Kimama & rogerson guard stations flooring

The Bureau of Land Management Idaho Region is soliciting quotations for flooring repair and replacement work at the Kimama and Rogerson Guard Stations located in Minidoka and Twin Falls Counties, Idaho. The scope of work includes demolition of existing flooring materials and installation of ceramic tile flooring (288 square feet), ceramic wall tile (453 square feet), resilient tile flooring (882 square feet), modular carpet tile (140 square yards), and resilient base trim (480 linear feet) at both facilities. This is a firm-fixed-price construction contract estimated between $50,000 and $100,000, classified under NAICS code 238330 (Flooring Contractors). Award will be made to the lowest price responsible offeror whose quotation conforms to all solicitation requirements. The original proposal deadline of March 30, 2026 was extended via Amendment 0001 to April 2, 2026 at 10:00 a.m. MDT, and a mandatory site inspection tour was conducted on March 18, 2026 at Kimama Guard Station, with the Contracting Officer Patricia A. Fort available at (208) 373-3910 or pfort@blm.gov for questions.

This acquisition is designated as a Total Small Business set-aside with a small business size standard of $19.0 million. The contract period of performance runs from April 13, 2026 through June 20, 2026, with the contractor required to commence work within 10 calendar days of receiving the notice to proceed and complete all work within 60 calendar days, subject to liquidated damages of $700 per day for delays. Quotations must remain valid for a minimum of 60 days, and the successful contractor must furnish performance and payment bonds totaling 100 percent of the contract price within 10 days of award. Work must comply with prevailing wage rates determined by the Department of Labor, ranging from $14.26 to $40.00 per hour depending on trade classification, and must adhere to Buy American construction material requirements and Davis-Bacon prevailing wage compliance standards. All offerors must be registered in the System for Award Management (SAM) and meet applicable federal, state, and local requirements, including contractor certifications and representations as specified in the solicitation documents.