Amendment_0001_to_140R2024R0015_0001.pdf

(x)

140R2024R0015 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Sacramento CA 95825-1898 2800 Cottage Way, Room E-1815

R20

Division of Acquisition Services Regional Office Mid-Pacific Region Bureau of Reclamation

11/12/20240001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

11/12/2024

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

A. TITLE: B. F. Sisk Dam SOD Modifications, Phase II

B. PURPOSE: The purpose of this amendment is to incorporate various changes to solicitation documents.

C. DESCRIPTION: Amendment 01 Description of Changes:

1) Standard Form 1442, box 11 is revised from 1,095 to 1,350 days.

2) Section F number of days is revised from 1,095 to 1,350.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140R2024R0015/0001

3) Section J - New Incorporated Attachments:

Attachment 13 - Virtual Site Visit Attendance

3DEC24

Attachment 14 - Virtual Presentation 3DEC24

Attachment 15 - In Person Site Visit Sign In

Sheet 4DEC24

Attachment 16 - In Person Site Visit Agenda 4DEC24

Attachment 17 - Price Schedule in Excel

Attachment 18 - CAD Files (this attachment is available under separate cover. To request, please email Roxana Ahola at rahola@usbr.gov and cc: Abelardo (Carlos) Lopez at aclopez@usbr.gov to request the Kiteworks link.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation No.: 140R2024R0015, B. F. Sisk Dam SOD Modifications, Phase II San Luis Unit, West San Joaquin Division, Central Valley Project, California

F-1

SECTION F - DELIVERIES OR PERFORMANCE

Clause Title Date

52.211-18 Variation in Estimated Quantity APR 1984 52.236-15 Schedules for Construction Contracts APR 1984

52.242-14 Suspension of Work APR 1984

FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND APR 1984

COMPLETION OF WORK

The Contractor shall be required to

(a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 1,095 1,350 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

FAR 52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION SEP 2000

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $15,735 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Amendment 0001 rahola Cross-Out

Solicitation No.: 140R2024R0015, B. F. Sisk Dam SOD Modifications, Phase II San Luis Unit, West San Joaquin Division, Central Valley Project, California

J-1

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

Due to the large file sizes, attachments 1-3 and 18 are available under separate cover via Kiteworks. To obtain these files, please send an email to request the Kiteworks link to Roxana Ahola at rahola@usbr.gov and cc: Abelardo (Carlos) Lopez at aclopez@usbr.gov

Attachment Number

List of Documents, Exhibits, and other Attachments

Specifications

2 Drawings

3 Appendices

DI-137 -Release of Claims

5 General Decision Number: Wage Determination

6 Subcontracting Plan

7 Past Performance Questionnaire

8 Past Performance Data Form

9 Key Personnel

10 Corporate Experience and Management

11 Offeror Responsibility Information

12 Electronic Proposal Submission Instructions Kiteworks

13 Virtual Site Visit Attendance 3DEC24

14 Virtual Presentation 3DEC24

15 In Person Site Visit Sign In Sheet 4DEC24

16 In Person Site Visit Agenda 4DEC24

17 Price Schedule in Excel

18 CAD Files (See top of this page for request instructions)

Amendment 0001