Solicitation_W912PA-17_R-0006.pdf

0011038590

Improve Street Lighting, Chievres Air Base, Belgium

PROJECT: R-CH #O2-16031-16

MAGNITUDE: Estimated betw een $ 250,000.00 and $ 500,000.00

INSTRUCTIONS TO OFFERORS: Offerors shall submit the documentation requested in Section L, Instructions to Offerors, as w ell as complete the Representations and Certif ications (Reps & Certs) in Section K. Offerors shall also submit Section A of the SF1442 w ith completed blocks #14,15,16,17,20a,20c, and block #19 if Amendments w ere issued.

SITE VISIT: An organized site visit has been scheduled for Wednesday, 6 September 2017 at 12.00 hrs. Participants w ill meet at Gate 14, Chievres Air Base, 7950 CHIEVRES (Belgium).

POINT OF CONTACT (POC) for technical info and site visit : Please contact David Diricq to confirm attendance to the Site Visit at david.diricq.ln@mail.mil.

DRAWINGS: Draw ings w ill be made available at the site visit. Any bidders unable to attend site visit may request draw ings via email to:lindsay.k.carrington.civ@mail.mil AND usarmy.rheinland-pfalz.409-contr-spt-bde.mbx.409csb-bru-request@mail.mil. A delay in receipt of draw ings w ill not extend the closing date.

LINDSAY K. CARRINGTON +3227179617

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

24-Aug-2017

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________200 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________25 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US MILITARY FORCE - RCO BENELUX

MARIETA LUNA

32-2-7179616

LEUVENSESTEENWEG 13

SINT-STEVENS-WOLUWE 1932

W912PA

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

09:00 AM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

00-32-2-7179610FAX:TEL: 00-32-2-7179616 TEL: FAX:

W912PA-17-R-0006 58

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912PA-17-R-0006

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job As Built Drawings

FFP

The contractor shall be responseible for the delivery of precise and accurate as-built drawings to the Contracting Officers Representative (COR) with the implantation of cables and posts in accordance with (IAW) paragraph G-01 of the Statement of Work (SOW)..

FOB: Destination

PURCHASE REQUEST NUMBER: 0011038590

NET AMT

0002 1 Job Work Site Preparation

FFP

(IAW) the specifications identified in TP-1-02 of the Statement of Work (SOW).

0003 1 Job Dismounting Work

FFP

(IAW) the specifications identified in TP-1-03 of the Statement of Work (SOW).

0004 650 Meter Trenching in Natural Ground

FFP

(IAW) the specifications identified in TP-2-01 of the Statement of Work (SOW).

0005 23 Meter Drilling Under Road

FFP

(IAW) the specifications identified in TP-2-02 of the Statement of Work (SOW).

0006 46 Meter Open and Close Concrete Overlays

FFP

The contractor shall be responsible for the opening and closing of concrete overlays (IAW) the specifications identified in TP-2-03 of the Statement of Work

(SOW).

0007 31 Meter Open and Close Hydrocarbon Overlays

FFP

(IAW) the specifications identified in paragraph TP-2-04 of the Statement of Work

(SOW).

0008 27 Each Earthwork for Base

FFP

(IAW) the specifications identified in TP-2-05 of the Statement of Work (SOW).

0009 27 Each Concrete Work for Bases

FFP

(IAW) the specifications identified inTP-3-01 of the Statement of Work (SOW).

0010 13 Each Existing Light Posts 12m high/2m arm

FFP

The contractor shall install thirteen (13) 12m high/2m arm light posts currently in the Government's possession i(IAW) the specifications identified in TP-3-02 of the Statement of Work (SOW)..

0011 18 Each New Light Posts 12m high/3m arm

FFP

The posts shall be column type and shall be made of similar finishing as the ones already installed. The light posts shall conform to the specifications identified in paragraph TP-3-02 of the SOW.

Each post shall be fitted with an identification mark mentioned on the as-built drawing the contractor shall provide to the COR. On straight sections, the contractor shall properly align the posts. The final implantation must be approved by the COR before any earthwork.

Concerns: fixed light columns.

Unit: each.

0012 1 Job Electric Connections and Protections

FFP

The contractor shall be responsible for all connections and all necessary protections in the existing sidewalk cabinets, as well as inside the electrical substations, (IAW) the specifications identified in TP-4-01 of the SOW.

0013 17 Each LED Light Fixture Type Ia

FFP

The contractor shall install light fixtures of traffic type, and (IAW) the specifications identified in TP-4-02 of the SOW.

0014 30 Each LED Light Fixture Type Ib

FFP

The contractor shall install light fixtures of traffic type, and (IAW) the specifications identified in TP-4-02 of the SOW.

0015 1 Job Dimming System + Astronomic Clock

FFP

The contractor shall install a dimming system with astronomic clock in accordance with (IAW) the specifications identified in paragraph TP-4-02,c, II Dimming.

0016 24 Each Connection of Distribution Cables

FFP

The contractor shall be responsible for the connection of the existing distribution cables located at the bottom of the light posts, (IAW) the specifications identified in TP-4-03 of the SOW.

0017 770 Meter Supply/ Installation of Electric Cables

FFP

The contractor shall be responsible for the supply and installation of electric cables (IAW) the specifications identified in TP-2-01 and TP-4-03 of the SOW.

0018 770 Meter Supply/ Installation of Copper Cable

FFP

The contractor shall be responsible for the supply and installation of bare copper cables (IAW) the specifications identified in TP-2-01 and TP-4-03 of the SOW.

0019 590 Meter OPTION Trenching in Natural Ground

FFP

(IAW) the specifications identified in TP-2-01 of the Statment of Work (SOW).

0020 39 Meter OPTION Drilling Under Road

FFP

(IAW) the specifications identified in TP-2-02 of the Statment of Work (SOW).

0021 1 Meter OPTION Open and Close Concrete Overlays

FFP

The contractor shall be responsible for the opening and closing of concrete overlays in accordance with (IAW) section TP-2-03 of the Statement of Work

(SOW).

0022 1 Meter OPTION Open and Close Hydrocarbon Overlays

FFP

(IAW) the specifications identified in TP-2-04 of the Statment of Work (SOW).

0023 1 Meter OPTION Earthwork for Base

FFP

(IAW) the specifications identified in TP-2-05 of the Statment of Work (SOW).

0024 1 Meter OPTION Concrete Work for Bases

FFP

(IAW) the specifications identified in TP-3-01 of the Statment of Work (SOW).

0025 8 Each OPTION New Light Posts 12m high/3m arm

FFP

The posts shall be column type and shall be made of similar finishing as the ones already installed. The light posts shall conform to the specifications identified in paragraph TP-3-02 of the SOW.

Each post shall be fitted with an identification mark mentioned on the as-built drawing the contractor shall provide to the COR. On straight sections, the contractor shall properly align the posts. The final implantation must be approved by the COR before any earthwork.

0026 3 Each OPTION New Light Posts 10m high

FFP

The posts shall be column type and shall be made of similar finishing as the ones already installed. The light posts shall conform to the specifications identified in paragraph TP-3-02 of the SOW.

Each post shall be fitted with an identification mark mentioned on the as-built drawing the contractor shall provide to the COR. On straight sections, the contractor shall properly align the posts. The final implantation must be approved by the COR before any earthwork.

0027 1 Job OPTION Electrical Connections and Protections

FFP

The contractor shall be responsible for all connections and all necessary protections in the existing sidewalk cabinets, as well as inside the electrical substations, as required by paragraph TP-4-01 of the SOW.

0028 8 Each OPTION LED Light Fixture Type Ib

FFP

The contractor shall install light fixtures of traffic type, and in accordance with paragraph TP-4-02 of the SOW.

0029 3 Each OPTION LED Light Fixture Type Ic

FFP

The contractor shall install light fixtures of traffic type, and in accordance with paragraph TP-4-02 of the SOW.

0030 1 Job OPTION Dimming System + Astronomic Clock

FFP

The contractor shall install a dimming system with astronomic clock that conforms to the specifications identified in paragraph TP-4-02, c, II Dimming.

Generally, the light fixture shall be equipped with a dimmer system to reduce the consumed energy via a smart management system on the light that will adapt the illumination level according to the needs of each user and to the environmental conditions.

This system shall be decentralized and will be based on a permanent and safe communication between each lamp, motion sensors and electronic modules on each light fixture able to select the suitable configuration.

This system shall be autonomous, as it will just need to use the modules on the light fixtures to run, without any centralized controller.

0031 11 Each OPTION Connection of Distribution Cables

FFP

The contractor shall be responsible for the connection of the existing distribution cables located at the bottom of the light posts, as stated in paragraph TP-4-03 of the SOW.

0032 650 Meter OPTION Supply/ Installation of Electric Cables

FFP

The contractor shall be responsible for the supply and installation of electric cables as required by paragraphs TP-2-01 and TP-4-03 of the SOW.

0033 650 Meter OPTION Supply/ Installation of Copper Cable

FFP

The contractor shall be responsible for the supply and installation of bare copper cables as required by paragraphs TP-2-01 and TP-4-03 of the SOW.

Section E - Inspection and Acceptance

CONVENTIONAL FORCES EUROPE

CONVENTIONAL FORCES EUROPE (CFE) TREATY VERIFICATION INSPECTION

Contractor-owned or controlled structures and containers located on U.S. Government installations are subject to short-notice inspections by CFE treaty inspection teams. The Government will endeavor to provide the Contractor as much notice as possible in the event of such inspections. The contractor shall provide access to such structures and containers at the request of the Government. The Contractor shall report such inspections to the Contracting Officer in writing within ten (10) calendar days of completion of the inspection. Contractor-owned or controlled structures and/or containers on U.S. installations may have to be inspected to comply with the CFE treaty even if Contractor personnel are unavailable to provide access. Any costs borne by the Contractor or any impact on contract performance as a result of the inspection will be a matter of negotiation between the Contractor and the Contracting Officer.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government 0012 Destination Government Destination Government 0013 Destination Government Destination Government 0014 Destination Government Destination Government 0015 Destination Government Destination Government 0016 Destination Government Destination Government 0017 Destination Government Destination Government 0018 Destination Government Destination Government 0019 Destination Government Destination Government 0020 Destination Government Destination Government 0021 Destination Government Destination Government 0022 Destination Government Destination Government 0023 Destination Government Destination Government 0024 Destination Government Destination Government 0025 Destination Government Destination Government 0026 Destination Government Destination Government 0027 Destination Government Destination Government 0028 Destination Government Destination Government 0029 Destination Government Destination Government 0030 Destination Government Destination Government

0031 Destination Government Destination Government 0032 Destination Government Destination Government 0033 Destination Government Destination Government

CLAUSES INCORPORATED BY FULL TEXT

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

Section F - Deliveries or Performance

NOTICE TO PROCEED

The notice to proceed will be provided as indicated below:

[__________] The effective date of contract will constitute the date of notice to proceed.

[___X______] A notice to proceed letter will be issued.

[__________] The date of the letter transmitting the contract will constitute the date of the notice to proceed.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 200 dys. ADC 1 BENELUX

MR. JEAN-PHILIPPE DI NANNO

20006 CHIEVRES AIR BASE

7950 CHIEVRES

BELGIUM

068/27-56-64

WK3E47

0002 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0003 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0004 200 dys. ADC 650 (SAME AS PREVIOUS LOCATION)

0005 200 dys. ADC 23 (SAME AS PREVIOUS LOCATION)

0006 200 dys. ADC 46 (SAME AS PREVIOUS LOCATION)

0007 200 dys. ADC 31 (SAME AS PREVIOUS LOCATION)

0008 200 dys. ADC 27 (SAME AS PREVIOUS LOCATION)

0009 200 dys. ADC 27 (SAME AS PREVIOUS LOCATION)

0010 200 dys. ADC 13 (SAME AS PREVIOUS LOCATION)

0011 200 dys. ADC 18 (SAME AS PREVIOUS LOCATION)

0012 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0013 200 dys. ADC 17 (SAME AS PREVIOUS LOCATION)

0014 200 dys. ADC 30 (SAME AS PREVIOUS LOCATION)

0015 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0016 200 dys. ADC 24 (SAME AS PREVIOUS LOCATION)

0017 200 dys. ADC 770 (SAME AS PREVIOUS LOCATION)

0018 200 dys. ADC 770 (SAME AS PREVIOUS LOCATION)

0019 200 dys. ADC 590 (SAME AS PREVIOUS LOCATION)

0020 200 dys. ADC 39 (SAME AS PREVIOUS LOCATION)

0021 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0022 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0023 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0024 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0025 200 dys. ADC 8 (SAME AS PREVIOUS LOCATION)

0026 200 dys. ADC 3 (SAME AS PREVIOUS LOCATION)

0027 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0028 200 dys. ADC 8 (SAME AS PREVIOUS LOCATION)

0029 200 dys. ADC 3 (SAME AS PREVIOUS LOCATION)

0030 200 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0031 200 dys. ADC 11 (SAME AS PREVIOUS LOCATION)

0032 200 dys. ADC 650 (SAME AS PREVIOUS LOCATION)

0033 200 dys. ADC 650 (SAME AS PREVIOUS LOCATION)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 200 days after the Notice to Proceed is issued.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of 159.EURO for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Section G - Contract Administration Data

ELECTRONIC FUNDS TRANSFER

FOREIGN VENDORS REQUESTING PAYMENT VIA ELECTRONIC FUNDS TRANSFER

Foreign vendors requesting payment via Electronic Funds Transfer (EFT) shall provide the following information on their invoice at time of invoice submission. Only one EFT instruction per invoice is authorized.

- Bank Name:

- Bank Identification Code (BIC):

- International Bank Account Number (IBAN):

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS

(JUNE 2012)

(a) Definitions. As used in this clause–

(1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(4) Receiving report means the data required by the clause at 252.246-7000, Material Inspection and Receiving Report.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/.

(c) The Contractor may submit a payment request and receiving report using other than WAWF only when–

(1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer's determination with each request for payment;

(2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System);

(3) DoD makes payment for rendered health care services using the TRICARE Encounter Data System (TEDS) as the electronic format; or

(4) When the Governmentwide commercial purchase card is used as the method of payment, only submission of the receiving report in electronic form is required.

(d) The Contractor shall submit any non-electronic payment requests using the method or methods specified in Section G of the contract.

(e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payments requests.

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

CONSTRUCTION

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

DIRECTORATE OF PUBLIC WORKS

UNIT 21419

APO AE 09708

DODAAC: WK3E47

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC W56FJX Issue By DoDAAC W912PA Admin DoDAAC W912PA Inspect By DoDAAC WK3E47 Ship To Code WK3E47 Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) WK3E47 Service Acceptor (DoDAAC) WK3E47 Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

JEAN-PHILIPPE DI NANNO

jean-philippe.dinanno.ln@mail.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

LINDSAY K CARRINGTON

Lindsay.k.carrington.civ@mail.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section H - Special Contract Requirements

SPECIAL INSTRUCTIONS

SYSTEM FOR AWARD MANAGEMENT (SAM)

Only contractors who are registered and have an active account in the System for Award Management (SAM) may be awarded a contract as a result of this solicitation.

WIDE AREA WORKFLOW (WAWF) SYSTEM

Payment for this acquisition will be made through the Wide Area Workflow (WAWF) system. Contractors shall be registered in WAWF. See web site https://wawf.eb.mil for registration. Additional WAWF information is included in FAR Clauses 252.232-7003 & 252.232-7006.

PERMITS AND RESPONSIBILITIES

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any applicable laws, codes, and regulations applicable to the performance of the work. The Contractor shall also take proper safety and health precautions to protect the work, the workers, the public, and the property of others. The Contractor shall be responsible for all damages to persons or property that occur as a result of the Contractor’s fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work that may have been accepted under the contract.

LIABILITY

For the purpose of this contract the Contractor is considered as an independent Contractor and not as an agent of the US Government. During the performance the Contractor shall be liable and will indemnify and hold harmless the Government, its agents and employees against any actions or claims for all damages to persons or property, including death arising or resulting from fault, negligence, wrongful act or wrongful omission of the Contractor.

TRANSLATION

Drawings, specifications, instructions, or other documents furnished to the Contractor by the Government in connection with the performance of the work shall be in the English language only. Such translations thereof as are necessary or proper for the performance of the work shall be provided by the Contractor. Errors or omissions in such translations from the Government furnished drawings, specifications, instructions or other documents shall be the responsibility of the Contractor. The English text shall apply in the event of disagreements occasioned by differences between the text and the Contractor’s translation of drawings, specifications, instructions or other documents furnished by the Government pursuant to the provisions of the contract. All correspondence, drawings, and other documents submitted by the Contractor shall be entirely in English, except as otherwise provided in the contract.

PREPARATION, SUBMISSION OF INVOICES AND PAYMENT

Contractor shall submit his invoice electronically through the Wide Area Workflow (WAWF) online application system for payment. WAWF Instructions are being provided to the Contractor under separate cover upon request.

WAWF also provides online training: https://wawf.eb.mil/. Invoice must include the appropriate amount due, percentage of work completed, or an itemized listing of quantities (by building, if applicable) and a description of items and discounts accurate in accordance with the Schedule and the terms and conditions of the contract. In addition, the invoice shall specify the date on which all work, or to portion or percentage of work invoiced under the contract, was completed. Taxes and duties will be listed and excluded from invoice prices.

ENVIRONMENTAL LAWS.

All materials should meet regional, provincial, national and local ecology laws in respect to all materials and their disposal. Contractor will be insured against and solely responsible for any ecological damage caused both to US and Host Nation interested parties. Furthermore, the Contractor agrees to hold the US Government harmless in any lawsuit concerning ecological damages.

WEATHER DELAYS

Reference paragraph (b) (1), FAR 52.249-10 Clause “DEFAULT (FIXED PRICE CONSTRUCTION) (APR 1984)”. Unless unusually severe (seasonal) weather conditions prevails, no extension will be granted for delays experienced by the Contractor. A log book shall be kept by the Contractor to record weather conditions, and any eventual inclemency’s which may preclude the continuation of work in accordance with the requirements of tender document “Marchés Publics – 1978, chapter I, Item 28” (for BELGIUM). This log book shall be presented as a summary of the work performed, the weather conditions and the report on personnel attendance on the work site. It shall serve as a base for determining the final completion date of the works.

PERFORMANCE STANDARDS

(a) In the event of conflict between the applicable standards and any requirement or condition of the specifications and the contract, the specifications and the contract shall govern.

(b) Copies of the applicable Belgian standards and regulations will not be furnished with this specifications. US Army, Government specifications, regulations and other publications made part of this contract by reference herein are available for reading at the local facilities engineering office located at :

USAG BENELUX

Directorate of PublicWorks, Engineering Division Hangar #6 Chievres Air Base 7950 Chievres, Belgium

MEASUREMENTS AND QUANTITIES

Unless stated otherwise, all quantities and measurements listed in the specifications, drawings, and price breakdown are estimates only. The offeror themselves shall familiarize with the job site, determine the extent, nature and scope of work as appropriate.

CONSERVATION OF ELECTRICITY AND WATER

The United States Government will make available to the Contractor, from existing outlets and supplies, all reasonably required amounts of electricity and water free of charge to the Contractor. The Contractor shall carefully conserve utilities furnished without charge.

GOVERNMENT-FURNISHED UTILITIES

Utilities. Water and electrical power required for the execution of this project will be made available to the Contractor without charge, in accordance with the contract clause “AVAILABILITY AND USE OF UTILITY SERVICES (APRIL 1984), FAR 52.236-14. Necessary connections to lines shall be made by the Contractor without additional cost to the Government. Electrical connections or temporary installations shall be made in accordance with VDE 0100. No other material, equipment, or services shall be furnished by the Government unless expressly stated elsewhere herein.

Telephones. Telephone facilities shall be made available without charge at a location designated by the Contracting Officer to make calls within the military reservation areas only. Use of telephones in family quarters by the Contractor or his/her employees or Sub-Contractors is strictly prohibited.

U.S. AND HOST NATION HOLIDAYS

US Holidays: Work Shall be performed on U.S. holidays occurring during the normal workweek. When a U.S holiday occurs on a Saturday or a Sunday, the holiday is observed on the preceding Friday or following Monday, respectively.

Host Nation Holidays: Work Shall Not be performed on local Host Nation* holidays occurring during the normal workweek.

* Local host nation holidays occur in the region/state where contract performance takes place.

The U.S. holidays are:

New Year's Day January 1st

M L King Memorial Day 3d Monday in January

Presidents' Day 3d Monday in February Memorial Day last Monday in May Independence Day July 4th

Labor Day 1st Monday in September Columbus Day 2d Monday in October Veterans' Day November 11th Thanksgiving Day 4th Thursday in November Christmas Day December 25th

The Belgium holidays are:

New Year’s Day 01 January Easter Monday varies yearly Labor Day 01 May Ascension Day varies yearly Bank Holiday varies yearly Whit-Monday varies yearly National Independence Day 21 July Assumption 15 August All Saints Day 01 November Armistice Day 11 November Dynasty Day varies yearly Christmas Day 25 December

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-6 Unique Entity Identifier OCT 2016 52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.215-2 Audit and Records--Negotiation OCT 2010 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-29 Notification Of Visa Denial APR 2015 52.222-50 Alt I Combating Trafficking in Persons (MAR 2015) Alternate I MAR 2015 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014 52.228-4 Workers' Compensation and War-Hazard Insurance Overseas APR 1984 52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-29 Terms for Financing of Purchases of Commercial Items FEB 2002 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Items JAN 2017 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.215-7008 Only One Offer OCT 2013 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.225-7993 (Dev) Prohibition on Providing Funds to the Enemy (Deviation

2015-O0016)

SEP 2015

252.229-7000 Invoices Exclusive of Taxes or Duties JUN 1997 252.232-7008 Assignment of Claims (Overseas) JUN 1997 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7005 Airfield Safety Precautions DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea APR 2014

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

(a) Definitions. As used in this clause-- Internal confidentiality agreement or statement means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.

Subcontract means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

Subcontractor means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.

(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.

(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause.

(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 120 days. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF CONTRACT

(FEB 2000)

In the event of inconsistency between any terms of this contract and any translation into another language, the English language meaning shall control.

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

United States law will apply to resolve any claim of breach of this contract.

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work.