PPSC DQ 27-006 Operable Wall Partitions

Pikes Peak State College is requesting quotes for furnishing and installing a new electrically operated operable partition system at its Downtown Studio Campus in Colorado Springs under documented quote solicitation PPSC DQ 27-006, with quotes due November 13, 2026 at 2:00 p.m. Mountain Standard Time and a mandatory jobsite visit on October 29, 2026 at 9:00 a.m.

The scope requires complete removal of the existing operable wall system, delivery of all materials and equipment, installation of the new partition system with track and operating components, testing, adjustment, commissioning, and final inspection. The contractor must provide a turnkey installation compliant with applicable building codes and manufacturer specifications, including warranty documentation and any required training. Qualified personnel with appropriate training and experience in electric wall partition installation are mandatory. Work must minimize disruption to campus operations and maintain a safe work area throughout the project.

The contract is anticipated to begin November 17, 2026 and must be completed by June 30, 2027, with an estimated project duration of 3–4 months. PPSC identifies Spring Break (March 22–28, 2027) as an ideal completion window. Pricing must remain firm during the initial contract term and include all fees for delivery and installation.

Award will be made to the respondent whose acceptable quote is determined most advantageous, with price as the primary consideration, though sample quality and delivery lead time may be evaluated. The contractor must provide proof of Good Standing with the Colorado Secretary of State and an insurance certificate before contract execution. Written inquiries are due November 4, 2026, with responses published November 6, 2026. The estimated award date is November 16, 2026. Respondents must complete Colorado Vendor Self Service registration and submit W9 and PERA forms; optional certifications for small business, minority-owned, woman-owned, and service-disabled veteran-owned status may be claimed with supporting documentation.