1240LU25R0018Amend001SF30.pdf

(x)

1240LU25R0018

x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

40LU

TOWNSEND MT 59644

415 SOUTH FRONT STREET

ALISHA KNAUB

USDA-FS INTERMOUNTAIN ZONE CSA 9

07/16/20250001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

07/16/2025

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Amendment 001 - LOLO NATIONAL FOREST - Lolo Building T150 Reconstruction

This amendment makes the following changes and is hereby included in this solicitation:

- Adding Division 27 Telecom (Pay Item 14) and Division 28 Safety and Security (Pay Item

15) to the Schedule Of Items. Use the attached Amendment 001 Schedule of Items when submitting business/price proposal.

- Changes the completion date from 426 days after Notice to Proceed is issued to a completion date of March 1, 2027.

- Removes the following sentence from Section L.2(b)(iii) located on page 36 of the solicitation document: The schedule shall indicate completion deadlines for each of the two phases identified in the specifications and identify the critical path and diagram its

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

ALISHA D. KNAUB

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

1240LU25R0018/0001

progress.

- Makes the following changes to Volume 1 of the project specifications (See attached revised document, dated 8/12/2025):

- Revised option numbering to match plans.

- Added Drexel under metal roof panels manufacturers (07 4113-2, section 2.01, A).

- Removed specification section 10 5123 -lockers.

- Removed Division 13 - Special Construction.

- Added Arcadia under aluminum windows manufacturers (08 5113-2, section 2.01, A).

- Added C.H.I. coiling door substitution under Overhead Coiling Doors (08 3323-2 section

2.01, A)

- Makes the following changes to Volume 2 of the project specifications (See attached revised document, dated 8/12/2025):

- Removed specification Section 28 2300 -

Video Surveillance.

- Added OCC CAT6 substitution request under

Communications Copper Horizontal Cabling (27

1513-2, Section 2.02, A)

- Added OCC fiber substitution request under

Communications Optical Fiber Backbone Cabling (27

1323-2, Section 2.02, B)

- Makes the following changes to the drawings

(See attached revised document, dated 8/12/2025):

- Revised option item numbering throughout the drawings.

- Revised sheet A510 showing non-continuous jambs.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

aknaub Highlight aknaub Highlight aknaub Highlight