception: Schedules will be either accepted, partially accepted or not accepted.

3. Informational Submittals: Government will acknowledge Informational submittals:

a. Informational submittals will not be returned when they comply with specifications.

b. Informational submittals that do not comply with specifications may be returned for resubmittal or additional information may be requested.

1.07 HARD COPY OF TRANSMITTALS

A. Addresses for codes listed in Table 01 33 00A – List of Submittals:

1. Contracting Officer, Bureau of Reclamation, Attn: UC-840, 125 South State St., Room 6107, Salt Lake City, UT 84138-1147.

2. Construction Engineer, Bureau of Reclamation, 1235 La Plata Hwy, Farmington, New Mexico, 87401.

3. Technical Service Center, Bureau of Reclamation, Attn: 86-68160, PO Box

25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

4. Executive Director Gallup Joint Utilities, PO Box 1270, Gallup, New Mexico, 87305.

5. Navajo Tribal Utility Authority (NTUA), Attn: Operations Manager, PO Box 1749, Shiprock, NM 87420.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A – List of Submittals:

1. Responsible codes starting with “86-6” are located in the Technical Service

Center. Send these submittals to the TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not the responsible code but show “No. of sets to be sent to” in Table 01 33 00A – List of Submittals.

D. Provide copy of transmittal letter on CDMS.

01 33 00 - 8

E. When “No. of sets to be sent to” is 0, send a copy of transmittal letter to that office.

F. Submittals required by the specifications, but not listed in Table 01 33 00A – List of Submittals:

1. Submit in accordance with this section.

2. Submit to CE, unless otherwise specified.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

01 33 00 - 9

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility Authority, and Gallup indicates the City of Gallup New Mexico.

*** R Code indicates Responsible Code.

RSN Clause or Section Title Submittals Required Due Date or

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

1 Schedule of Values Schedule of Values for lump sum CLINs

Submitted and approved before first payment

A CO CDMS

01 14 10-1 Use of Site Land Use and Landscape Rehabilitation Plan

At least 63 days before use of site

A CE CDMS

01 31 19-1 Project Management and Coordination

Written Summary Monthly once onsite construction begins.

A CE CDMS

01 31 19-2 Project Management and Coordination

Off ROW Land Use Coordination

At least 45 days before use of OFF ROW land

I CE CDMS

01 31 19-3 Project Management and Coordination

Key Personnel Within 7 days after receipt of Notice of Award

A CE CDMS

01 31 19-4 Project Management and Coordination

Replacement of Key Personnel

A minimum of 7 business days prior to work being performed by new personnel

A CE CDMS

01 31 30-1 Contract Document Management System

Approval Data Within 21 days of Award

A CE 0 1 0 0

CDMS

01 31 30-2 Contract Document Management System

Final Data Within 14 days of completion of work

A CE 0 2 2 0

CDMS

01 32 10-1 Construction Program

Representative Information

Within 7 days after receipt of Notice of Award

I CE CDMS

01 32 10-2 Construction Program

Baseline Schedule Within 21 days after receipt of initial Notice to Proceed

A CE CDMS

01 32 10-3 Construction Program

Updated Schedule Reports

Monthly or with Progress Payments

A CE CDMS

01 33 00 - 10

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 32 10-4 Construction Program

Time Impact Analysis

Within 28 days after CO directs a contract change, with any proposal for a future modification, with any value engineering proposal, or with any request or claim for an equitable adjustment to the contract.

A CE CDMS

01 35 10-1 Safety Data Sheets Complete LHM and

SDS

At least 14 days before jobsite delivery of hazardous material

I CE CDMS

01 35 10-2 Safety Data Sheets Updated LHM and

SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

I CE CDMS

01 35 20-1 Safety and Health Safety Program Submitted and accepted before commencing onsite work.

Submit at least 45 days before beginning onsite work. See RSHS

A CE CDMS

01 35 20-2 Safety and Health Site Inspection Weekly I CE CDMS 01 35 20-3 Safety and Health Job Hazard

Analyses At least 7 days before commencing onsite activities for each phase of work

A CE CDMS

01 35 20-4 Safety and Health Monthly Accident Summary Report

First day of each month. See

RSHS

01 33 00 - 11

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 35 20-5 Safety and Health Respirator Users Documentation and Records

At least 45 days before beginning onsite work

A CE CDMS

01 35 30-1 Contractor’s Onsite Safety Personnel

Resume At least 45 days before beginning onsite construction;

resubmit upon personnel change

A CE CDMS

01 35 30-2 Contractor’s Onsite Safety Personnel

Safety Inspection Reports

At least once each week

I CE CDMS

01 46 00-1 Quality Procedures Definable Features of Work List

Within 21 days after receipt of initial Notice to Proceed

A CE CDMS

01 46 00-2 Quality Procedures Contractor Quality Control (QC) Plan

At least 45 days before beginning onsite work

A CE CDMS

01 46 00-3 Quality Procedures Contractor’s Daily Report

At least once each week

I CE CDMS

01 46 00-4 Quality Procedures Quality Control Supervisor (QCS) Resume

At least 45 days before beginning onsite work.

Resubmit upon personnel change.

A CE CDMS

01 46 00-5 Quality Procedures Contractor’s Quality Testing Plan

At least 45 days before beginning onsite work

A CE CDMS

01 46 00-6 Quality Procedures Summary of Monthly Test Results

Monthly, on or before 5th day of each month

A CE CDMS

01 46 20-1 Testing Agency Services

Testing Agencies Services Plan

At least 45 days before testing is required

A CE CDMS

01 46 25-1 Special Inspections Preconstruction Submittals

At least 45 days before special inspection is required

01 33 00 - 12

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 46 25-2 Special Inspections Test Reports Within 1 day of special inspection completion

A CE CDMS

01 46 25-3 Special Inspections Certificates At least 45 days before special inspection is required

A CE CDMS

01 46 25-4 Special Inspections Closeout Submittals Within 14 days of completion of work

A CE CDMS

01 51 00-1 Temporary Utilities

Water Storage At least 42 days before beginning onsite construction

A CE CDMS

01 52 10-1 Field Office Delivery Schedule At least 35 days before beginning onsite work

A CE CDMS

01 55 00-1 Vehicular Access and Parking

Preconstruction Digital Recording

At least 21 days before beginning onsite work

A CE 0 1 0 0

01 55 00-2 Vehicular Access and Parking

Post-Construction and Post-Repair Digital Recording

At least 21 days before leaving site.

A CE 0 1 0 0

01 55 20-1 Traffic Control Traffic Control Plan and Permit Applications

At least 70 days before affecting public traffic.

A CE CDMS

01 55 20-2 Traffic Control Permits At least 45 days before affecting public traffic

I CE CDMS

01 56 15-1 Protection of Existing Utilities

Utility Owner Acknowledgement

At least 45 days prior to submitting pipe laying diagram and at least 45 days prior to excavation

01 33 00 - 13

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 56 15-2 Protection of Existing Utilities

Utility Crossing Investigation

At least 45 days prior to submitting pipe laying diagram and at least 45 days prior to excavation

A CE CDMS

01 56 15-3 Protection of Existing Utilities

Work Plan within Utility Easements

With pipe laying diagram and at least 45 days prior to excavation

A CE CDMS

01 57 20-1 Environmental Controls

Copy of Applicable Air Quality Permit

At least 14 days before beginning onsite work

I CE CDMS

01 57 20-2 Environmental Controls

Dust Control Plan At least 14 days before beginning onsite work

I CE CDMS

01 57 30-1 Water Pollution Control

Stormwater Pollution Prevention Plan (SWPPP)

At least 45 days before start of onsite construction work

A CE CDMS

01 57 30-2 Water Pollution Control

Spill Prevention, Control, and Countermeasure (SPCC) Plan

At least 45 days before delivery or storage of oil

A CE CDMS

01 57 40-1 Pesticides Pesticide Use Plan At least 45 days before application of first pesticide

A CE CDMS

01 57 50-1 Tree and Plant Protection

Protection Plan At least 45 days before beginning onsite work

A CE CDMS

01 57 90-1 Preservation of Historical and Archeological Data

Alternate Use Area or Borrow Area

At least 45 days before beginning offsite work, if commercial site;

if non-commercial site then at least 6-months prior to use of land

01 33 00 - 14

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 61 10-1 Buy American Buy American Certificates

Prior to project closeout

I CE CDMS

01 64 40-1 Government- Furnished Products

Shortage Report Within 2 days of inspection

I CE CDMS

01 71 20-1 Surveying Surveying Plan Within 45 days after Notice to Proceed, and approved before beginning survey work

A CE CDMS

01 71 20-2 Surveying Resumes At least 45 days before beginning survey work;

resubmit upon personnel change

I CE CDMS

01 71 20-3 Surveying Accuracy Check Results

At least 45 days before beginning survey work

I CE CDMS

01 71 20-4 Surveying Completed and Reduced Survey Notes

Weekly I CE CDMS

01 71 20-5 Surveying Original Field Survey Books

Weekly I CE CDMS

01 71 20-6 Surveying Quantity Survey Notes and Computations

Accompanying progress payment requests

I CE CDMS

01 71 20-7 Surveying Workday's Survey Notes

At conclusion of workweek

I CE CDMS

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

At least 45 days before beginning onsite work

I CE CDMS

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of hazardous waste disposal

I CE CDMS

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 45 days before beginning environmental assessment

I CE CDMS

01 33 00 - 15

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 74 00-4 Cleaning and Waste Management

Environmental Site Assessment

Within 14 days of completion of work

I CE CDMS

01 78 30-1 Project Record Documents

Electronic Media Release Form, Upon Request

Accompanying request for electronic media

I CE CDMS

01 78 30-2 Project Record Documents

Progress As-Built Drawings

Monthly once onsite construction begins

A CE CDMS

01 78 30-3 Project Record Documents

Final As-Built Drawings

Within 28 days of (and no earlier than 60 days prior to) Government issued substantial completion of work

A CE CDMS

01 78 30-4 Project Record Documents

Draft O&M Manual Within 28 days of Government issued substantial completion of work

A CE CDMS

0 2 2 2

01 78 30-5 Project Record Documents

Final Drawings Within 14 days of approval of

RSN 01 78 30-3

A CE CDMS

0 2 0 2

01 78 30-6 Project Record Documents

Final O&M Manuals

Within 14 days of approval of

RSN 01 78 30-4

A CE CDMS

0 2 2 2

01 80 15-1 Commissioning Qualifications Within 150 days after Notice to Proceed

A CE CDMS

01 80 15-2 Commissioning Test Plan At least 60 days prior to commissioning and no earlier than 120 days prior to commissioning

01 33 00 - 16

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

01 80 15-3 Commissioning Testing Procedures At least 60 days prior to commissioning and no earlier than 120 days prior to commissioning

I CE CDMS

01 80 15-4 Commissioning Test Reports Within 7 days of completing each test

I CE CDMS

01 80 15-5 Commissioning Discrepancy and Corrections List

Within 7 days of completing each test

I CE CDMS

01 80 15-6 Commissioning Post-Testing and Commissioning Documentation

Within 60 days of completing commissioning

A CE CDMS

03 11 10-1 Concrete Forming Formwork Design and Drawings

45-days before placing concrete

A CE CDMS

03 20 00-1 Concrete Reinforcing

Reinforcement Diagrams and Lists

45-days before placing concrete

A CE CDMS

03 20 60-1 Concrete Anchors Instructions 45-days before installation of anchors

I CE CDMS

03 20 60-2 Concrete Anchors Test Data and Results

Within 7 days of completing each test

I CE CDMS

03 30 00-1 Cast-in Place Concrete

Approval Data

At least 45-days before placing concrete

A 86-68530 CDMS

03 30 00-2 Cast-in Place

Concrete Placement Schedule

At least 45-days before placing concrete

A CE CDMS

03 30 00-3 Cast-in Place

Certifications concrete

A CE CDMS

03 30 00-4 Cast-in Place

Test Reports

Monthly A CE CDMS

01 33 00 - 17

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

03 35 10-1 Concrete Floor Hardener

Manufacturer's Instructions concrete

A CE CDMS

03 48 00-1 Plant-Precast Concrete Structures

Certificates before installing first structure

A 86-68120 CDMS

03 48 00-2 Plant-Precast Concrete Structures

Shop Drawings concrete

A 86-68120 CDMS

03 48 00-3 Plant-Precast Concrete Structures

Product Data and concrete

A 86-68120 CDMS

03 62 20-1 Nonshrink Grout for Equipment and Metalwork

Packaged Nonshrink Grout Data

At least 45-days before placing concrete

A 86-68530 CDMS

03 63 00-1 Epoxy Grout Approval Data before beginning grouting

A 86-68530 CDMS

04 22 10-1 Reinforced Concrete Unit Masonry Assemblies

Approval Data, Certifications, and Mix Design

At least 45-days before beginning construction of the wall

A 86-68120 CDMS

04 22 10-2 Reinforced Concrete Unit Masonry Assemblies

Sample Kit construction of the wall

I 86-68120 CDMS (Transmittal letter)

0 1 1 0

04 22 10-3 Reinforced Concrete Unit Masonry Assemblies construction of the wall

A 86-68120 CDMS

05 12 10-1 Structural Steel Qualifications

At least 90-days framing

A 86-68120 CDMS

05 12 10-2 Structural Steel Dimensional framing

01 33 00 - 18

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

05 12 10-3 Structural Steel Approval Drawings and Data

At least 90-days before installing framing

A 86-68120 CDMS

05 12 10-4 Structural Steel Test Reports At least 90-days before beginning work

A 86-68120 CDMS

05 12 10-5 Structural Steel Weld Inspection Reports framing

A 86-68120 CDMS

05 12 10-6 Structural Steel Final Drawings and Data framing

A 86-68120 CDMS

05 12 10-7 Structural Steel AISC “Quality Certified Fabricator” Certificate

At least 90-days before installing framing

A 86-68120 CDMS

05 40 00-1 Cold-Formed Metal framing

Approval Drawings and Data framing

A 86-68120 CDMS

05 40 00-2 Cold-Formed Metal framing

Certifications framing

A 86-68120 CDMS

05 40 00-3 Cold-Formed Metal framing

Erection Plans and Manual framing

A 86-68120 CDMS

05 51 30-1 Metal Ladders Shop Drawings and Product Data framing

A 86-68120 CDMS

05 52 20-1 Fall Protection Rail System

Approval Drawings and Data

At least 45-days before beginning work on rail system

A 86-68120 CDMS

05 52 20-2 Fall Protection Rail System before end of construction

A 86-68120 CDMS

05 52 20-3 Fall Protection Rail System

Operation and Maintenance before payment

01 33 00 - 19

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

06 82 10-1 Fiberglass Reinforced Plastic (FRP) Fabrications

Commercial Product Data onsite work

A 86-68120 CDMS

06 82 10-2 Fiberglass Reinforced Plastic (FRP) Fabrications onsite work

A 86-68120 CDMS

07 19 20-1 Silane Water Repellant before applying repellent

I 86-68120 CDMS

07 19 20-2 Silane Water repellent

I 86-68120 CDMS

07 19 20-3 Silane Water

Documentation repellent

I 86-68120 CDMS

07 21 13-1 Sound Control Batt Insulation insulation

A 86-68120 CDMS

07 21 13-2 Sound Control Batt insulation

I 86-68120 CDMS

07 21 20-1 Extruded Polystyrene Foam onsite work

A 86-68120 CDMS

07 21 50-1 Spray Applied Polyurethane Foam insulation

01 33 00 - 20

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

07 21 50-2 Spray Applied Polyurethane Foam insulation

A 86-68120 CDMS

07 21 50-3 Spray Applied Polyurethane Foam insulation

A 86-68120 CDMS

07 41 13-1 Insulated Metal Roof Panels

Sample and Color panels

A CE CDMS (Transmittal letter)

0 1 1 0

07 41 13-2 Insulated Metal Roof Panels

Qualifications At least 45-days

07 41 13-3 Insulated Metal Roof Panels

07 41 13-4 Insulated Metal Roof Panels

Closeout Maintenance Data

Within 14-days of completion of onsite work

07 42 13-1 Insulated Metal Wall Panels

Sample and Color panels

A CE CDMS (Transmittal letter)

0 1 1 0

07 42 13-2 Insulated Metal Wall Panels

Qualifications At least 45-days before installing panels

A 86-68120 CDMS

07 42 13-3 Insulated Metal Wall Panels panels

A 86-68120 CDMS

07 42 13-4 Insulated Metal Wall Panels

Closeout Maintenance Data of installing

01 33 00 - 21

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

07 72 30-1 Roof Hatches Product Data and

07 92 00-1 Joint Sealants and Masonry Joints

Approval Data and Color Samples

At least 45-days before installing joint

A CE CDMS (Transmittal letter)

0 1 1 1

07 92 00-2 Joint Sealants and Masonry Joints joint

A 86-68120 CDMS

08 11 10-1 Steel Doors and Frames doors

A 86-68120 CDMS

08 11 10-2 Steel Doors and Frames doors

A 86-68120 CDMS

08 31 25-1 Floor Access Hatches panels

A 86-68120 CDMS

08 33 20-1 Roll up Doors Approval Drawings and Data

At least 45-days before installing doors

A 86-68120 CDMS

08 33 20-2 Roll up Doors Sample and Color doors

A CE CDMS (Transmittal letter)

0 1 1 0

08 33 20-3 Roll up Doors Certification At least 45-days before installing doors

08 33 20-4 Roll up Doors

Instructions At same time as equipment is shipped

I 86-68120 CDMS

08 41 10-1 Aluminum Framed Entrances and Storefronts

At least 45-days

01 33 00 - 22

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

08 41 10-2 Aluminum Framed Entrances and Storefronts

Approval Sample Kits

At least 45-days before ordering

A CE CDMS

0 1 1 1

08 41 10-3 Aluminum Framed Entrances and Storefronts

Shipping Confirmation

At least 45-days before installing

A CE CDMS

08 41 10-4 Aluminum Framed Entrances and Storefronts

Certifications At least 45-days before installing

A CE CDMS

08 41 10-5 Aluminum Framed

Instructions At least 45-days

A CE CDMS

08 41 10-6 Aluminum Framed

Documentation At least 45-days

A CE CDMS

08 45 13-1 Structured- Polycarbonate Panel Assemblies

A CDMS

08 71 00-1 Door Hardware Hardware Schedule and Approval Data

At least 45-days before installing hardware

A 86-68120 CDMS

08 71 00-2 Door Hardware Instructions At least 45-days before installing hardware

09 29 00-1 Gypsum Board Approval Data gypsum board

A 86-68120 CDMS

09 65 10-1 Rubber Wall Base Approval Data and Color Sample Kit

At least 45-days before installing wall base

A CE CDMS

0 1 1 0

09 65 10-2 Rubber Wall Base Instructions wall base

I 86-68120 CDMS

09 96 20-1 Coatings Approval Data coating work

01 33 00 - 23

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

09 96 20-2 Coatings Final Approval Data coating work

09 96 20-3 Coatings Paint Chip Samples coating work

A CE CDMS (Transmittal letter)

0 1 1 0

09 96 20-4 Coatings Qualifications coating work

A 86-68530

/ CE

CDMS

09 96 20-5 Coatings Quality Control Plan

At least 45-days before beginning coating work

A 86-68530 CDMS

09 96 20-6 Coatings Contractor Quality Testing Report

At least 14-days after completion of test

A 86-68530 CDMS

10 14 00-1 Signage Shop Drawings and Approval Data

At least 45-days before beginning coating work

10 44 20-1 Fire Extinguishers Approval Data before procurement

A 86-68410 CDMS

10 44 20-2 Fire Extinguishers Maintenance Data procurement

A 86-68120 CDMS

13 34 21-1 Metal Building System

Approval Drawings and Data

At least 90-days before procurement

A 86-68120 CDMS

13 34 21-2 Metal Building

Certification

At least 90days procurement

A 86-68120 CDMS

13 34 21-3 Metal Building

Design Data procurement

A 86-68120 CDMS

13 34 21-4 Metal Building System

Anchorage Design procurement

01 33 00 - 24

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

13 34 21-5 Metal Building System

Erection Plans, Manual, and procurement

A 86-68120 CDMS

13 34 21-6 Metal Building System

Fabricator Qualifications procurement

A 86-68120 CDMS

21 13 13-1 Automatic Fire Sprinkler Systems

Approval Drawings and Data

At least 45-days before

21 13 13-2 Automatic Fire Sprinkler Systems

Test Plan after completing installation and testing

I 86-68410 CDMS

21 13 13-3 Automatic Fire Sprinkler Systems

Final Drawings and

At Commissioning

A 86-68410 CDMS

21 13 13-4 Automatic Fire Sprinkler Systems

At Commissioning

I 86-68410 CDMS

21 15 00-1 Hybrid Water Mist Fire Suppression procurement

A 86-68410 CDMS

21 15 00-2 Hybrid Water Mist Fire Suppression System procurement

A 86-68410 CDMS

21 15 00-3 Hybrid Water Mist Fire Suppression

Test Plan procurement

A 86-68410 CDMS

21 15 00-4 Hybrid Water Mist Fire Suppression

Final Drawings installation and testing

01 33 00 - 25

Table 01 33 00A – List of Submittals

* Submittal types: A – Action, I – Information ** CO indicates Contracting Officer, CE indicates Construction Engineer, WCAO indicates Western Colorado Area Office, TSC indicates Technical Service Center, NTUA indicates Navajo Tribal Utility

Delivery Time Type

R Code

No. of sets to be sent to:

CO CE TSC Gallup/

NTUA

21 15 00-5 Hybrid Water Mist Fire Suppression System

Operation and procurement

A 86-68410 CDMS

21 15 00-6 Hybrid Water Mist Fire Suppression System

Delivery of Extra Materials procurement

A 86-68410 CDMS

21 15 00-7 Hybrid Water Mist Fire Suppression System

Training Notification installation and testing

A 86-68410 CDMS

22 13 16-1 Plant Piping…