W912P614B0008_McCook_Reservoir_Groundwater_Monitoring_Wells_RTA_Specifications.pdf

CHICAGO DISTRICT

LEADERS IN CUSTOMER CARE

SPECIFICATIONS FOR

CHICAGOLAND UNDERFLOW PLAN (CUP)

McCOOK RESERVOIR, ILLINOIS

GROUNDWATER MONITORING WELLS

CONSTRUCTION SOLICITATION

AND SPECIFICATIONS

CERTIFIED FINAL DOCUMENT-

READ TO ADVERTISE (RTA)

W912P6-14-B-0008 June 24, 2014

CUP McCook Reservoir Groundwater Monitoring Wells W912P6-14-R-0008

PROJECT TABLE OF CONTENTS

SECTION TITLE

DIVISION 00 PROCUREMENT & CONTRACTING REQUIREMENTS

00010 SOLICITATION, OFFER, AND AWARD, SF 1442, BIDDING SCHEDULE

00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00600 REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF BIDDERS

00700 CONTRACT CLAUSES

00800 SPECIAL CONTRACT REQUIREMENTS

WAGE RATES

DIVISION 00 – LEVEL 2 – AVAILABLE INFORMATION

00 31 32.13 SUBSURFACE DRILLING AND SAMPLING INFORMATION

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00 GENERAL PROVISIONS

01 11 00 SUMMARY OF WORK

01 22 00 MEASUREMENT AND PAYMENT

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 35 45 CHEMICAL DATA QUALITY CONTROL

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 QUALITY CONTROL

01 45 00.10 QUALITY CONTROL SYSTEM (QCS)

01 52 02 TEMPORARY CONSTRUCTION FACILITIES

01 57 20.01 ENVIRONMENTAL PROTECTION FOR ILLINOIS

01 58 00 PROJECT SIGN AND SAFETY SIGN

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 33 – UTILITIES

33 24 13 GROUNDWATER MONITORING WELLS

-- End of Project Table of Contents –

W81G6641117298

PROJECT TITLE: McCOOK GROUNDWATER MONITORING WELLS

PROJECT DESCRIPTION: The project consists of the installation of seven deep groundw ater w ells around the perimeter of the McCook Reservoir, the abandonment of one existing w ell, and initial chemical sampling of the new ly installed w ells. The w ells w ill require a 10" minimum bore diameter, 300'-500' deep into bedrock. Groundw ater w ells w ill be outf itted w ith dedicated variable speed environmental sampling pumps that are compatible w ith a portable generator (provided by others), groundw ater level transducers w ith internal pow er and datalogging capabilities, and a barometric pressure transducer.

COMPETITION FOR THIS ACQUISITION IS RESTRICTED TO SMALL BUSINESS CONCERNS

The North American Industry Classif ication System Code (NAICS) is 237990, w ith a size standard of $33.5M.

Est. Cost for Construction is betw een $1M and $5M.

Applicable DBA Wage Rates: Wage Determination Number IL140009 dated 06/20/2014.

SITE VISIT/PRE-BID MEETING: A Site Visit/Pre-Bid Meeting is scheduled for 8 July, 2014 at 1:00PM at the Law ndale Avenue Solids Management Area Visitor Center, 7601 S. LaGrange Road, Willow Springs, IL 60480.

Continued on Page 6

X

ALEX HEINZEL 312.846.5368

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

24-Jun-2014

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________310 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________Section 00700

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________28 Jul 2014 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U. S. ARMY ENGINEER DISTRICT, CHICAGO

231 SOUTH LASALLE STREET SUITE 1500

CHICAGO IL 60604-1437

W912P6

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912P6-14-B-0008 27

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Task

MOBILIZATION TO THE PROJECT SITE

FFP

Under this line item, the Contractor will be compensated for the totality of its activities/"tasks" needed to mobilize its equipment and labor force to the project site.

PURCHASE REQUEST NUMBER: W81G6641117298

NET AMT

0002 1 Task

DEMOBILIZATION TO THE PROJECT SITE

FFP

Under this line item, the Contractor will be compensated for the totality of its activities/"tasks" needed to mobilize its equipment and labor force to the project site.

0003 1 Job

TEMPORARY CONSTRUCTION FACILITIES

FFP

0004 1 Job

MONITORING WELLS

0005 1 Job

DECOMISSIONED WELL

0006 11 Each

WATER QUALITY SAMPLING AND ANALYSIS

0007 20 Hours

BLASTING STANDBY TIME

0008 1 Cost

PERFORMANCE AND PAYMENT BONDS

FFP

FOR LINE ITEMS (0001 THROUGH 0007)

THIS IS A COST REIMBURSABLE LINE ITEM - The Government will reimburse the Contractor for the actual cost of acceptable performance and payment bonds, upon receiving evidence of payment (paid invoice) from the bonding company or agency, not to exceed the total amount of the contract line item. The Government will not pay more than the total line item amount for the performance and payment bonds. The actual cost of the bonds is less than the line item amount, the contract will be modified to adjust the line item accordingly.

Adjustment(s) to the line item will also be made for any revisions to the actual bond costs associated with contract changes.

TOTAL BID AMOUNT

TOTAL BID AMOUNT (LINE ITEMS 0001 THROUGH 0008): $_________________________________ Offerors are required to fully complete the entire bid schedule to include entering unit and extended prices for all line items.

BID SCHEDULE NOTES

Block 10 Continued –

CONTINGENCY STATEMENT: The receipt of BIDS is contingent upon the USACE’s receipt of the Real Estate Waiver for Right of Entry to the project site. In this respect, the USACE is under no obligation to receive bids for this project until such approval has been made.

IMPORTANT NOTES REGARDING THIS ACQUISITION:

1. BID CONDITIONS:

a. The above Bid Schedule contains and combination of Firm Fixed Price (FFP) and Cost

Reimbursable line items. Although “FFP” is shown in the description of the Cost Reimbursable line items, it is not to be construed as a Firm Fixed Price line item. In this case, the FFP represents the Contract Type, which is Firm Fixed Price. Therefore, the Contractor will be reimbursed as stated within the extended description of the cost reimbursable line item.

b. The Government intends to award all Base Bid Items to the successful bidder at the bid prices provided under its winning bid schedule.

c. Split awards or multiple award contracts will not result from this Solicitation.

2. COMPETITION: Competition for this acquisition is RESTRICTED TO SMALL BUSINESS concerns.

3. SUBMISSION OF BIDS:

a. BIDS OR MODIFICATIONS TO BIDS THAT ARE RECEIVED BY FACSIMILE

ORTELETYPE WILL NOT BE CONSIDERED. All Sealed Bids must be submitted in accordance with the procedures set forth in Block No. 13 of Page 1 of this Solicitation Document.

b. Bidders are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in the space provided, by completing Blocks 8 and 15 of the Amendment (Standard Form 30), by separate letter, or by telegram prior to opening of bids.

c. SF 1442 BACK (Page 2 of the Solicitation): Bidders shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C.)

d. Section 00600 (Representations and Certifications): The bidder must fully complete Section 00600 of this Solicitation and submit it along with all other documents required by this Solicitation. Bids received without this Section fully completed may be rejected, considered non-responsive and ineligible for award.

e. BID GUARANTEE: The bidder is required to submit a Bid Guarantee for this procurement. Any bidder failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award. The Bid Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

f. BONDS AND INSURANCE: The Contractor will be required to furnish proof of insurance, including copies of the required endorsements, and performance any payment bonds within 10 calendar days following the Contractor’s receipt of the contract award.

4. DELIVERY OF BIDS:

a. Sealed Bids: Regardless of the method of delivery (mailed or hand-carried), bids and all other documents called out in the Solicitation shall be enclosed and sealed in an envelope that is clearly marked “Bid” and shall include the assigned Solicitation Number, and the Bid Opening Date and Time.

b. Mailed Bids: It is the responsibility of each bidder to ensure that its Sealed Bid is received by the Chicago District’s – USACE Contracting Branch, located at 231 South LaSalle Street, Suite 1500, Chicago, IL 60604 prior to the date and time set for the opening of the bids – See Block 13A of Page 1 of the Solicitation.

c. Hand-carried Bids Delivered on the Day of the Bid Opening: For bids being hand carried prior to

12:00PM on the day of the opening, call the Contract Specialist. For bids being hand-carried after 12:00PM on the date of the bid opening, the bidder shall deliver the sealed bid directly to the Bid Opening Room, which is located at 231 South LaSalle Street, Suite 1600, Chicago, IL 60604.

Prior to 2:00PM on the date of the bid opening, it is the responsibility of each bidder to ensure that its bid is received by the Chicago District’s Contracting Branch prior to the date and time set for the opening of bids.

d. The POC for bids is Alex Heinzel, 231 S. LaSalle Street, Suite 1500, Chicago, IL 60604.

5. BID OPENING ROOM:

a. The designated Bid Opening Room is the USACE Main Conference Room, located on the 16th floor at 231 South LaSalle Street, Suite 1600, Chicago, Illinois 60604.

b. In order to gain access, all interested participants must check in at the Security Desk in the lobby (Clark Street entrance) with a valid photo ID. The Security desk will issue an access card for gaining access to the USACE Main Office, Suite 1500.

c. Each visitor is required to check‐in at the USACE Main Office, Suite 1500, where they will be asked to sign‐in and will then be directed to the Bid Opening Room. All individuals intending to attend the Bid Opening must allow enough time to go through security and check in at the USACE office before being escorted to the Bid opening room.

6. QUESTIONS: PLEASE NOTE: INTERESTED BIDDERS MUST SUBMIT THEIR CONTRACTING

AND TECHNICAL INQUIRIES IN WRITING TO ALEX HEINZEL AT alex.heinzel@usace.army.mil. –

BE SURE TO INCLUDE THE SOLICIATION NUMBER W912P6-14-B-0008 AND PROJECT

TITLE ON THE SUBJECT LINE OF YOUR EMAIL.

Section 00100 - Bidding Schedule/Instructions to Bidders

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management JUL 2013 52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Davis-Bacon Act--Secondary Site of the Work JUL 2005 52.232-15 Progress Payments Not Included APR 1984 52.232-38 Submission of Electronic Funds Transfer Information with

Offer

JUL 2013

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price Construction contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

19.6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal

Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is: Illinois, Cook County, Willow Spring.

52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB

2009)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American Act--Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American Act should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American Act before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American Act, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% of the bid price or $3,000,000 whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Regina G. Blair, Chief of Contracting USACE Chicago District 231 S. LaSalle St. Suite 1500 Chicago, IL 60604

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 8 July, 2014 at 1:00PM.

(c) Participants will meet at the Lawndale Avenue Solids Management Area Visitor Center, 7601 S. LaGrange Road, Willow Springs, IL 60480.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/

Section 00600 - Representations & Certifications

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2014)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990..

(2) The small business size standard is $33.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( X ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation. This provision applies to solicitations using funds appropriated in fiscal years 2008, 2009, 2010, or 2012.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.214-14, Place of Performance – Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xvi) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvii) 52.225-4, Buy American Act--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $79,507, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xviii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xix) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xx) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran--Representation and Certifications. This provision applies to all solicitations.

(xxi) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

(i) 52.219-22, Small Disadvantaged Business Status.

(A) Basic.

(B) Alternate I.

(ii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iii) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

(iv) 52.222-52, Exemption from Application of the Service Contract Act to Contracts for Certain Services–Certification.

(v) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA– Designated Products (Alternate I only).

(vi) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

Section 00700 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-7 Anti-Kickback Procedures OCT 2010 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

SEP 2013

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUL 2013

52.204-13 System for Award Management Maintenance JUL 2013 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

AUG 2013

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

MAY 2012

52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns JUL 2013 52.219-14 Limitations On Subcontracting NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 Payrolls and Basic Records JUN 2010 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) JUL 2005 52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010 52.222-36 Affirmative Action For Workers With Disabilities OCT 2010 52.222-37 Employment Reports on Veterans SEP 2010 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons FEB 2009 52.222-54 Employment Eligibility Verification AUG 2013 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

DEC 2012

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995 52.228-14 Irrevocable Letter of Credit DEC 1999 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002 52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts JUL 2013 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes JUL 2002 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items DEC 2013 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2010 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.252-4 Alterations in Contract APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A MAR 2014 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

MAR 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities FEB 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.239-7001 Information Assurance Contractor Training and Certification JAN 2008 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea JUN 2013 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days following the Contractor’s acknowledgement of the Notice to Proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 310 calendar days days after the Contractor’s acknowledgement of the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,046.45 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (SEP 2010)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable…