W912L8-16-R-0006_SOW.doc

Performance Work Statement (PWS) Operations and Training Building Modifications Project Number PYKL132005 164th Air Wing, Memphis, Tennessee

Statement of Work (SOW) C17 Seat Production and Modification 167th Airlift Wing, Martinsburg, WV

1.0 GENERAL

Deliverables:

Performance Objective

(The Service required—usually a will statement)

Deliverable completed

1.1

PERFORMANCE PERIOD

The period of performance for this project is 90 calendar days.

1.2

PROJECT DESCRIPTION

Project Name: C17 Seat Production

1.3

REFERENCES

In general, all technical specifications are provided within this SOW. However, in the event any project element is not covered in the specifications provided, the Contractor should refer to the Specification Hierarchy for direction related to the element.

1.3.1 Specification Hierarchy

The specification hierarchy is the collection of technical specifications to be used for all projects. The Contractor should refer to the specifications provided within this SOW of materials and products to be used first before moving to the next technical specification listed in the specification hierarchy. The hierarchy is listed in the order of precedence (i.e. “A” supersedes “B”, “B” supersedes “C”, etc.).

The hierarchy is as follows:

A.

Any Specifications provided in SOW.

B.

Specifications provided from manufacturer.

2.0 GENERAL REQUIREMENTS FOR ALL WORK

2.1

DESCRIPTION OF WORK

2.2

VERIFICATION OF DIMENSIONS

The Contractor will be responsible for the proper coordination and proper relation of the work required. The Contractor will verify all dimensions and advise the Contracting Officer of any discrepancies prior to proceeding with phase of the work. ONLY the Contracting Officer approves time and additional work. In the event there is adequate time to perform the extra work at the time the UNFORSEEN work is approved no additional time will be awarded; approved by contracting officer only.

2.9 Drawings and Specifications: Contain Project details of work required.

3.0 Deliverables

3.3 Progress Schedules: Required for projects with a performance period of 30 days or longer.

3.3.1 The schedule shall begin in the form of a Progress Chart of suitable scale to indicate appropriately the percentage of work scheduled for completion at any time.

3.3.2 In the event of differing site conditions, change in specifications, additional work, etc., which would require a time extension in excess of 60 calendar days, a revised schedule is to be prepared. The revised schedule will reflect work completed up to the date of revision, the percentages adjusted accordingly, and performance time extended to the new completion date established by a Modification (MOD) to the contract as a result of the change.

3.3.3 The initial and revised schedules will include time for a final inspection and correction of any list items, which might be discovered during the final inspection.

3.5 Work Performance: Contractor will manufacturing of air crew seating and accessories as specified in 3.5.1.

3.5.1 Manufacturing includes but is not limited to:

3.5.1.1 – Twenty-Four (24) C-17 Flight Deck Seat Bottom with Confor Foam

3.5.1.1.1 Deck seat Bottom is to measure 21L X 19.5W (IN)

3.5.1.1.2 Seat bottom cover is to fit all C17 flight deck seats. Made with Air Force blue inherently fire resistant polyester Trevira fabric, Mil-spec metal snaps 5/8 inch, sheepskin in grey color, and fire retardant Velcro.

3.5.1.1.3 Cushion is to be 45 Blue Confor Foam covered in fire retardant Muslin, with certifications provided

3.5.1.2 – Twenty-Four (24) C-17 Flight Deck Back Rest with Confor Foam

3.5.1.2.1 Flight Deck Back Rest is to measure 21.5L X 20W (IN)

3.5.1.2.2 Back rest cushion cover is to fit all C17 flight deck seats. Made with Air Force blue inherently fire resistant polyester Trevira fabric, Mil-spec metal snaps 5/8 inch, sheepskin in grey color, and fire retardant Velcro.

3.5.1.2.3 Cushion is to be 45 Blue Confor Foam covered in fire retardant Muslin, with certifications provided

3.6 Documentation: Contractor will provide accurate, complete documentation for this contract 99% of time. In the event of errors the contractor will provide corrections timely.

3.6.1 Submittals, payment

3.6.2 RFI

3.6.3 Warranty and Closing documentation

Contractor will warranty product for at least One Year to include replacement parts, and repairs as specified in clause(s) 52.246-19 and by Contracting Officer. The contractor will repair and/or replace all product damaged by the contractor or their subcontractors and warranty said product for the standard warranty period of new equipment of like kind, but for no less than one year.

3.6.4 Any other called out in Specifications and Drawings.

3.6.5 Approved Drawings in Adobe® Portable Document Format AND AutoCAD® format.

This project is to manufacture new seating for aircrew seating on C17 Globemasters. The project will include the manufacturing and customization of aircrew seating including flight deck seat bottoms and flight deck back rests.