Amendment_1_-_McNamara_Road_0001.pdf

(x)

140L3623R0006 x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

LMALMA

05/05/20230001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)

BLM MT STATE OFFICE

ATTN: CHRISTINE MUNDT

5001 SOUTHGATE DR

BILLINGS MT 59101

CODE 6. ISSUED BY

BLM MT-STATE OFFICE

ATTN: CHRISTINE MUNDT

5001 SOUTHGATE DR

BILLINGS MT 59101

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

04/21/2023

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Project Title: McNamara/Johnsrud Roads, Chip Sealing and Site Improvements - Great American Outdoors Act, Montana

See Page 2 of 6 for changes incorporated by this amendment.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Christine Mundt

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Solicitation No: 140L3623R0006 PROJECT DESCRIPTION: McNamara/Johnsrud Roads, Chip Sealing and Site Improvements (GAOA)

Amendment No. 0001

Description of Changes - This amendment incorporates the following information:

1. In Section A, remove Standard Form 1442 “Solicitation, Offer, and Award” in its entirety and replace with the revised Standard Form 1442 “Solicitation, Offer, and Award” (dated 05/05/2023).

2. Remove Section F, Deliveries or Performance, in its entirety and replace with the attached Section F, Deliveries or Performance (Revised).

Acknowledgement - See Block 11 above regarding how to acknowledge this amendment. The Government must receive the acknowledgement at the place designated for receipt of offers (See Block 8 of the Standard Form 1442).

Proposal Response Date - The hour and date for receipt of proposals remains unchanged at 5:00 pm Mountain Time on May 22, 2023.

Third Party – If you have given a copy of the solicitation to someone else, please forward this amendment accordingly.

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040608721

BLM MT-STATE OFFICE

ATTN: CHRISTINE MUNDT

5001 SOUTHGATE DR.

BILLINGS MT 59101

LMA

BLM - Montana State Office 5001 Southgate Drive Billings, MT 59101 via email to BLM_MT_Procurement@blm.gov

Christine Mundt 4068965030

3x 05/05/2023

140L3623R0006

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

A. Project Title: McNamara/Johnsrud Roads, Chip Sealing and Site Improvements - Great American Outdoors Act, Montana

B. Location of the Work: The project work is located in Missoula County, Montana.

C. Estimated Range of the Project: The estimated price range of this acquisition is between $500,000 and $1,000,000.

D. The North American Industrial Classification System (NAICS) Code is 237310. The applicable Small Business Size Standard is $45.0 Million.

E. This solicitation is issued as a Total Small Business Set-Aside procurement.

F. SAM Unique Entity ID Number:________________________

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO (If "YES", indicate within how many calendar days after award in Item 12b.)

10 calendar days and complete it within ________________ _____ _ __________ 454 calendar days after receiving

FAR 52.211-10

05/22/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85) Prescribed by GSA FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

PAGE 4 OF

BLM MT STATE OFFICE

ATTN: CHRISTINE MUNDT

5001 SOUTHGATE DR.

BILLINGS MT 59101

LMA

Christine Mundt

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

The Invoice Processing Platform (IPP) ipp.gov

(866) 973-3131 IPPCustomerSupport@fiscal.treasury.gov

1 (Revised)

SECTION F – DELIVERIES OR PERFORMANCE (REVISED)

F.1 52.211-10, ALT I

COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK – ALTERNATE I APR 1984

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than September 15, 2024. The contractor shall provide their proposed construction schedule (see Section L and Section M) to ensure that work is completed between the date of Notice to Proceed receipt and the September 15, 2024, deadline.

The time stated for completion shall include final cleanup of the premises. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by June 20, 2023. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

F.2 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS APR 1984

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

2 (Revised)

F.3 52.242-14 SUSPENSION OF WORK APR 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted

(1) By an act of the Contracting Officer in the administration of this contract, or

(2) By the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

F.4 BLM 1510-

52.211-70 BLM - VARIATION IN QUANTITY (DEVIATION) MAY 1987

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 20 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 120 percent or below 80 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.