STATEMENT_OF_WORK_BXRH132055_Renovation_of_B1500.pdf

STATEMENT OF WORK

for

PROJECT NO. BXRH132055

RENOVATION OF B-1500

IDAHO AIR NATIONAL GUARD

26 November 2018

Prepared by:

124 CES/CEC, Idaho Air National Guard, Boise, ID 83705

Tel: DSN 422-5596 FAX: DSN 422-5977

Renovation of Building 1500 2

This Page is intentionally left blank

Renovation of Building 1500 3

TABLE OF CONTENTS

SUBJECT PAGE

TAB A – PROJECT DESCRIPTION 2

1A. Project Title 4 1B. Project Number 4 1C. Objective 4

2. Scope 4

3. Specifications 9

4. General Requirements 9

5. Site Conditions 12

6. Supervision 13

7. Submittals 13

8. Site Safety 14

9. Antiterrorism Force Protection 14

10. Clean-Up 15

Renovation of Building 1500 4

STATEMENT OF WORK (SOW)

BXRH132055

RENOVATION OF B-1500

Work to be accomplished consists of furnishing all plant, labor, equipment, appliances, materials, licenses or permits required and performing all operations in connection with maintenance and repairs to the Idaho Air National Guard, Gowen Field.

PROJECT DESCRIPTION

PROJECT TITLE: RENOVATION OF B-1500

PROJECT NUMBER: BXRH132055

1. OBJECTIVES:

1.1. OVERVIEW: Existing Site Conditions

1.1.1. Building 1500 is located on the north side of Ellsworth and East of Taxiway Echo. This facility served as the Gowen Field C-130 squadron operations until 2005 when the Base Realignment and Closure Committee recommended the relocation of the 189th Airlift Wing. Building 1500 was approximately 13,154 square feet and was remodeled in 2000 to its current 24,508 square feet. The design of 1500 has a hallway which wraps around ¾ of the building separating outer offices from an inner core of briefing rooms and work spaces.

2. SCOPE:

2.1. REFER TO BLDG 1500 SPECIFICATIONS AND DRAWINGS

2.2. OVERVIEW: Basis of Design

2.2.1.1. Interior Design Narrative: The interior design concept will be to replicate the existing finishes throughout. New framed walls will have a painted gypsum board wall finish to match existing. Rubber wall base trim will be replaced throughout. Existing carpet will be removed and replaced with carpet tile. New acoustical ceiling tiles are to match existing. The existing doors are in good condition and appear to be reusable without refinishing. The finishes in the new latrines will be tile floor and wall.

2.2.2. Exterior Design Narrative: Exterior work includes the removal of an air intake louver in the mechanical room and exterior windows within the secure area. These are identified on the floor plan drawing A2.1. The louver and window openings are then to be infilled with the same wall construction as is existing. At the secure area, this

Renovation of Building 1500 5 is either a 6" metal stud wall with a brick veneer, or a 7-5/8" CMU wall with furring and gypsum board finished interior. At mechanical room, existing wall construction is 'giant brick'. The wall assemblies for this infill are further described on the floor plan drawing. On the east side of the building, a portion of the sidewalk and parking lot will be removed as required to install a new fire water line from the street to the mechanical room to supply a new sprinkler system in throughout the building. Once the piping is installed, the parking lot and sidewalk will be patched back. Electrical Systems Narrative (Power and Lighting): The existing electrical system equipment is located in the mechanical room and appears to have capacity for modifications.

The electrical service consists of a 1200 amp, 208Y /120V, 3-phase, 4-wire, Main Switchboard with externally mounted transient voltage surge suppression. In reviewing the existing drawings, the equipment is approximately 15 years old and there are spare switches available for additions to the electrical system. Panel boards are also located in the mechanical room as well as in other areas, closer to loads served. The panel boards also have externally mounted TVSS for surge protection.

The surge counters viewed had zero occurrences registered on the indicator panels.

Unless the counters were recently manually reset, if surge suppression is critical, it is recommended to evaluate the existing devices and possibly replace. Emergency panel board EC supplies selected, generator backed, receptacle, lighting and mechanical loads. A manual transfer switch, located in the mechanical room, is connected to normal power with the disconnect located on the exterior of the building. The exterior disconnect has a cable used to connect to a portable generator. Emergency lighting is not tied into the generator system and light fixtures appear to be provided by battery backed ballasts integrated into the fixtures and exit signs. A new panel board 'F' is indicated, connected to emergency power, for the secure area. The new panel board supplies critical loads in this area only. The existing demand on the generator will require final evaluation to verify the capacity is adequate to supply the revised loads. Lighting in the facility primarily consisted of recessed grid mounted, fluorescent light fixtures with dual level switching. All lighting within the facility is being replaced with LED light fixtures with controls as required per IECC.

2.2.3. Mechanical Systems Narrative: Existing HVAC and Plumbing: All the mechanical equipment in this building is 16 years old and has reached 1/2 to 2/3 useful service life. Building space heating and air conditioning is with 4-pipe fan coil units.

Chilled water is produced with an air cooled, direct expansion {R22), chiller located outside the main mechanical room. The existing chiller is failing and the base has expressed a need for replacement. Heating water is produced with two gas fired, sealed combustion, copper tube boilers. Chilled and heating water circulation is by base mounted, end suction pumps with variable frequency drives. Ventilation is a combination of energy recovery and direct exhaust via roof mounted exhaust fan.

Primary ventilation air is from the energy recovery ventilator {ERV) ducted to the

Renovation of Building 1500 6 return side of each fan coil unit. This requires that the fan coil units operate continuously during occupied hours. The HVAC controls are direct digital {semiconductor based), and date to pre-open protocol. Existing water heaters, plumbing fixtures, water distribution piping, and roof drains all appear to be in good condition. Proposed HVAC and Plumbing: The intent is to reuse and rework the existing equipment to the greatest extent possible. Secure Area penetration requirements will be met with first by evaluating cost effective relocation of the service and second by using countermeasures outlined in UFC 4-101-05 Sensitive Compartmented Information Facilities Planning, Design, and Construction, with Change 1. The last renovation of this building pre-dates UFC 4-010-01 Minimum Antiterrorism Standards for Buildings. The outside air intakes for the ventilation system are located at grade level behind the chiller screen wall. The intakes will be moved to the roof level to comply with the criteria. If new toilet rooms are designed, then new plumbing fixtures will be installed and modifications to the existing piping will be kept to minimum necessary. Proposed HVAC Secure Area: The debriefing rooms in the secure area have cooling loads that differ from the surrounding offices.

These loads are sporadic and more intense than regularly occupied office areas.

Each debriefing room should have individual thermostatic control to avoid large temperature swings. Proposed Heating and Cooling Plant: The existing air-cooled chiller will be removed and replaced with a new, air-cooled, modular, heat recovery chilled water plant. The existing boiler plant will be removed and replaced with new boilers per the new base standard. Heating and cooling plant upgrades will include upgrades to the direct digital controls and circulation pumps as necessary.

Equipment in the main mechanical room will be rearranged to accommodate service clearance requirements for the new boilers.

2.2.4. Information and Communication Technology (ICT) Infrastructure Narrative: The telecom room includes the entrance facility with (2) 4-inch underground conduits containing twisted pair, coaxial and optical fiber entrance cables. The building entrance terminal is (2) 100 pairs units located on the west wall of the room along with a wall mounted optical fiber enclosure and the CATV head end. Grounding for telecommunications is provided on the same wall b the telecommunications main grounding bus bar which bonds the primary protection hardware, cable shields, metal equipment racks and overhead cable tray to the electrical service entrance ground. Horizontal distribution is provided from rack mounted patch panels located on the two 7' high, 19" EIA 310 compliant equipment racks bolted to the concrete floor and fastened at the top to the overhead, wire basket style, cable tray.

Horizontal cables include Category 6 {Cat-6) unshielded twisted pair {UTP) cables, multimode optical fiber cables and coaxial cables to the work station outlet locations throughout the entire building. The equipment racks also contain the local area network switches and cable management for patch cords interconnecting the horizontal cross connect with the network equipment providing voice and data

Renovation of Building 1500 7 network connectivity. Additional systems in the room include paging through (4) Bogen, wall mounted amplifiers located on the east wall and the cable television amplifier and taps located on the west wall. This space provides NIPRNet service and will remain in service to support the portion of the building that is not to be included in the new SIPRNet service area. A new telecom room will be provided to support the area to be served by SIPRNet connectivity. The new SIPRNet telecom room will be constructed within the bounds of the secure area with walls to structure and penetrations will be sealed for smoke, heat and sound. Dedicated conduits will be extended to the existing telecom room for backbone cabling and extension of the telecommunications grounding network. No ceiling will be installed and the space will be conditioned by a dedicated HVAC system with redundant distribution from the system serving the remainder of the secure area. Three, 7'. 2-post equipment racks will be bolted to the concrete floor and fastened to the overhead, ladder style cable rack. Vertical and horizontal cable management will be provided for routing cables and patch cords among the three racks. Backbone cables from the NIPRNet telecom room will include indoor, plenum rated, 12-strand, OS2 performance, optical fiber terminated in a rack mounted enclosure with splice trays for fusion splicing to preterminated LC pigtails and a 25-pair. 24 AWG, Category 3 cable terminated on 110 blocks at both ends. New horizontal cabling will be provided to work stations in the secure area to include (2) plenum rated, color coded, Cat-6 UTP and (2) OM4, multimode optical fibers on a 4-port, angled faceplate. Cables will be certified to specified performance levels and labeled with horizontal identifications and field adjustments noted on the redline markup drawings for creation of the record documents. Design will include special conditions and requirements for pathways and cabling in meeting rooms and briefing rooms for audio visual devices and presentation sources. The large assembly room will be provided with facilities for both NIPRNet and SIPRNet connectivity.

2.2.5. Furnishings Narrative: New furnishings are not including in the scope of work for this project. Furniture for this space will be moved over from building 146 where applicable.

2.2.6. Demolition narrative: To reduce overall project cost, efforts have been taken during the design phase to minimize demolition. Flooring and wall base trim throughout the work area will be removed and replaced. Where necessary, walls will be removed.

Doors, door frames and associated hardware will be removed according to the plan.

Wherever possible, doors, frames, hinges, closers and any other hardware will be salvaged and reused. Door locksets will be replaced throughout the project. Existing wall accessories such as mirrors, white boards, eye wash stations, etc. will be removed unless they are scheduled to remain. Existing millwork not planned to stay will be removed. Where walls are removed the ceiling grid will be removed and replaced with new grid and ceiling tiles. Existing components of the PA system

Renovation of Building 1500 8 located in walls that are scheduled to be removed will be removed and relocated if necessary. Refer to 4.2 Electrical Systems Narrative for work related to ceiling lighting, power, and controls. Refer to 4.3 Mechanical Systems Narrative for work related to ceiling diffusers

2.2.7. Anti-Terrorism Force Protection Narrative: The scope of the project is limited to an interior renovation. Therefore, ATFP measures involving modification beyond the exterior of the building walls, such as standoff distance, shall not be considered.

Exterior doors and windows will not be replaced. The air intake for mechanical systems is to be moved to the roof to limit airborne contamination potential. (Refer to section 4.3 above). A mass notification system is to be installed throughout the building. Where possible, existing components of the mass notification system will be reused. No structural changes to the building are anticipated.

2.2.8. Fire Protection Narrative: The existing building is NOT equipped with fire sprinklers.

A new sprinkler system will be installed throughout the building as part of this work. The new sprinkler system will be installed per UFC 3-600-01 and NFPA 13.

The existing fire alarm system will be demolished and removed. A new fire alarm/mass notification system will be installed per UFC 4-021-01 and NFPA 72 throughout the building.

3. SPECIFICATIONS:

3.1. REFER TO RENOVATION OF B-1500 SPECIFICATIONS

3.1.1. Project manual dated 11-14-18;

3.2. REFER TO RENOVATION OF B-1500 DRAWINGS Titled “IDANG BUILDING 1500”;

CSHQA Job Number 15238.100

3.3. All specification, drawings and narratives will be provided to the contractor prior to bid.

Any additional information requested will require a formal “Request for Information” will be submitted to the Contracting Officer in writing per the solicitation requirements.

4. GENERAL REQUIREMENTS:

4.1. BASE ACCESS:

4.1.1. The contractor shall comply with all applicable installation/facility access and local security policies and procedures, which may be obtained from the Contracting Officer or the Contracting Officer Representative. The Contractor shall also provide all information required for background checks to meet

Renovation of Building 1500 9 installation access requirements to be accomplished by the local installation’s Security Forces. The Contractor shall ensure compliance with all personal identity verification requirements as directed by DoD, HAF and/or local policy. Should the Force Protection Condition (FPCON) change, the Government may require changes in Contractor security matters or processes.

4.1.2. Contractor must have prior approval for personnel to work in any restricted areas aircraft taxiway or aircraft parking ramps. A letter to Contracting Officer with employee's name, SSN, and what dates they will be working in any restricted areas. This letter will be made available to Contracting Officer no-less-than 7 working days prior to start of work to allow for coordination with Base Security- Forces.

4.1.3. All workers will have a flight line restricted area security, noise safety, and

Foreign Object Detection (FOD) briefing before being allowed to enter aircraft taxiway or parking ramp area.

4.1.4. The Contracting Officer and/or Contracting Officer Representative shall provide guidance and directions for restricted area access during Pre-Construction meeting and anytime their after.

4.2. PERFORMANCE:

4.2.1. Submission of bids by a Contractor shall be accepted as prima fascia evidence that he has examined the specifications and drawings and has satisfied himself as to the nature and location of the work and all other matters, which can in any way affect the work or cost thereof under this contract. Any failure of the Contractor to acquaint himself with all available information, including a physical survey of the site of the proposed work, will not relieve him from successfully performing all the work required to be done for a complete, finished job.

4.2.2. The above brief outline of principle features of the work in no way limits the responsibilities of the Contractor to perform all work and furnish all plant, labor, and material required by the specifications and plans referred herein.

4.2.3. The Contractor may use any article, etc., for which he has requested, in writing from the Contracting Officer prior to bid, and received written notification of acceptance as a product.

4.2.4. All work performed under this scope of work shall be conducted in accordance with applicable Federal, State, and Local regulations, ANG policies and regulations.

Renovation of Building 1500 10

4.2.5. Work will conclude with final acceptance by the Contracting Officer or Contracting Officer Representative, warranty delivery, and financial closeout.

4.2.6. Contractors are responsible for verifying all measurements required for bidding purpose during site walk through.

4.2.6.1. Questions asked after site visit must be submitted in writing to Contracting

Officer or Contracting Officer Representative no later than 7 calendar days after the site walk through.

4.2.7. The scope of work is to restore several facilities to meet current health, safety, and security requirements. The work to be conducted will include minor demolition and repair in an existing facility.

4.3. BARRICADING:

4.3.1. When necessary, the Contractor will provide barricades sufficient to prevent vehicles and/or pedestrian traffic from inadvertently entering the construction area.

4.4. SCHEDULING:

4.4.1. A proposed schedule on an AF Form 3064 will be presented and accomplished in accordance with a mutually agreed upon schedule between the Contractor, the Base Civil Engineer (BCE) or BCE Representative, and the Contracting Officer or the Contracting Officer Representative.

4.4.2. Construction schedules shall outline critical paths, project milestones, submittal deadlines, and all scheduled meetings.

4.4.3. Initial schedule will be submitted to the Contracting Officer 7 working days prior to the Pre-construction meeting. The Contracting Officer and/or Contracting Officer Representative and the Base Civil Engineer (BCE) and/or BCE Representative will review the schedule and approve or request changes during the Pre-construction meeting.

4.5. MEETINGS:

4.5.1. The Contractor will record and provide meeting minutes for all construction meetings to include the Pre-Construction meeting.

Renovation of Building 1500 11

4.5.2. All meeting minutes will be on letter head, memo format and will include:

attendance sheet, date of meeting, time of meeting, location of meeting, list of decisions, and comments provided.

4.5.3. All meeting minutes will be submitted to the Contracting Officer and Contracting Officer Representative no less than 5 calendar days after the date of the meeting for acceptance.

4.6. DISPOSAL/RECYCLING OF WASTE, HAZARDOUS MATERIALS, AND

ENVIRONMENTAL COMPLIANCE:

4.6.1. Any waste or excess material resulting from performance of this contract shall be tracked by weight and documentation will be provided to the Contracting Officer or the Contracting Officer Representative at the completion of the project.

Contractor will recycle all material that can be recycled, and record the weight of material recycled; this information will be provided to the Contracting Officer or the Contracting Officer Representative at the completion of the project.

4.6.2. Waste removed from the base will be disposed of in accordance with applicable Federal, State, and Local regulations.

4.6.3. The weight of any waste that is diverted away from a landfill will be recorded and will be provided to the Contracting Officer or the Contracting Officer Representative at the completion of the project.

4.6.4. The Contractor shall comply with all Federal, State, and Local regulations pertaining to the protection of the environment and the emission of hazardous pollutants in the performance of this contract. The Contractor shall provide a copy of all correspondence with Federal, State, and Local regulations pollution control authorities to the Contracting Officer or the Contracting Officer Representative and the ANG Civil Engineering Environmental Protection Monitor. Contractor is required to provide Safety Data Sheets (SDSs), via the submittal process in section 7, for all materials being used in the performance of this contract; SDSs must be provided no later than 5 working days prior to commencing work.

Contractor is also required to document and report the quantities of hazardous materials used in the performance of this contract.

4.6.5. Hazardous wastes generated as part of this project must be managed in accordance with all applicable laws. The waste must not leave Gowen Field without the approval of the Base Environmental Office. The Base Environmental Office will provide initial guidance and training in Hazardous Waste procedures.

Renovation of Building 1500 12

4.6.6. Contractor will be provided a copy of the Installation Environmental Commitment Statement, and ensure all personnel working on the project have read and understand the Statement.

4.6.7. Environmental, Safety and Bioenvironmental representatives from the installation will have the opportunity to meet with the Contractor prior to commencing work, and to collaborate with the Contractor to resolve any safety/occupational health/environmental concerns.

4.7. TRAFFIC CONTROL:

4.7.1. The following standards shall be observed at all times. Careful attention and strict adherence to these precautions can prevent accidental damage and possible injury to both pedestrians and drivers. Disregard of these rules, at the very least, will be grounds for removal from the base.

4.7.2. Vehicles operators must be in the possession of a valid driver’s license and current vehicle registration and insurance.

4.7.3. Vehicle operators shall obey the speed limits set by local officials. Vehicles shall not be driven over 25mph, and will not exceed 10mph when near joggers or troops.

4.7.4. Vehicle operators will not use a cell phone while driving. It is acceptable to pull over and park a vehicle to use a cell phone.

4.7.5. Vehicle operators shall ensure that all equipment carried on their vehicles is properly stowed and secured.

4.7.6. No privately owned firearms are allowed on base. This includes concealed carry permit holders.

4.7.7. The use of seatbelts is mandatory for all vehicle occupants during any vehicle operations.

5. SITE CONDITIONS:

5.1. DEMOLITION AND PREPARATION WORK:

5.1.1. The Contractor is responsible to protect existing facilities from damage resulting from the demolition associated with this project.

Renovation of Building 1500 13

5.1.2. The Contractor shall replace all damaged materials with new materials, to the satisfaction of the Contracting Officer Representative, at no additional cost to the Government.

5.1.3. The Contractor shall bring any unforeseen project conditions to the attention of the Contracting Officer and the Contracting Officer Representative immediately.

5.1.3.1. Differing site conditions, which may alter the scope of work, shall be approved by the Contracting Officer prior to such work to be performed.

5.2. WEATHER CONDITIONS:

5.2.1. No protection from the elements is provided for materials, personnel, or equipment by the Government.

5.3. FIELD MEASUREMENTS:

5.3.1. The Contractor shall verify all measurements at the project site and become fully acquainted with the location and project conditions before bidding the work.

6. SUPERVISION:

6.1. The Contractor shall have a competent superintendent in charge of the work at all times. Anyone found incompetent shall be removed at once and replaced by someone satisfactory when requested by the Contracting Officer or the Contracting Officer Representative.

6.2. The Contractor shall report ALL labor hours (including subcontract labor hours) required for performance of services provided under this contract for the Idaho National Guard via a secure data collection site. The Contractor is required to completely fill in all required data fields using the following web address: https://www.ecmra.mil/.

Reporting inputs will be for the labor executed during the period of performance during each Government Fiscal Year (FY), which runs October 1 through September 30.

While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year, beginning with 2017. Contractors may direct questions to the help desk at http://www.ecmra.mil/

7. SUBMITTALS:

7.1. Submittals for this project will include at a minimum:

• Mechanical systems (boilers, chillers, pumps) https://www.ecmra.mil/ http://www.ecmra.mil/

Renovation of Building 1500 14

• Wall finishes

• Floor finishes

• Ceiling Tiles

• Plumbing finishes

• Door hardware

• Light hardware

• Electrical Panels and hardware

• Construction Performance Schedule (Critical Path Method)

• SDS for any chemical which will be brought on to the installation.

7.2. All submittals will be processed with an AF Form 3000 as the coversheet, and routed through the Contracting Officer for approval.

7.3. Prior to the start of work on the Base, a schedule using AF 3064 or similar document shall be submitted and approved, through the Contracting Officer or the Contracting Officer Representative. Any changes to the schedule must be submitted for acceptance.

7.4. Prior to installation or use, the Contractor shall submit to the Contracting Officer or the

Contracting Officer Representative for approval of the manufacturer's product information, specifications and instructions for the materials intended for use on the job.

7.5. The Contractor shall submit material items for approval on an AF Form 66 within 10 calendar days of the “Notice to Proceed” – or – on the AF Form 66 indicating when each material item shall be submitted for approval.

7.6. Ensure that any disapproved material submittal will not impact the approved project execution schedule, as disapproved submittal shall not be considered grounds for a time extension. Allow for a minimum of 5 calendar days for the Government’s processing of material submittals.

7.7. The Contractor shall not order, deliver, or install any materials without Contracting

Officers material approval, or remove any materials on site which have not been properly approved.

8. SITE SAFETY:

8.1. The Contractor shall provide and maintain work environments and procedure which will:

8.1.1. Maintain OSHA compliance at the job site and while on Idaho National Guard, Gowen Field.

Renovation of Building 1500 15

8.1.2. Safeguard the public and government personnel, property, materials, supplies and equipment exposed to Contractor operations and activities.

8.1.3. Avoid interruptions of Government operations and delays in project completion dates.

8.1.4. Control costs in the performance of this contract.

8.2. The Contractor shall ensure that any additional measures the Contracting Officer or the Contracting Officer Representative determines to be reasonable and necessary for the purposes of safety are applied.

8.3. Welding, brazing, soldering, metal cutting or grinding and any work which has the potential to create a flammable hazard will require the Contractor to obtain a Hot Work Permit from the Idaho National Guard, Gowen Field Fire Department.

8.4. The Contractor will provide barricades sufficient to prevent vehicles and pedestrian traffic from inadvertently entering the construction area on an “as needed” basis, where it is reasonable or required.

8.5. The Contractor is required to provide a current mishap prevention plan to the

Contracting Officer or the Contracting Officer Representative before the ‘Notice to Proceed’ will be issued.

8.6. If the contract requires confined space entry the Contractor will provide, to the

Contracting Officer and the Contracting Officer Representative, a copy of their training plan and proof that personnel conduction the confined space entry have been trained according to IAW and OSHA guidelines.

9. ANTITERRORISM FORCE PROTECTION:

9.1. The Contractor shall comply with all applicable installation/facility access and local security policies and procedures, which may be obtained from the Contracting Officer or the Contracting Officer Representative. The Contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the local installation’s security forces. The Contractor shall ensure compliance with all personal identity verification requirements as directed by local policy. Should the Force Protection Condition (FPCON) change, the Government may require changes in Contractor security matters or processes.

9.2. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate

Renovation of Building 1500 16

Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (AFI 31-101 and AFI 10-245), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

9.3. All Contractor employees, to include subcontractor employees, requiring badged access to Government Installations, Facilities and Controlled Access areas shall complete AT Level I awareness training within 30 calendar days after contract start date. Certificates of completion for each affected Contractor employee and subcontractor employee will be maintained by the Contracting Officer or the Contracting Officer Representative. AT level I Awareness Training is available at the following website: http://jko.jten.mil

10. CLEAN-UP:

10.1. During the progress of this project, the Contractor shall at all times keep the residue from work from being dragged, tracked off, or blown onto the active taxiways and runway adjacent to the work area. The immediate work area will be cleaned up at the end of each workday. Any debris carried out of the work area by vehicles, equipment, wind, water, etc. . . . will be cleaned up immediately, or as directed by the Contracting Officer or the Contracting Officer Representative. All clean up shall be accomplished by the Contractor at no cost to the government. The entire work area shall be properly cleaned and left free from all scraps, waste, etc. leaving a neat professional appearing worksite that complies with all environmental laws. At the completion of the project, the Contractor shall remove all materials and residue from the job site and any work area. The debris cleaned up will be disposed of in a manner acceptable with current environmental standards. The Contractor shall further agree to repair any damage caused to the facility or the surrounding area that is caused by him or his workers.

END

http://jko.jten.mil/

PROJECT NO. BXRH132055