12445225R0030.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

1147599

USDA-FS CSA EAST 12

1720 PEACHTREE ST NW

STE 876S

ATLANTA GA 30309-2449

Drew Cranford at:

andrew.cranford@usda.gov

ONLY EMAIL SUBMITTED PROPOSALS SHALL BE

ACCEPTED. SEE SECTION L FOR MORE.

ANDREW CRANFORD 817-900-2902

1x 07/24/2025

12445225R0030

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

PROJECT: LaMina Trails and Bridges reconstruction

SET ASIDE: COMPETITIVE 8A IAW with FAR 19.803

LOCATION: El Yunque National Forest, Puerto Rico

SITE VISIT: Section L FAR 52.236-27 Alt I Site Visit (construction)(Feb 1995)

RFI'S / QUESTIONS: submit to POC in block 8 via email NO later than COB 19AUG2025

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 545 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR 52.212-8

_______________________ 08/26/2025

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 8/2014)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA-FS CSA EAST 12

1720 PEACHTREE ST NW

STE 876S

ATLANTA GA 30309-2449

JALISA C. SIMS

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 8/2014) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

12445225R0030

0001 La Mina Trail Reconstruction 1 LS

Product/Service Code: Y1LB

Product/Service Description: CONSTRUCTION OF

HIGHWAYS, ROADS, STREETS, BRIDGES, AND RAILWAYS

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Table of Contents

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

B.2 SCHEDULE NOTES

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

C.2 PROJECT LOCATION

C.3 MAGNITUDE OF CONSTRUCTION PROJECT

C.4 TECHNICAL SPECIFICATIONS

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

F.2 OTHER REQUIREMENTS

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

G.2 OTHER REQUIREMENTS

SECTION H--SPECIAL CONTRACT REQUIREMENTS

H.1 CLAUSES

H.2 OTHER REQUIREMENTS

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

J.1 ATTACHMENTS

PART IV--REPRESENTATIONS AND INSTRUCTIONS

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF

OFFERORS OR RESPONDENTS

K.1 PROVISIONS

K.2 OTHER STATEMENTS OF OFFERORS OR RESPONDENTS

SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR

RESPONDENTS

L.1 PROVISIONS

L.2 INSTRUCTIONS

SECTION M--EVALUATION FACTORS FOR AWARD

M.1 PROVISIONS

M.2 PROPOSAL EVALUATION

M.3 TECHNICAL EVALUATION FACTORS

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

See Section J attachments for Schedule of items. Attachment must be completely filled out and returned with SF1442 to be considered responsive. SOIs will be submitted during the Phase II portion of this solicitation.

B.2 SCHEDULE NOTES

a) Contractor will fill in the 1442 items 14 through 20c; B.1 of this solicitation and the Bid Schedule in each package for section J. The minimum amount of documents to be returned is the 1442 filled out correctly, B.1 above and each of the four project bid schedules. If discrepancies exist in the calculation of price, the amount listed on the 1442 shall be the evaluated price. INCIDENTAL

PAYMENT INSTRUCTIONS

b) The intent of the contract is to provide for the complete work of the project described in the contract. Unless otherwise provided, the contractor shall furnish all labor, materials, equipment, tools, transportation, and supplies, taxes and fees requirements and perform all work required to complete the project in accordance with the drawings, specifications, and provisions of the contract. Payment for contract work will be made for and under those pay items included in the Schedule of Items (which is one lump sum price for the contract). All other work and materials will be considered as incidental to and included in the payment for items shown.

PRICING DATA SUBMISSION:

c) In accordance with FAR 15.403-4(a)(1), Requiring Certified Cost or Pricing Data, it is requested that pricing data be submitted to show the breakdown of costs for the above CLIN(s). The price breakdown attachment located in Section J shall be submitted with your proposal. Failure to complete and submit the price breakdown attachment could result in disqualification from award.

This requested information is so that the Contracting Officer can make the determination of a fair and reasonable price.

WAGE DETERMINATION:

d) Construction wages shall be paid for all applicable labor categories for each price schedule line item and shall be included in all pricing in accordance with FAR 52.222-6, Construction Wage Rate Requirements. See Section J, for Wage Determination(s) included as part of this solicitation.

IMPORTANT INFORMATION:

a) Under no circumstances will any oral statements made be binding upon the Government unless such statements or agreements are issued in writing by the Contracting Officer.

b) Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract, you shall not proceed within the change and shall immediately notify the Contracting Officer.

END OF SECTION

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

See attached SOW in Section J attachments

C.2 MAGNITUDE OF CONSTRUCTION PROJECT

In accordance with FAR 36.204, this project is estimated to be between $5,000,000 and $10,000,000.

C.3 SUMMARY OF WORK TO BE PERFORMED

1) The Contractor shall be responsible for all necessary work to achieve required outcomes, including labor, equipment, tools, personal protective equipment (PPE), coordination with Authorities Having Jurisdiction (AHJ), internal construction permits, incidental design, travel, fees, and other related expenses. Work includes all civil, structural, mechanical, electrical, plumbing, gas systems, fire protection, special systems (network/phone), equipment, furniture and all finishes.

1. All work outlined in Section J

2. Any and all other construction tasks as required to complete the project in accordance with section J; these construction documents provide requirements of the project as well as required outcomes and objectives.

C.4 TECHNICAL SPECIFICATIONS

1.) CODES/STANDARDS

a) The Contractor is responsible for securing all needed permits and for ensuring compliance with all federal, state, and local codes and design standards, latest editions.

b) The Contractor shall adhere to the following code requirements for work performed, testing and inspections, including, but not limited to the following:

1) Occupational Safety and Health Administration (OSHA) – CFR1926.

2) International Building Code (IBC) 2015 Edition

3) International Mechanical Code (IMC) 2015 Edition

4) International Plumbing Code (IPC) 2015 Edition

5) International Fuel Gas Code (IFGC) 2015 Edition

6) National Electric Code (NEC) 2014 Edition

7) National Fire Protection Association Codes NFPA 101 2012 Edition

8) The Standard Specifications for the Construction of Roads and Bridges on Federal

Highway Projects FP-14 located at https://highways.dot.gov/federal-lands/specs If discrepancies are found between the statement of work and codes or standards as referenced in this SOW, the codes or standards shall govern, unless noted otherwise.

c) Quality Assurance/Quality Control https://highways.dot.gov/federal-lands/specs

1) All materials shall be approved by Contractor Officer’s Representative via the submittal process prior to installation.

2) All materials shall be installed per manufacturer’s instructions, applicable codes and good work practices.

3) Housekeeping will be accomplished daily. All debris and trash generated by this project will be disposed of properly in accordance with governing national, state and local environmental regulations.

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

All shipments of materials, equipment and/or supplies shall be addressed to the Contractor and not to the Government.

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

The Government singularly identifies each project with a contract number at time of award. The contract number is a unique identifier to purposely and permanently represent an awarded project.

The Government issued contract number is to be referenced on all official communication starting upon notice of award.

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

FAR 52.246-12 Inspection of Construction (AUG 1996) FAR 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements (AUG

1996)

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

FAR 52.211-18 Variation in Estimated Quantity (APR 1984) FAR 52.236-15 Schedules for Construction Contracts (APR 1984) FAR 52.242-14 Suspension of Work (APR 1984)

FAR 52.211.10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within _10__ calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ___545 calendar days_____. The time stated for completion shall include final cleanup of the premises.

(End of clause)

F.2 OTHER REQUIREMENTS

Not Applicable

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

AGAR 452.204-70 Modification for Contract Closeout

G.2 OTHER REQUIREMENTS

G.1 ADDRESS FOR CORRESPONDENCE

(a) It is the intent of the Government to use electronic means as much as possible while administering this contract.

(b) Administration of this contract is under the cognizance of the Forest Service.

1. The Procuring Contracting Officer (PCO) for this procurement is: Jalisa Sims Telephone Number: (346) 579-4178 jalisa.sims@usda.gov

2. The Contracting Officer’s Representative (COR) for this procurement will be designated via a separate letter at the time of award.

(c) Most correspondence should be sent via e-mail directly to the Contracting Officer Drew Cranford at andrew.cranford@usda.gov Include the Contract Number on all correspondence.

(d) PAYMENT PROCESS

(a) FAR 52.232-5, Payments Under Fixed -Price Construction Contracts, requires that before the first progress payment under the contract is submitted, the contractor shall prepare a Schedule of Values including each principal category of the work which when added together equal the total contract price. A sample format is available from the Contracting Officer. The following is the detail required by the Contracting Officer:

(1) The principle categories of work shall be broken into line items of sufficient detail to allow meaningful measurement of the work on a monthly basis as determined by the COR. Units of measure appropriate to the type of work shall be used. “Lump sum” pricing of line items shall be avoided except where payment for that line item is to be requested based on 100% completion of that line item or where there is no other practical unit of measure.

(2) The cost of preparatory work (e.g., shop drawings or product submittals), field and home office overhead, profit, insurance, taxes, warranties, as-built drawings, etc., shall be pro-rated into items of physical work and not listed as separate line items. Cost of Performance and Payment Bonds may be listed as a single line item and not pro-rated. Also, cost of mobilization and demobilization relating to transportation or installation costs associated with such items as site trailers, heavy equipment, mailto:jalisa.sims@usda.gov mailto:andrew.cranford@usda.gov temporary batch plants, temporary on-site manufacturing and assembly facilities, temporary on-site quarter’s facilities, temporary sanitation facilities, temporary utility connections, and/or temporary secured storage facilities may be listed as line items and not pro-rated. If mobilization is listed separately, a line item for demobilization must be listed separately. A detailed listing of the items included and the individual cost for each item shall be provided in support of proposed amounts for mobilization and demobilization.

(b) Material stored on site may be included in earned progress if the Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform in contract.

(c) The following are instructions for submitting pay requests:

(1) Requests are to be submitted with signature for the Contractor certification statement

(scanned signature okay) to the CO and COR. Use of a format that complies with all the requirements of the “Payments” clause of the contract is mandatory. The “Contractor Payment Application” form will be provided at the Pre-Construction meeting.

(2) The Contractor is responsible for delivery of each request for payment to the billing office. Hand delivery to the COR in the field does not constitute delivery to the billing office.

(3) If the contractor wishes to inquire concerning the status of any pay request, the contractor should contact the Contracting Officer.

(4) A completed Release of Claims that complies with the requirements of the “Payments” clause must be submitted with the request for final payment. A sample format is available from the Contracting Officer.

(d) The final payment request will be rejected and returned to the contractor if all items required under the contract have not been completed, submitted, approved, and accepted prior to the receipt of the request, e.g., deficient work items, as-built, payrolls, reports, O&M manuals, delivery of extra stock material, etc.

(e) The final invoice must be marked “Final” and be accompanied by a Release of Claims form, which lists the final payment as outstanding, in the Remarks field. The Release of Claims form is available from the CO. Final payment will be made within 30 Calendar days upon receipt of a properly executed invoice.

(f) The contractor will contact the Designated Billing Office with any payment issues or concerns.

Note: In accordance with FAR 52.232‐40, Providing Accelerated Payments to Small Business Subcontractors (Nov 2021) ‐‐ Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor. This applies to all small business subcontractors at all tier levels.

Solicitation No: 12445224R0030 Project Name: LaMina Trail and Bridges Reconstruction

FAC 2025-04 June 11, 2025

G.7. CERTIFICATION OF PAYMENTS - RELEASE OF CLAIM

The Contractor, when submitting final payment under this contract, shall submit to the Contracting Officer:

(a) A certification that the Contractor has made payment from proceeds of prior payments, or that he will make timely payment from the proceeds of the progress or final payment then due him, to any subcontractors and suppliers in accordance with established contractual arrangements; and

(b) A properly executed Contractor's Release. The Release of Claims form is available from the Contracting Officer. Failure to submit this completed release will result in a delay of final payment.

G.8. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This paragraph specifies the procedure for the determination of time extensions for unusually severe weather. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(a) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(b) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

(c) Weather delays will be based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The contractor’s progress schedule must reflect consideration of these anticipated adverse weather delays in all-weather dependent activities.

(d) Upon acknowledgment of the notice to proceed (NTP) and continuing throughout the contract, the contractor will record on the Contractor’s Daily Report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delays must prevent work on critical activities for 50 percent or more of the contractor’s scheduled workday.

(e) The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in accordance with the criteria previously described above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair- weather workdays, and issue a bilateral modification.

FAC 2025-04 June 11, 2025

SECTION H--SPECIAL CONTRACT REQUIREMENTS

H.1 CLAUSES

Not Applicable

H.2 OTHER REQUIREMENTS

Minimum Insurance Coverage Requirements

Pursuant to FAR clause FAR 52.228-5, Insurance-Work on a Government Installation paragraph (a), Contractors shall present evidence and maintain, as a minimum, the amounts of insurance coverage indicated below:

(1) Workers Compensation and Employer's Liability. The Contractor is required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they must be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 must be required, except in States with exclusive or monopolistic funds that do not permit worker's compensation to be written by private carriers.

(2) General Liability. The Contractor must have bodily injury liability insurance coverage written on a comprehensive form of policy of at least $500,000 per occurrence.

(3) Automobile Liability. The Contractor must have automobile liability insurance written on a comprehensive form of policy. The policy must provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States must provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage or loss.

(4) Aircraft Public and Passenger Liability. When aircraft are used in connection with performing the contract, the Contractor must have aircraft public and passenger liability insurance. Coverage must be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger injury. Coverage for passenger injury must be at least $200,000 multiplied by the number of seats or passengers; whichever is greater.

FAC 2025-04 June 11, 2025

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR): https://www.acquisition.gov/browse/index/far (Clauses are located at FAR part 52 and begin with 52)

Department of Agriculture Acquisition Regulation (AGAR):https://www.acquisition.gov/agar (Clauses are located at AGAR part 452 and begin with 452)

Deviations to clauses may be viewed at: USDA FAR Class Deviations

FAR 52.202-1 Definitions (JUN 2020) FAR 52.203-3 Gratuities (APR 1984) FAR 52.203-5 Covenant against Contingent Fees (MAY 2014) FAR 52.203-6 Restrictions on Subcontractor Sales to the Government (JUN 2020) FAR 52.203-7 Anti-Kickback Procedures (JUN 2020) FAR 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper

Activity (MAY 2014) FAR 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) FAR 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (JUN

2020) FAR 52.203-13 Contractor Code of Business Ethics and Conduct (NOV 2021) FAR 52.203-14 Display of Hotline Poster(s) (NOV 2021) FAR 52.203-17 Contractor Employee Whistleblower Rights (NOV 2023) (Whistleblower

Guidance to contractor employees) FAR 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (JAN 2017) FAR 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

(JUN 2020)

FAR 52.204-13 System for Award Management Maintenance (OCT 2018) FAR 52.204-14 Service Contract Reporting Requirements (OCT 2016) FAR 52.204-19 Incorporation by Reference of Representations and Certifications (DEC

2014) FAR 52.204-21 Basic Safeguarding of Covered Contractor Information Systems (NOV

2021) https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/far/part-52 https://www.acquisition.gov/agar https://www.acquisition.gov/agar/part-452-solicitation-provisions-and-contract-clauses https://www.usda.gov/about-usda/general-information/staff-offices/departmental-administration/office-contracting-and-procurement-ocp/usda-far-class-deviations https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fcontent.govdelivery.com%2Fattachments%2FUSDAPSD%2F2023%2F04%2F04%2Ffile_attachments%2F2456937%2FWhistleblower%2520Guidance.docx&wdOrigin=BROWSELINK https://view.officeapps.live.com/op/view.aspx?src=https%3A%2F%2Fcontent.govdelivery.com%2Fattachments%2FUSDAPSD%2F2023%2F04%2F04%2Ffile_attachments%2F2456937%2FWhistleblower%2520Guidance.docx&wdOrigin=BROWSELINK

FAC 2025-04 June 11, 2025

FAR 52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023)

FAR 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021)

FAR 52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023) FAR 52.204-30 Federal Acquisition Supply Chain Security Act Orders—Prohibition (Dec

2023) FAR 52.209-6 Protecting the Government's Interest when Subcontracting with

Contractors Debarred, Suspended, or Proposed for Debarment, or Voluntarily Excluded (JAN 2025)

FAR 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018)

FAR 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015)

FAR 52.210-1 Market Research (NOV 2021) (DEVIATION JUNE 2025) FAR 52.215-2 Audit and Records -- Negotiation (JUN 2020) FAR 52.215-8 Order of Precedence—Uniform Contract Format (OCT 1997) FAR 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data (AUG 2011) FAR 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data-Modifications

(JUN 2020)

FAR 52.215-12 Subcontractor Certified Cost or Pricing Data (JUN 2020) FAR 52.215-13 Subcontractor Certified Cost or Pricing Data (JUN 2020) FAR 52.215-15 Pension Adjustments and Asset Reversions (OCT 2010) FAR 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other

Than Pensions (JUL 2005) FAR 52.215-19 Notification of Ownership Changes (OCT 1997) FAR 52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than

Certified Cost or Pricing Data (NOV 2021) FAR 52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than

Certified Cost or Pricing Data – Modifications (NOV 2021) FAR 52.219-6 Notice of Total Small Business Set-Aside (NOV 2020) FAR 52.219-9 Small Business Subcontracting Plan (JAN 2025) FAR 52.219-14 Limitations on Subcontracting (OCT 2022)

[Contracting Officer check as appropriate.]

☐ By the end of the base term of the contract and then by the end of each subsequent option period; or

☐ By the end of the performance period for each order issued under the contract.

FAR 52.219-17 Section 8(a) Award (OCT 2019) FAR 52.219-18 Notification of Competition Limited to Eligible 8(a) Participants (OCT

2022) FAR 52.219-28 Post award Small Business Program Representation (JAN 2025) FAR 52.222-3 Convict Labor (JUN 2003) FAR 52.222-4 Contract Work Hours and Safety Standards -- Overtime Compensation

(MAY 2018)

https://www.acquisition.gov/sites/default/files/page_file_uploads/USDA_RFO_Deviation_Part-10.pdf

FAC 2025-04 June 11, 2025

FAR 52.222-6 Construction Wage Rate Requirement (AUG 2018) FAR 52.222-7 Withholding of Funds (MAY 2014) FAR 52.222-8 Payrolls and Basic Records (JUL 2021) FAR 52.222-9 Apprentices and Trainees (JUL 2005) (DEVIATION FEB 2025) FAR 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) FAR 52.222-11 Subcontracts (Labor Standards) (MAY 2014) FAR 52.222-12 Contract Termination - Debarment (MAY 2014) FAR 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations (MAY 2014) FAR 52.222-14 Disputes Concerning Labor Standards (FEB 1988) FAR 52.222-15 Certification of Eligibility (MAY 2014) FAR 52.222-30 Construction Wage Rate Requirements-Price Adjustment (None or

Separately Specified Pricing Method) (AUG 2018) FAR 52.222-35 Equal Opportunity for Veterans (JUN 2020) FAR 52.222-36 Equal Opportunity for Workers with Disabilities (JUN 2020) FAR 52.222-37 Employment Reports on Veterans (JUN 2020) FAR 52.222-40 Notification of Employee Rights Under National Labor Relations Act

(DEC 2010)

FAR 52.222-50 Combating Trafficking in Persons (NOV 2021) FAR 52.222-55 Minimum Wages for Contractor Workers under Executive Order 14026

(JAN 2022)

FAR 52.222-62 Paid Sick Leave under Executive Order 13706 (JAN 2022) FAR 52.223-2 Reporting of Biobased Products Under Service and Construction Contracts

(MAY 2024) (DEVIATION FEB 2025)

FAR 52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2024) FAR 52.223-21 Foams (MAY 2024) FAR 52.223-23 Sustainable Products & Services (MAY 2024) (DEVIATION FEB 2025) FAR 52.225-13 Restrictions on Certain Foreign Purchases (FEB 2021) FAR 52.226-1 Utilization of Indian Organizations and Indian-Owned Economic

Enterprises (JUN 2000) FAR 52.226-7 Drug-Free Workplace (MAY 2024) FAR 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving

(MAY 2024)

FAR 52.227-1 Authorization and Consent (JUN 2020) FAR 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (JUN

2020) FAR 52.227-4 Patent Indemnity -- Construction Contracts (DEC 2007) FAR 52.227-17 Rights in Data-Special Works (DEC 2007) FAR 52.228-2 Additional Bond Security (OCT 1997) FAR 52.228-5 Insurance – Work on a Government Installation (JAN 1997) FAR 52.228-11 Individual Surety - Pledge of Assets (FEB 2021) (DEVIATION MAY

2023) FAR 52.228-12 Prospective Subcontractor Requests for Bonds (DEC 2022) FAR 52.228-14 Irrevocable Letter of Credit (NOV 2014) https://www.usda.gov/sites/default/files/documents/far-class-deviation-eliminate-hard-copy-original-documents-signatures-notarization-seals-bonds-other-seals.pdf https://www.usda.gov/sites/default/files/documents/far-class-deviation-eliminate-hard-copy-original-documents-signatures-notarization-seals-bonds-other-seals.pdf

FAC 2025-04 June 11, 2025

FAR 52.228-15 Performance and Payment Bonds -- Construction (JUN 2020)

(DEVIATION MAY 2023)

FAR 52.229-3 Federal, State, and Local Taxes (FEB 2013) FAR 52.229-4 Federal, State, and Local Taxes (State and Local Adjustments) (FEB 2013) FAR 52.232-5 Payments under Fixed-Price Construction Contracts (MAY 2014) FAR 52.232-17 Interest (MAY 2014) FAR 52.232-23 Assignment of Claims (MAY 2014) FAR 52.232-24 Prohibition of Assignment of Claims (MAY 2014) FAR 52.232-27 Prompt Payment for Construction Contracts (JAN 2017) FAR 52.232-33 Payment by Electronic Funds Transfer – System for Award Management

(OCT 2018)

FAR 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (MAR

2023) FAR 52.233-1 Disputes (MAY 2014) Alt 1 (DEC 1991) FAR 52.233-3 Protest after Award (AUG 1996) FAR 52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) FAR 52.236-2 Differing Site Conditions (APR 1984) FAR 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) FAR 52.236-5 Material and Workmanship (APR 1984) FAR 52.236-6 Superintendence by the Contractor (APR 1984) FAR 52.236-7 Permits and Responsibilities (NOV 1991) FAR 52.236-8 Other Contracts (APR 1984) FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements (APR 1984) FAR 52.236-10 Operations and Storage Areas (APR 1984) FAR 52.236-11 Use and Possession Prior to Completion (APR 1984) FAR 52.236-12 Cleaning Up (APR 1984) FAR 52.236-13 Accident Prevention (NOV 1991)

Alternate I (NOV 1991) FAR 52.236-17 Layout of Work (APR 1984) FAR 52.236-21 Specifications and Drawings for Construction (FEB 1997)

Alternate I (APR 1984) Alternate II (APR 1984)

FAR 52.236-26 Preconstruction Conference (FEB 1995) FAR 52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by

American Security Drone Act-Covered Foreign Entities (NOV 2024) FAR 52.242-13 Bankruptcy (JUL 1995) FAR 52.243-4 Changes (JUN 2007) FAR 52.244-2 Subcontracts (JUN 2020) FAR 52.244-6 Subcontracts for Commercial Products and Commercial Services (JAN

2025) (DEVIATION FEB 2025)

FAR 52.246-21 Warranty of Construction (MAR 1994)

Alternate I (MAR 1994) FAR 52.248-3 Value Engineering – Construction (OCT 2020) https://www.usda.gov/sites/default/files/documents/far-class-deviation-eliminate-hard-copy-original-documents-signatures-notarization-seals-bonds-other-seals.pdf

FAC 2025-04 June 11, 2025

FAR 52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012)-Alternate I (SEP 1996)

FAR 52.249-10 Default (Fixed-Price Construction) (APR 1984) FAR 52.253-1 Computer Generated Forms (JAN 1991)

FAR 52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)

(a) Definitions. As used in this clause—

“Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item.

Postconsumer material is a part of the broader category of “recovered material.”

“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall—

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to __COR_______

(end of clause)

FAR 52.252-6 Authorized Deviations in Clauses (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR 4) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

(End of clause)

FAC 2025-04 June 11, 2025

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

J.1 ATTACHMENTS

J01 Statement of Work J02 Forest Service Supplemental Specs J03 LaMina Trail – drawings J04 Attachment Construction Experience form J05 Attachment Architect Engineering experience form J06 Attachment Past Performance J07 Attachment Key Personnel J08 Schedule of items LaMina

J09 WD PR

FAC 2025-04 June 11, 2025

PART IV--REPRESENTATIONS AND INSTRUCTIONS

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER

STATEMENTS OF OFFERORS OR RESPONDENTS

K.1 PROVISIONS

FAR 52.204-29 Federal Acquisition Supply Chain Security Act Orders—Representation and Disclosures (Dec 2023)

FAR 52.236-28 Preparation of Proposals – Construction (OCT 1997)

FAR 52.204-8 Annual Representations and Certifications (JAN 2025) (DEVIATION FEB 2025)

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is____237310______________ [insert NAICS code].

(2) The small business size standard is ______45M_______ [insert size standard].

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519 if the acquisition—

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) (1) If the provision at FAR 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at FAR 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) ☐ Paragraph (d) applies.

(ii) ☐ Paragraph (d) does not apply and the offeror has completed the individual https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_204_7

FAC 2025-04 June 11, 2025 representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) FAR 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in FAR part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) FAR 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) FAR 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) FAR 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at FAR 52.204-7, System for Award Management.

(v) FAR 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) FAR 52.204-26, Covered Telecommunications Equipment or Services- Representation. This provision applies to all solicitations.

(vii) FAR 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations- Representation.

(viii) FAR 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) FAR 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

https://www.acquisition.gov/far/part-52#FAR_52_203_2 https://www.acquisition.gov/far/part-13#FAR_Part_13 https://www.acquisition.gov/far/part-52#FAR_52_203_11 https://www.acquisition.gov/far/part-52#FAR_52_203_18 https://www.acquisition.gov/far/part-52#FAR_52_204_3 https://www.acquisition.gov/far/part-52#FAR_52_204_7 https://www.acquisition.gov/far/part-52#FAR_52_204_5 https://www.acquisition.gov/far/part-52#FAR_52_204_26 https://www.acquisition.gov/far/part-52#FAR_52_209_2 https://www.acquisition.gov/far/part-52#FAR_52_209_5 https://www.acquisition.gov/far/part-52#FAR_52_209_11

FAC 2025-04 June 11, 2025

(x) FAR 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) FAR 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) FAR 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied FAR part 19 in accordance with FAR 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) FAR 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied FAR part 19 in accordance with FAR 19.000(b)(1)(ii).

(xiv) [Reserved]

(xv) [Reserved]

(xvi) FAR 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) FAR 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at FAR 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) FAR 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) [Reserved]

(xx) FAR 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at FAR 52.225-1.

(xxi) FAR 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies https://www.acquisition.gov/far/part-52#FAR_52_214_14 https://www.acquisition.gov/far/part-52#FAR_52_215_6 https://www.acquisition.gov/far/part-52#FAR_52_219_1 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/part-19#FAR_19_000 https://www.acquisition.gov/far/part-19#FAR_19_000 https://www.acquisition.gov/far/part-52#FAR_52_219_2 https://www.acquisition.gov/far/part-19#FAR_Part_19 https://www.acquisition.gov/far/part-19#FAR_19_000 https://www.acquisition.gov/far/part-52#FAR_52_222_38 https://www.acquisition.gov/far/part-52#FAR_52_223_1 https://www.acquisition.gov/far/part-52#FAR_52_223_2 https://www.acquisition.gov/far/part-52#FAR_52_223_4 https://www.acquisition.gov/far/part-52#FAR_52_225_2 https://www.acquisition.gov/far/part-52#FAR_52_225_1 https://www.acquisition.gov/far/part-52#FAR_52_225_4

FAC 2025-04 June 11, 2025 to solicitations containing the clause at FAR 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) FAR 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at FAR 52.225-5.

(xxiii) FAR 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxiv) FAR 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) FAR 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

☒ (i) FAR 52.204-17, Ownership or Control of Offeror.

☐ (ii) FAR 52.204-20, Predecessor of Offeror.

☒ (iii) FAR 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

☐ (iv) FAR 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

☐ (v) FAR 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

☒ (vi) FAR 52.227-6, Royalty Information.

☒ (A) Basic.

☐ (B) Alternate I.

☐ (vii) FAR 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in https://www.acquisition.gov/far/part-52#FAR_52_225_3 https://www.acquisition.gov/far/part-52#FAR_52_225_6 https://www.acquisition.gov/far/part-52#FAR_52_225_5 https://www.acquisition.gov/far/part-52#FAR_52_225_20 https://www.acquisition.gov/far/part-52#FAR_52_225_25 https://www.acquisition.gov/far/part-52#FAR_52_226_2

FAC 2025-04 June 11, 2025

SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in any updates to the representations and certifications posted on SAM.

(End of provision)

FAR 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it “does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument” in paragraph (c)(1) in the provision at FAR 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at FAR 52.212-3, Offeror Representations and Certifications- Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it “does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services” in paragraph (c)(2) of the provision at FAR 52.204-26, or in paragraph (v)(2)(ii) of the provision at FAR 52.212-3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause FAR 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S.