Solicitation_for_Posting.pdf

Renovate Fire Station NAICS Code: 236220 Size Standard: $36,500,000.00 Set Aside: Total Small Business

Build / Renovate Fire Station Project Location Number: PSTE 139022, PSTE 122002 Location: Joint Base McEntire, Eastover, SC 29044 Project Magnitude is Betw een $5,000,000.00 to $10,000,000.00 This Project is Being Solicited Pursuant to FAR 14.2 - Solicitation of Bid

Funds are not presently available for this contract. Currently, the Government anticipates funds w ill become available prior to but no later than midnight 30 September 2019. This action has been identif ied on the National Guard priority list for aw ard if funds become available and the prices received are w ithin an aw ardable range.

Aw ard w ill be made to the responsible bidder w hose bid conforms to the invitation for bids and is the most advantageous to the Government considering only price and price related factors.

X

CHRISTOPHER ALLAN JONES 8032992043

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

19-Jul-2019

(RFP)

(IFB)

CALL:

Repair and Add To Fire Station, Building 62

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________540 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________21 Aug 2019 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______42 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USPFO FOR SOUTH CAROLINA

9 NATIONAL GUARD ROAD

COLUMBIA SC 29201-4763

W912QG

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

PSTE 122022 & 139022

8. ADDRESS OFFER TO (If Other Than Item 7)

8032991540FAX:TEL: 8032991450 TEL: FAX:

W912QG19B0002 53

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912QG19B0002

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Firestation Construction, PSTE 139022

FFP

MILCON: Provide all plant, labor, new and current material, transportation, tools, equipment, appliances, supplies, services, permits, insurance and supervision necessary to construct a 9,169 SF Crash, Fire and Resucue Fire addition (apparatus/vehicle bay) to the existing Fire Station utilizing conventional construction methods to accomodate the mission of the facility. Construct PEMB facility, slab on grade, with roof, architecturally compatible to existing facility.

Provide mechanical, electrical, fire protection and detection, communication and plumbing systems as required. Provide lighting and floor and ceiling finishes as necessary. Provide pavements and site improvements FOB: Destination MFR PART NR: Construction

NET AMT

0002 1 Job Firehouse Renovation, PSTE 122002

FFP

Nonpersonal services: Major demolition, renovation and reconfiguration of 8,231 SF interior spaces, wall, floor, and ceiling systems to include coverings and finishes. Reconfigure electrical, plumbing, and mechanical systems as necessary.

Repair building envelope to include windows and doors for force protection purposes and for high performance building energy measure requirements. Replace heating, ventilation, and air conditioning system and affiliated boilers. Provide communications support for alarm room reconfiguration. Repair exterior pavements and provide site work.

MFR PART NR: Renovation

0003 1 Job OPTION C01: Carport Paving

FFP

See plans and specifications

MFR PART NR: Option

0004 1 Job OPTION A01:Manufactured Aluminum Canopy Carport

FFP

See plans and specifications

0005 1 Job OPTION A02:Translucent Daylight Panels in Bay

FFP

See plans and specifications

0006 1 Job OPTION A03: Overhead Coiling Door in Bay

FFP

See plans and specifications

0007 1 Job OPTION A04: Daylighting Tubes

FFP

See plans and specifications

0008 1 Job OPTION C02: Dumpster Pad

FFP

See plans and specifications

0009 1 Job OPTION A05: Upgrade Storefront

FFP

See plans and specifications

0010 1 Job OPTION A06: Rooftop Daylighting Monitor

FFP

See plans and specifications

0011 1 Job OPTION A07: Upgrade Painted CMU Walls

FFP

See plans and specifications

0012 1 Job

CMRA

FFP

The contractor shall report ALL contractor labor hours (including subcontractor labor hours) required for performance under this contract for the South Carolina Army National Guard via a secure data collection site. The contractor is required to completely fill in all required data fields using the following web address:

http://www.ecmra.mil/.

Reporting inputs will be for the labor executed during the performance period during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year beginning with 2019.

Contractors may direct questions to the help desk at: http://www.ecmra.mil. This requirement applies to CLINS: 0002, 0009, 0010 and 0011.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government 0005 N/A N/A N/A Government 0006 N/A N/A N/A Government 0007 N/A N/A N/A Government 0008 N/A N/A N/A Government 0009 N/A N/A N/A Government 0010 N/A N/A N/A Government 0011 N/A N/A N/A Government 0012 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 N/A N/A N/A N/A

0005 N/A N/A N/A N/A

0006 N/A N/A N/A N/A

0007 N/A N/A N/A N/A

0008 N/A N/A N/A N/A

0009 N/A N/A N/A N/A

0010 N/A N/A N/A N/A

0011 N/A N/A N/A N/A

0012 N/A N/A N/A N/A

SECTION 00010 Solicitation Contract Form

TABLE OF CONTENTS

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00010 - BID SCHEDULE, NOTES

SECTION 00100 - INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

SECTION 00600 – REPRESENTATIONS & CERTIFICATIONS

SECTION 00700 - CONTRACT CLAUSES

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

ATTACHMENT 1 – PLANS AND SPECIFICATIONS Project # PSTE 122022 and PSTE 139022 Dated 14 May

SECTION 00010 NOTES

NOTES

1. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.fbo.gov.

2. Facsimile transmission of bid is not authorized. Electronic submission of bids will NOT be accepted.

3. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.fbo.gov. For security reasons, all potential offerors, plan rooms and printing companies are required to be registered in the GSA System for Award Management (SAM) database. Firms can register via the SAM internet site at https://www.sam.gov/portal/public/SAM/. Interested bidders are required to submit their representations and certifications at the same site.

4. A complete bid package must contain the following:

(a) Offer, Standard Form (SF) 1442 front and back signed

(b) Section 00010 Line Items- all items must be priced

(c) An Original Bid Bond and original Power of Attorney is required along with the bid on the due date.

(d) Section 00600, Representations and Certifications, completed and return only additional certifications found in this section In addition, the offeror must have entered current and complete data within the past year in Online Representations and Certifications at www.sam.gov.

(e) When completing the “Offeror” portion of the SF 1442 (Blocks 14 – 20), an official having the authority to contractually bind the company must sign the SF 1442 in accordance with FAR 4.102.

One copy of the SF1442 is required to have an original signature.

(f) All amendments to the solicitation must be acknowledged.

(g) Mark the front of the envelope with the following: BID No. W912QG-19-B-0002, and the Name and

Address of Bidder. See Block 13A of SF 1442 for required number of copies.

5. Joint Venture Requirements - Parties wishing to propose as a joint venture must submit, with the Pro Forma documents, an executed copy of the joint venture agreement. The joint venture agreement shall be executed in accordance with FAR 4.102(d). Each joint venture partner shall submit evidence satisfactory to the Contracting Officer that its Board of Directors has approved its participation in the joint venture or by an instrument of similarly binding character in the case of an unincorporated entity. Offerors are reminded that to obtain an award the awardee, to include a joint venture, must be registered in the System for Award Management (SAM) database.

Applicable to set-aside solicitations: Joint Ventures must meet applicable size standards (See FAR Subpart 19.1).

Submit with the proposal any size determination for the Joint Venture entity received from the Small Business Administration. A Joint Venture where-in one party is not a small business may be referred to the Small Business Administration ( IAW FAR 19.302 (b)) to determine eligibility. All questions regarding Joint Ventures must be directed to the Small Business Administration (SBA) and not the Contracting Officer.

NOTE: An Original Bid bond and Original Power of Attorney is required with submission of the bid.

The bid bond is due on the date as stated on the SF1442 block 13. The bid bond must be on a SF24 form.

Rejection of a bid bond shall be in accordance with FAR 28.101-4 Noncompliance with bid guarantee requirements.

End of Section 00010 word document

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO OFFERORS

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. Description of the Project: The project is a combination of MILCON and SRM funding. PSTE 139022

(MILCON) will be used to construct a 9,169 SqFt crash, fire, and rescue building addition (apparatus/vehicle bay) to the existing fire station. Construction will utilize conventional construction methods. PSTE 122002 (SRM) will be used for major demolition, renovation and reconfiguration of 8,231 SqFt on interior spaces, wall, floor and ceiling systems to include coverings and finishes.

2. Instructions to Bidders:

2.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled W912QG-19-B-0002 entitled Repair and Add to Fire Station, Building 62, Project Numbers PSTE 122022 and PSTE 139022, at McEntire Joint National Guard Base, Eastover, SC

2.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price.

2.3. This solicitation is set-aside 100% for small businesses.

3. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

3.1. A pre-bid conference will be conducted on 01 August 2019 at 9:00 AM for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at Joint Base McEntire. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

3.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to SGT Christopher Jones at the following addresses:

christopher.a.jones292.mil@mail.mil AND james.o.robinson10.mil@mail.mil.

Firm Name and Telephone Number Visitor’s Name and Social Security No.

Drivers License Citizenship

3.3. This information must be provided in advance, 5 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

3.4. Visitors must pick up their passes at the Installation’s Main Entry Gate prior to arrival. You will be required to present the following information upon arrival: (1) Vehicle Registration, (2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Safety Inspection and Car Rental agreement if applicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

3.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

3.6. A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

4. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

4.1. Submit all questions in the format shown below by email to the contracting office at the addresses show below. Do NOT contact AE or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line: Reference No. SOLICITATION W912QG-19-B-0002 Email: christopher.a.jones292.mil@mail.mil AND james.o.robinson10.mil@mail.mil.

PRE-BID INQUIRY FORMAT

Date of Bid Inquiry: _______________

From: ______________________________ Company Name: ________________________________

Address:_____________________________________________________________________________

Phone Number: _____________________________ Fax Number:______________________________

Email address: ________________________________________________________________________

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

4.1. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

4.2. All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to bid opening. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS

EARLY IN THIS PROCESS.

4.3. Any changes to the drawings, specifications, etc. will be issued in the form of an amendment.

However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on FBO at http://www.fbo.gov

4.4. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

4.5. RESERVED.

4.5.1. Amendments, if/when issued will be posted to https://www.fbo.gov/ for electronic downloading.

This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

5. BID REPOSITORY AND BID OPENING:

5.1. A bid repository is provided for hand carried bids and is located at 1 National Guard Road, Columbia, SC 29201. Hand carried bids must be deposited in the repository prior to the time established for opening of bids.

Bidders are cautioned that they will be required to sign-in and obtain a visitor’s pass to enter the facility and should allow time to accomplish this. See instructions for obtain access to the base in the Site Visit instruction. Follow the same instruction for obtaining entry to hand carry bid. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

5.2. The bid opening will occur at the time and date specified in Block 13 of the SF1442 1 National Guard

Road, Columbia, SC 29201. All interested offerors and their major subcontractors are encouraged to attend the bid opening.

6. WAGE DETERMINATION:

6.1. Construction Wage Rates are applicable to this project are SC190028, 04/19/2019 SC28 for

Richland County, SC as shown in Section 00800.

7. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS: This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

8. CLAUSES:

8.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

9. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids including the bid bond.

10. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

11. Subcontracting Plan – –NOT REQUIRED.

12. List of Brand Name or Sole Source Justifications posted on FBO

1. HVAC Controls/Harris Integrated Solutions

2. Carpet Tile/

3. Cores and Lockset/Best

4. Fire Alarm System/Monaco Enterprises, Inc

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-22 Alternative Line Item Proposal JAN 2017 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.219-2 Equal Low Bids OCT 1995 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.232-38 Submission of Electronic Funds Transfer Information with Offer

JUL 2013

252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

CLAUSES INCORPORATED BY FULL TEXT

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed price contract resulting from this solicitation.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

23.4% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

Eastover, South Carolina; Richland County

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Office of Chief Counsel ATTN: NGB Protest Decision Authority 111 S. George Mason Drive Arlington, VA 22204-1373 FAX: (703) 607-3684 or 3682

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for:

01 August 2019 at 9:00 AM

(c) Participants will meet at:

Joint Base McEntire 169th FW CE Conference Room 1325 South Carolina Roadt, Suite 8 Eastover, SC 29044

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any DFARS (48 CFR Chapter Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00600 - Representations & Certifications

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an…