Repair B707 Heating and Ventilation Systems
Closed Solicitation Posted
This opportunity was awarded. See the award notice from .
- Solicitation number
- FA6670-26-B-0002
- Agency
-
Reserve Command
Air Force, Department of Defense
- Responses due
- Set-aside
- Service-Disabled Veteran-Owned Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Niagara Falls, New York 14304, United States
Notice details come from SAM.gov. Updated .
About this opportunity
The Department of the Air Force Reserve Command seeks repair of heating and ventilation systems in Building B707 at Niagara Falls Air Reserve Station, with bids due June 1, 2026, by 1:30 PM (amended from the original May 22 deadline). The procurement is a 100 percent Service-Disabled Veteran-Owned Small Business set-aside.
Place of performance is Niagara Falls, New York. Work involves replacement of two climate control units and two condensing units, demolition and disposal of existing equipment, and installation of valves, piping, venting, insulation, and electrical components. The climate control units must include a DX cooling coil rated at 97,000 BTU/HR with 4,000 CFM supply and return air, plus two hot water reheat coils; the condensing units must each provide 158,000 BTU/HR capacity on three-phase 480V power with a minimum of three stages of unloading control. Existing refrigerant is R-22 (prohibited for replacement); contractors must select an EPA SNAP-approved alternative refrigerant with zero ozone depletion potential. All personnel requesting base access must present a valid State Enhanced or Real ID or valid United States Passport. Performance time is 45 calendar days from notice to proceed. A mandatory site visit was held April 29, 2026; site visit questions and answers were posted May 20, 2026. The contract is Firm Fixed-Price with performance and payment bonds required within 10 calendar days of award. NAICS code is 236220; PSC is Z1BZ. Davis-Bacon prevailing wage requirements apply per Wage Determination NY20260019, effective May 18, 2026. Amendment 1 (May 20) extended the bid opening date; Amendment 2 (May 28) incorporated revised wage determination. Electronic bid submissions will not be accepted.
Notice text
4 versions
Update #4 · Latest ·
28 May 2026
Amendment 2 posted. Revised Wage Determination posted.
________________________________________________________
20 May 2026
Amendment 1 posted. Bid Opening dated extended to 1 June 2026 at 1330.
Site Visit Questions and Answers posted.
________________________________________________________
29 April 2026
Site Visit Sign In Sheets posted
________________________________________________________
A Site Visit has been scheduled for-
Wednesday April 29, 2026 at 9:30 am
Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by noon on Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
___________________________________________________________
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair B707 Heating and Ventilation Systems.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 26-0005, Repair Heating and Ventilation Systems B707, to include the following: This project will replace climate control units and condensing units in B707. Demolish and dispose the existing control and condensing units. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate complete and proper installation.
oWork will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Update #3 ·
20 May 2026
Amendment 1 posted. Bid Opening dated extended to 1 June 2026 at 1330.
Site Visit Questions and Answers posted.
________________________________________________________
29 April 2026
Site Visit Sign In Sheets posted
________________________________________________________
A Site Visit has been scheduled for-
Wednesday April 29, 2026 at 9:30 am
Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by noon on Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
___________________________________________________________
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair B707 Heating and Ventilation Systems.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 26-0005, Repair Heating and Ventilation Systems B707, to include the following: This project will replace climate control units and condensing units in B707. Demolish and dispose the existing control and condensing units. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate complete and proper installation.
oWork will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Update #2 ·
29 April 2026
Site Visit Sign In Sheets posted
________________________________________________________
A Site Visit has been scheduled for-
Wednesday April 29, 2026 at 9:30 am
Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by noon on Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
___________________________________________________________
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair B707 Heating and Ventilation Systems.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 26-0005, Repair Heating and Ventilation Systems B707, to include the following: This project will replace climate control units and condensing units in B707. Demolish and dispose the existing control and condensing units. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate complete and proper installation.
oWork will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Update #1 ·
A Site Visit has been scheduled for-
Wednesday April 29, 2026 at 9:30 am
Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304
Instructions to obtain base access can be found in Section L-002.
Attachment 4 MUST be e-mailed to Contracting Office by noon on Monday 27 April 2026.
**PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport**
Prime contractors, subcontractors and/or suppliers may attend the site visit.
___________________________________________________________
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair B707 Heating and Ventilation Systems.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 26-0005, Repair Heating and Ventilation Systems B707, to include the following: This project will replace climate control units and condensing units in B707. Demolish and dispose the existing control and condensing units. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate complete and proper installation.
oWork will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 45 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106.
The NAICS code is 236220 and the Small Business Size Standard is $45,000,000.
Electronic bid submissions will not be accepted or returned.
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Files
Show all 11
Notice history
| Notice | Type | Posted |
|---|---|---|
| Repair B707 Heating and Ventilation Systems | Award Notice | |
| This notice | Solicitation | |
| Repair B707 Heating and Ventilation Systems | Pre-Solicitation |
Similar open opportunities
| Opportunity | Agency | Set-aside | Responses due |
|---|---|---|---|
| Repair Naval Reserve Training Facility B3370 | Air Mobility Command | Total Small Business | |
| Repair Mechanical Systems IDIQ (FY 27-32) | AFLCMC Wright Patterson AFB | No set-aside | |
| Or-bandon marsh NWR-bandon HVAC | — | No set-aside | |
| Cooling Water System Repair and Reliability Project | ENDIST Omaha | No set-aside | |
| HVAC repair JV resource_jordan valley | Oregon-Washington Region | Total Small Business |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity